The URL can be used to link to this page

CONTRACT 5551 Public Works Contract CLOSED Agreement No. 5551 PUBLIC WORKS CONTRACT BETWEEN THE CITY OF EL SEGUNDO AND ALL AMERICAN ASPHALT FY 17/18 PAVEMENT REHABILITATION , PROJECT NO.: PW#18-18 This CONTRACT is entered into this 20th day of June,2018,by and between the CITY OF EL SEGUNDO, a general law city and municipal corporation ("the City") and ALL AMERICAN ASPHALT, ("the Contractor"). 1. WORK. A. The Contractor will provide all work required by the Contract Documents (the "Work"). The Contractor agrees to do additional work arising from changes ordered by the City in accordance with the Contract Documents. B. The Contractor and the City agree to abide by the terms and conditions contained in the Contract Documents; C. The Contractor will furnish all of the labor; supplies and materials; equipment; printing; vehicles; transportation; office space and facilities; all tests, testing �� rr�tl�r�� <ar�c� �l� t��t��r� r�w��,�l��r�v�;�° (exc�� s otl�r�r°��rise exp�•�s�l;� '�+�+��t�a l��It��•��1�r�d��11��+��i,��rt�:��ci'to perl�z•��and�ctir�m�lete the�"�m�� itc� ��~�:aw�i��tN��•w��.�s ��.q��d of the Contractor by the Contract Documents. D. "Contract Documents"means the Notice Inviting Bids;Instructions to Bidders; Supplementary Instructions to Bidders; Proposal; this Contract; Standard Specifications; Supplementary Conditions; Exhibits; Technical Specifications; List of Drawings; Drawings; Addenda; Notice to Proceed; Change Orders; Notice of Completion; and all other documents identified in the Contract Documents which together form the contract between the City and the Contractor for the Work. The Contract Documents constitute the complete agreement between the City and the Contractor and supersede any previous agreements or understandings. 2. CONTRACT SUM. The City agrees to pay the Contractor a sum not to exceed one million, fifty thousand, seven hundred, seventy Dollars and zero Cents($1,050,770.00)for the Work in the manner set forth in the Contract Documents. The City may adjust this ° amount as set forth in the Contract Documents. 3. TIME FOR PERFORMANCE. A, The Contractor will fully complete the Work within forty (40) working days (the "Contract Time.") Agreement No. 5551 B„ The Contract Time will commence when the City issues a Notice to Proceed. The Contract Documents will supersede any conflicting provisions included on the notice to proceed issued pursuant to this Contract. C. The Contractor may not perform any Work until: i. The Contractor furnishes proof of insurance as required by the Contract Documents; and i�. The City gives the Contractor a written, signed, and numbered purchase order and notice to proceed. D, By signing this Contract,the Contractor represents to the City that the Contract Time is reasonable for completion of the Work and that the Contractor will complete the Work within the Contract Time. E. Should the Contractor begin the Work before receiving written authorization to proceed, any such Work is at the Contractor's own cost and risk. 4. DISPUTES. Disputes arising from this contract will be determined in accordance with the Contract Documents and Public Contracts Code §§ 10240-10240.13. 5. THIRD PARTY CLAIMS. In accordance with Public Contracts Code § 9201, the City will promptly inform the Contractor regarding third-party claims against the Contractor, but in no event later than ten (10) business days after the City receives such claims. Such notification will be in writing and forwarded in accordance with the "Notice" section of the Contract Documents. As more specifically detailed in the Contract Documents, the Contractor agrees to indemnify and defend the City against any third-party claim. 6. TAXPAYER IDENTIFICATION NUMBER. The Contractor will provide the City with a Taxpayer ldentification Number. 7. PERMITS AND LICENSES. Unless otherwise provided, the Contractor, at its sole expense,will obtain and maintain during the Contract Time,all necessary permits, licenses, and certificates that may be required in connection with the Work. 8. OWNERSHIP OF DOCUMENTS. All documents, data, studies, drawings, maps, models,photographs and reports prepared by the Contractor under the Contract Documents are the City's property. The Contractor may retain copies of said documents and materials as desired, but will deliver all original materials to the City upon the City's written notice. 9. INDEMNIFICATION. The Contractor agrees to indemnify, defend, and hold the City harmless as set forth in the Contract Documents. The requirements as to the types and limits of insurance coverage to be maintained by the Contractor as required by the Contract Documents, and any approval of such insurance by the City, are not intended to and will Agreement No. 5551 not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Contractor pursuant to the Contract Documents, including, without limitation, to the provisions concerning indemnification. lO. INDEPENDENT CONTRACTOR. The City and the Contractor agree that the Contractor will act as an independent contractor and will have control of all work and the manner in which is it performed. The Contractor will be free to contract for similar service to be performed for other employers while under contract with the City. The Contractor is not an agent or employee of the City and is not entitled to participate in any pension plan, insurance, bonus or similar benefits the City provides for its employees. Any provision in this Contract that may appear to give the City the right to direct the Contractor as to the details of doing the work or to exercise a measure of control over the work means that the Contractor will follow the direction of the City as to end results of the work only. ll. AUDIT OF RECORDS. The Contractor will maintain full and accurate records with respect to all services and matters covered under this Contract. The City will have free access at all reasonable times to such records, and the right to examine and audit the same and to make transcript therefrom, and to inspect all program data, documents,proceedings and activities. The Contractor will retain such financial and program service records for at least three (3) years after termination or final payment under the Contract Documents. 12. NOTICES. All communications to either party by the other party will be deemed made when received by such party at its respective name and address as follows: The City The Contractor City of El Segundo-Public Works All American Asphalt 350 Main Street 400 E Sixth St. El Segundo, CA 90245 Corona, CA 92879 Attn: John Gilmour Attn: Mark Luer Any such written communications by mail will be conclusively deemed to have been received by the addressee three (3) days after deposit thereof in the United States Mail, postage prepaid and properly addressed as noted above. In all other instances, notices will be deemed given at the time of actual delivery. Changes may be made in the names or addresses of persons to whom notices are to be given by giving notice in the manner prescribed in this paragraph. 13. NO THIRD PARTY BENEFICIARY. This Contract and every provision herein is for the exclusive benefit of the Contractor and the City and not for the benefit of any other • party. There will be no incidental or other beneficiaries of any of the Contractor's or the City's obligations under this Contract. 14. INTERPRETATION. This Contract was drafted in, and will be construed in accordance with the laws of the State of California, and exclusive venue for any action involving this Contract will be in Los Angeles County. Agreement No. 5551 15. EFFECT OF CONFLICT. In the event of any conflict, inconsistency, or incongruity between any provision of the Contract Documents,precedence will be as follows: A. This Contract; B. The Standard Specifications; and C, Precedence of documents as determined in the Standard Specifications. 16. SEVERABILITY. If any portion of the Contract Documents are declared by a court of competent jurisdiction to be invalid or unenforceable, then such portion will be deemed modified to the extent necessary in the opinion of the court to render such portion enforceable and, as so modified,such portion and the balance of this Contract will continue in full force and effect. 17. AUTHORITY/MODIFICATION. The Parties represent and warrant that all necessary action has been taken by the Parties to authorize the undersigned to execute this Contract and to engage in the actions described herein. This Contract may be modified by written amendment. The City's city manager,or designee,may execute any such amendment on the City's behalf. 18. ACCEPTANCE OF FACSIMILE SIGNATURES. The Parties agree that this Contract, agreements ancillary to this Contract, and related documents to be entered into in connection with this Contract will be considered signed when the signature of a party is delivered by facsimile transmission. Such facsimile signature will be treated in all respects as having the same effect as an original signature. 19. COVENANTS AND CONDITIONS. The parties agree that all of the provisions�hereof will be construed as both covenants and conditions, the same as if the words importing such covenants and conditions had been used in each separate paragraph. 20. CAPTIONS. The captions of the paragraphs of this Contract are for convenience of reference only and will not affect the interpretation of this Contract. 21. TIME IS OF ESSENCE. Time is of the essence for each and every provision of the Contract Documents. Agreement No. 5551 IN WITNESS WHEREOF the parties hereto have executed this contract the day and year first hereinabove written. CITY OF EL SEGUNDO ALL AMERICAN ASPHALT � � � .m � � _� �� _ .. .__ .,�..�_.� , __.��..m.....�. �.._ __._._., � � ��. Gre� �°�.�� n Signee N�r�rc Michael F�rkas� Cit��+�� r Signee Title Secretary A"�,�.",1"��:��°T: � ,� �""� '�� Tax a er ID No, 95-2595043 � �........_..wm�� P Y .�.................��......... �.�..��_.�.._� 'C"►°�� Weaver, City Clerk Contractor State License No.: 267073 Contractor City Business License No.: 17327 r"�1��'��VED AS TO FORM;. M � for ��.:�:�� ..... ...... � �1a�:r~� D. �.., City Attorney .��'�° �°��,�� Insurance Reviewed by:_m_ �� ..... �� Premium is for contract term and is subject to adjustment based on final contract price . ��1i��t�&�te�� FAITHFUL PERFORMANCE BOND FY 17/18 PAVEMENT REHABILITATION PROJECT NO.: PW#18-18 Bond No. 7657263 Bond Fee:$4,151.00 All American Asphalt __ _ �m("PRINCIPAL") and_ �/and..��v��p�...Comp_—y _.....,� ..nd -- ....�...._��_.._m. _��a corpoxation an of Ma la Fidelit � _�.�. ...w.... incorporated under the laws of the State of µ��,r��„m„m,m,,,,,,,,,,,,,,,,,,,, ,yy_.______ and licensed by the State of California to execute bonds and undertakings as sole surety, as surety ("SURETY"), are held and firmly bound unto the CITY OF EL SEGUNDO ("CITY") in the sum of c�m�c G��.ill�c��,�i�t�r. t��.�,.seven k��a��c�t�� v��t :..,�),t�Lw�.�r'#I�� t��mmc� z�rc� ct��;�._�,�.Y.��5(� 7"��.4DC� ,� lawful money of the United States, which may be increased or decreased by a rider hereto executed in the same manner as this bond, for the payment of which sum PRINCIPAL and SURETY bind themselves, their successors, and assigns,jointly and severally, by this instrument. PRINCIPAL or SURETY will apply this bond for the faithful performance of any and all of the conditions and stipulations set forth in this bond, SPECIFICATIONS NO. PW 18-18, and the public works contract executed with such Specifications. In the case of any default in the performance of the conditions and stipulations of this undertaking, it is agreed that PRINCIPAL or SURETY will apply the bond or any portion thereof,to the satisfaction of any damages,reclamation, assessments,penalties,or deficiencies arising by reason of such default. BOND CONDITIONS 1. PRINCIPAL will construct the public improvements identified ,.,.�ir��m� SPECIFICATIONS NO. PW 18-18, a copy of which is on file with CITY's ��7�,�i��t��t�� "� I::�ir✓�sion ("Public l��•r��jt�a�t"). ��,��a �a��•1c�a�°mance will be in acco�•�l�r�c;� ��ut�� CITY'�^�V��t�:� and ��f��es (CITY D��"�V�NG I��'��d��. PW 18-18) which are ��a�t�� E of this '��a�t�� w�vhen said plans and profiles are approved by the City Council and filed with CITY's Engineering Division. CITY has estimated the required amount of the bond as shown above. 2. PRINCIPAL's work on the Public Project will be done in accordance with CITY's plans and specifications and with any permit issued by CITY. Should PRINCIPAL fail to complete all required work within the time allowed, CITY may, at its sole discretion, cause all required work to be done and the parties executing the bond will be firmly bound for the payment of all necessary costs therefor. 3. PRINCIPAL will guarantee its work against any defective work, labor, or materials on the Public Project for a period of one (1) year following the Public Project's completion and acceptance by CITY. Should PRINCIPAL fail to correct its work against any Agreement No. 5551 defective work, labor, or materials, CITY may, at its sole discretion, cause all required work to be done and the parties executing the bond will be firmly bound for the payment of all necessary costs therefor. 4. This bond is conditioned upon and guarantees due compliance with all applicable law including, without limitation, the El Segundo Municipal Code ("ESMC"). 5. SURETY, for value received, agrees that no changes, extensions of time, alteration or modification of SPECIFICATIONS NO. PW 18-18 or of the obligation to be performed will in any way affect its obligation on this bond, and it waives notice of any such change, extension of time, alteration or modification of the contract documents or of the obligation to be performed. 6. This bond consists of this instrument; the plans and specifications identified above; and the following two (2) attached exhibits all of which are incorporated herein by reference: A. A certified copy of the appointment, power of attorney, bylaws or other instrument entitling or authorizing the persons executing this bond to do so; B. A certificate issued by the county clerk for the county in which SURETY's representative is located conforming with California Code of Civil Procedure § 995.640 and stating that SURETY's certificate of authority has not been surrendered, revoked, cancelled, annulled, or suspended, or in the event that it has,that ^ renewed authority has been granted; and 7. Should PRINCIPAL perform its obligations within the time allowed, PRINCIPAL's obligation will be void one (1) year following the acceptance of the performance by CITY; otherwise this obligation will remain in full force and effect. [SIGNATURES ON FOLLOWING PAGE] Agreement No. 5551 SIGNED AND SEALED this 25th y June , 18 . da of 20 �� ` All American As halt�� m�� " � ��:� F�t�'�N�ty._and L�ep��xd �a�ra��ny of��l�n� . �..... .... ��...�__�.. ��..._..�......................... ��C� ��'� �'�� :'� sP^�"��, SURETY's �„�:��, �� ,��°. . � � � �, � ° �:� _. .. _ �� .... ._.: :..._.... .. ... .... ..... .... ....m.�� .� :.:� ....... �� .... � �_ �"1��CF��.��'� ��'��°I"r�i��" SURETY's �`��,�,�� ";��°�"�.�""� Rebecca Haas-Bates, Attorney-in-Fact ��N�'IPAL's MAILING SURETY's MAILING ADDRESS. ABT)RESS: 4UU East Sixth Street 777 S. Figueroa Street, Suite 3900 Corona, �..�... ... .... .... � .... .,��..... ........ ---- --— ---- A 92879 Los An eles, CA 90017 NOTE: (1) ALL signatures must be acknowledged by a notary public. Return one(1) original to City Clerk's Office. (2) Bond shall be effective for one(1)year after acceptance ofthe job, Agreement No. 5551 �� I, � � G�� C�rkoftheCnurrty of��,t��.�p��q�� State af��pi��r��,a�and forsaid County ��"'"�W�� cERri�rr�►t ' � �� " �� ' � � �a�� C�� c�6�� i��r��tk�d��p�' �� w��'u�� I�� r��r�r��..;�ar��rr��Na��hr��i��or�:�ur�r°�s�r��w�t�it��a��t��p t�m��li�"�wr��a��e�r�th��k��r��+��r�fn t'��t�r��. I��r��r��.�wa��t� �d��4��t�R��r��`��a��tr��, ��v'�w�t�'��c� � ��V�ii�6�i�5o��i��9�n�.rC� � �"s�� C��rr��h�v� rw�� rad��d��I� ��r�r��g�+�r� � � � , �. �""�"�""` � COUNTY CI.ERK w� CAL�FORN�A ALL-PURPOSE ACKNOWLEDGEMENT �VIL COD 1 � A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached.and not the truthfulness.accuracv.or validitv of that document. State of California County of Rivez�side on 06/29/2018 before me, ��.k��:�� An ela Part-a �ot�r Public w.�...�.�.�.�� Date Here Insert name and Tille of lhe Officer personally appeared Mark Luer and Michael Farkas Name(s)of Signer(s) �^r who proved to me on the basis of satisfactory evidence to be the p��rsc�r�(�� rhv�� n�rr�� l'�r� ��brs�r�� to the withi�a Ira�lru�n��t �nd ��krro�vlecYg�d t� nru� th�� 1��s�a�/th�y executed �Fa� s��n� in �i�h�r�th�ir ��.�thr�rAa�c! ��p��it;�r�i��}� ��n�� that by ��r•1�� signature(s) on the instrument the person(s), or the entity upon behalf ��;, REBECCAANGELAPARRA of which the person(s)acted,executed the instrument. � � � NotaryPublic—California z � �� °^�� Riverside County > "`� Commission#2192458 I certify under PENALTY OF PERJURY under the laws of the State of � My comm.ExPires May n,�oz� California that the forgoing paragraph is true and correct. WITNESS my hand,,��a�'f��seal. �" ,,��"�� ,�� ' �"'�� "� � �� "�i�a�7��A�� Place Notary Seal Above 5��nab��rr��rt� ry Public OPTIONAL Though the information below is not required by law,it may prove valuable to person relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Tit�e or Type of�ocument Performance Bond No. 7657263 Document Date: 06/25/2018 Number of Pages: ThTee 3 � Signer(s)Other Than Named Above: F�delwt �al�d IC)� Cb�a��m ��a ��i� N�r�� Capacity(+es)Claimed by Signer(s) Signe�s Name: Mark Luer Signer's Name: Michael '�� ❑ Individual ❑ Individual X Corporate Officer—Title(s): President X Corporate Officer—Title(s) ��e�r��r� ❑ Partner❑ ❑ Limited ❑General ❑ Partner❑ ❑ Limited o General _ ❑Attorney in Fact • �' ❑Attorney in Fact � . ❑Trustee Top of Ihumb here Top of thumb here ❑Trustee ❑Other: ❑Other: Signer is Representing: ��is Representing: �Idi�rr��nc��As h�l� �tlN Arra�ri��rn As waas� Agreement No. 5551 CAL�FORNIA ALL-PIJRPOSE ACKNOWLEDGMENT CIViL CODE§ 1189 '��.��:��.��a��^,��,,��.�.� ocumenpto Iwh'��ch this certificate�s attac edhland notl theetruthfluln ssyac u acytlor val ditylofthat do uhment�.ned the State of Califomia � Count of Oran e � Y ��.__�.�....�...........��.._... _ _._,,,,,,_�.��,_ befoYe me, ,_,,,,,,,,,liana Gomez,Notary Public On 06 25/2018 Li�� Y��mmIT^ �mmmm �f Date !-fere Insert Name and Title of the Officer personally appeared Rebecca Haas-Bates ��ITmmm Name�,ot Si �i'�s,lW� g�� ....�.....�..a..� ..�.�.. ...�� mm�...�.�_�._.. . �___ -_._.�..�..�...��_.�. �.�.. ....�.. ....._� .�� ......�. d uv��wr� ��c�v�� t+� r�� r�rr 4�� so� r�� is��rry� �r�dd�r�� t� k�� t�i� ��r�aar�'�� r,�k��ca�� r�ba,rr�� 6��"�� s�aE��r��s�c� �� +N��uirn �r-��tr-�r��r�� r�� c�4�¢��r��d�� t� �� h�� °s��lth�;� �x��a��d �� r�� K� �J�7�r�t�ro�"��a�htari��a��a��+�N�,��r��d��4 b��'��''6��"�ic°�i�r��r��.�a��.��a�a�t��r�n�t��r��, ��r��#u�� aap�a�t ka�d��l� c��ufi��h� �a�ars�r'��t��l, ��at�d �� ar��ta°at��rw�. I certify under PENALTY OF PERJURY under the laws of the State of Calitornia that tF�e foregoing paragraph �„�� , is true and correct. ,��:;��;�A �ivaNa�oMez WITNESS my hand and official seal. � ��;F Notary Public-California � � M • Orange County ,�„ � Commission I!2243326 , . °" �� iy Comm.Expires May 20,2022 Slgf1atUCe._� _„�m w„w .�..�.� ._..�.�.�� .... Signature of Nofary Public Place Notary Sea/Above OPTIONAL ' Though fhis section is optional, completing this information can deter alteration of the document or fraudu/ent reattachment of this form io an unintended document. Description of Attached Document Title or Type of Document: a'u�°��c�i��a�p��3��r�d�f� '��">�"�� Document Date: 06/25/2018 All American�� Number of Pages: Three 3 Signer(s) Other Than Named Above: __� Asphalt Capacity(ies) Claimed by Signer(s) ��W��m� Signer's Name: Rebecca Haas-Bates �_� Signer's Name:,.�� ... ��..�� _.. ❑Cor orate Officer — Title s : ❑ Corporate Officer — Title(s): IT� p � ) .�...�..�.��.�....�... ...� Partner — ❑ Limited ❑ General O Partner — CI Limited ❑General ❑ Individual Q'Attorney in Fact ❑ Individual O Attorney in Fact �Trustee O Guardian or Conservator ❑Trustee ❑ Guardian or Conservator ❑Other: �„_ ❑ Other: - �� Si ner Is �� _.�..�. ��__ � �.�....�,. ,�� .� � .� �" _.��.��_..._.,....—,. g Representing: w'��'�� °�s�t�ti9� �ry��Nzc� __.�.._.� _�...�....�... � P �� ma��a�� r�r� �)�,.a��,��c�a�� g ��2�Ma�� ......_� .�.._...��.._.�...� � W�.�� r��.�.�� ry �g�., *�.�F��.��.>^�� 02014 National Notary Association •www.NationalNota or 1-800-US NOTARY(1-800-876-6827) Item #5907 Agreement No. 5551 EXl'RACT FROM BY-LAWS OF THE COMPANIES "Article V, Section 8, ��u•�q�a �-pt��i'. The Chief Executive Officer,the President,or any Executive Vice President or Vice President may, by written instrument under the attested corporate seal, appoint attorneys-in-fact with authority to execute bonds, policies, recognizances, stipulations, undertakings, or other like instruments on behalf of the Company, and may authorize any officer or any such attorney-in-fact to affix the corporate seal thereto;and may with or without cause modify of revoke any such appointment or authority at any time." CERTIFICA7E I, the undersigned, Vice President of the ZURICH AMERICAN INSURANCE COMPANY, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and the FIDELITY AND DEPOSIT COMI'ANY OF MARYLAND, do hereby certify that the foregoing Power of Attorney is still in full force and effect on the date of this certificate;and I do further certify that Article V,Section 8,of the By-Laws of the Companies is still in force. This Power of Attorney and Certificate may be signed by facsimile under and by authority af the following resolution of the Board of Directors af the ZURICH AMERICAN INSURANCE COMPANY at a meeting duly called and held on the 15th day af December 1998. RESOLVED: °That the signature of the President or a Vice President and the attesting signature of a Secretary or an Assistant Secretary and the Sea]of the Company may be affixed by facsimile on any Power of Attorney...Any such Pawer or any certificate thereof bearing such facsimile signature and seal shall be valid and binding on the Company." This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directars of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at a meeting duly called and held on the Sth day of May, 1994, and the follawing resolution of the Board of Directors of the FIDELITY AND DEPOSTT COMPANY OF MARYLAND at a meeting duly called and held on the 1 dth day of May, 199d. RESOLVED: "That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically reproduced signature of any Vice-President, Secretary,or Assistant Secretary of the Company, whether made heretofore or hereafter,wherever appearing upon a certified capy of any power of attorney issued by the Company,shall be valid and binding upon the Company with the samc farce and effect as though manually affixed. IN TESTIMONY WHEREOF,I have hereunto subscribed my name and affixed the corporate seals of the said Companies, this zetr, ,.......�._..._..day of�une zo�a ��q pKra�� "` +'� "y `;� www � wew� :�" w ��. ""'� '" «�rw ��`� �� i ��M��._.W.�._ . ' hael C.Fay,Vice President TO REPORT A CLAIM WITH REGARD TO A SURETY BOND,PLEASE SUBMIT A COMPLETE DESCRIPTION OF THE CLAIM INCLUDING THE PRINCIPAL ON THE BOND,THE BOND NUMBER,AND YOUR CONTACT INFORMATION TO: Zurich Surety Claims 1299 Zurich Way Schaumburg,IL 60196-1056 r,wrwuv.r�,�as�antst�9�ir��;;�ii��a��,��ra� 800-626-4577 Agreement No. 5551 PRF7657263 ......... .......__ _....._..��W� Bond Number City of EI Segundo ... .... ...,,,,,,...Obl igee ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS:That the ZURICH AMERICAN INSURANCE COMPANY,a corporation of the State of New York,the COLdNIAL AMERICAN CASUAI,TY AND SURETY COMPANY, a corporation of the State of Maryland, and the FIDELITY AND DEPOSIT CdMPANY OF MARYLAND a corporation af the State of Maryland (herein collectively called the "Companies"), by Michael P. Bond,Vice President,in pursuance of authority granted by Article V,Section 8,of the By-Laws of said Companies,which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof,do hereby nominate, constitute, and appoint B��h�.�H��s o��taa:�..... .. .... � .... -�----- ....��e_.��m..... .�... . -� its true and lawful agent and Attomey-in-Fact,to make,execute,seal and deliver, for, and on its behalf as surety, and as its act and deed: any and a!f bonds and undertakings,and the execution of such honds or undertakings in pursuance of these presents,shail be as binding upon said Campanies, as fully and amply,to a11 intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the ZURICH AMERICAN INSURANCE COMPANY at its office in New York,New York.,the regularly elected officers of the COLdIJIAL AMERICAN CASUALTY AND SURETY CdMPANY at its office in Owings Mills, Maryland., and the regularly elected officers of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at its office in Owings Mills, Maryland.,in their own proper persons. The said Vice President does hereby certify that the extract set forth an the reverse side hereof is a true copy of Article V,Section$,of the By-Laws of said Campanies,and is now in force. IN WITNESS WHEREOF,the said Vice-President has hereunto subscribed his/her names and affixed the Corporate Seals of the said ZURICH AMERICAN INSiJRANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND,this 25th day of.1une ,q,D, zola ATTEST: ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COiVIPANY OF MARYLAND � �� ' �,a�cr�,�� .�. w� �.� .�^,�" "�� A*� � By: Michae!P. Bond � �,,� Vice President �,.r., � r �`"° a ` � °r,r��,... ��,.�..��i��rC�. �_� �,,,� � ._ By: Dawn E.Brown Secretary State of Maryland County of Baltimore On this t day of__une „ A.D. 2016 , before the subscriber,a Notary Public of the State of Maryland,duly commissioned and qualified,Michael P.Bond,Vice President and Dawn E.Brown,Secretary of the Companies,to me personally known to be the individuals and officers described in and who executed the preceding instrument,and acknowledged the execution of same,and being by me duly swoen,deposeth and saith,that he/she is the said officer of the Cornpany aforesaid,and that the seals affixed to the peeceding instrument aee the Corporate Seals of said Companies,and that the said Corporate Seals and the signature as such of£icer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporations. IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed my Official Seal the day and year first above written. �,��,�ur��r� `"�� k�.Y�r"f .r��; G1.J�1 �� '.e`,�' �,�,�.w� Constance A.Dunn,Notary Public ��r�;�� ;''�,` My Commission Expires:July 4,2019 �''ar�,;;��a��t'"� No 466Z ` STATE aF CALIFQR1YxA ' � Agreement No. 5551 .. :I��'.A.�."�"`��"' Q�` �"S�"�NCE s�rr�nrczs cv arn�a�d ` , �ertY�icate of AuthorYt� " THIS IS TO CE1ZTlFY, 7hrrr, purs�t►��o tlie l��su�'w�ce Code vf!Ju SlW6 of Ca!lfornlo, � l+lde[ity ared De,poart Ca►rrpa�Fy vf Marykd�d af Baui►nore, Maryland, orgariized rurde�lhe 1aH�s of Maryland, subjscr ro!ts Articfes�Irrcorporarlo�x or 0lI�eJ'fundanra�u�l ar�ga�f�liorta!docun�e�us; �r hereby pxrthorlZed[o trnn,tcut wi�hin flu�_Slate, subfeCt to al!prnvision,r of Nu:r Cer�lftcrou�, rhe�'alldwi�g c,rnsscs of lnsura��ce.• l�rra, Marites, Surety. Plate Gla,�r, I.�cbillty, Rrorke��' Co�npen.satton, Cammox Can�ier IsuLili�y, Bo�'er aad Mrul+dnuy, Burglary, Credit, �',��e�`�,�, 7"ealh aiuf VBhicle, r�rrtoniabile, �ircr�f't, ared M�sceYlcutevas ' . aJ surJ�clussrs ara,ra�v ar nrcy her�rar be de,��ted tn r!�I�uuransc Lrnvf oflhe Stare of Cal{�'ornta. � THTS GERTIFICAT`E is�zzprrssly cauliliorred upon�he halder hereof�tow and I�rrec�ter bel�r,g !n fuu c�rpltar�r wirh all, cu�d�mt iit vlofa�lori r�''arry, af rlee npplic�ablc laws anr!luwfu!requ�rernents marle unde�•atul�orlry ojrlra Iakvs of the St�e of Cct!{fvn��as lor�g aa sic�h lawa�r r�equirernenkr are irs e,fj"�c� a��d app!l�able, mtd as sud� laws and requb-entenls no�U ara, or n�ay Irere�er be chan,ged or amrr�ded. , , . IN WITNFSS WHERBOF, e,�`ecatrue as df lhe 29t1t day of,1a►uwry. 1985, I frave hRreul�JO SBt my h[trtd alld c�auded lTty Offt'C(al JRRI t0 bC � . ��ed thi,r 29th cfay af Jmruary, 1485. F� �sa.00 { s��r re�wa.er caum,:�tiener . Rec.No, ,�4314 Flled 12/3l84 By Yictaria S, 5idbary �� " C�71flca�lon ° I �,��r;�d'��~sig�1'r�r��r�"�ana�r�,�,�s��rra�w��"�'��t��'C'�d�f�rr��r�,a�h��b,�C;��t�"�e � �t�ro c�+�v��+^er�°�"�rd�fd�ced�r�f��c�h��,��tlJz��ie c�p��'�a�'"a��,�r"rr�1 w��s�,�'dl�^�,�r�a�'aJ.�?�', er��'1�t+��.ti�r��►��r„�r� +�r,�, ��lr�r�c� tr+�r��rr�'��"��a�,��l�c�+"�r��r�C"�ac�lcs��,��C�� t +�e��a��d�""�ta�x��rr�'t�r��+��„��',�"ar�,��r��`�r �c:� , , � IN �W:�" � "6� ��", ��aw�� t�set a�r,�r�wa�",�cC cax.rsd my . �w�"JM„P��",��e�l��c�ta��rl��fi�^.�,�r�'�'al,4�r�u�'� ��. , . l. Clark Kelso " � , �r�*�CaKa.ocia,w T'0.�..L,,:{ �AM�� . peufine D'Andrea . �� Agreement No. 5551 LABOR AND MATERIALS BOND FY 17/18 PAVEMENT REHABILITATION PROJECT NO.: PW#18-18 Bond No. 7657263 I��:t1"�t:� Fee:Premium is included in the performance bond �x��ted in: 2 Counterparts All American Asphalt v�_ �, as principal ("PRINCIPAL") and F,.�_ Y_� p y of Maryland � � _ , a corporation idelit and Deposit Com an incorporated under the laws of the State of,,,Mar�rland ______ __� _ � and licensed by the State of California to execute bonds and undertakings as sole surety, as surety ("SURETY"), are held and firmly bound unto the CITY OF EL SEGUNDO ("CITY") in the sum of one lawful�money�of the�United S�tates,wh ch may be��nc eased�o�decreased by a�ider hereto executed in the same manner as this bond, for the payment of which sum PRINCIPAL and SURETY bind themselves, their successors, and assigns, jointly and severally, by this instrument. This bond is conditioned upon and guarantees payment by PRINCIPAL to contractors, �a��c��a7t�M��t�rs, a�t��i �c�r°�c.�� renting ��ai�rc��at� ��.��rr��r�� i[I��1��1�� 1 ��.11 t'I�.I��"��r°�.I.'S s�aL��c�n�:r��tc��•� for all mat�;;�i��l�� ar�a�w�ir��s, �p°caa��c��.t°� c�a�ry c��k�e�-�t��aNi��, ��d equipment used in, upon, for or about th� ��t��•��7�� ,��" t��; wta��: �c�r�t�:��l�re�� n SPECIFICATIONS NO. PW 18-18 ("Publi� F''�~a��;t""��, ��hr� ��k��N��: �w��r�� c��t�� t�d C��G"�t�c� �:��alic ��'r��t;� ��.� t'a��r�l�! �^t�t•�:�'��' ��kst�rw of any ki�� .rd��`��ed for the A't�l�l�u Project. Lt� �1��. ��u of ��r c4��`�� w�� @�� ac,� of the �c�r�c�it�t�t�:� and stipu��at��at�� of this ��t��C��t��i��„, it �;� �� t 1'l�I➢��:"&I�,�°'��.., r�r~ �1:.��.1�:"��Y will apply the bond or any ��a��t��r�� th��t°��#;�i�.c��a��tisfaction c��<��y damages,recl�i��i��a�assessments,penalties, or defi�i�;��ci�� ari�z�� r�;�� of such c�ci"��lt. BOND CONDITIONS 1. PRINCIPAL will construct the public improvements identified in SPECIFICATIONS NO. PW 18-18, and the public works contract executed for such Specifications,copies of which is on file with CITY's Engineering Division("Public Project"). Such performance will be in accordance with CITY's plans and profiles (CITY DRAWING FILE NO. PW 18-18), which are made a part of this bond when said plans and profiles are approved by the City Council and filed with CITY's Engineering Division. 2. PRINCIPAL will pay all contractors, subcontractors, and persons renting equ ipment. 3. PRINCIPAL will pay for all materials and other supplies, for equipment used in, on, for or about the performance of the Public Project, and will pay for all work and labor Agreement No. 5551 thereon. 4. This bond is conditioned upon and guarantees due compliance with all applicable law including, without limitation,the El Segundo Municipal Code ("ESMC"). 5. SURETY, for value received, agrees that no changes, extensions of time, alteration or modification of SPECIFICATIONS NO. PW 18-18, or of the obligation to be performed will in any way affect its obligation on this bond, and it waives notice of any such change, extension of time, alteration or modification of the contract documents or of the obligation to be performed. 6. This bond consists of this instrument; the plans and specifications identified above; and the following TWO (2) attached exhibits all of which are incorporated herein by reference: A. A certified copy of the appointment, power of attorney, bylaws or other instrument entitling or authorizing the persons executing this bond to do so; and B. A certificate issued by the county clerk for the county in which SURETY's representative is located conforming with California Code of Civil Procedure § 995.640 and stating that SURETY's certificate of authority has not been surrendered, revoked, cancelled, annulled, or suspended, or in the event that it has,that renewed authority has been granted. 7. Should PRINCIPAL perform its obligations within the time allowed, PRINCIPAL's obligation will be void upon the acceptance of the performance by CITY; otherwise this obligation will remain in full force and effect. [SIGNATURES ON FOLLOWING PAGE] Agreement No. 5551 AI Amer canAs ha tD this �5th da of,�une Y �.. �,,..� .�... ....�� 2018 �.,�� p �, ..�..� �- ' � � � � ��""u�.�.��.�.�� ......._�....Fide@�t�y and b�p ...� I��co .�_ �: c�:�d��ar�°� y of M�rya�a�� PRINCIPAL �� .....wm�. .. �, 's PRESID��,T 1 SURETY's � �, ��..�,��"� �+�� :�,'� � � � � � � �, ,� YRIIVC,I�__ ... � . :..�� _�� .��..�.. �"��"�� . .. � ,�� Rebecca Haas-Bates Attorne -in-Fap�� .�°s ��,�.��°r�,�� su�TY s �'�&�� "��w� ,��.��"� �"� y ct �P'R3�iCIPAL's MAILING ADDRESS: SURETY's MAILING ADDRESS: Corona CA 9287eet s An Feles,rCA 9treet, Suite 3900 _,�. ast � _. —� __,. �... ... g � ��.�.. __ . ...—,�.._..._ . ww....... � g 0017 NOTE: (1) ALL signatures must be acknowledged by a notary public, Return one (1) original to City Clerk's Office. Agreement No. 5551 �� n f ��.�c��, ° in n r � ° q,,�, � � t of �� , ��s� :�a�� w'�a , of �� T � ��.nt'v � ��T � �,� �� '��q��t�� ,:,,�� "� � �,� �� i � �t�� `�"�� .�.�� . �� ,.� ��+�� "� �'"°F��. �� R��t��4;�a4�1�C�t��C��C��1��'��Cfw��1��d��4�°�" ' ��M,"�� b��s��r��wr�e�ow�i�ao�� k��.�r�� b,�a i� �"b d,��a��a�wtc�rr�r��tt��,c��t��c^��k�� Yr��,��d��.�r�� q�d"1�b�.9�q�C1•"�i6' �4.f"�&AaGP��"�R�P��p��"Y"�4�N�� i w�+ �� :��'�� 58j(1{iUUlliy Ufl ""�""""��^"" �M� �� .. �....��«� C�UN� �� CAL�FORNIA ALL-PURPOSE ACKNOWLEDGEMENT 1 � A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached.and not the truthfulness.accuracv.or validitv of that document. State of California County of Riverside �_ on 06/29/2018 before me, Rebecca An ela Paanra Nota Public „ Date Here Insert name and Tille of the Officer personally appeared Mark Luer and Michael Farkas Name(s)of Signer(s) W�...................................................................................................................................................� .� who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) 4s/are subscribed to the within instrument and acknowledged to me that heEshe/they executed the same in #�isl�ie#their authorized capacity(ies), and that by #is!#�eF/their s��e,�,,, REBECCAANGELAPARRA signature(s) on the instrument the person(s), or the entity upon behalf � NotaryPublic-California ; of which the person(s)acted, executed the instrument. �°n��' ��'�y RiverSide County qm Commission I{2192458 My�er�m,€�pl��5a��y»,zoz� I certify under PENALTY OF PERJURY under the laws of the State of California that the forgoing paragraph is true and correct. WITNESS my hand��"�N seal„ �� n�ry�at�ar+� ,�� _ ""�� '� ��.»�,�.�� Place Notary Seal Above �ig�a�lGere uC N ary puarAlc OPTIONAL Though the information below is not required by law,it may prove valuable to person relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document Pa ment Bond No. 7657263 Document Date: 06/25/2018 Number of Pages Three 3 � Signer(s) Other Than Named Above: �'xd�Vi# ��?� �si�r7'a��r s�f d��r�� Capacity(ies)Claimed by Signer(s) Signers Name: Mark Luer Signer's Name:Michael Farkas ❑ Individual ❑ Individual X Corporate Officer—Title(s): President X Corporate Officer—Title(s): Secreta ❑ Partner❑ ❑ Limited ❑General o Partner❑ ❑ Limited ❑ General � ❑Attomey in Fact ' ❑Attorney in Fact ' ❑Trustee Top oF thumb here Top of thumb here ❑Trustee ❑Other. ❑Other: Signer is Representing:. Signer is Representing: �,NI A�n�ru��r A�s atiw�Nt �II�rr��rd��n.��.h�a�, Agreement No. 5551 ��s��. . �. � � � M I t� 11 � `� �. �. ��:��:��,�� ry public or other officer completing this certificate verifies only the identity of the indivi ^��X v A nota � �� 'dual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of Califomia ) County of Qr�_._� ..... ) On 06/25/2018 before me ry Public Liliana 4��a��x,Na�� Da�e ��V�m � ��Here lnse �Wn��of the �rt Name and Title �Ofiicer �� -Bates personally appeared Re ecca Haas � � ......—._.�..._....___ __._...�.�.... .�.� _....�� Name�of Signer�`s,l .,�.�..� .�.. ..�,��.._..�........ .._.��.,��.� ... ..... ... ... �..�.�. ____........�.._�,�.�� +�v��c� �r'��r�s� �� u�u� c�r� tha� ��sa� t�P :��Gs��t�r�+ avi��ra�� t� be t�°o� �.��`��a�� B��s� �a�rra�(�}, isP��. �uk��,o�i�� tr� �h� vrr�ti��Arb s�ros��a�r��'�� ! ��krr��ral�� r� �o� that ��"'�h�l'kk�e� ��;��,�k�� t�� m� flr�u P�w�/��r��akr'��a�6��srw;��3��p�c�ty�i��,�c�c�t��4�ay��p�h��fC��i�`��,�natu�°��rrr��a�am��r�,�w�c�n��'��p��r�t�p�(��,, �r�k��w��b�y u�a�rw ��C6 a��t�i�3� th� �r+��w�+�e�a�, ��t�d, �x��t��i the o�r��ut'��r�. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. "�` ��,� �iuANA�oM�z � WITNESS my hand and official seaL _ �' � �: Notary Public-California Z � r '�'� �" Orange County D j �`, Commission It 2243316 " �� y Comm.Expires May 2p,2022 ' SIgf18tUC2 ....� �..__.... �_.:��.�_...m�. Signature of �r��a��c�,�� Place Notary Sea/Above " OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudu/ent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: _ mM�'�r��c��ti Bond No, "ifa��r3 Document Date: 06/25/2018 All American �� m Number of Pages: Three 3 Signer(s) Other Than Named Above; Asphalt Capacity(ies) Claimed by Signer(s) � � mm��mmW �� Signer's Name: Rebecca Haas-F3ates ��,� Signer's Name:�_ ❑ Cor orate Officer — Title s : p � ) � �� _.__�. ❑Pa ner — ❑ Limited ❑ General ��WW� � Cor orate Officer — Title s : ,_ �� ❑ Partner — O Limited ❑General ❑ Individual C�3'Attorney in Fact ❑ Individual O Attorney in Fact ❑Trustee ❑Guardian or Conservator ❑Trustee ❑Guardian or Conservator ❑Other: ___ O Other: aa �w�r�Is �� a��r�torr � Signer Is Rep�.. _.....�. � _..�.. 9 M� � � __.w_ , �.. resenting� �._—_._ Fxt��;bo��mand f?��t C�a��ra�a�N��t�f �G��,��m�u�a� 0020 4 Na onal No ary Assoc at o�www.Nat ona No.�tary.�org�00-US NO�RY(1�80 876 827)��It m�#5907 Agreement No. 5551 EXT C7 F Y-LA F THE C PA IE "Article V,Section 8 a�4'R��u�.��, iq7-��=��4, The Chief Executive Officer,the President,or any Executive Vice President ar Vice President a�ad�u��^„ l�y �vri&��d� 3a�«;��s��a:nt a�r�rc��.r k@�� attc^:��a:�,9 e��r�`��ar�°��t�: �;�.��6„ �o�a��s.��r�� ,��sa��:y�w ar�-�"r�cti� �rri�a'bt ��zt�t9��r�ty� tcr ux��.u�� r��>w��6�r g�arlic��„ w��,,e��r�br�u��s, �;4i�aa9��tia��b��. unc�9�.rt.a�i�ti�;�m or i�tt��M�r l��t� �a��stuuuub��a�� rr� ��;8��11"��d`t'��a��, (��a��,��ay, ddra�8 u��su+� ��M��k��d�3r� a�a��,�r ��'��s��'�¢ s�r;�y ;��4a°�8� wa�t��p�d�ti��io�ro-��b�!"��7sr�Bza�cor}�¢aaF�A�.��:a��x�thec��„a�zuat r��y ww�9�o�a�•��uik�r�a�pt'�^arau�s�.��r�a��rc9u��r ew�6'"r�vc�ka��ru�r�t��°9•b��,��ydc��raq��ma�c��•srou��l��tse�d��sui�r��a,Y � ��rtt��."' . CERTIFICATE I, the undersigned, Vice President of the ZURICH AMERICAN INSURANCE COMPANY, the CdLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and the FIDELITY AND DEPOSIT CdMPANY OF MARYLAND, do hereby certify that the foregoing Power of Attorney is still in full force and effect on the date of this certificate;and I do further certify that Article V,Section 8,of the By-Laws of the Companies is still in force. This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the ZURICH AMERICAN INSU1tANCE COMPANY at a meeting duly called and held on the 15th day of December 1998. RESOLVED: °That the signature of the President or a Vice President and the attesting signature of a Secretary or an Assistant Secretary and the 5ea1 of the Company may be affixed by facsimile on any Power of Attorney...Any such Power or any certificate thereof bearing such facsimile signature and seal shall be valid and binding an the Company." This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at a meeting duly called and held on the Sth day of May, 1994, and the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the l Oth day of May, 1990. RESOLVED: "That the facsimile or rnechanically reproduced seal af the company and facsimile or mechanically reproduced signature of any Vice-President,Secretary,or Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a certified copy of any power of attorney issued by the Company,shall be valid and binding upon the Company with the same force and effect as though manually affixed. IN TESTIMONY WHEREOF,I have hereunto subscribed my name and affixed the corporate seals of the said Companies, this 25ch day of�une w zo�a �.�roti�� ,*^.��"""�"��'�,� � � � � a�ww �" �� i��. a a "r*', �P�.,��«,..��,� l �'�� % M�chael C.Fay Vic e President TO REPORT A CLAIM WITH REGARD TO A SURETY BOND,PLEASE SUBMIT A COMPLETE DESCRIPTION OF THE CLAIM INCLUDING THE PRINCIPAL ON THE BOND,THE BOND NUMBER,AND YOUR CONTACT INFORMATION TO: Zurich Surety Claims 1299 Zurich Way Schaumburg,II,60196-1056 r�w�n�.�°��k�S"��,�rMpa��e�a)r��,,�,u,,,,,�°i+�l��,crr�x� 800-626-4577 Agreement No. 5551 PRF7657263 .�.................�..�..,.......,.w._._..,.�..._m..............................................�Bond Number City of EI 5�+,�wus�Ya ��...,...,..._........................... .....................��...... _ Obligee ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND POWER OF ATTORNEY KNOW ALL MEN BY"I'F�ESE PRESENTS:That the ZUELTCH AMERICAN INSURANCE COMPANY,a corporation of the State of New York,the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, a corporation of the State of Maryland, and the FIDELITY AND DEPOSTT COMPANY OF MARYLAND a corporation of the State of Maryland (herein collectively called the "Companies"}, by Michael P.Bond,Vice President, in pursuance of authority granted by Article V,Section 8,of the By-Laws of said Companies,which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof,do hereby nominate,constitute, and appoint Rebecca HaasBates a ent and Attorne in-Fact,to m.�.�� .. _......... ......�,__�---�..�.�n� .... __,...�.� ....... m�..,m its true and lawful g y- ake,execute,seal and deliver, for, and on its behalf as surety,and as its act and deed: any and all bonds and undertakings,and the execution of such bonds or undertakings in pursuance of these presents,shall be as binding upon said Companies, as fully and amply,to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the ZURICH AMERICAN INSURANCE COMPANY at its office in New York,New York.,the regularly elected officers of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings Mills, Maryland., and the regularly elected officers of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at its office in Owings Mills, Maryland.,in their own proper persons. The said Vice President does hereby certify that the extract set forth on the reverse side hereof is a true copy of Article V,Section 8,of the By-Laws of said Companies,and is now in force. IN WITNESS WHEREOF, the said Vice-President has hereunto subscribed his/her names and affixed the Corporate Seals of the said , ZURICH AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND,this Zsm day of June ,A.D. 2o1e ATTEST: ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND 9;��lr�^^"'�� *m mera�7r �,.�� ',p��r,y"' � Mw a � � �,�'Gt#� � �uw .�i. By: Michae!P. Bond �w �,„�w, Vice President na._ �� " � �.n��P�°�a^,......_, 4' ir-aa�r�rY, ti �� By: Dawn E.Brown Secrefary State of Maryland County of Baltimore y _ � q„r}. 2o1e before the subscriber,a NoYary Public of the StaYe of dn this da of�� P++lxte�l��acl„c9��C�+c�aaa�eoa��uarrsLci&�tt€1��n�tlufr�a6 3V9urh�rt 1' I�'��a��m�`i�c F'�tsr"�l��tti��l��k+�^r�C�,.�irtw��e�ra^t�ar�^tzd"t9��:,�.'rcaar�q��rtio��„YCa avu��pF�1G'�ks�n+�Mra tcs�r�;C6�c��a��^6�Er��9�;��a�i�r8"&it�+��i+�wa;e��t9 ont��ao��w6�rtr�;�x��a��<9 t6ac�pa�rt��a�a�om��u��twa�uA��na�r�a�„�aX��rtaOC��t��a�+l��e��)�aYro��„'w„a„�:ta�aaaGs r�k'.��mmv7a,,at��k��uo��W��+oa��.��,}" ��wr¢a�ar �v��r;��tBa ¢ba�a9 s�b,ft9�,t@a��1•o�dsli�.b�„��4'�tt�,+�a�a��t a'�4��ra,�^r��N�� 'a�pnz�;��uty�af¢ar�e�axaa��a�€9�laa'st�6�c��r�al��d'��xti��'6 tar k3�a:��r�a�rJi�aro�i��to�s��;ar��ae�t��`a�r�r�r�t'a: S�r6;��6"sG�ws@�.ta�rvp7�s�utic�s,mdtt9 t6t�t�� ^,��i�6 d"aror�a�'�r[c��a�7x�u�� C��9a�s��,�n�taace�s:;aa�;��u s��'1'ti�ctir v��a'�;�d�0y apf�'��sl�war��aaa�:��x�rou�'9 rt¢��Na�^^s3si�¢$�n�t�urau�a�t V��kro� aauaC�t�crr�t}+�so�r��dimr�cta��rm�s�s9"t8�e saa�a�9�"�ar��r��admc�s��s. IN TESTIMONY WHEREdF,I have hereunto set my hand and affixed my Official Seal the day and year first above written. ��,tH�i d4 r�p�"if�A'"e,e 4.,,. f r �,� � �'v'�/ S d Y� � 4e�'4�„'� � ��.f. Canstance A.Dunn,Nota Public �"'�'��ry�� `' ry �,,��'rMr,t.ra ws ,^ My Commission Expires:July 9,2019 a�r�,r�x�m,e�� Nn, 4662 ' STATE 4F C�LIFQRIYXA � o � � Agreement No. 5551 „ ��`.A►.�.�`��:"'' Q�" ��"S�'"��.�.NCE SAN FR,ANGiSCO . Am�ndcd Y CertY�icate o� AuthorYt� ` THIS IS TO CEnTlFY, 71rpr, pu�Su�l1!!D!!!e()Ltll!'WiCd CO�/G vf!li[SlW@ Of C�fOrn/G, „ . l+lde[ity ar�.d�tpa�it Carrrpo��of Marylur�d vf Ballimort, Mar,�land, argmtii�ed�rrrderuie,��s afMarylrtrrd, 5!►bjcGT!p 1!S A177cles(�f lrltOlpOra7rOlt ar o1lr��°,�ar��rra�arnl orgunlwliorwl docun�enls,"rs hereby oauhorl�eri ro rrctnract withrn thi,s Srate, subfeet to a/l prm+isiona of Hei,r CertTfic��, rhe�`ouowir�g crnsses of lnsura,�ce.• 1�'ire, Ma,��c�, Surety. Plete Gla,�s, LtcbilJiy, Worke,�' Co,npen.satton, Cammox Car�er Iscbiliq�, Boi�er and Mae/dnsry, Burglary, Credit, ,�prinJF'ler, �'�o�h afad Velucle, Arctonrobile, Aircn�t, and Mlscellaneores ' . Qs sruJ�cicxrsrs ara,raw or nuty Irera�rer be de,��te�fn rlre l�uurance Lmva of ehe Srute of Cal(fornfa. � T�.[S CERT7FICATE is�xpressly conrlilioned upon lhe halder hereof�ww and I�rrec�ter bafrt,g 1n fuu cbmp114►�ce w�th all, cu,d�mt iii vlaf�lor:of rrrry, of r�ee npplicrrble law.�anr!lawfrcl requirernenls rnnrle unde+•autl�oriry njtlee lakvs of the S�n�e of Cn!{fvrnlc�cts�or�g as s��h �awa�r��eqwrensen�r are iri eff'�ct arrd apJ�llcable, u�id as sud� laws prcd�erlu�-enteRlS no�U ara, or n�ay hereaftsr bC chan,ged dt amer�ded. , . � IN W1TNE5S Wk�ERBOF, e�'ecxrue as af lhe 2�'Ir day of Ja�usury, �985, ! fravt ItRlP,lUftO SBt J73y Jt[�!#� Rry� L�i41'P.Q J►t� O�C�Ql JEG�G 10 bC � • . a,QZred u�i,r 29th duy af Jmt¢ary, l985. Fcc �54.00 Brncc Butmet � . Rec.No, 543�4 � r��•W c�:�� jl� ��r�4 By Yictoria S, 5idbary . ` C�^IlflcaPton �� - �rn t�o�r'bcw,��r �� rr �� ha� �C�Z t��e�,��c�'��rz,�r�a h�r�^l�„��f,��hat�" � �'w�,��a�r�� `��rrr�srlxsl�a�er a �"�r��,��"�r�a �'cr�'i�ra�a�r� iaa � »� � .!'" �.�°' "��r��a��te ia�mr�+ta�'�, �'��z��rit�r",t�! �a '.�� cra��rt�sc�r�^�r�t6�rr�a,��"�f��w��Z�t�a�,P""sr�r"�`�l�a�t��e�r�'�d C"�r��at'��"�T r�r�,�rr'aj�,a�r��ra,�r��"'�r��ara�aw,�"�� , . IN �'�`�� +'��U C dr�v� �car��a s�et atr��,��caured�ny . �„�",��°�J,s��l�a 1a��x�a�t�rl,�.��"�of,��r�r��', ��fl�. , l. Gark Kelso ' ,.aoaP.tln..�ano.Cenur.Ac:aueel� P�.�..1�,:� �A�J�.�- . Pauline I7'And�ea r �� Agreement No. 5551 PROPOSAL FOR THE FY 17/18 PAVEMENT REHABILITATION PROJECT NO.: PW 18-18 Date MaY �� ,20m 18 Company Name: All American Asphalt TO THE CITY OF EL SEGUNDO: In accordance with the City of El Segundo's Notice Inviting Sealed Bids, the undersigned BIDDER hereby proposes to furnish all materials, equipment, tools, labor, and incidentals required for the above stated project as set forth in the Plans, Specifications, and contract documents therefor, and to perform all work in the manner and time prescribed therein. BIDDER declares that this proposal is based upon careful examination of the work site,Plans, Specifications, Instructions to Bidders, and all other contract documents. Submittal of this bid shall be considered evidence that the BIDDER has satisfied himself regarding the contract documents, access and any other field conditions which may affect bid prices. If this proposal is accepted for award, BIDDER agrees to enter into a contract with the City of El Segundo at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to the City of El Segundo of the proposal guarantee accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids, and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE CITY OF EL SEGUNDO RESERVES THE RIGHT TO INCREASE OR DECREASE THE AMOUNT OF ANY QUANTITY SHOWN AND TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all apparent expenses, taxes, royalties, and fees. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. If awarded the Contract, the undersigned further agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within ten working days after the date of the City of El Segundo's notice of award of contract to the BIDDER, including sending by U.S. Mail a Public Works Contract for signature by the Awardee,the proceeds of the security accompanying this bid shall become the property of the City of El Segundo and this bid and the acceptance hereof may, at the City of El Segundo's option, be considered null and void. I-C-1 Agreement No. 5551 1� �Ph�� .��:�+�►"�'�.��,�C M" Q.'�'�'�"��"i"C�t'�i�"�"�" COMPLIANCE BIDDER certifies that in all previous contracts or subcontracts,all reports which may have been due under the requirements of any agency, State, or Federal equal employment opportunity orders have been satisfactorily filed, and that no such reports are currently outstanding. ��t,�ti��6��"�"�'"�ll+� t��.".�'��"l�+N ��;��I"�T"��":"�'�.��C�N BIDDER certifies that affirmative action has been taken to seek out and consider minority business enterprises for those portions of the work to be subcontracted, and that such affirmative actions have been fully documented,that said documentation is open to inspection,and that said affirmative action will remain in effect for the life of any contract awarded hereunder. Furthermore, BIDDER certifies that affirmative action will be taken to meet all equal employment opportunity requirements of the contract documents. N��`��'��1.��..��:.��'��f'� ��I�C"��:t��.'��"��:� BIDDER declares that the only persons or parties interested in this proposal as principals are those named herein; that no officer, agent, or employee of the City of El Segundo is personally interested, directly or indirectly, in this proposal; that this proposal is made without connection to any other individual,firm,or corporation making a bid for the same work and that this proposal is in all respects fair and without collusion or fraud. I-G2 Agreement No. 5551 BID SCHEDULE FY 17/18 PAVEMENT REHABILITATION PROJECT NO.: PW 18-18 Company Name: All American Asphalt Note: Bid Item Work described below is abbreviated for formatting purposes. The contractor warrants by entering pricing below that he has thoroughly read the entire bid document package, has thoroughly reviewed the site, and that his pricing encompasses all work described in the bid documents sections and r��;��t�for execution of work. ._�� .. �....._ ITEM IpN UNIT QTY p�CE AMOUNT NO. __....�_._. ......... DESCRIPT. ....w.__ �� .� ....�.— �..� BASE BID ITEMS w �._�� .......�........ ...._._ ..._.. __�..� Mobilization and Traffic Control, �I1,2�0•S� �k12(� .S� 1 including Traffic Control Plans LS 1 $ $ _...... ..�.�...�.. � .�._....._. .....�. 2 Cold mi112"existing asphalt concrete SF 623 341 � �2� ��,�� (AC)pavement ' $ � . _ _ ..._ 3 Overlay 2"new asphalt concrete (AC) SF 623 341 D'� 5�9�0 .5� pavement ' $ $ .. ....... �.�..._ ��._ _ 4 Adjust El Segundo City sewer manhole EA 45 ��" � 2�,25b. � assemblies to final grade , $ � __ _..._�_. ....� _..........�� ... �o �___. 5 Adjust El Segundo City sewer valve EA , 6 ��' �' assemblies to final grade � $ . .� _ ...... M_ 6 I Adjust El Segundo City water valve EA 139 3W` � �1��- assemblies to final grade � � ..�.._. ..._ ....�.� __u..�., � � Adjust El Segundo City water manhole EA 1 �� O�O . final grade � $ AdjusbEl Seo undo Cit storm mm�� WWW��^mmmm manhole asse �� g g y drain EA 14 �°�" � 9 I�p. �� mblies to final grade ��..��_.. ...._.....��_ _ �..�.,____�_ ��....��_. $.w_.��. manhole as e blies t�final �ra� �� ZSo.�� ' �... 9 rm drain EA 5 �S� g de $ $ �. ...........� �.. Adjust El Segundo City storm drain vault � � aoo• 2�0. � 10 assemblies to final grade EA 1 $ $ .._.... ... Adjust El Segundo City storm drain � tJp�_ � 11 storm drain inlet assemblies to final EA 1 5�� rade, and re-stencil $ $ ....... �....._ �_._. Adjust Southern California Gas �- �ITm % 12 Company gas valve assemblies to final EA 5 �W �S� rade $ $ I-C-3 a Agreement No. 5551 _... _. �..�...w . Adjust Southern California Edison I �r� �-- ��µ 13 electric manhole assemblies to final EA 7 grade $ $ �.... .._�...... .... _u � �..��r m 14 Adjust Southern California Edison EA 2 2,600 a �OtiO. electric vault assemblies to final grade � � .....�... .... _..... �� .. �_.._�_. ..�...�n Adjust El Segundo City �o� �- � ��WWm,�� 15 telecommunications vault assemblies to EA 1 ° �` ��N��1 �s�,�e $ � 16 Adjust Bell Systems telecommunications EA 16 � l�`�� mm'WW manhole assemblies to final grade $ '� .._._... . _ _._. .. . M ........ _.... __..�.� Adjust TWC telecommunications vault 1050 • � loSb � 17 assemblies to final grade EA 1 $ $ __.... _. _M.... ...._ .._. .�......�.�. _._..�. ig Adjust AT&T telecommunications EA 1 �� I �� mm� nal grade $ $ ........ man o e assem ies to fi..... _ ..� .�..�..w_w..� ,�...mm....� _...��w�.�_.. .. ...... 19 Adjust T.V. Cable telecommunications EA 1 �" � 2�b�. � vault assemblies to final grade ,� � � Adjust Equmix telecommunications �S� r �p�u . . � _ � 20 manhole assemblies to final grade EA 1 $ $ �. . � Adjust Qwest telecommunications l{�jp.� . �,,.�� ,� 21 manhole assemblies to final grade EA 5 $ � �� J � � � _ � Ad'ust Nextlink telecommunications 6Dp. ��.. 22 ....._. al grade EA 1 $ � vault assemblies to fin_ ......N ...IT........... �._._._ . .._.._ �__,_�......... . 23 Adjust Level 3 telecommunications EA 2 lo�D• r �?JCsp. � I manhole assemblies to final grade � $ �.�...... _ ....... ....... ........._..�..�.�............. � �.... 24 Adjust MFN telecommunications EA 6 I �� 9�� manhole assemblies to final grade $ $ � ' Adjust TCG telecommunications � � �p�jp .� � �� SO - 25 manhole assemblies to final grade EA 1 $ $ __m....._ww .......�.._ � ...... _ ..�� 26 Adjust MFS telecommunications EA 1 ��'� ��O manhole assemblies to final grade $ $ 27 � Adjust monitoring well assemblies to � EA 15 �� ,5�• � final grade � � I-C-3b Agreement No. 5551 28 Control District vault assemblies to final Adjust Los Angeles County Flood r Ea g 2ao�. 1�o m- � rade $ $ ,�� _ ._._ _ _ ��. �_ �.. Adjust Los Angeles County Flood l S� - 29 Control District valve assemblies to final EA 6 � �rade $ � �.....� __�.W. ....._ ... ..._ .. ._�... _. ..._....��_ Adjust Los Angeles County Flood � 2�.p 30 Control District manhole assemblies to EA 4 I �. final rade $ $ ��......�........� _. �� ... .. 31 Remove & Replace all survey LS 1 �id� 8�" monuments and ties. $ $ ...... .�. ...._. �_....._. Remove & Replace all traffic striping, ��. ��m� i 32 curb and pavement markings, and LS 1 , 50��0�_ �avement markers $ $ _ .��. _ �_........�.._�._ �..... M ....... � ........�.�_�- �,- 33 Remove &Replace all loop detectors and I EA 34 25�� J��' appurtenances. $ � � _..�.�..._ .... . ...... �._ 34 Remove and Replace damaged portion of LS 1 < <i�0-� �`►�D . � Dou las St catch basin. � $ _ g .. Remove and Replace damaged portion of m � �. ��C�O-� «�d�p � �_ 35 Douglas St cross gutter, including base LS 1 i and as halt work. $ $ TOTAL BID (#1 thru#35) _ $_mmmmm www�wm��D TOTAL BID WRITTEN IN WORDS: .� .�_. � ,..:�,�,�"��_.��..�'�?'.��.a��.�..'�,�!titiC�" ��.; _:. �� _.v.C�"�� . C`�u.c�, 2s�-o � : I-c-3c Agreement No. 5551 BIDDER'S INFORMATION Company Name: All American Asphalt BIDDER certifies that the following information is true and correct: Form of Legal Entity (i.e., individual, partnership, corporation, etc.) Corporation Bu or�o�ation, Stat�00 East S xthtSt eeite., California) � California � Address Corona, CA 92879 � ✓LL4� Telephone No. (951) 736-7600 ��mm Facsimile No. 951 736-7646 �._.....�._..��..��m �_ �... ,....�.. State Contractor's License No. and Class Ori mal Date Issued�01/19/71 � p' 01/31/2020 g� Ex iration Date The following are the names,titles, addresses, and phone numbers of all individuals, firm members,partners,joint venturers, and/or corporate officers having principal interest in this proposal: Mark Luer, President 400 East Sixth Street war J. Carlson, Vice President Corona CA 92879 _��.. _�� ... __ ...... � mmmmm� tary �mm (951) 736-7600 ic aemm ITITmarkas, Secre � The date of any voluntary or involuntary bankruptcy judgments against any principal having an interest in this proposal is as follows: N/A All current and prior DBA's, aliases, and/or fictitious business names for any principal having an interest in this proposal are as follows: N/A I-C-4 Agreement No. 5551 BIDDER'S INFORMATION(CONTINUED) Company Name: All American Asphalt Bidder shall list the name of the person who attended the mandatory pre-bid job walk: Name: Abraham Monteil Title: Foreman I-C-S Agreement No. 5551 IN WITNESS WHEREOF, BIDDER executes and submits this proposal with the names, titles, hands, and seals of all a forenamed principals this '�� day of MaY _�, 2018 . BIDDER All American A��halt �...�� .._ .� �� _...... � .�.. �.....�...� �rk Luer, F�rc�s��d�rot _ �..�. ��,...._� _� �.�..wm. � '� �"�M.� .. .�.__ _ .... ��W^�r�.m� ��n, �c� Pres��r��. W .... ....._��_�..m .. �_ ........� �� .......��. _..._��..� ...� ry � �w.��.��.. ,�_..�..�. �.. ...... _�......�. Michael �"ar��C� w„ Secretary �P��A��a�h� Subscribed and sworn i� l�t�� day of , 20_. NOTARY PUBLIC � I-C-6 Agreement No. 5551 CALIFORNIA JURAT GOV CODE � 8202 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California County of Riverside Subscribed and sworn to (or affirmed) before me on this 25th day of Mav , 2018 , Date Month By (1) Mark Luer Name of Signer Proved to me on the basis of satisfactory evidence be the person who appeared before me (.) (,) ��s,�,"� �u„Ytu;�,�Av�b,.�.,.'rerv��l'E �' Vir..;�r,z,��u»,wi.a;„�awn r",�..,�,us.,;., � � � w ' COURTNEY CHAPAS �and ��* � �a �u Notary Public -California �� Q� �""�� Riverside County �, � ��,"��' comm�ss�o� #21�2saa �r (2) E�ward J. Carlson u � �r � � fik��Comm �'�twrires Nov 20 2020y'; Name of Signer w , ��. ��;��,��Im�w�iw wvfw�'��'iµ�'"°�w�"'�'fi�v�'"'YdR d�v ,+'��,r�,��mG m'a�"'e�^�a, Proved to me on the basis of satisfactory evidence be the person who appeared before me.) Signature Pia�e Notary seai nbo�e Sag a re of P� �Public OPTIONAL Though the information below is not required by law, it may prove valuable to person relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Further Description of Any Attached Document . . Title or Type of Document:E�adcCer's&raf�a�ra��tr�ar� ToP or m�mb nere Top of lhumb here Document Date: 5-25-201$ Number of Pages: 3 Signer(s)Other Than Named Above: None Agreement No. 5551 CALIFORNIA JU1�J'�T GOV CODE � 8202 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California County of Riverside Subscribed and sworn to (or affirmed) before me on this 25th day of May ��2018 . Date Month By (1) Michael Farkas Name of Signer Proved to me on the basis of satisfactory evidence be the person who appeared before me (.) (,) �� ,� COURTNEY CHAPAS � � "� ' �� " Notary Public -Califomia z, (aCld � w�: �'�'^.�� r � � ��', Riverside County ? "��"�� ' Commission #2172984 ' �2� � "� M�Comm.1 7s��ires Nov 2tlY 2020�� ,»�7��r � �-7� r��w�f�n.a ��„ G ,,�, ,� � � . Name of Signer Proved to me on the basis of satisfactory evidence be the person who appeared before me.) Signature � Place Notary Seal Above �P��N k ?�.'Of N�h fy PUb�IC OPTIONAL Though the information below is not required by law, it may prove valuable to person relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Further Description of Any Attached Document . . Title or Type of Document:Badd��'r�f+�rra�atApr�� ,,,,,,, � ToP or mumb nere Top of thumb here Document Date: 5-25�2018 Number of Pages: 3 Signer(s)Other Than Named Above: NoneIT,_ . Bond No. 08597423 Agreement No.��e: 05/29/2018 PROPOSAL GUARANTEE BID BOND FY 17/18 PAVEMENT REHABILITATION PROJECT NO.: PW 18-18 KNOW ALL MEN BY THESE PRESENTS that, All American Asphalt ��rv�w µ , as BIDDER, and Fidelity and Deposit Company of Maryland �� , as SURETY, are held and firmly bound unto the City of El Segundo, in the penal sum of _Ten Percent of Total Amount Bid----- � DOLLARS ($10%0 of Bid��),Which is ten (10%) percent of the total amount bid by BIDDER to the City of El Segundo for the above stated project, for the payment of which sum, BIDDER and SURETY agree to be bound,jointly and severally, firmly by these presents. THE CONDITIONS OF THIS OBLIGATION ARE SUCH that, whereas BIDDER is about to submit a bid to the City of El Segundo for the above stated project, if said bid is rejected, or if said bid is accepted and a contract is awarded and entered into by BIDDER in the manner and time specified, then this obligation shall be null and void, otherwise it shall remain in full force and effect in favor of the City of El Segundo. IN WITNESS WHEREOF the parties hereto have set their names,titles,hands, and s�als�kiis 16th day of MaY _.�.....�..�_..�..�, 20..�..8.............• BIDDER* All American Asphalt 400 East Sixth Street, ��rc�e��, CA 92879- Phone (951)736-7600 �_ �� ...��._��___ ........� � � �� ' � L� � �" ��,�,� ,�- � � ��'�. °�" .�.��'��'v�'��"°" _---- SURETY* Fidelity and Deposit Company of Maryland 777 S. Figueroa Street, Suite 3900, Los Angeles, CA 90017-David Wei (213;270-060G .....� .�.p_w.WW_. � �� .�.�.__..._..._�,�. �_ � w �� M� �^°� �"��°� � " ' ____._....W W W ._._ Rebecca Haas-Bates,Attorney-in-Fact ��please See Attached"" Subscribed and sworn to this day of�wwwwwwwww m m�___� 20 . NOTARY PUBLIC *Provide BIDDER/SURETY name, title, address and telephone number and the name, title, address and telephone number for authorized representative. I-C-7 Agreement No. 5551 CALIFORNIA ALL-PURPOSE ACKNOWLEDGEMENT CIVML CODE § 7789 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the ' document tn which this certificate is attached.and not the truthfulness.accuracv_or validitv of that d�cument. State of California County of� I�i�C��^�� on May 25, 2018 before me, _ Courtney+�1��;r�.��„Notary Public a Date Here Insert name and Title of the Officer personauy appeared �m��,��al J. Carlson _ _. _._. .�.._..._ Name(s)of Signer(s) n__ _...........__ who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/a�e subscribed to the within instrument �'�'�"��"�°"�"°�`"��'��°�''�� "�� N�� and acknowled ed to me that he/ �u � � . COURTNEY CHAPAS �� 9 �►�`� executed the same in �� his/�eif authorized capacity(+es), and that by his/#er#qei� �� `,�� Notary Public California �W, Riverside County signature(s) on the instrument the person(s), or the entity upon behalf ��< +�� of which the person(s)acted, executed the instrument. � � �,ry�� Commission #2172984 �` �µn ��,u�M�C,omm��ires Nov 20 2020�� .��,��,,,�-��,� I certify under PENALTY OF PERJURY under the laws of the State of . California that the forgoing paragraph is true and correct. WITNESS my hand�r� �a�Fi�� 9 s��1. �, �i,,��y�ctarg°+� Place Notary Seal Above �i�n�u�of�dp6� ��dkrMdc OPTIONAL Though the information below is not required by law, it may prove valuable to person relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document Bid BonCl Document Date: Ma 16 2018 _� Number of Pages: _ 1 Signer(s)Other Than Named Above: I�C��Ne S gner's NameClaEd a d JSCarlson) _�. � ��'p� p•ws Name: � � �..._ ........�n ❑ Individual ❑ Indi�r� �tl X Corporate Officer—Title(s):_Vice President . a��e�r�ar�k� �i��r—Title(s):�,,, ❑ Partner❑ ❑ Limited ❑ General _ �I� ❑ Partner❑ ❑ Lirr�f�❑General ,I V�I :,,, � ❑Attorney in Fact • �• ❑Attorney in Fact "� ' � ❑Trustee Top of lhumb here ❑Trustee �' Top of thumb here ❑Other: ❑Other: � �� Signer is Representing: Signer is, p ng: �"��,� Re resenti ,�II Arr��r��c�r�r�.��r�l�� AIN Ft��r��p�� Fa��t . �m� Agreement No. 5551 CALIFORN�A ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE§ 1189 ��s��.:��~�,.�f��,��:��;��;�.��.��:�,��:��^«��.��^'�� .�. ';: � �" ,� A notary public or other officer completing this certificate verifies only the identity of the individual who signed the � document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of Califomia � County of Oran e � � before me, , ry Public On OS/16/2018 ��_ �� A.MacFarlane Nota, �� ^r Date Here Inser[�Name and Title of the Ofiicer personally appeared Rebecca Haas�Bates � Name�of Signer'(s,l�W�� who proved to me on the basis of satisfactory evidence to be the person(s} whose name(�}. is/a�e subscribed to the within instrument and ackno�l�dc��i t�a me that lae/she/ths� ��c;�t�� the same in 11is(her/'their authorized capacity�, and that by h��9�erl��a,r signature�.on the inst�ra�r��d�t the person(s�, or the entity upon behalf of which the person(s),ac#ed, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. ��w�k� A.MACFARLAN� g �4� � Si nature M� "°mm~• �^�`��, NotaryPublic-CaliFomia z �� ...�... __ r`�'95 ""� �� OrangeCounty � �� gy��`(�,/� Of n/Ota PUb1lC � �+�� ,�� Commission�2188592 � ry ��+��""' �^y Comm,Expires�1ar 27,2021 ��'� �� . Place Notary Sea!Above � OPTIONAL ' � Though this section is optional, comp/eting this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document yp .,, _�W _ Document Date: W /16/2018 Title or T e of Document: �Bid Bond � OS � � � Number of Pages: One 1 Signer(s) Other Than Named Above: All American Asphalt Capacity(ies) Claimed by Signer{s) Signer's Name: Rebecca Haas-Bates��ITIT Signer's Name:,____ ❑Corporate Officer — Title(s): � .. .._,.. �Corporate Officer — Title(s):. ❑ Partner — � Limited ❑General O Partner — ❑ Limited ❑General �� ❑ Individual �d'Attorney in Fact ❑ Individual O Attorney in Fact ❑Trustee ❑ Guardian or Conservator �Trustee ❑ Guardian or Conservator ❑Other: 6.��«,..�..��_. �.�...�....._��.�.__ __. ❑ Other. .....�._._ ._ � ......._ m�.._____ Signer Is Representing; �,,,,�„�,_,,, „�_,...,,,,, �� ,._�_, Signer Is Representing: _ �_�_ „ Fidelit,�and De�osrt C"'��w�r�a��of Mar l�and� � r ^ r r � .�,"�'�Ca.��,�'��".��+a,"�v�','�""",-'��+r� �'�u�:�r'�'��"�w"*'�r`��r��F.^�"�o�'aai"'��c��S 02014 National Notary Association • www.NationalNotary.org • 1-800-US NOTARY(1-800-876-6827) Item #5907 EXTRACT FROM BY-LAWS OF THE COMPANIES Agreement No. 5551 "Article V, Section 8,Attornevs-in-Fact. The Chief Executive Officer,the President,or any Executive Vice President or Vice President may, by written instrument under the attested corporate seal, appoint attorneys-in-fact with authority to execute bonds, policies, recognizances, stipulations, undertakings, or other like instruments on behalf of the Company, and may authorize any officer or any such attorney-in-fact to affix the corporate seal thereto;and may with or without cause modify of revoke any such appointment or authority at any time." CERTIFICATE I, the undersigned, Vice President of the ZURICH AMERICAN INSURANCE COMPANY, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the faregoing Power of Attorney is still in full force and effect on the date of this certificate;and I do further certify that Article V, Section 8,of the By-Laws of the Companies is still in force. This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the ZURICH AMERICAN INSURANCE COMPANY at a meeting duly called and held on the 15th day of December 1998. RESOLVED: "That the signature of the President or a Vice President and the attesting signature of a Secretary or an Assistant Secretary and the Seal of the Company may be affixed by facsimile on any Power of Attorney...Any such Power or any certificate thereof bearing such facsimile signature and seal shall be valid and binding on the Company." This Power of Attomey and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at a meeting duly called and held on the Sth day of May, 1994, and the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the l Oth day of May, 1990. RESOLVED: "That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically reproduced signature of any Vice-President, Secretary, or Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a certified copy of any power of attorney issued by the Company,shall be valid and binding upon the Company with the same force and effect as though manually affixed. �� °�� uq��taa subscribed my name and affixed the corporate seals of the said Companies, �� 'I'Ih��i'� WHEREOF f Nr��ve this "��dayof.µ_ C't �� , ��er�,��, ,.��q�t�"""�, �+t„rti w.,y.��.,, a'++�('�c�"i"'�W�* "�'' � �� .�..w. �°�'.M�� r ��. � s�,� �� 88AL � ' �` ��», ��, �r,� �+�.� '��..,.� •.,�� .... �„ ar� '�d,�,�w��^ � MichaelITBond,Vice President TO REPORT A CLAIM WITH REGARD TO A SURETY BOND,PLEASE SUBMIT ALL REQUIRED INFORMATION TO: Zurich American Insurance Co. Attn: Surety Claims 1299 Zurich Way Schaumburg,IL 60196-1056 ZURICH AMERICAN INSURANCE COMPANY Agreement No. 5551 COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS:That the ZURICH AMERICAN INSURANCE CONIP'ANY, a corporation of the State of New York, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, a corporation of the State of Maryland, and the PTDELITY AND DEPOSTT COMPANY OF MARYLAND a corporation of the State of Maryland (herein collectively called the "Companies"), by DAVID MCVICKER,Vice President,in pursuance of authority granted by Article V,Section 8,of the By-Laws of said Companies,which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, do hereby nominate, constitute, and appoint William SYRHIN, Rebecca HAAS-BATES, Sergio D. BECHARA and Richard ADAIR, all of Irvine, California, EACH its true and lawful agent and Attomey-in-Fact,to make,execute,seal and deliver,for,and on its behalf as surety,and as its act and deed: any and all bonds and undertakings,and the execution of such bonds or undertakings in pursuance of these presents,shall be as binding upon said Companies, as fully and amply,to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the ZURICH AMERICAN INSUFtANCE COMPANY at its o�ce in New York,New Yark., the regularly elected officers of the COLONIAL AMERICAN CASUALTY AND SLTRETY COMPANY at its o�ce in Owings Mills,Maryland.,and the regularly elected officers of the FTDELTTY AND DEPOSIT COMPANY OF Mt1RYLAND at its office in Owings Mills, Maryland.,in their own proper persons. The said Vice President does hereby certify that the extract set forth on the reverse side hereof is a true copy of Article V, Section 8,of the By-Laws of said Companies,and is now in force. IN WIT'NESS WHEREOF, the said Vice-President has hereunto subscribed his/her names and affixed the Corporate Seals of the said ZURICH AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND,this l Oth day of July,A.D.2017. ATTEST: ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND �q tr�[sy��r� , ��,��i�qj"*+'� �� ^ ��"*�. � ;?�4+� r.°a�a4r�f: SEAL � � "� "" ; r��—,_�°��:. «..� � �+� � �� +u� ��.�., ��,� ,..�,� �§,"�„ ..�� t � � n � p � �� , ,�� p� �,�„ �� '.. � �id`w"brr°�o�m� �r�rr��.�,�'�.._ ..- ��,.�,,,��p�..re,�' � �n. q �1".e" � �„,� �. � Assistant Secretary Vice President T Dawn E.Brown David McVicker State of Maryland County of Baltimore On this lOth day of July, A.D. 2017, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, DAVID MCVICKER,Vice President,and DAWN E.BROWN,Assistant Secretary, of the Companies,to me personally known to be the individuals and officers described in and who executed the preceding instrument, and acknowledged the execution of same, and being by me duly sworn, deposeth and saith,that he/she is the said officer of the Company aforesaid,and that the seals affixed to the preceding instrument aze the Corporate Seals of said Companies,and that the said Corporate Seals and the signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporations. IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed my Official Seal the day and year first above written. ``N��tl"�'"�*""'�. i w q,.tN;r`' �-�p ,�) „ '; r � ad; (/t p- ._) / "'� Y ; `�,..r(I�"X'`.,r;''✓t..CAlr�f,IZ...�....+i-� F, f.A.n.!'V�,a'� 'J M F„YI�"4 �^4 . `A+'r�ar��qaa%Xww°„ Constance A.Dunn,Notary Public My Commission Expires:July 9,2019 POA-F 012-0033D Agreement No. 5551 ZURICH AMEffiCAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS:That the ZURICH AMERICAN INSURANCE COMF'ANY,a corporation of the State of New York,the COLONIAL AMERICAN CASUALTY AND SiJRETY COMPANY, a corporation of the State of Maryland, and the FIDELITY AND DEPOSIT COMPANY OP MARYLANU a corporation of the State of Maryland (herein collectively called the "Companies"), by DAVID MCVICKER,Vice President,in pursuance of authority granted by Article V, Section 8,of the By-Laws of said Companies,which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, do hereby nominate, constitute, and appoint William SYRKIN, Rebecca HAAS-BATES, Sergio D. BECHARA and Richard ADAIR, all of Irvine, California, EACH its true and lawful agent and Attomey-in-Fact,to make,execute, seal and deliver,for,and on its behalf as surety,and as its act and deed:any and all bonds and undertakings,and the execution of such bonds or undertakings in pursuance of these presents,shall be as binding upon said Companies, as fully and amply,to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the ZURICH AMERICAN INSLJRANCE COMPANY at its office in New York,New York.,the regularly elected officers of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings Mills,Maryland.,and the regularly elected officers of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at its office in Owings Mills, Maryland.,in their own proper persons. The said Vice President does hereby certify that the extract set forth on the reverse side hereof is a true copy of Article V, Section 8,of the$y-Laws of said Companies,and is now in force. IN WI"I'NESS WHEREOF, the said Vice-President has hereunto subscribed his/her names and affixed the Corporate Seals of the said ZURICH AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND,this lOth day of July,A.D.2017. ATTEST: ZURICH AMERICAN INSURANCE CONIPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND , , � �,,�,�u�r�� .��w�i�s.� � ^� � :�*w.,��'� .a�+��ww,sr�T��'� w" � ,� �^,y e�m x BBAL � ;� � �» : ��t — z�� ,,,�, �`� r� .�.� �� p�,�,� �'cc,� „ ,,,,"",��,�k� A+k�: a. , �*',_ry. a� �Mi�XX��B{AW'�''w ��, �� u � �� m��n,�� m��,��. _ �`��*r� �� ..__.......��....._ .. _ ...�. Assistant Secretary Vice President Dawn E.Brown David McVicker State of Maryland County of Baltimore On this lOth day of July, A.D. 2017, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, DAVID MCVICKER,Vice President,and DAWN E.BROWN,Assistant Secretary, of the Companies,to me personally known to be the individuals and officers described in and who executed the preceding instrument, and acknowledged the execution of same, and being by me duly swom, deposeth and saith,that he/she is the said officer of the Company aforesaid,and that the seals affixed to the preceding instrument are the Corporate Seals of said Companies,and that the said Corporate Seals and the signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporations. IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed my Official Seal the day and yeaz first above written. �„�aa,rur�a�a� 4,o yM,•.ro:.t.,��,i. d yatMY' '�"° : '� :;'M Y�,�„,�� ,.a,. Y r. � f Y�� . / , �,B� �.A'.� /�..A.x!r�..r�....� x "�gJeY.^ ,.�w�;;^ ,..4J"7^,=.'!l4�..mv'r a_G... �yf'1��I11AI�y`4r��'M Constance A.Dunn,Notary Public My Commission Expires:July 9,2019 POA-F 012-0033D Agreement No. 5551 CONTRACTOR'S LICENSE DECLARATION (Business and Professions Code Section 7028.15) 1. BIDDER'S Contractor's License Number is: 267073 Class No.: Class A, C-12 2. The expiration date of BIDDER'S Contractor License is: 01/31/2020 3. BIDDER acknowledges that Section 7028.15(e) of the Business and Professions Code provides as follows: "A licensed contractor shall not submit a bid to a public agency unless his or her contractor's license number appears clearly on the bid,the license expiration date is stated, and the bid contains a statement that representations herein are made under penalty of perjury. Any bid not containing this information, or a bid containing information which is subsequently proven false, shall be considered non-responsive and shall be rejected by the public agency." The undersigned declares, under penalty of perjury, that the representations made by the undersigned in this bid proposal are true and correct. Executed on ��"� �_, 20�$, at Corona, CA (insert City and State where Declarati�n srg�led). ��.�� ,. . .--.�^....�� .. .....�.. ��t��ttzre Edward J. Carlson .�.�.�.��.�............ �...ee.................._.........._��,� T ped Name Vice President ��.......�.................��...........................�.. Title All American Asphalt Company Name � I-C-8 Agreement No. 5551 NON-COLLUSION DECLARATION TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID (pursuant to Cal. Pub. Contract Code § 7106) The undersigned declares: halt the party I am the ice President � o f All American Asp � making the foregoing bid. The bid is not made in the interest of, or on behalf of, any undisclosed person, partnership, company, association, organization, or corporation. The bid is genuine and not collusive or sham. The bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid. The bidder has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or to refrain from bidding. The bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price of the bidder or any other bidder, or to fix any overhead,profit, or cost element of the bid price, or of that of any other bidder. All statements contained in the bid are true. The bidder has not,directly or indirectly, submitted his or her bid price or any breakdown thereof,or the contents thereof,or divulged information or data relative thereto,to any corporation,partnership, company, association,organization, bid depository,or to any member or agent thereof, to effectuate a collusive or sham bid, and has not paid, and will not pay, any person or entity for such purpose. Any person executing this declaration on behalf of a bidder that is a corporation, partnership, joint venture,limited liability company,limited liability partnership,or any other entity,hereby represents that he or she has full power to execute, and does execute,this declaration on behalf of the bidder. I declare under penalty of perjury under the laws of the State of California that the foregoing ' �� [date] at is true an correct an t at t is declaration is executed on 0��,��"`�� m _ , �.....w��.��Corona��.�.��.�.�.....��rtY�� A [state].�� Dated this LL��'""�day of MaY.�..�.�.��....�m_„ 20 �8.. Edward J. Carlson .._��...__�..�..__.�.....��_........_..m...eee.... .m�� .. _.......... ............�... Name Vice President ��__�� .... .�. ...._�..� ........._.......�w�.u. Title ��a�.,��°��,� ....�._ .�.� _.� .... .... ..�.�__ 51�1'�� I�"L" �� I-C-9 Agreement No. 5551 CALIFORNIA ALL-PURPOSE ACKNOWLEDGEMENT CIVML CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached.and not the truthfulness_accuracv_or validitv of that document. State of California county of Riverside on Ma�,25, 2018 betore me,_______ITITITCourtne�C��:�,Notary Public ,� Date � Here Insert name and Title of the Officer personally appeared Edward 7. Carlsonmm __wwwwwww ITITITITIT_ Name(s)of Signer(s) _.......... y who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/�eyF executed the same in ��`" �� ` ��'�`��' COURTNEY CHAPAS �°" his/#er-�#ei� authorized capacity(+es), and that by his/6er/�heir ,� �;�� y �,e ;�, Notary Public -California �� signature(s) on the instrument the person(s), or the entity upon behalf r�° k�� ' ° R�vers�de County �: of which the person(s)acted, executed the instrument. �' `°�-a�� Commission # 2172934 � I certi under PENALTY OF PERJURY under the laws of the State of �� r��.�� Me+Comm ��l�!��° �Nov202020 `�� fY � �� ,„„u,� z��w�„�, _��a� ��M California that the forgoing paragraph is true and correct. WITNESS my hand�r�d�sff��a�ak��9. Signature Place Notary Seal Above Si n ure of Not Pu ic OPTIONAL Though the information below is not required by law, it may prove valuable to person relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document N�n-Collusion Decl�r�ti�n. Document Date: MaV 25, 2018 Number of Pages: 1 __ _ Signer(s)Other Than Named Above: Nar�e Capacity(+es)Claimed by Signer(s) Signer's Name: �dward J, Carlson Signer's Name:_,,,_ ❑ Individual o Individual X Corporate Officer—Title(s): Vice President _„�_,_„ ❑ Corporate Officer—Title(s): ❑ Partner❑ ❑ Limited❑General ❑ Partner❑ ❑ Limited o General . ..- � ❑Attorney in Fact � • � �� ❑Attorney in Fact ' ❑Trustee Top of thumb here ❑Trustee Top of thumb here ❑ Other: ❑ Other: Signer is Representing: Signer is Representing;. �I��G7"f�l"IG�CI�r��6�1�....._....� N"hll.1��7"N�p"NC�311�w��'�N� ........_ Agreement No. 5551 WORKER'S COMPENSATION CERTIFICATION Section 1861 OF THE LABOR CODE (Workers' Compensation) Pursuant to Section 1861 of the Labor Code,the BIDDER, in submitting his/her PROPOSAL, shall sign the following certification: "I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers' compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract." � � �� Signature of Bidder; ��'"�M��'W��°� � Title: Edward J. Carlson, Vice President Business Name: All American Asphalt 400 East Sixth Street Business Address: Corona, CA 92879 Telephone Number: ( 951 ) 736-7600 � � Dated this��,,;;� _day of MaY , Zp 18 I-C-10 Agreement No. 5551 BIDDER'S CERTIFICATION OF SUBCONTRACTORS FY 17/18 PAVEMENT REHABILITATION PROJECT NO.: PW 18-18 Company Name: All American Asphalt As detailed in Section 2-3.1 (Page II-B-3) of the General Provisions, BIDDER certifies that it has listed below all subcontractors who will ��•1``u�°�r� �ca�•I� in excess of one-half of one percent (0.5%) of the total bid price or certifies that�a��,� ��,��+>�� s fully qualified to perform and will perform that portion of the work itself. Subcontractor's� Description of Contractor Portion of License No. & Work Name of DIR Subcontracted Estimated Subcontractor Address Registration No. $Amount (Number and Street) � (CSLB #) ._ .. . n._ (City, Zip Code) (DIR#) �. � - �.�.�n �._ � E ec�� _ lq'.� E �.c�te.�� lQl,`�� ,�.........�_�.�.._ ....._�� _ .��..� ......� 5 �560- t�/C,w� �-?r qC28cQ lnb000� �.. .c�� 2 �.��.�"�. .�� .�� .W.�.�.. �._......�.. � w.�..�........ . ,� � .�.�� .: ��_ s�- 1��c�.. �..��...�+.�� . l00000 �.. �1��n� ��or.�. � ..._��«�..M. �:..::�. �� C.� � t`�� _...��.. � .. _ ..__ .w..�....... i (Make copies of this r�r��,if additional space is needed) M mo � ��a�'�� MaY ��2018 _��...��.ww� �ai�„r��r�B d�_� .........�. _....... ._..�ay.._ �..�.__.�.. �' r' , der Date Edward J. Carlson, Vice President I-C-11 Agreement No. 5551 REFERENCES Company Name: All American Asphalt The following are the names, addresses, and telephone numbers for public agencies for which BIDDER has performed similar work as the prime contractor or major subcontractor within the past five (5)years: 1. Project Title: Base Line Rd. Location: Rancho Cucamonga Cityr of Rancho Cucamorr,�� 10500 Civic Center Drive; Rancho Cucarn�� , CA 91730 Name and address of owner Romeo David (909)477-2740 Name and current telephone number of person familiar with project Type of Work: Pavement Rehab Contract amount: $ 30,470 07/2017 n.��...��..�..��.�..��... Date completed: _..�..��...._ Amount of work done by my/our firm under contract $ Minimum of 50% Y y � No Di our firm have an financial interest in Pro'ect? 2, Project Title: Margarita Road Pavement Location: Temecula City of Temecula 41000 Main Street; Temecula, CA 92590 Name and address of owner William Becerra (951) 694-6444 Name and current telephone number of person familiar with project Type of Work: Road Pavement Contract amount: $ , 7� �.,....w �� ,m,m . mm�y Date completed: � 11/2017 � Amount of work done by my/our firm under contract $ Minimum of 50% Did your firm have any financial interest in Project? No I-G 12 Agreement No. 5551 3. Project Title: Navajo Road Pavement Location: Apple Valley Town of Apple Valley 14955 Dale Evans Street; Apple Valley, CA 92307 Name and address of owner Rich Berger (760) 240-6444 Name and current telephone number of person familiar with project Type of Work: Road Rehabilitation Contract amount: $ 849,182 p 11/2017 ��.._� - _mmmm Date com leted: Amount of work done by my/our firm under contract$ Minimumof 50% Did your firm have any financial interest in Project?_ No 4, Project Title: Water Wharehouse Location: Victorville City of Victorville 14343 Civic Dr.; Victorville, CA 92392 Name and address of owner Carlos Seanez (760) 955-5162 Name and current telephone number of person familiar with project: Type of Work: Paving .... 251,008 ......� .� p 06/2017 ontract amount: $� Date com leted: Amount of work done by my/our firm under contract $ Minimum of 50% Did your firm have any financial interest in Project? No 5. Project Title: Citywide Slurry Seal Location: Santee City of Santee 10601 Magnolia Ave Buildin 4 Santee, CA 92071 Name and address of owner Toby M. Espinola (619) 258-4100 Name and current telephone number of person familiar with project: I-G 13 Agreement No. 5551 Type of Work: Slurry Seal Contract amount: $ �258,061.90� Date completed: 10/2017 Amount of work done by my/our firm under contract$ Minimum of 50% Did your firm have any financial interest in Project?wy� No Bidder may attach additional reference pages if necessary. The following are the names, addresses, and telephone numbers for all brokers and sureties from whom BIDDER intends to procure insurance bonds: m..,� Y �mpany of Maryland Agent: Millinimum Corporate Solutions roker: Fidelit abd deposit Co� �� 777 S. �pc�ueroa St#3900 5530 Trabuco Rd An��les, CA 90017 Irvine, CA 92620 �.....�.__...�....�...��°S........�......._�__......�......ti�...._..��_,_�.�.. ) -0600 ('��) 857-4500 13 270 I-G 14 Agreement No. 5551 BIDDER'S STATEMENT OF PAST CONTRACT DISQUALIFICATIONS FY 17/18 PAVEMENT REHABILITATION PROJECT NO.: PW 18-18 Company Name: All American Asphalt Please state all instances of being disqualified, removed, or otherwise prevented from bidding on, or completing, a federal, state, or local government project due to a violation of a law or safety regulation. 1„ Have you ever been disqualified from any government contract? Yes ❑ No L� � 2. If yes, explain the circumstances: 3� Are you registered in accordance with Labor Code § 1725.5 [Note: failure to register requires the City to reject your bid as nonresponsive]? Yes ❑ No L� ��e��,�. �� __W..� __.� ... ��.�. .._ .....�_....,. B�c�r�:�� s �ai��7��t��r� All American Asphalt ..... �� ...__w�.�.__mm�_..... Name (Please Print) I-G 15 Agreement No. 5551 INSURANCE REQUIREMENTS [MUST BE SUBMITTED "h�"� �[��1�� ➢�l��;�f (�"C"��OPOSAL] FY 17/18 PAVEME�"1'"�f F��:�i�,d"�"�"1��"1ON PROJECT NO.: PW 18-18 Company Name:_ All American Asphalt To be awarded this contract, the successful bidder must procure and maintain the following types of insurance with coverage limits complying, at a mi�nimum, with the limits set forth below: Tvne of Insurance Limits Commercial general liability: $2,000,000 Business automobile liability: $1,000,000 Workers compensation: Statutory requirement Commercial general liability insurance must meet or exceed the requirements of ISO-CGL Form No. CG 00 O1 11 85 or 88. The amount of insurance set forth above must be a combined single limit per occurrence for bodily injury, ��•��a�°�� injury, and property damage for the policy coverage. Liability policies must be endorsed to t��.r��;City, its officials, and employees as"additional insureds"under said insurance coverage and to state that such insurance will be deemed "primary"such that any other insurance that may be carried by the City will be excess thereto. Such endorsement must be reflected on ISO Form No. CG 20 10 11 85 or 88, or equivalent. Such insurance must be on an "occurrence," not a"claims made," basis and will not be cancelable or subject to reduction except upon thirty (30) days prior written notice to the City. Insurer will agree in writing to waive all rights of subrogation against the City, its officers, officials, employees and volunteers for losses arising from work performed by Contractor for the City. Automobile coverage must be written on ISO Business Auto Coverage Form CA 00 O1 06 92,including symbol 1 (Any Auto). The Consultant must furnish to the City duly authenticated Certificates of Insurance evidencing maintenance of the insurance required under this Agreement,endorsements as required herein,and such other evidence of insurance ar copies of policies as may be reasonably required by the City from time trr �i�rr�•. I��r��e,� ��t��w� I�� pV��c.�� r�'r�h G�d��riit�:�l aN�s��•�a•:� with��Y�°�� A.M. Best Company Rating ��r��l�ett'l��t le.�a��x��,�i��i�ug�f�`�:"1�"��L�� 'ka�`i�.��'�'��'��e��rust re�le��1��t�t"�he insurer will provide thirty ��t�y' t't�:o�tw�.�, �a�C«��ru�:�ll��aa ��"�o��a��,�, "'i�"�e Consultant will require its insurer to modify such certificates to delete any exculpatory wording stating that failure of the insurer to mail written notice of cancellation imposes no obligation, and to delete the word "endeavor" with regard to any notice provisions. The City requires California Worker's Compensation Coverage with the associated Waiver. Out-of- state coverage will not be accepted in lieu of the California coverage, because the work is being performed in the State of California. By signing this form, the bidder certifies that it has read, understands, and will comply with these insurance requirements if it is selected as the City's consultant. Failure to provide this insuranr.e will render the bidder's proposal "nonresponsive." ' �� .. MaY . .�,,, � 2018 ...�......_�. .,�.� ��'��'�.�� ._.... ��_�m� _ Date B��;r"s �"�r��tr��;...�..��w �.._._ Edward J. Carlson, Vice Pres�dent I-G 16 Agreement No. 5551 END PROPOSAL SECTION I-C-17 Agreement No. 5551 ��"�`,. f "';,: � � ,�� .d�*..�....�1� „. , � ,� � �� i�� V � r � �r �' I w..��^� ,�"� Ilw�,�"� �� .��✓ ,�F� ,� �� m��'��"�VI'��'I'��1�:��us,��,. � ;.:��" �,��w, �u�,. ,�,�� ,d�� „��u� .��tl '�� INSf .� May 18, 2018 ADDENDUM NO. 1 to THE CONTRACT DOCUMENTS, SPECIFICATIONS, AND PLANS for FY 17/18 PAVEMENT REHABILITATION PROJECT NO. PW 18-18 ATTENTION BIDDERS: The following additions, modifications, and clarifications to the specifications shall be included in, and become a part of, any contract which may be executed for the above project in the City of El Segundo: 1. The bid due date and time IS STILL Tuesday, May 29,2018, at 11:00 am. 2. The attached additional specifications and plans have been added to the bid documents. These include information relating to the traffic signal loops. Contractor will be required to adhere to these when reinstalling the loops. Note that the front loops will be required to be "d-type" loops, or in other words, bicycle/motorcycle detectable loops. Note that the existing advanced loops on Douglas St.,just north of Rosecrans Ave. are abandoned, and can be removed without needing to be replaced. The Bid Schedule has been replaced with the attached schedule, to update the number of loops to be installed to be 34 (bid item number 33). Contractor shall use this schedule in his proposal. No other changes to the bid table or the plans/specs have been made. As evidence that the BIDDER has read this Addendum,the BIDDER must acknowledge same in the space provided below and submit this Addendum with the Bid Proposal. Failure to r;ovidP such acknowledgement shall render the bid as non-responsive and subject to rejection. Print Company Name: All American Asphalt Print Name: Edward J. Carlson, Vice President � � ..._� .._��.�. Signature� m �� w�� Date: May� 018 ..............__.�..... �...m��"�=.. ��_. � __ � __. Page 1 of 1 350 Main Street,El Segundo, CA 90245 (310)524-2316 CAL�FORNIA ALL-PURPOSE ACKNOWLEDGEMENT �'�e��t�. 5551 1189 �n��t�Na'Y��1�4�s�r�N�M�dl��r°t��l'�"ia.z;��r��l��i��k��u��iE`��;��ta ve�rrtA��ar��Y��1��tw��°��"��i��i��wcii��i�i�A�x�w�i��w��a��#t�tr: ��uw��t�a��a�i�it�1��is�:��a��r��a�i��;��t��9��.��r��r��t t�w�4�e�tl7fzal�t��,�.w^a��a��'z��w.t�r vrk�i�dp¢�r��"t6��at a�s��:a.¢rrrn.s�t, State of California County of Ri^��i��,�,�..,,,,,�. On 06/29/20�18 before me �� r��1��1��°r� t��C��° I'�r�i1i�, IT�..�, � Here Insert name and Tille oF lhe Officer personally appeared �'y��'�� ^�� N!�amv�@�g�r��»i�p�r��r�� Yti1�14� I�1'�'U�C� ��Y �G"E"I� �DN� �h� �G�:�tlS G1f S��I��c��:'�C�X� EvIIf�G�IC� 1{� �� 1G �3�i"��71"q��'+"� hA��1C3w"sC' f&�1�11��y5� 4'S��31-�� SR.Y�DSGI'I�'dG� �Ck �� 1Wlt�l�ll 1�"'Na�l"L8d11�1'V� a�~�� ;��¢r��aa+�l��y�d� ha rn� t�r�t ka�:l��e,��r �x��tiat��l th� ��rra� ir� riis��a�l�6��r �r��c�ri��d c��p��i4y�i��, ��d tB7�t b�± r��P�k��'ar tw�t� REBECCA ANGELA PARRA ��"�� hl�'� Iq�YS�9"UI"I��'�tl�'��Y�'�G�"'�tl(�r"�, Clf��1��l��I'��"LI�CdI��OG��I�' NotaryPublic-California ��''��'��"�� "�,p� Riverside County ��,;1 Commission#2192458 I certify under F"��IAN�OF PERJURY under the laws of the State of My Comm.Expires May 17,zozi California that��f�a�'�cair�g paragraph is true and correct. WITNESS my hand��i��seal. �� ° � � .,. ' �"` � �� N�I'��fl�o�'� �� Place Notary Seal Above ��n��°�� N� OPTIONAL Though the information below is not required by law, it may prove valuable to person relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document ��-�� •••• Document Date: ��f��18 Number of Pages. ��1"�� ., Signer(s)Other Than Named Above: ��fi �f Ed�� ur�dC� Capacity(ies)Claimed by Signer(s) Signer's Name: Michael Farkas Signer's Name: ❑ Individual ❑ Individual X Corporate Officer—Title(s): Secretary ❑Corporate Officer—Title(s): ❑Partner❑ ❑ Limited o General .il�� 1 ❑ Partner❑ ❑ Limited a General _ :.. ❑Attorney in Fact • �' � ❑Attorney in Fact Top of thumb here Top of lhumb here ❑Trustee ❑Trustee ❑Other: ❑Other: Signer is Representing: Signer is Representing: A,II 6��w��i+��f�� h��'� � �.. _ .� Agreement No. 5551 . , . � �. � � , I ��1�� F � . PROJECT NO.: PiJV 18-18 P Llc wo s �rPART NT ENGINEE NG DIVISION 350 MAIN STREET EL SEC�UNDO, CA 90245 310m5�4-2300 &�� 7'!��F��N��.a��.�.c,��c��r��;0��c:a��/��,c��y ��,��w�� u� .. :!`f��r�w��.u��.��;1��fi�l�a��:�J.�n��.�� u�� ,��.�,� �"c��.�� .. A AT Y � I 'I'II�1 '�iT AY, AY 15, 201 AT 10 A IN WEST CONFE NCE ROOM CITY HALL 350 ST ET EL SEG O, CA 90245 BIDS �iTE TUES�AY, MAY 29, 2018 AT 11:00 AM � Agreement No. 5551 BIDS WILL BE RECEIVED UP TO THE HOUR OF 11:00 A.M. TUESDAY, MAY 29, 2018 IN THE OFFICE UF "I'H� C1TY LLElZK CITY HALL 350 MAIN STREET EL SEGUNDO, CALIFORNIA 90245 AT WHICH TIME THEY WILL BE PUBLICLY OPENED 2 Agreement No. 5551 SPECIAL INSTRUCTIONS TO CONTRACTORS Contractors are required to review section 7-3 of the STANDARD SPECIFICATIONS, pages II-B-24 thru II-B-27 "LIABILITY INSURANCE". ONLY CONTRACTORS ABLE TO OBTAIN AND FURNISH THE REQUIRED COVERAGE AND ENDORSEMENT "ISO" FORMS SHOULD CONSIDER SUBMITTING A BID PACKAGE. The Contractor will be required to apply and obtain an Encroachment Permit from the City Public Works Department as well as any applicable Building/Safety Permit from the City Planning and Building Safety Department. The permits will be issued on a"no-fee"basis. The Contractor shall be responsible for calling the Building Safety Division for inspections. All noted deficiencies shall be corrected by the contractor.The project will not be accepted as complete until the contractor obtains a final sign-off from the Department of Planning and Building Safety. 3 Agreement No. 5551 TABLE OF CONTENTS SECTION I—LEGAL PAGE A. NOTICE INVITING SEALED BIDS I-A-1 TO A-3 B. BIDDING INSTRUCTIONS I-B-1 TO B-8 1. DEFINITION I-B-1 2. BIDDER'S REPRESENTATIONS I-B-1 3. BIDDING DOCUMENTS I-B-2 4. 1NTERPRETATION OR CORRECTION OF BIDDING DOCUMENTS I-B-2 5. PRODUCT SUBSTITUTIONS I-B-3 6. SUBCONTRACTORS I-B-3 7. ADDENDA I-B-3 8. PRE-BID CONFERENCE I-B-3 9. FORM AND STYLE OF BIDS I-B-4 10. BID SECURITY I-B-S 11. MODIFICATION OR WITHDRAWAL OF BID I-B-6 12. OPENING OF BIDS I-B-6 13. REJECTION OF BIDS I-B-6 14. AWARD I-B'� C. PROPOSAL � � �� I-C-1 TO C-17 1. PROPOSAL, FIRST PAGE I-C-1 2. BID SCHEDULES I-C-3 a. BASE BID b. ALTERNATIVE BID 3. BIDDER'S INFORMATION I-C-4 4. BIDDER AND NOTARIAL ACKNOWLEDGEMENT I-C-6 5. PROPOSAL GUARANTEE BID BOND I-C-7 6. CONTRACTOR'S LICENSE DECLARATION I-C-8 7. NON-COLLUSION DECLARATION I-C-9 8. WORKER'S COMPENSATION CERTIFICATION I-C-10 9. DESIGNATION OF SUBCONTRACTORS I-C-11 10. REFERENCES I-C-12 11. BIDDER'S STATEMENT OF PAST DISQUALIFICATIONS I-C-15 11. INSURANCE REQUIREMENTS I-C-16 D. CITY OF EL SEGUNDO PUBLIC WORKS CONTRACT I-D-1 TO D-5 E. FAITHFUL PERFORMANCE BOND I-E-1 TO E-3 F. MATERIAL AND LABOR BOND I-F-1 TO F-3 � Agreement No. 5551 SECTION II—GENERAL REQUIREMENTS PAGE A. GENERAL SPECIFICATIONS II-A-1 TO A-2 1. REGISTRATION OF CONTRACTORS II-A-1 2. INSURANCE AND CITY BUSINESS LICENSE II-A-1 3. EMERGENCY INFORMATION II-A-1 4. FURNISHING OF WATER II-A-1 5. CALIFORNIA—OCCUPATIONAL SAFETY AND HEALTH ADMINISTRATION II-A-1 6. SOUND CONTROL II-A-2 7. AIR POLLUTION CONTROL II-A-2 8. WORKER iINIFORMS II-A-2 B. GENERAL PROVISIONS II-B-1 TO B-36 0-0 STANDARD SPECIFICATIONS II-B-1 0-1 GENERAL II-B-1 0-2 NUMBERING OF SECTIONS II-B-1 1-2 TERMS AND DEFINITIONS II-B-1 1-3 ABBREVIATIONS II-B-2 2-1 AWARD AND EXECUTION OF THE CONTRACT II-B-2 2-1.1 ACCESS TO PROJECT SITE , II-B-2 2-1.2 OWNERSHIP AND USE OF CONTRACT II-B-3 DOCUlV1ENTS 2-3 SUBCONTRACTS II-B-3 2-3.1 GENERAL II-B-3 2-3.2 ADDITIONAL RESPONSIBILITY II-B-4 2-4 CONTRACT BONDS II-B-4 2-5 PLANS AND SPECIFICATIONS II-B-4 2-5.1 GENERAL II-B-4 2-5.2 PRECEDENCE OF CONTRACT DOCUMENTS II-B-S 2-5.4 ACCURACY OF PLANS AND SPECIFICATIONS II-B-S 2-8 RIGHT-OF-WAY II-B-6 2-8.1 ADDITIONAL WORK AREAS AND FACILITIES II-B-6 2-9 SURVEYING II-B-6 2-9.1 CONSTRUCTION SURVEYING II-B-6 2-9.2 MEASUREMENT AND PAYMENT II-B-7 3-3 EXTRA WORK II-B-7 3-3.2 PAYMENT II-B-7 3-3.2.2 BASIS FOR ESTABLISHING COSTS II-B-7 3-3.2.2.3 TOOLS AND EQUIPMENT RENTAL II-B-7 3-3.2.3 MARK UP II-B-7 ii Agreement No. 5551 SECTION II—GENERAL REQUIREMENTS (Continued) PAGE 3-3.3 DAILY REPORTS II-B-8 3-4 CHANGED CONDITIONS II-B-8 3-5 DISPUTED WORK II-B-9 4-1 MATERIALS AND WORKMANSHIP II-B-9 4-1.3 INSPECTION REQUIREMENTS II-B-9 4-1.6 TRADE NAMES OR EQUALS II-B-10 5-2 PROTECTION II-B-11 5-2.1 INCORRECT LOCATION OF UTILITIES II-B-11 5-4 RELOCATION - II-B-11 5-4.1 RESPONSIBILITY OF UTILITY REMOVAL II-B-11 QR RELOCATION 5-5 DELAYS II-B-11 5-5.1 CALCULATING IDLE TIME II-B-11 6-1 CONSTRUCTION SCHEDULE AND II-B-12 COMMENCEMENT OF WORK 6-1.1 CONTRACT SCHEDULE II-B-12 6-12 CONTENT OF CONTRACT SCHEDULE II-B-12 6-1.3 EFFECT OF CONTRACT SCHEDULE II-B-12 6-1.4 COMMENCEMENT OF CONTRACT TIME II-B-13 6-4 TERMINATION OF THE CONTRACT FOR DEFAUL II-B-14 6-4.1 GENERA_L II-B-14 6-4.2 TERMINATION OF CONTRACTOR'S II-B-14 CONTROL OVER THE WORK 6-4.3 SURETY'S ASSUMPTION OF CONTROL II-B-14 6-6 DELAYS AND EXTENSIONS OF TIME II-B-15 6-6.1 GENERAL II-B-15 6-6.2 EXTENSION OF TIME II-B-16 6-63 PAYMENT FOR DELAYS TO CONTRACTOR II-B-16 6-6.4 WRITTEN NOTICE AND REPORT II-B-16 6-7 TIME OF COMPLETION II-B-16 6-7.2 WORK DAYS AND WORKING HOURS II-B-16 6-7.4 NIGHT WORK II-B-17 6-7.5 WEEKEND AND HOLIDAY WORK II-B-17 6-8 COMPLETION, ACCEPTANCE,AND WARRANTY II-B-17 6-8.1 GENERAL GUARANTY II-B-18 6-9 LIQUIDATED DAMAGES II-B-18 6-11 DISPUTES AND CLAIMS; PROCEDURE II-B-18 6-ll.1 GENERAL II-B-18 6-11.2 FORM II-B-19 iii Agreement No. 5551 SECTION II—GENERAL REQUIREMENTS (Continued) PAGE 6-11.3 CLAIMS SUBMITTED TO ENGINEER II-B-21 6-11.4 CLAIMS IS PREREQUISITE TO OTHER REMEDY II-B-21 6-11.5 DECISION ON CLAIMS II-B-21 6-ll.6 APPEAL OF ENGINEER'S DECISION II-B-22 6-11.7 MEDIATION II-B-22 . 6-11.8 ARBITRATION II-B-22 6-11.9 WHEN ARBITRATION DECISION BECOMES II-B-22 BINDING 6-11.10APPEAL TO SUPERIOR COURT; WAIVER II-B-23 OF JURY TRIAL 6-ll.11AB 626 CLAIMS; PROCESS II-B-23 7-2 LABOR II-B-24 7-2.2 PREVAILING WAGES II-B-24 7-23 PAYROLL RECORDS II-B-25 7-3 INSURANCE II-B-25 7-3.1 GENERAL II-B-25 7-3.2 INDEMNIFICATION AND DEFENSE II-B-28 7-5 PERMITS II-B-29 7-8 WORK SITE MAINTENANCE II-B-29 7-8.1 WORK SITE MAINTENANCE II-B-29 7-8.1.1 GENERAL II-B-29 7-8.1.2 WATERING II-B-29 7-8.6 WATER POLLUTION CONTROL II-B-29 7-8.6.1 GENERAL II-B-29 7-9 PROTECTION AND RESTORATION OF EXISTING IMPROVEMENTS II-B-30 7-10 SAFETY II-B-31 7-10.6 TRAFFIC AND ACCESS II-B-31 7-10.7 STREET CLOSURES, DETOURS, AND BARRICADES II-B-31 7-10.8 PROTECTION OF THE PUBLIC II-B-32 7-15 HAZARDOUS MATERIAL II-B-32 9-2 LUMP SUM WORK II-B-33 9-3 PAYMENT II-B-34 9-3.2 PARTIAL AND F1NAL PAYMENTS II-B-34 9-33 DELIVERED MATERIALS II-B-35 100-1TERMINATION OF AGENCY LIABILITY II-B-35 iv Agreement No. 5551 SECTION III—TECHNICAL SPECIFICATIONS PAGE IIi-A-1 TO III-A-42 ATTACHMENTS ATTACHMENT A: PROJECT IMPROVEMENT PLANS ATTACHMENT B: CENTER LINE TIE&BENCHMARK SHEETS ATTACHMENT C: STANDARD PLANS v Agreement No. 5551 1�TC)T'I�E II�VI�'i�IG �EAI�E� �3IT�S 7/ Y S � C a� m The City of El Segundo is accepting sealed bids in the City Clerk's of�ce, 350 Main Street, El Segundo, California 90245, until 11:00 a.m. on: S A�l, r�Y 2 , 2 at which time they will be publicly opened. Bids will not be accepted after that time. As described in the Bidding Documentsy the bids are for a public works project (66ProjecY') which consists of Pavement Rehabilitation and related worrk as shown on the plans on file with the City's Public Works Depat°cment. Work on the Project must be performed in strict conformity with Specifications No. 18-18 as adopted by the El Segundo City Council on April 30,2018 which is filed with the Public Works �epar�ment. Copies of the Plans, Specifications, Contract Documents and Engineer's estimate are available frorn the Engineering I)ivision of the Public Works I�epartment, City of El Segundo, 350 Main Street, El Segundo, Califorriia, 90245. Plans And Specifications are alternately available electronically via p��a��/�v��a N�,�m��„��o��la.�..a�a.?�!�tl��w��rw��°�° �Q°a��°� �t �ti��°,��u��wt ��um�� G�,�nv�� A pre-bid meeting is scheduled for Tuesday,lVlay 15,2018 at 10 AM,at the West Conference Room, 350 Main Street, El Segundo, CA 90245. Bidders' attendance at this meeting is mandatory. Questions regarding the bid shall be submitted by 5:00 pm on Thursday, May 17, 2018 to #��µ!TMf�w��a�_cmmC��;�r�.��at��m��b��m,'me�cy�m��m��r"��m��cw+��iw��p��,�a�a b�t��t ,d��t �u��u. The terms and conditions for bidding on the Project are described in the attached Bidding Instructions. This project requires payment of State prevailing rates of wages for Los Angeles County. The contractor must post copies of the prevailing schedule at each job site. Copies of these rates of wages are available from the State of California Department of Industrial Relations Prevailing Wage Unit,Telephone No.(415)703-4774. The website for this agency is currently located at http://www.dir.ca.gov. Note that the Project is subject to compliance monitoring and enforcement by California Depa�tment of Industrial Relations. Pursuant to California law, the City must find bids failing to comply with all applicable Labor Code requirements including, without limitation, Labor I-A-1 Agreement No. 5551 Code §§ 1725.5 and 1771.4 to be nonresponsive, The contractor to whom the contract is awarded must assist in locating, qualifying, hiring and increasing the skills of minority group employees and applicants for employment, as set forth in Executive Order 11246 and 11375. Any contract entered into pursuant to this notice will incorporate the provisions of the State Labor Code. Compliance with the prevailing rates of wages and apprenticeship employment standards established by the State Director of Industrial Relations will be required. Affirmative action to ensure against discrimination in employment practices on the basis of race, color, national origin, ancestry, sex, or religion will also be required. The City of El Segundo hereby affirmatively ensures that minority business enterprises will be afforded full opportunity to submit bids in response to this notice and will not be discriminated against on the basis of race,color,national origin,ancestry,sex,or religion in any consideration leading to the award of contract. The Contractor's duty to pay State prevailing wages can be found under Labor Code Section 1770 et. Seq. and Labor Code Sections 1775 and 1777.7 outline the penalties for failure to pay prevailing wages and employ apprentices including forfeitures and debarment. Five percent(5%)will be deducted from each progress payment and retained by the City. The remainder less the amount of all previous payments will be paid to the Contractor. Pursuant to Public Contracts Code ("PCC") § 22300, the Contractor may substitute securities for retention monies held by the City or request that the City place such monies into an escrow account. The Contractor is notified,pursuant to PCC § 22300, any such election will be at the Contractor own expense and will include costs incurred by the City to accommodate the Contractor's request. In entering into a Public Works contract, or a subcontract, to supply goods, services, or materials pursuant to a public works contract,the Contractor, or Sub-Contractor, offers and agrees to assign to the awarding body all rights,title and interest in,and to,all causes of action it may have under Section 4 of the Clayton Act(15 U.S.C. Section 15)or under the Cartwright Act (Chapter 2 [commencing with Section 16700] of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of goods, services, or materials pursuant to the public works contract or the subcontract. This assignment shall be made and become effective at the time the awarding body tenders final payment to the Contractor, without further acknowledgment by the parties. Bids must be prepared on the approved Proposal forms in conformance with the Instructions to Bidders and submitted to the City Clerk, 350 Main Street, City of El Segundo, in a sealed envelope plainly marked on the outside: I-A-2 Agreement No. 5551 "SEALED BIDS FOR PROJECT NO.: PW 18-18 FY 17/18 PAVEMENT REHABILITATION IN THE CITY OF EL SEGUNDO DO NOT OPEN WITH REGULAR MAIL" The bid must be accompanied by a bid bond, made payable to the City of El Segundo for an amount no less than ten percent (10%) of the amount bid for the base contract. I No bid will be accepted from a Contractor who has not been licensed in accordance with the provisions of the State Business and Professions Code. For this project, those acceptable classes of license shall be"A". The successful Contractor and his Sub-Contractors will be required to possess the correct license for their project classifications, and valid City Business Licenses from the City of El Segundo. The City of El Segundo reserves the right to reject any or all bids, to waive any irregularity, and to take all bids under advisement for a period of ninety(90) calendar days. Any contract entered into pursuant to this notice shall become effective or enforceable against the City of El Segundo only when the formal written contract has been duly executed by the appropriate officer(s) of the City of El Segundo. DATED this day of � 20 , CITY OF EL SEGUNDO, CALIFORNIA Tracy...We........................._.. aver, City Clerk I-A-3 Agreement No. 5551 BIDDING INSTRUCTIONS 1. DEFINITIONS. Unless provided otherwise, the definitions in the Greenbook, Special Conditions, or other Contract Documents are applicable to all Bidding Documents. l.l "Addenda" means written or graphic instruments issued by the City before the Bid Deadline that modify or interpret the Bidding Documents by additions, deletions, clarifications, or corrections. 1.2 "Alternate" means a proposed change in the Work, as described in the Bidding Documents which, if accepted, may result in a change to either the Contract Sum or the Contract Time, or bo,th. 1.3 "Bid Deadline" means the date and time designated in the Notice for Bids as the last date and time for receipt of Bids, as may be revised by Addenda. 1.4 `Bidder" means a person or firm that submits a Bid. 1.5 "Bidding Documents" means the construction documents prepared and issued for bidding purposes including all Addenda. 1.6 "Lump Sum Base Bid" means the sum stated in the Bid for which Bidder offers to perform the Work described in the Bidding Documents,but not including unit price items or Alternates. . 1.7 "Unit Price"means an amount stated in the Bid for which Bidder offers to perform the Unit Price Work for a fixed price per unit of ineasurement. �. BIDDER'S REPRESENTATIONS, By making its Bid, Bidder represents that: 2.1 Bidder read, understood, and made the Bid pursuant to the requirements in the Bidding Documents. 2.2 Bidder visited the Project site and is familiar with the conditions under which the Work will be performed and the local conditions as related to the Contract Documents. 2.3 The Bid is based upon the materials, equipment, and systems required by the Bidding Documents. 2.4 Bidder and all Subcontractors, regardless of tier, have the appropriate current licenses issued by the State of California Contractor's State License Board for the Work to be performed. If Bidder is a joint venture, the Bidder will have a joint venture license appropriate for the performance of the work, and each member of the joint venture will likewise have the appropriate license. Business and Professions Code §§ 7000-7191 establish licensing requirements for contractors. If a Bidder, that is a specialty contractor, submits a Bid involving 3 or more specialized building trades, the work of which is more than incidental and supplemental to the performance of the Work for which Bidder holds a specialty contractor license, Bidder must also hold either (1) a specialty contractor "C" license in each such trade, (2) a General Engineering contractor"A" license, or(3) a General Building contractor"B" license. This requirement is applicable whether or not Bidder lists a Subcontractor for each such trade. 2.5 If licensure or proper licensure is controverted, then proof of licensure pursuant to this section must be made by production of a verified certificate of licensure from I-B-1 Agreement No. 5551 the Contractors' State License oard which establishes that the individual or entity bringing the action was duly licensed in the proper classificatian of contractors at all times during the performance of any act or contract covered by the action. Nothing in this subdivisian requires any person or entity cantroverting licensure ar praper licensure ta produce a verified certificate. When ljcensure or proper licensure is controverted9 the burd�n of proof to establish licensure ar proper licensure is on the licensee. 2.6 Bidder has the �expertise and financial capacity to perforrm and camplete all obligations undar the Bidding Documents. 2.7 The person exeauting the id Fo is duly authorized and empowered to execute the �id Form orn idder's behalf. 2.8 Bidder is aware of and, if awarded the Contract, will comply with Applicable Code Requirements in its performance of the Work. � 2.9 The Bidder has paid the City's business license fee(s) 2.10 The Bidder, per, SB 854 requirements f�r public prraje�ts, has r�gist�r�� with and paid their annual fee to the Califo ia State epart ent of Indust-rial Relations. Information about SB 854 and its requirements can be faund at this linko http://www,dir.ca.gov/Public-Works/SB 854ohtml 3e BIDDiNG DOCLJMEN 1 S 3.1 Bidders may obtain complete sets af the Bidding Documents frar�n the City9s Public VVorks Depa�ment for the sum stated in the Notice for�ids. 3.2 idders will use a co plete se�of iddin� Docu �nts in preparing ids. 3.3 The City rnakes co�ies of the idding ocu ents available, an the above te s, forr the sole pu�pose of obtaining Bids for the Work and does not confer a license or grant perrnission forr any otherr use of the Bidding Documents. 4. INTEIZPRETATION OR CORRECTION OF BIDDING DOCUMENTS. 4.1 Before submitting its Bid, �idderr will carefully study and compare the various documents cornprrising the Bidding Documents and cornpare i�hem with any other work being bid concurrently or presently under construction which relates to the �/ark for which the id is sub itted; vvill exa ine the Project site9 the conditions under which the Work is to be performed, and the local conditions; and will at once repo�t to the City's Representative errors, inconsistencies, or ambiguities discovered. 4,2 equests for clarification or interpretation of the idding ocurnents will be addressed to the City9s epresentative. 4,2.1 The release of the bid package be�ins a auiet period for potential Bidders participating in this project. The City of El Segundo realizes it is critical to provide Bidders with a vehicle to ask questions so that auality respornses can be prepared. uestions ust be submitted in writing to project rnanagers via the City website: ��,.��„fr"w'4."�"'"�`«`�":.I�"��"�llw�l�k,_�Yqd'�af,��5r"w�a�l,lVw'��)d4�N�4��wt:. 1!��Iv�Cw^at�.tlYrut<�� tlr4t,,G�11� a�^r��. Responses to all questiorns will be provided in writing to all� idders in accordance with the schedule below. We vvill not identify companies or I-B-2 Agreement No. 5551 individuals that pose questions. Potential bidders must not call City of El Segundo employees to discuss potential projects or ask questions regarding the bid. Questions Due by 5:00 pm, 5/17/2018 Questions Answered by S:OOpm, 5/22/2018 4.3 Clarifications, interpretations, corrections, and changes to the Bidding Documents will be made by Addenda. Clarifications, interpretations, corrections, and changes to the Bidding Documents made in any other manner will not be binding and Bidders must not rely upon them. 5. PRODUCT S,UBSTITUTIONS. No substitutions will be considered before award of Contract. Substitutions will only be considered after award of the Contract and as provided for in the Contract Documents. 6. SUBCONTRACTORS. 6.1 Each Bidder will list in the Bid Form all first-tier Subcontractors that will perform work, labor or render such services. The Bid Form contains spaces for the following information when listing Subcontractors: (1) Work Activity; (2)name of Subcontractor; (3) city of Subcontractor's business location. Failure to list any of these items on the Bid Form will result in the City treating the Bid as if no Subcontractor was listed for the Work and that Bidder represents to the City that it is fully qualified to perform that portion of the Work and will perform do so. 6.2 Subcontractors listed in the Bid Form will only be substituted after the Bid Deadline with the City's written consent in accordance with California law. 7. ADDENDA. 7.1 Addenda will be in writing and issued only by the City. Addenda will be mailed or delivered to all who are known by the City to have received a complete set of B idding Documents and who have provided a street address for receipt of Addenda. 7.2 Copies of Addenda will be made available for inspection at the City's Public Works Department. 73 The City will issue Addenda so that they are received by prospective Bidders not later than three (3)business days before the Bid Deadline. Addenda that withdraw the request for Bids or postpone the Bid Deadline may be issued anytime before the Bid Deadline. 7.4 Each Bidder is responsible for ensuring that it has received all issued Addenda before issuing a Bid. 8. PRE-BID CONFERENCE. Bidder will attend a Pre-Bid Conference where the City will discuss the Bidding Documents,answer questions,accept comments,and conduct a Project site visit. The City requires all Pre-Bid Conference attendees to arrive for the meeting on time and to sign an attendance list which is used to determine if Bidders meet this requirement. Any Bidder not attending the Pre-Bid Conference in its entirety will be I-B-3 Agreement No. 5551 deemed to have not complied with the requirements of the Bidding Documents and its Bid will be rejected. 9. FORM AND STYLE OF BIDS 9.1 Bids will be submitted on the Bid Form included with the Bidding Documents.Bids not submitted on the City's Bid Form will be rejected. 9.2 All blanks on the Bid Form will be filled in legibly in ink or by typewriter. 9.3 Bidder's failure to submit a price for any Alternate or unit price will result in the Bid being considered as nonresponsive. If Alternates are called for and no change in the Lump Sum Base Bid is required, enter"No Change." 9.4 Each Bidder must fill out the "Bidders Statement of Past Contract Disqualifica- tions" form stating any and all instances of contract disqualifications due to a violation of a law or safety regulation. The Bidder must explain the circumstances of each disqualification. The City may reject the bid based on such information. 9.5� Bidder will make no stipulations on the Bid Form nor qualify the Bid in any � manner. 9.6 The Bids will be based upon full completion of all the Work as shown on the plans and specifications. It is expressly understood that the plans are drawn with as much accuracy as is possible in advance, but should errors, omissions or discrepancies ` exist in the plans which show conditions that vary from those encountered in � construction, the Bidder (if awarded the Contract) specifically agrees to construct � a completed work ready for the use and in the manner which is intended. In the event of increasing or decreasing of work, the total amount of work actually done � or materials or equipment furnished must be paid for according to the unit or lump sum price established for such work under the contract, wherever such unit or lump sum price has been established. In the event no prices are named in the contract to cover such changes or alterations,the cost of such changes must be covered as extra work. 9.7 The Bid Form will be signed by a person or persons legally authorized to bind Bidder to a contract. Bidder's Representative will sign and date the Declaration included in the Bid Form.Failure to sign and date the declaration will cause the Bid to be rejected. 9.8 Bids must be submitted in writing on the Proposal forms provided by the City of El Segundo. One (1) set of these Proposal forms is inserted loose herein for use by the bidders. Bidders are required to submit one (1) original set of the proposal forms. All information requested therein must be clearly and legibly set forth in the manner and form indicated. 9.9 Bidders must satisfy themselves by personal examination of the work site, Plans, Specifications, and other contract documents, and by any other means as they may believe necessary,as to the actual physical conditions,requirements and difficulties under which the work must be performed. No bidder shall at any time after submissions of a proposal make any claim or assertion that there was any misunderstanding or lack of information regarding the nature or amount of work necessary for the satisfactory completion of the job. Any errors, omissions, or discrepancies found in the Plans, Specifications, or other contract documents shall be called to the attention of the City of El Segundo and clarified prior to the I-B-4 Agreement No. 5551 submission of proposals. 10. BID SECURITY 10.1 Each Bid will be accompanied by Bid Security, in the amount of 10% of the Lump Sum Base Bid as security for Bidder's obligation to enter into a Contract with the City on the terms stated in the Bid Form and to furnish all items required by the Bidding Documents. Bid Security will be a Bid Bond on the form provided by the City or a certified check made payable to "City of El Segundo." When a Bond is used for Bid Security, failure to use the City's Bid Bond form will result in the rejection of the Bid. 10.2 If the apparent lowest responsible Bidder fails to sign the Agreement and furnish all items required by the Bidding Documents within the time limits specified in these Instructions to Bidders, the City will disqualify such Bidder and select the � next apparent lowest responsible Bidder until all bids have been exhausted or the City may reject all bids. In such an event,the disqualified Bidder will be liable for and forfeit to the City the amount of the difference, not to exceed the amount of the Bid Security,between the amount of the disqualified Bid and the larger amount for which the City procures the Work. 10.3 If a Bid Bond is submitted and an attorney-in-fact executes the Bid Bond on behalf of the surety, a notarized and current copy of the power of attorney will be affixed to the Bid Bond. The surety issuing the Bid Bond will be listed in the latest published State of California, Department of Insurance list of, "Insurers Admitted to Transact Surety Insurance in This State." 10.4 The City will retain Bid Security until the occurrence of one of the following: 10.4.1 All items required by the Bidding Documents have been furnished and the Agreement has been signed by the successful Bidder and the City. 10.4.2 The specified time has elapsed during which Bids may be withdrawn. 10.4.3 All Bids have been rejected. 10.5 The Bid Form,Bid Security, and all other documents required to be submitted with the Bid must be enclosed in a sealed opaque envelope. The envelope must be addressed to the City Clerk. The envelope must be identified with the Bidder's name and address, and identify the Project for which the Bid is submitted, as follows: "SEALED BID5 FOR PW 18-18: FY 17/18 PAVEMENT REHABILITATION. DO NOT OPEN WITH REGULAR MAIL." Proposals may be mailed or delivered by messenger. 10.6 Bids will be deposited at the designated location on or before the Bid Deadline. A Bid received after the Bid Deadline will be returned to Bidder unopened. 10.7 Bidder will assume full responsibility for timely delivery at the location designated for receipt of Bids. 10.8 Oral,telephonic,facsimile,or telegraphic Bids are invalid and will not be accepted. 10.9 All proposals must be submitted,filed,made,and executed in accordance with State and Federal laws related to bids for contracts of this nature whether the same is expressly referred to herein or not. Any bidder submitting a proposal shall by such action thereby agree to each and all of the terms, conditions, provisions, and requirements set forth, contemplated, and referred to in the Plans, Specifications, and other contract documents, and to full compliance therewith. I-B-S Agreement No. 5551 11. MODIFICATION OR WITHDRAWAL OF BID. 11.1 Before the Bid Deadline, a submitted Bid may be modified or withdrawn. Notice of such action will be given to the City in writing and signed by the Bidder's authorized representative. A change so made will be so worded as not to reveal the amount of the original Bid. 11.2 A withdrawn Bid may be resubmitted up to the Bid Deadline, provided that it then fully complies with the Bidding Requirements. 11.3 Bid Security will be in an amount sufficient for the Bid as modified or resubmitted. 11.4 Bids may not be modified,withdrawn, or canceled within ninety(90)calendar days after the Bid Deadline unless otherwise provided in Supplementary Instructions to Bidders. 11.5 Proposals may not be withdrawn after said Bid Deadline without forfeiture of the proposal guarantee. 11.6 The withdrawal of a proposal will not prejudice the right of the bidder to submit a new proposal, providing there is time to do so. 11.7 No tnention shall be made in the proposal of Sales Tax, Use Tax, City Business License, or any other tax, as all amounts bid will be deemed and held to include any such taxes, which may be applicable. 11.8 No mention shall be made in the proposal of the cost of bonds as all amounts bid will be deemed and held to include any such costs,which may be applicable. 12. OPENING OF BIDS. Bids submitted in the manner required by these instructions and are received on or before the Bid Deadline will be opened publicly. 13. REJECTION OF BIDS. 13.1 The City will have the right to reject all Bids. 13.2 The City will have the right to reject any Bid not accompanied by the required Bid Security or any other item required by the Bidding Documents, or a Bid which is in any other way materially incomplete or irregular. 13.2.1 Unrequested/unauthorized conditions, limitations,or provisions attached to a proposal will render it irregular and may cause its rejection. The completed proposal forms shall be without interlineations, alterations, or erasures. Alternative proposals will not be considered unless specifically requested. No oral, telegraphic, or telephonic proposal, modification, or withdrawal will be considered. 13.3 In the event that any bidder acting as a prime contractor has an interest in more than one proposal,all such proposals will be rejected,and the bidder will be disqualified. This restriction does not apply to subcontractors or suppliers who may submit quotations to more than one bidder, and while doing so, may also submit a formal � proposal as a prime contractor.No proposal will be accepted from a bidder who has not been licensed in accordance with the provisions of the State Business and Professions Code. I-B-6 Agreement No. 5551 14. AWARD , 14.1 The City may retain all bids for a period of ninety (90) calendar days for examination and comparison, and to delete any portion of the work from the contract. 14.2 The City will have the right to waive nonmaterial irregularities in a Bid and to accept the lowest responsive Bid as determined by The City. 14.3 The City will have the right to accept Alternates in any order or combination,unless otherwise specifically provided in the Bidding Do�cuments. 14.4 The City will determine the low Bidder on the basis of the sum of the Lump Sum Base Bid plus all unit prices multiplied by their respective estimated quantities as stated in the Bid Form, if any, plus the Contractor Delay Damages multiplied by the "multiplier" as stated in the Bid Form, plus the amounts of all accepted Alternates. 14.4.1 Inclusion of Contractor Delay Damages within the Bid Form is solely for the purpose of determining the low bidder and establishing the City's maximum daily liability as a result of City delays to Contractor, if any, and City has no obligation to pay any daily Contractor Delay Damages except as provided for in these Contract Documents for Compensable Delays. In the event that City becomes liable to Contractor for compensable delays, City agrees to pay Contractor the daily Contractor Delay Damages set forth in the Proposal Form or Contractor's actual daily delay damages,whichever is less, for each day of Compensable .Delay as provided for by these Contract Documents. _ � 14.5 The City will select the apparent lowest responsive and responsible Bidder and notify such Bidder within thirty (30) calendar days (unless number of days is modified in Supplementary Instructions to Bidders)after the Bid Deadline or reject all bids. Within ten (10) days after receiving the City's notice that Bidder was selected as the apparent lowest responsible Bidder, Bidder will submit to the City all of the following items: 14.5.1 One original of the Agreement signed by Bidder. 14.5.2 One original of the Payment Bond. 14.5.3 One original of the Performance Bond. 14.5.4 Certificates of Insurance on form provided by the City. 14.5.5 Names of all Subcontractors, with their addresses, telephone number, facsimile number, trade on Bidders' company stationery. Evidence, as required by the City, of the reliability and responsibility of the proposed Subcontractors such as statements of experience, statements of financial condition, and references. 14.5.6 Preliminary Contract Schedule. 14.5.7 Selection of Retention Options and Escrow Agreement for Deposit of Securities in Lieu of Retention and Deposit of Retention. If not submitted, the City will withhold retention. 14.5.8 Cost Breakdown. 14.6 Before award of the Contract, the City will notify Bidder in writing, if the City objects to a Subcontractor proposed by Bidder, in which case Bidder will propose a substitute acceptable to the City. Failure of the City to object to a proposed I-B-7 Agreement No. 5551 Subcontractor before award will not preclude the City from requiring replacement of any Subcontractor based upon information received subsequent to award, information which cannot be properly evaluated before award due to time constraints, or information relating to a failure to comply with the requirements of the Contract. 14.7 If Bidder submits the original signed Agreements and all other items within ten(10) days after receiving the City's notification, and all such items comply with the requirements of the Bidding Documents,the City will award the Contract to Bidder by signing the Agreement and returning a signed copy of the Agreement to Bidder. 14.8 If the City consents to the withdrawal of the Bid of the apparent lowest responsible Bidder, or the apparent lowest responsible Bidder fails or refuses to sign the Agreement or submit to the City all of the items required by the Bidding Documents, within ten (10) days after receiving the City's notification, or the City determines that the Bidder is not financially or otherwise qualified to perform the Contract,the City may reject such Bidder's Bid and select the next apparent lowest responsible Bidder, until all bids are exhausted, or reject all Bids. I-B-8 Agreement No. 5551 PROPOSAL FOR THE FY 17/18 PAVEMENT REHABILITATION PROJECT NO.: PW 18-18 Date_....._ �.�..wW� y 20�� Company Name: �......._� �- TO THE CITY OF EL SEGUNDO: In accordance with the City of El Segundo's Notice Inviting Sealed Bids, the undersigned BIDDER hereby proposes to furnish all materials, equipment, tools, labor, and incidentals �°�c��ri�•�:.��' C"��• t�� above ��tc�d ��°�j�ct �s set lc�r�N� in the 1:'��r�� Spc��.��i��t�t��i�, <��c� contract �1�7��t��t�:� 11�u��for, an�� a� ��er��t.ta� all work br� tk�� mannetry�r��' �ime ��c��t'�1�� h�r,��in. BIDDER declares that this proposal is based upon careful examination of the work site,Plans, ��,ificati�:��,�, �r�s��°uctions to ��c��r':�, and all ��t��-��tr��t��nt�. `��.�k��~r�it�k�l ��f:"tl��:�t��c� ��tll be ccat�^�rd�r�c� evidence �1�� t4�� BIDDE�, �t��.:� ��t�:�1'i�c� �i�r��lf ��u��•�liz�� t�� :�s��lr��t. documents, access and any other field eonditiot�� r�v��i�#� ��<�� f"��1�id ry��. �� t�°�i��r'�r��a�a�� is ac;��c�for�w�^��d, BI��^��R agrees to ente�M ir�� t� ��a�trry�u� ��itl� t@�� mity ��°�� a��t�� at the t�rtiit�r�,��'/or �t�t��sum��s set forth in the t��6�vw�i��L�i� ��l��cit��. 1�;II7��T� t�t��r��ds that failure to enter into a contract in the manne�µ�r�c�' ti��p�`��'¢��c��`i�l r��r1�� 4�"�'to the City of El Segundo of the proposal guarantee accompanying this proposal. BIDDER understands that a bid is reqixired for the entire work, that the estimated quantities s�t f�a�-�1a �r� t�°r� ��c�Y ��;}��ci��d� �i�� 1�1� �'c;�M� ��a� ��ar��a��. ��`s�c��a��i��; ��;�� ,� t�a�t �ir��rl. ��z��a�.��t�� k��'��•�1��;�t�tr��t�r�i l� 1��* �<��,�� t tt�r�,�u��.��1 t��r��a��1.��"�rr�r•k �at��t��ar•�ly �c��,��l�t��< �1"i��: �;�'�"'� �� :�.11"�I]w+C� ��:�T`��""��",� "�'�T�'� ��'�' "�"� ��:'��.��;��9 ,�� ,��;��;,�� °�� ,�,��'��'�+��r��" ,�,,1�'�P QUANTITY SHOWN AND TO DELETE ��"�"1`i"��1"vC'�"��'�CO�i'�'��CT.It is a�ar��l�h��the unit and/or lur��a��r�a y��°ices bid ��,�� t1� a��•��t ��r�ses, �;��c�a, royalties, �a�� 1�.��. In the case of di�ur��t��s in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. If awarded the Contract, the undersigned further agrees that in the event of the BIDDER'S default in �„��.c��r�ing the ��c��rii°�cl t��ar�tt�act a��i �"ilira� the ��c��°�sary 1a�az�� t�u�� in:�taa'<a��t�e certificates w��t��i�t�ten wor�i�� y�s ��t��c�'the ��t� �a'�"'t�� City t�f�k��;�l Segra��r�c�"� ��.��:i��e ol"��d ��` �c,��.� t�� °�� :��T��►�+��, m��l��i�� s�n�i�n� t�� '�.�. M��il �� P��16� '�+'��r��s �"��r�tr��l ke�r ;;i�t�att��; b�'t}��°�i��,tl��: �i°��,�ci;�c�&"t��;�+��iti��om��r��n��la"r��i�� C�ti�11 L��:��tl�� ar•t��e;a�� c��1�� '�ty c�f�:;1 ��a�c�� l�i�; bi�i ��i ��t�:��cce��t��r�ce h��r�"r�a��y�,��,t�� "at� ��' 1::1 �c;��r�t��"� ��t��, k��c�c:��e��,cl ��al,l ��r�c� vc�id. I-C-1 Agreement No. 5551 � �1�� C"��:�L�:�"��+�G�'�' ��'��ORTUNITY COMPLIANCE BIDDER certifies that in all previous contracts or subcontracts,all reports which may have been due under the requirements of any agency, State, or Federal equal employment opportunity orders have been satisfactorily filed, and that no such reports are currently outstanding. AFFIRMATIVE ACTION CERTIFICATION BIDDER certifies that affirmative action has been taken to seek out and consider minority business enterprises for those portions of the work to be subcontracted, and that such affirmative actions have been fully documented,that said documentation is open to inspection,and that said affirmative action will remain in effect for the life of any contract awarded hereunder. Furthermore, BIDDER certifies that affirmative action will be taken to meet all equal employment opportunity requirements of the contract documents. f�T+��+i�"�}LLUSION DECLARA"�"�� BIDDER declares that the only persons or parties interested in this proposal as principals are those named herein; that no officer, agent, or employee of the City of El Segundo is personally interested, directly or indirectly, in this proposal; that this proposal is made without connection to any other individual,firm,or corporation making a bid for the same work and that this proposal is in all respects fair and without collusion or fraud. I-C-2 Agreement No. 5551 BID SCHEDULE FY 17/18 PAVEMENT REHABILITATION PROJECT NO.: PW 18-18 Company Name: Ww� ............. ��..ww Note: Bid Item Work described below is abbreviated for formatting purposes. The contractor warrants by entering pricing below that he has thoroughly read the entire bid document package, has thoroughly reviewed the site, and that his pricing encompasses all work described in the bid documents secttons�and t��:��s��° for execution of work. ...��... .�.. ......�.��. �.... �� .... . PRICE w.. . ....�m ITEM .._�. � ......��......�� T NO ...... . �.— � � � �DESCRIPTION UNIT QTY AMOUN � �� BASE BID ITEMS � .......�� ....� 1 Mobilization and Traffic Control, LS 1 including Traffic Control Plans $ $ ..�� (...�. 2 Cold mi112" existing asphalt concrete SF 623,341 AC)pavement $ $ mmmm3 Overlay 2" riew asphalt concrete (AC) SF 623,341 pavement $ $ ......_ ...._..�.....��........ 4 Adjust El Segundo City sewer manhole assemblies to final grade EA 45 $ $�� a djust El Segundo City sewer valve 5 ssemblies to final grade EA 6 $ $ T 6 ..�� .. � Adjust El Segundo City water valve assemblies to final grade EA 139 �.._. �..........�......__..... $ $ � Adjust El Segundo City water manhole .... ., EA..... .��...��l ...�.�.� � assemblies to final grade $ m mm m_$ � g Adjust El Segundo City storm drain EA 14 manhole assemblies to final grade � $ 9 Adjust Los Angeles County storm drain EA 5 manhole assemblies to final grade $ $ .....� _........__.. ._.. ....�......�. ... _ �..�..� ........ W��.._...... � 10 Adjust El Segundo City storm drain vault EA 1 assemblies to final grade $ $ W��........ ....._ _ _ _ ..._� Adjust El Segundo City storm drain 11 storm drain inlet assemblies to final EA 1 � ...��ti��x and re-stencil .. ��..... .�...._ _...� � __......... $ .��..�., _......... Adjust Southern California Gas 12 Company gas valve assemblies to final EA 5 �i°��c��:, $ $ I-C-3 a Agreement No. 5551 ....... Ad'ust South.__.. ..�..._. ��.._ ._.. � m.._. � ern California Edison 13 electric manhole assemblies to final EA 7 ��N�cic� $ $ 14 Adjust Southern California Edison EA 2 electric vault assemblies to final grade $ $ ..._�._� ........__...._��..�._�� ! . .....� ..._...�.._�.��. Adjust El Segundo City 15 telecommunications vault assemblies to EA 1 ' final rade $ � Adjust Bell Systems telecommunications � 16 manhole assemblies to final grade EA 16 $ $ Adjust TWC telecommunications vault 17 assemblies to final grade EA 1 $ $ Adjust AT&T telecommunications 18 manhole assemblies to final grade EA 1 , $ $ ' 19 Adjust T.V. Cable telecommunications EA 1 vault assemblies to final grade .��. _.._ ......._ ............. ._......._..._ � $ $.... ....... 20 Adjust Equinix telecommunications EA 1 manhole assemblies to final grade - � ' $ $ _...... .i W_ _ Adjust Qwest telecommunications 21 manhole assemblies to final grade EA 5 $ $ 22 Adjust Nextlink telecommunications EA 1 vault assemblies to final grade $ � 23 Adjust Leve13 telecommunications EA 2 manhole assemblies to final grade $ $ Adjust MFN telecommunications 24 manhole assemblies to final grade EA 6 $ $ Adjust TCG telecommunications 25 manhole assemblies to final grade EA 1 $ $ 26 Adjust MFS telecommunications EA 1 manhole assemblies to final grade $ $ 27 Adjust monitoring well assemblies to EA 15 final grade $ $ I-C-3 b Agreement No. 5551 ............._.....__.�. �� ' Adjust Los Angeles County Flood 28 Control District vault assemblies to final EA 8 rade $ $ w..W_.... ��...� ... �..._._.��..��__��_� _ . .____�� __�...._ ....._._ .......��..� ....__ ......... Adjust Los Angeles County Flood 29 Control District valve assemblies to final EA 6 I�rade $ $ Adjust Los Angeles County Flood 30 Control District manhole assemblies to EA 4 final rade I $ $ ° 31 Remove & Replace all survey LS 1 monuments and ties. $ $ ..... ........��........................��_�..�........._._ Remove & Replace all traffic striping, 32 curb and pavement markings, and LS 1 avement markers. $ $ 33 Remove & Replace all loop detectors and EA 30 appurtenances. . $ $ Remove and Replace damaged portion of 34 Douglas St catch basin. LS 1 $ $ �. ......._..______�..�._....... Remove and Replace damaged portion of ' 35 Douglas St cross gutter, including base LS 1 and as halt work. $ $ TOTAL BID (#1 thru#35)� �_................................................................ �.�_ TOTAL BID WRITTEN IN WORDS: I-C-3c Agreement No. 5551 BIDDER'S INFORMATION Company Name:. ____ ...__._ BIDDER certifies that the following information is true and correct: Form of Legal Entity (i.e., individual, partnership, corporation, etc.) If co oration, State of Inco oration i.e., California � iP �� ) ��......_...��.....................�......................_..,�. ��._a.�w�_ Business Address Telephone No. Facsimile No. State Contractor's License No. and Class Original Date Issued ,wwwwwwwww mmmmmm_ Expiration Date The following are the names,titles, addresses, and phone numbers of all individuals,firm members,partners,joint venturers, and/or corporate officers having principal interest in this proposal: The date of any voluntary or involuntary bankruptcy judgments against any principal having an interest in this proposal is as follows: All current and prior DBA's, aliases, and/or fictitious business names for any principal having an interest in this proposal are as follows: I-C-4 Agreement No. 5551 BIDDER'S INFORMATION(CONTINUED) Company Name:,�,,, Bidder shall list the name of the person who attended the mandatory pre-bid job walk: Name: Title: I-C-S Agreement No. 5551 IN WITNESS WHEREOF, BIDDER executes and submits this proposal with the names, titles, hands, and seals of all a forenamed principals this day of� �__W, 20,�,,,m. BIDDER p Subscribed and sworn to this day of �20_� NOTARY PUBLIC I-C-6 Agreement No. 5551 PROPOSAL GUARANTEE BID BOND FY 17/18 PAVEMENT REHABILITATION PROJECT NO.: PW 18-18 KNOW ALL MEN BY THESE PRESENTS that, . , as BIDDER, and , as SURETY, are held and firmly bound unto the City of El Segundo, in the penal sum of DOLLARS ($ ),which is ten (10%) percent of the total amount bid by BIDDER to the City of EI Segundo for the above stated project, for the payment of which sum, BIDDER and SURETY agree to be bound,jointly and severally, �rmly by these presents. THE CONDITIONS OF THIS OBLIGATION ARE SUCH that, whereas BIDDER is about to submit a bid to the City of El Segundo for the above stated project, if said bid is rejected, or if said bid is accepted and a contract is awarded and entered into by BIDDER in the manner and time specified, then this obligation shall be null and void, otherwise it shall remain in full force and effect in favor of the City of El Segundo. IN WITNESS WHEREOF the parties hereto have set their names,titles,hands,and seals this day of „ 20._....._��. BIDDER* SURETY* Subscribed and sworn to this day of , 20 NOTARY PUBLIC XProvide BIDDER/SURETY name, title, address and telephone number and the name, title, address and telephone number for authorized representative. I-C-7 Agreement No. 5551 CONTRACTOR'S LICENSE DECLARATION (Business and Professions Code Section 7028.15) 1. BIDDER'S Contractor's License Number is.,� Class No.: 2. The expiration date of BIDDER'S Contractor License is: 3. BIDDER acknowledges that Section 7028.15(e) of the Business and Professions Code provides as follows: "A licensed contractor shall not submit a bid to a public agency unless his or her contractor's license number appears clearly on the bid,the license expiration date is stated, and the bid contains'a statement that representations herein are made under penalty of perjury. Any bid not containing this information, or a bid containing information which is subsequently proven false, shall be considered non-responsive and shall be rejected by the public agency." The undersigned declares, under penalty of perjury, that the representations made by the undersigned in this bid proposal are true and correct. Executed on ___�, 20_, at (insert City and State where Declaration signed). Signature�_ _...................................._ �..�........� .... ......,,_ �_... Typed Name �........... .��.�...........�.�............�,,........ w�_ Title Company... ........................._. Name I-C-8 Agreement No. 5551 NON-COLLUSION DECLA TION TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID (pursuant to Cal. Pub. Contract Code § 7106) The undersi�ned declares� C am the ..... �_ _. °� _......�... . the party _m_._.__ __ - ..... _._. malcing the foregoing bid. "I'he bid is nat made in the interest af�, or on behalf of, any undisclosect person, partnership, campany; associatian, or�anization, or corporation. Th� bid is genuine and not collusive or sham. The biclder has not clir�ct(y or inclirectly induced or solicitecl any other bidder ta put in a false or sharn bid. The bidder has not directly ar inc[irect[y callucted, canspired, connived, ar agreed with any bidder �r anyone else to put in a sham bid, c�r ta refrain fram bidc{ing. The bidder has nc�t in any manner, directly ac indirectly, saught by a�re�m�nt, corr�munication, or conference r�vith anyone to fix th� bid price of the bidd�r or any ather bidder; or ta fix any averhead, profit, ar �ost element of the bid price; or of that af any ather bic{cter. All statements cantained in the bid are true. The bidcf�r has nat, directly or indirectly, submitted his or her bic� price or any breakda�vn thereaf,or the cantents thereaf,or divulged inf'armation or data refative thereto,to any corparation, partnership, campany, associatian, or�anizatian, bid depasitary, ar to any member or agent thereof; to effectuat� a callusive or sharn bid, and has not paid, and will nat paye any persan ar�ntity far such purpose. Any person executing this declaration on behalf of a bidder that is a corporation, partnership, joint ventuce. limited liability company, limited liability partnership,or any other entity, hereby represents that he or she has full power to execute, anci does execute,this declacation on behalf of the bidder. I d�clare under penalty of perjury Lsnder the [avvs of`the State of California that the foregoin� is true and correct and that this declaration is eXecuted on m_�date], at -----.. ..... _....—�city], [state}.r� ---- Dateci this day of . 20 Name ... ......__ . .. ....... -- .... ......... ...... ��....�....................................................m..m_ aa_�.....................................�....,., w.W..............................................................._ Title ........,., �.� . ...... .... .m.�_ Signature I-C-9 Agreement No. 5551 WORKER'S COMPENSATION CERTIFICATION Section 1861 OF THE LABOR CODE (Workers' Compensation) Pursuant to Section 1861 of the Labor Code, the BIDDER, in submitting his/her PROPOSAL, shall sign the following certification: "I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers' compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract." Signature of Bidder: Title: Business Name: Business Address: Telephone Number: ( )�w Dated this�,� day of� _ �, 20 I-C-10 Agreement No. 5551 BIDDER'S CERTIFICATION OF SUBCONTRACTORS FY 17/18 PAVEMENT REHABILITATION PROJECT NO.: PW 18-18 Company Name: As detailed in Section 2-3.1 (Page II-B-3) of the General Provisions, BIDDER certifies that it has listed belbw all subcontractors who will perform work in excess of one-half of one percent (0.5%) of the total bid price or certifies that the BIDDER is fully qualified to perform and will perform that portion of the work itself. �� mm� �m��m�mm�� w��m��.�m�mm ��a� ��m��,�� ww��. Subcontractor s Description of Contractor Portion of License No. & Work Name of DIR Subcontracted Estimated Subcontractor Address Registration No. $Amount �� umber and �„�� mm� (N Street) (CSLB#) .......�......... _�.W___ .....�.� (City, Zip Code) (DIR#) �.____ .......��..�__................ _.. .......��..._,. _..�._..�.� ...... .....__� ............. .. �.....�� (Make copies of this page if additional space is needed) ��.......................... Si nature of Bid...��,_ ......... _..........w.,.. .............................. g der Date I-C-11 Agreement No. 5551 REFERENCES Company Name: The following are the names, addresses, and telephone numbers for public agencies for which BIDDER has performed similar work as the prime contractor or major subcontractor within the past five (5) years: l. Project Title: Location: Name and address of owner Name and current telephone number of person familiar with project Type of Work: Contract amount: $ _ mmm mmmmm_ Date completed; Amount of work done by my/our firm under contract$mmmmmmmmmmmmmmmm_mITmmm� wwwwww_„ Did your firm have any financial interest in Project? q� m„m„m„m„m„m mmmmm 2, Project Title: Location: Name and address of owner Name and current telephone number of person familiar with project Type of Work: Contract amount: $_ .�..................................�._ ,w.... Date completed: . Amount of work done by my/our firm under contract$ Did your firm have any financial interest in Project?�LLLL�_ I-C-12 Agreement No. 5551 3. Project Title; Location: Name and address of owner Name and current telephone number of person familiar with project Type of Work: Contract amount: $�..................................�. w�w................................_ Date completed: Amount of work done by my/our firm under contract$ Did your firm have any financial interest in Project? 4. Project Title: Location: Name and address of owner Name and current telephone number of person familiar with project: Type of Work: Contract amount: $ mmmmmm� Date completed, _mmmmmmm � Amount of work done by my/our firm under contract$ ' Did your firm have any financial interest in Project? 5. Project Title: Location: Name and address of owner Name and current telephone number of person familiar with project; I-C-13 Agreement No. 5551 Type of Work: Contract amount: $._,_.....�................................................... Date completed: . Amount of work done by my/our firm under contract$ Did your firm have any financial interest in Project?_�_�_ Bidder may attach additional reference pages if necessary. The following are the names, addresses, and telephone numbers for all brokers and sureties from whom BIDDER intends to procure insurance bonds: I-C-14 Agreement No. 5551 BIDDER'S STATEMENT OF PAST CONTRACT DISQUALIFICATIONS FY l7/18 PAVEMENT REHABILITATION PROJECT NO.: P W 18-18 Company Name: Please state all instances of being disqualified, removed, or otherwise prevented from bidding on, or completing, a federal, state, or local government project due to a violation of a law or safety regulation. 1. Have you ever been disqualified from any government contract? Yes ❑ No ❑ 2. If yes, explain the circumstances: 3, Are you registered in accordance with Labor Code § 1725.5 [Note: failure to register requires the City to reject your bid as nonresponsive]? Yes �N No ❑ Bidder's Signature � �ww�� ..... Name (Please Print) I-C-l 5 Agreement No. 5551 INSURANCE REQUIREMENTS [MUST BE SUBMITTED WITH PROJECT PROPOSAL] FY 17/18 PAVEMENT REHABILITATION PROJECT NO.: PW 18-18 Company Name:__ ..... .... .. To be awarded this contract, the successful bidder must procure and maintain the following types of insurance with coverage limits complying, at a minimum,with the limits set forth below: Tvpe of:I.�rsa��•�,��; Limits Commercial general liability: $2,000,000 Business automobile liability: $1,000,000 Workers compensation: Statutory requirement Commercial general liability insurance must meet or exceed the requirements of ISO-CGL Form No. CG 00 O1 11 85 or 88. The amount of insurance set forth above must be a combined single limit per occurrence for bodily injury, personal injury, and property damage for the policy coverage. Liability policies must be endorsed to name the City,its officials, and employees as"additional insureds"under said insurance coverage and to state that such insurance will be deemed"primary" such that any other insurance that may be carried by the City will be excess thereto. Such endorsement must be reflected on ISO Form No. CG 20 10 11 85 or 88, or equivalent. Such insurance must be on an "occurrence," not a"claims made," basis and will not be cancelable or subject to reduction except upon thirty (30) days prior written notice to the City. Insurer will agree in writing to waive all rights of subrogation against the City, its officers, officials, employees and volunteers for losses arising from work performed by Contractor for the City. Automobile coverage must be written on ISO Business Auto Coverage Form CA 00 O1 06 92,including symbol 1 (Any Auto). The Consultant must furnish to the City duly authenticated Certificates of Insurance evidencing maintenance of the insurance required under this Agreement,endorsements as required herein,and such other evidence of insurance or copies of policies as may be reasonably required by the City from time to time. Insurance must be placed with admitted insurers with a cunent A.M. Best Company Rating equivalent to at least a Rating of"A:VII." Certificate(s)must reflect that the insurer will provide thirty (30)day notice of any cancellation of coverage. The Consultant will require its insurer to modify such certificates to delete any exculpatory wording stating that failure of the insurer to mail written notice of cancellation imposes no obligation, and to delete the word "endeavor" with regard to any notice provisions. The City requires �"��ft��4�ui��, Worker's Compensation Coverage with the associated Waiver. Out-of- state coverage will not be accepted in lieu of the California coverage, because the work is being performed in the State of California. By signing this form, the bidder certiftes that it has read, understands, and will comply with these insurance requirements if it is selected as the City's consultant. Failure to provide this insurance will render the bidder's proposal "nonresponsive." Date B idder s mm ' Signature I-G 16 Agreement No. 5551 END PROPOSAL SECTION I-C-17 Agreement No. 5551 PUBLIC WORKS CONTRACT BETWEEN THE CITY OF EL SEGUNDO AND FY 17/18 PAVEMENT REHABILITATION PROJECT NO.: PW#18-18 This CONTRACT is entered into this day of , 20 , by and between the CITY OF EL SEGUNDO, a general law city and municipal corporation ("the City") and , ("the Contractor"). L WORK. A. The Contractor will provide all work required by the Contract Documents (the "Work"). The Contractor agrees to do additional work arising from changes ordered by the City in accordance with the Contract Documents. B. The Contractor and the City agree to abide by the terms and conditions contained in the Contract Documents; C. The Contractor will furnish all of the labor; supplies and materials; equipment; printing; vehicles; transportation; office space and facilities; all tests, testing and analyses; and all matters whatsoever (except as otherwise expressly specified'to be furnished by the City)needed to perform and complete the Work and provide the services required of the Contractor by the Contract Documents. D. "Contract Documents"means the Notice Inviting Bids; Instructions to Bidders; Supplementary Instructions to Bidders; Proposal; this Contract; Standard Specifications; Supplementary Conditions; Exhibits; Technical Specifications; List of Drawings; Drawings; Addenda; Notice to Proceed; Change Orders; Notice of Completion; and all other documents identified in the Contract Documents which together form the contract between the City and the Contractor for the Work. The Contract Documents constitute the complete agreement between the City and the Contractor and supersede any previous agreements or understandings. 2. CONTRACT SUM. The City agrees to pay the Contractor a sum not to exceed 1,��k��m� �nc� �t��t^� �� for the Work in the manner set forth in the Contract Documents. The City may adjust this amount as set forth in the Contract Documents. 3. TIME FOR PERFORMANCE. A. The Contractor will fully complete the Work within working days (the "Contract Time.") I-D-1 Agreement No. 5551 B. The Contract Time will commence when the City issues a Notice to Proceed. The Contract Documents will supersede any conflicting provisions included on the notice to proceed issued pursuant to this Contract. C. The Contractor may not perform any Work until: i. The Contractor furnishes proof of insurance as required by the Contract Documents; and `i i. The City gives the Contractor a written, signed, and numbered purchase order and notice to proceed. D. By signing this Contract,the Contractor represents to the City that the Contract Time is reasonable for completion of the Work and that the Contractor will complete the Work within the Contract Time. F'. Should the Contractor begin the Work before receiving written authorization to proceed, any such Work is at the Contractor's own cost and risk. 4. DISPUTES. Disputes arising from this contract will be determined in accordance with the Contract Documents and Public Contracts Code §§ 10240-10240.13. 5. THIRD PARTY CLAIMS. In accordance with Public Contracts Code § 9201, the City will promptly inform the Contractor regarding third-party claims against the Contractor, but in no event later than ten (10) business days after the City receives such claims. Such notification will be in writing and forwarded in accordance with the "Notice" section of the Contract Documents. As more specifically detailed in the Contract Documents, the Contractor agrees to indemnify and defend the City against any third-party claim. 6. TAXPAYER IDENTIFICATION NUMBER. The Contractor will provide the City with a Taxpayer ldentification Number. 7. PERMITS AND LICENSES. Unless otherwise provided, the Contractor, at its sole expense,will obtain and maintain during the Contract Time,all necessary permits,licenses, and certificates that may be required in connection with the Work. 8. OWNERSHIP OF DOCUMENTS. All documents, data, studies, drawings, maps, models,photographs and reports prepared by the Contractor under the Contract Documents are the City's property. The Contractor may retain copies of said documents and materials as desired, but will deliver all original materials to the City upon the City's written notice. 9. INDEMNIFICATION. The Contractor agrees to indemnify, defend, and hold the City harmless as set forth in the Contract Documents. The requirements as to the types and limits of insurance coverage to be maintained by the Contractor as required by the Contract Documents, and any approval of such insurance by the City, are not intended to and will I-D-2 Agreement No. 5551 not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Contractor pursuant to the Contract Documents, including, without limitation, to the provisions concerning indemnification. lO. INDEPENDENT CONTRACTOR. The City and the Contractor agree that the Contractor will act as an independent contractor and will have control of all work and the manner in which is it performed. The Contractor will be free to contract for similar service to be performed for other employers while under contract with the City. The Contractor is not an agent or employee of the City and is not entitled to participate in any pension plan, insurance, bonus or similar benefits the City provides for its employees. Any provision in this Contract that may appear to give the City the right to direct the Contractor as to the details of doing the work or to exercise a measure of control over the work means that the Contractor will follow the direction of the City as to end results of the work only. 11. AUDIT OF RECORDS. The Contractor will maintain full and accurate records with respect to all services and matters covered under this Contract. The City will have free access at all reasonable times to such records, and the right to examine and audit the same and to make transcript therefrom, and to inspect all program data, documents,proceedings and activities. The Contractor will retain such financial and program service records for at least three (3) years after termination or final payment under the Contract Documents. 12. NOTICES. All communications to either party by the other party will be deemed made when received by such party at its respective name and address as follows: The Citv The Contractor City of El Segundo-Public Works _.............�..��.�_. 350 Main Street EI Segundo, CA 90245 Attn: John Gilmour Attn:. Any such written communications by mail will be conclusively deemed to have been received by the addressee three (3) days after deposit thereof in the United States Mail, postage prepaid and properly addressed as noted above. In all other instances, notices will be deemed given at the time of actual delivery. Changes may be made in the names or addresses of persons to whom notices are to be given by giving notice in the manner prescribed in this paragraph. 13. NO THIRD PARTY BENEFICIARY. This Contract and every provision herein is-for the exclusive benefit of the Contractor and the City and not for the benefit of any other party. There will be no incidental or other beneficiaries of any of the Contractor's or the City's obligations under this Contract. 14. INTERPRETATION. This Contract was drafted in, and will be construed in accordance with the laws of the State of California, and exclusive venue for any action involving this Contract will be in Los Angeles County. I-D-3 Agreement No. 5551 15. EFFECT OF CONFLICT. In the event of any conflict, inconsistency, or incongruity between any provision of the Contract Documents,precedence will be as follows: A. This Contract; B. The Standard Specifications; and � C. Precedence of documents as determined in the Standard Specifications. 16. SEVERABILITY. If any portion of the Contract Documents are declared by a court of competent jurisdiction to be invalid or unenforceable, then such portion will be deemed modified to the extent necessary in the opinion of the court to render such portion enforceable and,as so modified, such portion and the balance of this Contract will continue in full force and effect. 17. AUTHORITY/MODIFICATION. The Parties represent and warrant that all necessary action has been taken by the Parties to authorize the undersigned to execute this Contract and to engage in the actions described herein. This Contract may be modified by written amendment. The City's city manager,or designee,may execute any such amendment on the City's behalf. 18. ACCEPTANCE OF FACSIMILE SIGNATURES. The Parties agree that this Contract, agreements ancillary to this Contract, and related documents to be entered into in connection with this Contract will be considered signed when the signature of a party is delivered by facsimile transmission. Such facsimile signature will be treated in all respects as having the same effect as an original signature. 19. COVENANTS AND CONDITIONS. The parties agree that all of the provisions hereof will be construed as both covenants and conditions, the same as if the words importing such covenants and conditions had been used in each separate paragraph. 20. CAPTIONS. The captions of the paragraphs of this Contract are for convenience of reference only and will not affect the interpretation of this Contract. 21. TIME IS OF ESSENCE. Time is of the essence for each and every provision of the Contract Documents. I-D-4 Agreement No. 5551 IN WITNESS WHEREOF the parties hereto have executed this contract the day and year first hereinabove written. CITY OF EL SEGUNDO COMPANY NAME Gre�g...Carpenter................................................._�.�.�.�.�.�.�.�.�.�.....................................................�.�_� m��.��__.�—� _.�_,,��... Signee Name City Manager Signee Title ATTEST: �--- ----___-----__...............................__----.. Taxpayer ID No. .......................��.....�.m�....� Tracy Weaver, City Clerk Contractor State License No.: Contractor City Business License No.: APPROVED AS TO FORM: for Mark D. Hensley � City Attorney Insurance Reviewed b Y�..............................................��..��. I-D-S Agreement No. 5551 FAITHFUL PERFORMANCE BOND FY 17/18 PAVEMENT REHABILITATION PROJECT NO.: PW#18-18 Bond No. Bond Fee: ("PRINCIPAL") and IT ._...... _.. , a corporation incorporated under the laws of the State of �__and licensed by the State of California to execute bonds and undertakings as sole surety, as surety ("SURETY"), are held and firmly bound unto the CITY OF EL SEGUNDO ("CITY") in the sum of DOLLARS and �et�ts ., ��,_µ�m �, lawful money of the United States, which may be increased or decreased �� by a rider hereto executed in the same manner as this bond, for the payment of which sum PRINCIPAL and SURETY bind themselves, their successors, and assigns, jointly and severally, by this instrument. PRINCIPAL or SURETY will apply this bond for the faithful performance of any and all of the conditions and stipulations set forth in this bond, SPECIFICATIONS NO. PW 18-18, and the public works contract executed with such Specifications. In the case of any default in the performance of the conditions and stipulations of this undertaking, it is agreed that PRINCIPAL or SURETY will apply the bond or any portion thereof, to the satisfaction of any damages,reclamation,assessments,penalties,or deficiencies arising by reason of such default. BOND CONDITIONS 1. PRINCIPAL will construct the public improvements identified in SPECIFICATIONS NO. PW 18-18, a copy of which is on file with CITY's Engineering Division ("Public Project"). Such performance will be in accordance with CITY's plans and profiles (CITY DRAWING FILE NO. PW 18-18)which are made a part of this bond when said plans and profiles are approved by the City Council and filed with CITY's Engineering Division. CITY has estimated the required amount of the bond as shown above. 2. PRINCIPAL's work on the Public Project will be done in accordance with CITY's plans and specifications and with any permit issued by CITY. Should PRINCIPAL fail to complete all required work within the time allowed, CITY may, at its sole discretion, cause all required work to be done and the parties executing the bond will be firmly bound for the payment of all necessary costs therefor. 3. PRINCIPAL will guarantee its work against any defective wark, labor, or materials on the Public Project for a period of one (1) year following the Public Project's I-E-1 Agreement No. 5551 completion and acceptance by CITY. Should PRINCIPAL fail to correct its work against any defective work, labor, or materials, CITY may, at its sole discretion, cause all required work to be done and the parties executing the bond will be firmly bound for the payment of all necessary costs therefor. 4. This bond is conditioned upon and guarantees due compliance with all applicable law including, without limitation,the El Segundo Municipal Code ("ESMC"). 5. SURETY, for value received, agrees that no changes, extensions of time, alteration or modification of SPECIFICATIONS NO. PW 18-18 or of the obligation to be performed will in any way affect its obligation on this bond, and it waives notice of any such change, extension of time, alteration or modification of the contract documents or of the obligation to be performed. 6. This bond consists of this instrument; the ;plans and specifications identified above; and the following two (2) attached exhibits all of which are incorporated herein by reference: A. A certified copy of the appointment, power of attorney, bylaws or other instrument entitling or authorizing the persons executing this bond to do so; B, A certificate issued by the county cierk for the county in which SURETY's representative is located conforming with California Code of Civil Procedure § 995.640 and stating that SURETY's certificate of authority has not been surrendered, revoked, cancelled, annulled, or suspended, or in the event that it has,that renewed authority has been granted; and 7. Should PRINCIPAL perform its obligations within the time allowed, PRINCIPAL's obligation will be void one (1) year following the acceptance of the performance by CITY; otherwise this obligation will remain in full force and effect. [SIGNATURES ON FOLLOWING PAGE] I-E-2 Agreement No. 5551 SIGNED AND SEALED this day of, �20 w PRINCIPAL's PRESIDENT ......_._._._.__ SURETY's...... ___..�. PRESIDENT .._. .......ww_.................�.�WWW_W_ .�...�..._....._................ PRINCIPAL's SECRETARY SURETY's SECRETARY PRINCIPAL's MAILING SURETY's MAILING ADDRESS: ADDRESS: NOTE: (1) ALL signatures must be acknowledged by a notary public. Retum one(1)original to City Clerk's Office. (2) Bond shall be effective for one(1)year after acceptance of the job. I-E-3 Agreement No. 5551 LABOR AND MATERIALS BOND FY 17/18 PAVEMENT REHABILITATION PROJECT NO.: P W#18-18 Bond No. Bond Fee. _... �� .. ....u�.�.�as principal ("PRINCIPAL") and ' , a corporation incorporated under the laws of the State of and licensed by the State of California to execute bonds and undertakings as sole surety, as surety ("SURETY"), are held and firmly bound unto the CITY OF EL SEGLTNDO ("CITY") in the sum of DOL��1�'�� and cents ..�. ._ a"� ��,,�, lawful money of the United States, which may be increased or decreased by a rider hereto executed in the same manner as this bond, for the payment of which sum PRINCIPAL and SURETY bind themselves, their successors, and assigns, jointly and severally, by this instrument. This bond is conditioned upon and guarantees payment by PRINCIPAL to contractors, subcontractors, and persons renting equipment; payment by PRINCIPAL and all PRINCIPAL'S subcontractors for all materials, provisions, provender, or other supplies, and equipment used in, upon, for or a,bout the performance of the work contemplated in SPE�"�;i��1��"�"T"��5 NO. PW 18-18,("Pu��al�� '�c�jac��,), �.lr� ��rk�� a�°k� cont��:� exe�aa�c�� for stm�tiN��P��1i� �'��•��ject, and for all work or➢�t.��rw�a�`�.��ki�� c��mf°c��s��l �t'�wr�the Pu��[ic Pr��,j�;��t. In the case of any default in the performance of the conditions and stipulations of this undertaking, it is agreed that PRINCIPAL or SURETY will apply the bond or any portion thereof,to the satisfaction of any damages,reclamation, assessments,penalties, or deficiencies arising by reason of such default. BOND CONDITIONS 1. PRINCIPAL will construct the public improvements identified in SPECIFICATIONS NO. PW 18-18, and the public works contract executed for such Specifications,copies of which is on file with CITY's Engineering Division("Public Project"). Such performance will be in accordance with CITY's plans and profiles (CITY DRAWING FILE NO. PW 18-18), which are made a part of this bond when said plans and profiles are approved by the City Council and filed with CITY's Engineering Division. 2. PRINCIPAL will pay all contractors, subcontractors, and persons renting equipment. 3. PRINCIPAL will pay for all materials and other supplies, for equipment used in, on, for or about the performance of the Public Project, and will pay for all work and labor I-F-1 Agreement No. 5551 thereon. 4. This bond is conditioned upon and guarantees due compliance with all applicable law including, without limitation, the El Segundo Municipal Code ("ESMC"). 5. SURETY, for value received, agrees that no changes, extensions of time, alteration or modification of SPECIFICATIONS NO. PW 18-18, or of the obligation to be performed will in any way affect its obligation on this bond, and it waives notice of any such change, extension of time, alteration or modification of the contract documents or of the obligation to be performed. 6. This bond consists of this instrument; the plans and specifications identified above; and the following TWO (2) attached exhibits all of which are incorporated herein by reference: A. A certified copy of the appointment, power of attorney, bylaws or other instrument entitling or authorizing the persons executing this bond to do so; and , B. A certificate issued by the county clerk for the county in which SURETY's representative is located conforming with California Code of Civil Procedure § 995.640 and stating that SURETY's certificate of authority has not been surrendered, revoked, cancelled, annulled, or suspended, or in the event that it has,that renewed authority has been granted. 7. Should PRINCIPAL perform its obligations within the time allowed, PRINCIPAL's obligation will be void upon the acceptance of the performance by CITY; otherwise this obligation will remain in full force and effect. [SIGNATURES ON FOLLOWING PAGE] I-F-2 Agreement No. 5551 SIGNED AND SEALED this day of� 20 , ..�..�....��..�� w..��._�........ �_ . _ �� _ .�. .��..�........�. ��... — ...�. PRINCIPAL s PRESIDENT SURETY's PRESIDENT �.- ��...�._...� _ �._ ........ ....�. PRINCIPAL's SECRETARY SURETY's SECRETARY PRINCIPAL's MAILING ADDRESS: SURETY's MAILING ADDRESS: NOTE: (1) ALL signatures must be acknowledged by a notary public. Return one (1) original to City Clerk's Office. I-F-3 Agreement No. 5551 SECTION II - GENE��:rr�� 1�r ��,��i��f�i"i"�r CITY OF EL SEGUNDO PUBLIC WORKS DEPARTMENT GENERAL SPECIFICATIONS 1. l�F.r�"��"1"��.�'.��°�ON f.�l�° ��'��f"1�"��""�"(��..� No bid will be accepted from a Contractor who has not been licensed in accordance with the provisions of the laws of the State of California relating to licensing of contractors, for the type of work to be performed under this Contract. 2. INS��t�+C F�.��i�� `1��" C31..l�1�[�� LI�mm� �u�I�m Contractor and Sub-Contractors will obtain appropriate insurance and a City Business License before execution of the construction contract. 3. �:C�'f9;F�;GENt:"� ��^f"��.��"l"94.)b� The names, addresses and telephone numbers of the Contractor and Sub-Contractors,or their representatives, will be filed with the City Engineer and the City Police Department BEFORE �"��,�"��"➢�NG WORK. 4. FURNISHING OF WATER Water necessary for the prosecution of the work as herein specified will be furnished by the City in the following manner: The Contractor will deposit with the City Water Division the sum of Three Hundred Fifty Dollars ($ 350.00) to insure against damage to a 2 '/z" Fire Hydrant water meter which will be furnished and installed by the City at a point convenient to the site of the work. This deposit will be refunded to the Contractor upon completion of the Project if, after removal and inspection of said meter by the City, it is found to be in satisfactory condition. In event of damage to this meter while under the jurisdiction of the Contractor, all or any part of said deposit may be retained by the City. A non-refundable Activation Fee of One Hundred Dollars ($100.00) will be charged to the Contractor upon activation of the temporary meter. All water used from the temporary meter will be metered and charged to the Contractor at the prevailing rate plus the current daily meter rental rate. The Contractor will be charged a $15 reconnect fee if the Contractor wishes the City to relocate the temporary meter to another hydrant. Cost of water to be used shall be included in the Contract bid price of the items of work relevant to its use. II-A-1 Agreement No. 5551 5. �C��l,lf°��11� -(')��.��[�N��"I"1��'��I'� ��t� ��:^�'��""� � ��:��.."1�"Y� ,��N�`l��V��"9�'I��'T"I�'�l All work performed under this contract will be done in strict compliance with the Cal- OSHA Rules and Regulations, latest edition. 6. _SOUND CONTROL The Contractor will comply with all local sound control and noise level rules,regulations and ordinances that apply to any work performed pursuant to the contract. Each internal combustion engine, used for any purpose on the Project or re�ated to the � Project, will be equipped with a muffler of a type recommended by the manufacturer. No internal combustion engine will be operated on the Project without said muffler. The use of loud signals will be avoided in favor of light warnings except those required by safety laws for the protection of personnel. . 7. ��k�� '��l.gL�T'["C�)� �+�;��d"1��W The Contractor is put on notice that he must abide by all existing rules and regulations of the SCAQMD (South Coast Air Quality Management District), relating to all operations or equipment which discharge visible emissions or solid or liquid particles to the atmosphere. 8. WORKER UNIFORMS All workers under the employment of the Contractor or his/her Sub-Contractor shall wear the appropriate safety apparel as required by the latest edition of the Work Area Traffic Control Handbook (WATCHBOOK) while working in the public right-of way. Workers shall wear the correct Class visibility apparel for the speed zone working in, as required in the WATCHBOOK. II-A-2 Agreement No. 5551 CITY OF EL SEGUNDO PUBLIC WORKS DEPARTMENT GENERAL PROVISIONS 0-0 �:I�AND�� `��"f��I:CATI�:)dd'�11� 0-1 GENERAL Except as modified by these Standard Specifications,the provisions of the latest edition of the "Standard Specifications for Public Works Construction" ("Greenbook") and its supplements prepared and promulgated by the Southern California Chapters of the American Public Works Association and the Associated General Contractors of America, constitute the Standard Specifications for this project. 0-2 N��I'�:f:�f?M��N�� ° �5��„(�'��(��a The numbering contained within the Standard Specifications of the Contract Documents is intended to correspond with Greenbook numbering. 1-2 "��1�� I",@:L� I3k�F'i�I�"G(.��J"� The following definitions are added to Subsection 1-2 of the Greenbook: Acceptance—The date on which the City Council accepts the Work as complete. Architect,Design Engineers, Soils Engineer, Structural Engineers-Advisors employed by the City. City Council - The body constituting the awarding authority of the City. Compensable Delay--a delay entitling the Contractor to an adjustment of the Contract Sum and an adjustment of the Contract Time in accordance with this Agreement. Due Notice-A written notification,given in due time,of a proposed action where such notification is required by the contract to be given a specified interval of time (usually 48 hours or two working days) before the commencement of the contemplated action. Notification may be from Engineer to Contractor or from Contractor to Engineer. Engineer - The City Engineer, or designee, as defined in the Greenbook. Unless otherwise provided, all correspondence and decisions made relative to the contract will be by the City Engineer or his designated representative. PCC—California Public Contract Code. II-B-1 Agreement No. 5551 Prompt - The briefest interval of time required for a considered reply, including time required for approval of a governing body. Public Works Director—The City's Public Works Director, or designee. ❑ (Check if applicable) State Standard Specifications - State of California Standard Specifications, dated July 1992, Business and Transportation Agency, Department of Transportation Working Days-A working day is defined as any day,except Saturdays, Sundays, legal holidays and days when work is suspended by the Engineer, as provided in Subsection 6-3, and days determined to be non-working in accordance with Subsection 6-7, "Time of Completion." 1-3 ABBREVIATIONS The following abbreviations are added to Subsection 1-3.2 of the Greenbook: AAN American Association of Nurserymen AGC Associated General Contractors of America AISC American Institute of Steel Construction APWA American Public Works Association ASME American Society of Mechanical Engineers IEEE Institute of Electric and Electronic Engineers NEC National Electric Code Green Book The most current edition of the Standard Specification for Public Works Construction, and subsequent supplements prepared by Public Works Standards, Inc. WATCH Work Area Traffic Control Handbook SPPWC Standard Plans for Public Works Construction by the American Public Works Association SSPWC Standard Specifications for Public Works Construction by the American Public Works Association ASA American Standard Association CITY City of El Segundo 2-1 AWARD �i�� EXECUTION OF THE CONTRACT 2-1.1 ACCESS TO PROJECT SITE The following Subsection 2-1.1, Access to Project Site, is added to the Greenbook: Not later than the date designated in the City Notice to Proceed, the City will provide access to the real property and facilities upon which the Work is to be performed, including access to real property and facilities designated in the Contract Documents for the Contractor's use. II-B-2 Agreement No. 5551 2-1.2 +��"w��#I:��9�I1�.�,.1��.� l��f:�: �D1° �"C��"N"E�r�C,"T°��(`}(�l.�ll'�k �1:�"�, The following Subsection 2-1.2, Ownership and Use of Contract Documents is added to the Greenbook: The Contract Documents and all copies furnished to or provided by the Contractor are the City's property and may not be used on other work. 2-3 SUBCONTRACTS Subsection 2-3, Subcontracts, of the Greenbook is deleted in its entirety and replaced with the following Subsections 2-3.1, General, 2-3.2, Self Performance, and 2-3.3, Additional Responsibility: 2-3.1 GENERAL Except as provided in PCC §§ 4100 et. seq., each bidder will file with its bid the name and location of the place of business of each subcontractor who will perform work or labor or render service to the prime contractor in or about the construction of the work or improvement, or a subcontractor licensed by the State of California who, under subcontract to the prime contractor, specifically fabricates and installs a portion of the work or improvement according to detailed drawings contained in the plans and specifications, in an amount in excess of one-half of one percent of the prime contractor's total bid. Only one subcontractor will be listed for each portion of the work, which portion will be defined in the bid. In each instance, the nature and extent of the work to be sublet will be described. The failure of the Contractor to specify a subcontractor, or the listing of more than one subcontractor for the same portion of the work, constitutes an agreement by the Contractor that it is fully qualified to perform that portion itself and that it will perform that portion itself. The Contractor must have the City Council's written consent to substitute a subcontractor other than that designated in the original bid, to permit any subcontract to be assigned or transferred, or to allow a subcontract to be performed by other than the original subcontractor. Subcontracting of work for which no subcontractor was designated in the original bid, and which is more than one-half of one percent of the work, will be allowed only in cases of public emergency or necessity, and then only after a finding reduced to writing as a public record of the City Council setting forth the facts constituting the emergency or necessity. Violation of any of the above provisions will be considered a breach of the Contract, and the City may terminate the Contractor's control over the Work, cancel the contract, or assess the Contractor a penalty of not more than ten percent of the subcontract involved. II-B-3 Agreement No. 5551 All persons engaged in the work, including subcontractors and their employees will be considered as employees of the Contractor. The Contractor will be solely responsible for and have control over construction means, methods, techniques, sequences, procedures,and the coordination of all portions of the Work.The City will deal directly with, and make all payments to,the prime Contractor. When subcontracted work is not being prosecuted in a satisfactory manner, the Contractor will be notified to take corrective action. The Engineer may report the facts to the City Council. If the City Council so orders, and on receipt by the Contractor of written instructions from the Engineer,the subcontractor will be removed immediately from the Work. That subcontractor will not again be employed on the Work. If licensure or proper licensure is controverted,then proof of licensure pursuant to this section must be made by production of a verified certificate of licensure from the Contractors' State License Board which establishes that the individual or entity bringing the action was duly licensed in the proper classification of contractors at all times during the performance of any act or contract covered by the action.Nothing in this subdivision requires any person or entity controverting licensure or proper licensure to produce a verified certificate. When licensure or proper licensure is controverted, the burden of proof to establish licensure or proper licensure is on the licensee. 2-3.2 SELF PERFORMANCE The Contractor shall perform, with its own organization, Contract work amounting to at least 50 percent of the Contract Price except that any designated "Specialty Items" may be performed by subcontract and the amount of any such "Specialty Items" so performed will be deducted from the Contract Price before computing the amount required to be performed by the Contractor with its own organization."Specialty Items" will be identified by the Agency in the Bid or in the Special Provisions. Where an entire item is subcontracted, the value of the work subcontracted will be based on the Contract Unit Price. When a portion of an item is subcontracted, the value of work subcontracted will be based on the estimated percentage of the Contract Unit Price. This will be determined from information submitted by the Contractor, and subject to approval by the Engineer 2-3.3 �I��:�1'�'l�l*��, I�F��'+�)1��[��"l°�" The Contractor will submit experience statements for each subcontractor who will perform contract work that amounts to more than ten percent(10%) of the Work. 2-4 CONTRACT BONDS The fo(lowing paragraph is added to Subsection 2-4 of the Greenbook: The Faithful Performance Bond must be paid and in effect for one year after the II-B-4 Agreement No. 5551 acceptance of the job by the City, in accordance with the guarantee required by Subsection 6-8.1. 2-5 PLANS AND SPECIFICATIONS 2-5.1 GENERAL Subsection 2-5.1, General, of the Greenbook is deleted in its entirety and replaced with the following: The Contractor will maintain the following at the Work site: 1., One as-built copy of the Plans and Specifications, in good order and marked to record current ck►anges and selections made during construction. As-built plans must be submitted to the City representative for approval before the City pays a final retention amount. 2. The current accepted Contract Schedule., 3. Shop Drawings, Product Data, and Samples. 4. Approved permits from other agencies, including Cal-OSHA permits for trench shoring. 5. All other required submittals. The Plans,Specifications,and other Contract Documents will govern the Work. The Contract Documents are intended to be complementary and cooperative and to describe and provide for a complete project. Anything in the Specifications and not on the Plans, or on the Plans and not in the Specifications, will be as though shown or mentioned in both. Payment for any items on the plans for which there is no specific bid item will be included in the various items of work or in any item to which it is appurtenant. If the Contractor performs any work which it knows or should know involves an error, inconsistency, or omission without notifying and obtaining written consent from the Engineer, the Contractor will be responsible for the resulting losses, including, without limitation, the costs of correcting defective work. 2-5.2 PRECEDENCE OF CONTRACT DOCUMENTS The following paragraph is added to subsection 2-5.2 of the Greenbook: As the figured dimensions shown on the plans and in the specifications of the Contract II-B-S Agreement No. 5551 may not in every case agree with scaled dimensions, the figured dimensions will be followed in preference to the scaled dimensions, and plans to a large scale will be followed in preference to the plans to a small scale. Should it appear that the work to be done, or any of the matters relative thereto, are not sufficiently detailed or explained in the Contract,the Contractor will apply to the Engineer for such further explanations as may be necessary, and will conform thereto as part of the Contract so far as may be consistent with the terms thereof. Any items shown on drawings and not mentioned in the specifications will be of like effect as if shown or mentioned in both. 2-5.4 ACCURACY OF PLANS AND SPECIFICATIONS The following Subsection 2-5.4, Accuracy of Plans and Specifications, is added to the Greenbook: Although it�is believed that much of the information pertaining to conditions and existing utilities that may affect the cost of the Work will be shown on the Plans or indicated in the Specifications,the City does not warrant the completeness or accuracy of such information. The Contractor will carefully study and compare each of the Contract Documents with the others and with information furnished by the City and will promptly report in writing to the Engineer any errors, inconsistencies, or omissions in the Contract Documents or inconsistencies with applicable law observed by the Contractor. The Contractor will take field measurements, verify field conditions, perform soil investigations, and carefully compare with the Contract Documents such field measurements, conditions, and other information known to the Contractor before commencing the Work. Errors, inconsistencies, or omissions discovered at any time will be promptly reported in writing to the Engineer. 2-8 RIGHT-OF-WAY 2-8.1 ADDITIONAL WORK AREAS AND FACILITIES The following Subsection 2-8.1, Additional Work Areas and Facilities, is added to the Greenbook: When the Contractor arranges for additional temporary work areas and facilities, the Contractor will provide the City with proof that the additional work areas or facilities have been left in a condition satisfactory to the owner(s) of said work areas or facilities before acceptance of the work. 2-9 SURVEYING Subsection 2-9, Surveying, of the Greenbook is deleted in its entirety and replaced with the following Subsections 2-9.1, Construction Surveying, and 2-9.2, Measurement and II-B-6 Agreement No. 5551 Payment: 2-9.1 CONSTRUCTION SURVEYING The Contractor will provide for all construction surveying required to layout, monitor and complete the work. The surveying will be performed by a Land Surveyor or Civil Engineer authorized to practice land surveying by the State of California. The Project Benchmark is shown on the plans. The Contractor will establish all necessary control lines based on the plans and record information on file with the County of Los Angeles Surveyor and the Engineer. It is the responsibility of the Contractor to protect the survey control as shown on the plans. If the survey control is destroyed or disturbed during construction,the Contractor will provide for resetting them and file appropriate documents with the County of Los Angeles at the direction of the Engineer. Computations, survey notes, and other data used to accomplish the work will be neat, legible and accurate. Copies of all computations, survey notes, and other data (electronic format may be required)will be furnished to the Engineer before beginning work that requires their use. 2-9.2 MEASUREMENT AND PAYMENT Construction Survey — Unless a separate bid item is provided, payment will be considered included in the other items of the bid and no additional payment will be made therefore. 3-3 EXTRA WORK 3-3.2 PAYMENT 3-3.2.2 BASIS FOR ESTABLISHING COSTS 3-3.2.2.3 Tt"�� .u��7 ��1q�mm�Vi�1�mt�mm��m�1�m, Subsection 3-3.2.2.3,Tool and Equipment Rental, of the Greenbook is modified where the second and third paragraphs are replaced with "Regardless of ownership, the rates to be used in determining the equipment usage costs will not exceed those listed for the same or similar equipment in the California State Department of Transportation publication of Labor Surcharge and Equipment Rates effective for the period of usage." 3-3.2.3 MARK UP Subsection 3-3.2.3, Mark Up, of the Greenbook is deleted in its entirety and replaced with the following: II-B-7 Agreement No. 5551 (a) Work by Contractor. The following percentages will be added to the Contractor's costs and will constitute the markup for all overhead and profits. 1) Labor..................................................20 2) Materials ............................................15 3) Equipment Rental....,..,..�,..�,.,�..........,,15 4) Other Items and Expenditures............15 To the sum of the costs and markups provided for in this subsection, 1 percent will be added as compensation for bonding.No other formula,e.g.,the Eichleay or other method, may be used to calculate daily damages for office overhead, profit, or other purported loss. (b) Work by Subcontractors. When all or any part of the extra work is performed by a Subcontractor, the markup established in 3-3.2.3(a) will be applied to the Subcontractor's actual cost of such work. A markup of 10 percent on the first $5,000 of the subcontracted portion of the extra work and a markup of 5 percent on work added in excess of$5,000 of the subcontracted portion of the extra work may be added by the Contractor. (c) In the event that City becomes liable to Contractor for compensable delays,City agrees to pay Contractor the daily Contractor Delay Damages set forth in the Bid Form or Contractor's actual daily delay damages, whichever is less, for each day of Compensable Delay as provided for by these Contract Documents. 3-3.3 DAILY REPORTS The following paragraph is ac�ded to Subsection 3-3.3 of the Greenbook: If disagreement continues regarding extra work,the Contractor may seek compensation in accordance with the Claims procedure. Daily Reports required by this subsection must be made part of the Claim as supporting data for the Claim. 3-4 CHANGED CONDITIONS Subsection 3-4, Changed Conditions, of the Greenbook is deleted in its entirety and replaced with the following: If the Contractor encounters concealed or unknown conditions that differ materially from those anticipated or expected ("changed conditions"), the Contractor will immediately notify the Engineer in writing of such changed conditions(upon discovery and before disturbing such changed conditions),as provided in Subsection 6-11,so that the Engineer can determine if such conditions require design details that differ from those design details shown in the Contract Documents.Notwithstanding the time period set forth in Subsection 6-11.3, the Contractor is liable to the City for any extra costs II-B-8 Agreement No. 5551 incurred as a result of the Contractor's failure to promptly give such notice. Changed conditions include, without limitation, the following: l. Subsurface or latent physical conditions differing materiatly from those represented in the Contract Documents; 2. Unknown physical conditions of an unusual nature differing materially from those ordinarily encountered and generally recognized as inherent in work of the character being performed; and 3. Material differing from what is represented in the Contract which the Contractor believes may be hazardous waste as defined in California Health& Safety Code a § 25117 that is required to be removed to a Class I, II, or III disposal site in accordance with applicable law. The Engineer will promptly investigate conditions that appear to be changed conditions. The Engineer's decision, and any dispute regarding that decision, will be . made in accordance with Section 6-11 except that the Engineer will render a decision promptly. Any information provided pursuant to INFORMATION AVAILABLE TO BIDDERS is subject to the following provisions: 1. The information is made available for the Bidders' convenience and is not a part of the Contract. 2. The City has not determined the accuracy or completeness of such information and all such information is made available to Bidders without any representation or warranty by the City whatsoever as to its accuracy, completeness, or relevancy. 3. Bidders will independently evaluate such information for their use and will be solely responsible for use or interpretation of such information. Any such use or interpretation will not be the basis of any claim against the City. 3-5 DISPUTED WORK Subsection 3-5,Disputed Work,of the Greenbook is deleted in its entirety and replaced with the following. If the Contractor and the City do not reach agreement on disputed work, the City may direct the Contractor to proceed with the work.Any payment for the disputed work will be determined pursuant to the claims procedures in these Standard Specifications. Although not to be construed as proceeding under extra work provisions,the Contractor will keep and furnish records of disputed work as required by the Contract Documents. II-B-9 Agreement No. 5551 4-1 MATERIALS AND WORKMANSHIP 4-1.3 I�1'�l'E��;""�`1C�� [�B�(',��J3f�F.:N��'�9"�"� Subsection 4-1.3, Inspection Requirements, of the Greenbook is deleted in its entirety and replaced by the following: Unless otherwise specified, inspection at the source of production for such materials and fabricated items as bituminous paving mixtures, structural concrete, fabricated metal products, cast metal products, welding, reinforced and unreinforced concrete pipe, application of protective coatings, and similar shop and plant operations is not required. A certificate of compliance, signed by an authorized officer of the producer, certifying compliance with the contract documents will be submitted for all of the following materials: steel pipe, sizes less than 18 inches; vitrified clay pipe; asbestos cement pipe;cast iron pipe;reinforced concrete pipe;non-reinforced concrete pipe;and PVC sewer and water pipe; subject to sampling and testing by City. Standard items of equipment, such as electric motors,conveyors,plumbing fittings and fixtures, lumber, plywood, and so on, are subject to inspection at the job site. All other equipment items will be inspected and tested in accordance with the contract documents. The City does not provide full time inspection. The Contractor will provide 24-hour minimum notice for each inspection required by the work unless other arrangements have been agreed upon, in writing, with the City Engineer. Any inspection required outside of normal working hours and days, including holidays, will be at the Contractor's cost at rates established by the City. 4-1.6 `9'}�.t"�m:)l; T��:� �� C�.��.,� Subsection 4-1.6, Trade Names or Equals, of the Greenbook is deleted in its entirety and replaced with the following: Whenever any material, product, equipment, or service is specified by brand, trade, or proprietary name,the item so specified will be deemed to be followed by the words"or equal". For the Engineer's consideration of a proposed "equal" item, the Contractor, at its own expense, must submit, a minimum of ten (10) calendar days 1��:��°� the date of the bid opening, any and all documentation of the particulars of the proposed "equal item"that is deemed necessary by the Engineer to determine equivalency. The submitted documentation shall include, but not be limited to: ■ Written request with explanation of why the product should be considered as II-B-10 Agreement No. 5551 an equal product. � Material speciftcations. � Technical specifications. ■ Test data. �� Samples. * Comparison chart of key specifications of the "equal" item against similar specifications of the specified item. � Work locations and reference telephone numbers of at least three (3) locations where the proposed "equal" item has been recently installed under similar conditions. � Warranty data. . The Bidder will be notified by the Engineer whether or not the proposed "equal" product is acceptable to the City five (5) calendar days h�C`�a�� the date of the bid opening. Failure to submit all required documentation and/or submittal of incomplete documents may result in the Engineer's rejection of the proposed "equal" product without further consideration. Installation and use of a substitute shall not be made until approved by the Engineer. The Engineer's findings shall be final. If a substitute offered by the Contractor is not found to be equal to that which is specified,the Contractor shall furnish and install that which is specified. The specified Contract completion time shall not be affected by any circumstance developing from requests to use substitutes. 5-2 PROTECTION 5-2.1 IN�C"�:)I��I�:�:��1" ��:�C;�'C"q(��J !�)T:� [.dT��al"I"��:;� The following Subsection 5-2.1, Incorrect Location of Utilities, is added to the Greenbook: If the Contractor, while performing the Work, discovers utility facilities not identified correctly or not shown in the contract plans or specifications by the City,the Contractor will immediately notify the City and utility owner in writing. 5-4 RELOCATION 5-4.1 RESPONSIBILITY OF UTILITY REMOVAL OR RELOCATION The following Subsection 5-4.1, Responsibility of Utility Removal or Relocation, is added to the Greenbook: The City will be responsible to arrange for the removal,repair,or relocation of existing utilities located within the project limits if such utilities are not correctly identified in II-B-11 Agreement No. 5551 the contract plans or specifications by the City. The City will have the sole discretion to perform repairs or relocation work or permit the Contractor to do such repairs or relocation. 5-5 DELAYS The following paragraph is added to Subsection 5-5 of the Greenbook. Actual loss, as used in this Subsection, will be understood to include no items of expense other than idle time of equipment and necessary payments for idle time of workers, cost of extra moving of equipment, and cost of longer hauls. Compensation for idle time of equipment and idle time of workers will be determined by Subsection 5-5.1 and no markup will be added in either case for overhead and profit. The cost of extra moving of equipment and the cost of longer hauls will be paid for as extra work. 5-5.1 CALCULATING IDLE TIME The following Subsection 5-5.1, Calculating Idle Time, is added to the Greenbook: Equipment idle time will calculated in accordance with Subsection 3-3.2.2 and based upon the actual normal working time during which the delay condition exists,but in no cas�will exceed 8 hours in any one day. The days for which compensation will be paid will be the �alendar days, excluding Saturdays, Sundays and legal holidays, during the existence of the delay. Worker idle time will be calculated in accordance with Subsection 3-3.2.2. 6-1 CONSmi��'�t�� '�11:^,��.��1.s�; �+.�1�� CO�vlfv�t��9��:��L^� G'��1�" �r'f��I� Subsection 6-1, Construction Schedule and Commencement of Work, of the Greenbook is deleted in its entirety and replaced with the following Subsections 6-1.1, Contract Schedule, 6-1.2, Content of Contract Schedule, 6-1.3, Effect of Contract Schedule, and 6-1.4, Commencement of Contract Time: ,I��-��t��a��trra�� IT1v1`��tg�i�,. After contract award, the City will arrange for a pre- construction meeting to discuss the construction of the project. City will invite utility agencies and the contractor will arrange for all of its sub-contractors to attend the meeting. 6-1.1 ��.)�`I"��,�� SCHED��,]��° After notification of award and before starting any work, the Contractor will submit a Contract Schedule to the Engineer for review, as required by these Specifications within fifteen (15) calendar days of award. 6-1.2 CONTENT_OF CONTRACT SCHEDULE II-B-12 Agreement No. 5551 The Contract Schedule, and any updated Contract Schedule, will meet the following requirements: 1. Schedules must be suitable for monitoring progress of the Work. 2. Schedules must provide necessary data about the time for the Engineer's decisions. 3. Schedules must be sufficiently detailed to demonstrate adequate planning for the Work. � 4. Schedules must represent a practical plan to complete the Work within the Contract Time. 5. Schedules must show the critical path method for completing the Work. The Engineer's review of the form and general content of the Contract Schedule and any updated Contract Schedules is only for the purpose of determining if the listed requirements are satisfied, nothing more. 6-1.3 EFFECT OF CONTRACT SCHEDULE The Contract Schedule, and any updated Contract Schedules,will represent a practical plan to complete the Work within the Contract Time.Extension of any schedule beyond the Contract Time will not be acceptable. Schedules showing the Work completed in less than the Contract may be acceptable if judged by the Engineer to be practical. Acceptance of such a schedule by the Engineer will not change the Contract Time.The Contract Time, not the Contract Schedule, will control in determining liquidated damages payable by the Contractor and in determining any delay. If a schedule showing the Work completed in less than the Contract Time is accepted, the Contractor will not be entitled to extensions of the Contract Time for Excusable Delays or Compensable Delays or to adj ustments of the Contract Sum for Compensable Delays until such delays extend the completion of the Work beyond the expiration of the Contract Time. The Contractor will plan, develop, supervise, control, and coordinate the performance of the Work so that its progress and the sequence and timing of Work activities conform to the current accepted Contract Schedule. The Contractor will continuously obtain from Subcontractors information and data about the planning for and progress of the Work and the delivery of equipment, will coordinate and integrate such information and data into updated Contract Schedules, and will monitor the progress of the Work and the delivery of equipment.The Contractor will act as the expeditor of potential and actual delays, interruptions, hindrances, or disruptions for its own forces and those forces of Subcontractors. The Contractor will cooperate with the Engineer in developing the Contract Schedule and updated Contract Schedules. The Engineer's review and comments about any schedule or scheduling data will not relieve the Contractor from its sole responsibility to plan for, perform, and complete II-B-13 Agreement No. 5551 the Work within the Contract Time. Review and comments about any schedule will not transfer responsibility for any schedule to the Engineer or the City nor imply their agreement with(1)any assumption upon which such schedule is based or(2)any matter underlying or contained in such schedule. The Engineer's failure to discover errors or amissions in schedules that have been reviewed, or to inform the Contractor that the Contractor, Subcontractors, or others are behind schedule, or to direct or enforce procedures for complying with the Contract Schedule will not relieve the Contractor from its sole responsibility to perform and complete the Work within the Contract Time and will not be a cause for an adjustment of the Contract Time or the Contract Sum. The Contractor will perform the Work in accordance with the currently accepted Contract Schedule. 6-1.4 COMMENCEMENT OF CONTRACT TIME The Contract Time will commence when the City issues a Notice to Proceed.The Work will start on the date specified in the Notice to Proceed and within a maximum of fifteen (15) calendar days after the date of the Notice to Proceed, and be diligently prosecuted to completion with the time provided in the Specifications. 6-4 TERMINATION OF THE CONTRACT FOR DEFAULT Subsection 6-4, Termination of the Contract for Default, of the Greenbook is deleted in its entirety and replacad with the following Subsections 6-4.1, General, 6-4.2, Termination of Contractor's Control Over the Work, and 6-4.3, Surety's Assumption of Control: 6-4.1 GENERAL Should the Contractor fail to begin delivery of material and equipment, to commence the Work within the time specified, to maintain the rate of delivery of material, to execute the Work in the manner and at such locations as specified, or fail to maintain the Work schedule (as determined by the current accepted Contract Schedule) which will ensure the City's interest, or if the Contractor is not carrying out the intent of the Contract, the City may serve written notice upon the Contractor and the Surety on its Faithful Performance Bond demanding satisfactory compliance with the Contract. 6-4.2 TERMINATION OF CONTRACTOR'S CONTROL OVER THE WORK The City may terminate the Contractor's control over the Work without liability for damages when, in the City's opinion, the Contractor is not complying in good faith, has become insolvent, or has assigned or subcontracted any part of the Work without � the City's consent. Should such termination occur,the Contractor will be paid the actual amount due based on Contract Unit Prices or lump sums bid and the quantity and II-B-14 Agreement No. 5551 quality of the Work completed at the time of termination, less damages caused to the City by the Contractor's action or inaction. In the event of such termination of control, the City may do any one, or combination of, the following: 1. Serve written notice upon the Surety on its Faithful Performance Bond demanding satisfactory compliance with the Contract. In such event the Surety will, within 5 days, assume control and perform the Work as successor to the Contractor; 2, The City may perform the Work itself and deduct the cost thereof from any payment due to the Contractor; 3, The City may replace the Contractor with a different contractor to complete the work and deduct the cost thereof from any payment due to the Contractor. Nothing herein will waive, or serve as a limitation upon, any additional remedy the City may have under these Contract Documents or applicable law. 6-4.3 SURETY'S ASSUMPTION OF CONTROL Should the Surety assume any part of the Work, it will take the Contractor's place in all respects for that part, and will be paid by the City for all work performed by it in accordance with the Contract. If the Surety assumes the entire Contract, all money due the Contractor at the time of its default will be payable to the Surety as the Work progresses, subject to the terms of the Contract. If the Surety does not assume control and perform the Work within 5 days after receiving notice of cancellation, or fails to continue to comply, the City may exclude the Surety from�the premises. The City may then take possession of all material and equipment and complete the Work by City's forces, by letting the unfinished work to another contractor, or by a combination of such methods. In any event, the cost of completing the Work will be charged against the Contractor and its Surety and may be deducted from any money due or becoming due from the City. If the sums due under the Contract are insufficient for completion, the Contractor or Surety will pay to the City within 5 days of completion, all costs in excess of the sums due. The provisions of this subsection will be in addition to all other rights and remedies available to the City under applicable law. 6-6 ➢��;�..,�.�'"� ��R[� l.:y?��1��"�1:ONS OF °l`l"�'NI�� Subsection 6-6, Delays and Extensions of Time, of the Greenbook is deleted in its entirety and replaced with the following Subsections 6-6.1, General, 6-6.2, Extensions of Time, 6-6.3, Payment for Delays to Contractor, and 6-6.4, Written Notice and Report: II-B-15 Agreement No. 5551 6-6.1 GENERAL If delays are caused by unforeseen events beyond the control of the Contractor, such delays will entitle the Contractor to an extension of time as provided herein, but the Contractor will not be entitled to damages or additional payment due to such delays except as otherwise provided herein. Excusable delay may include: war, earthquakes exceeding 3.5 on the Richter Scale, government regulation, labor disputes outside the contemplation of the parties, strikes outside the contemplation of the parties, fires, floods; changes to the Work as identified herein, or other specific events that may be further described in the Specifications. Delays to the project caused by labor disputes or strikes involving trades not directly related to the project, or involving trades not affecting the project as a whole will not warrant an extension of time. The City will not grant an extension of time for a delay by the Contractor's inability to obtain materials unless the Contractor furnishes to the Engineer documentary proof. The proof must be provided in a timely manner in accordance with the sequence of the Contractor's operations and accepted construction schedule. Should delays be caused by events other than those included herein,the Engineer may, but is not required to, deem an extension of time to be in the City's best interests. 6-6.2 EXTENSIONS OF TIME If granted, extensions of time will be based upon the effect of delays to the critical path of the Work as determined by the current accepted Contract Schedule. Delays to minor portions of the Work that do not affect the critical path will not be eligible for extensions of time. 6-6.3 PAYMENT FOR DELAYS TO CONTRACTOR Any payment for compensable delay will be based upon actual costs as set forth in Subsection 5-5 excluding,without limitation,what damages, if any,the Contractor may have reasonably avoided. The Contractor understands that this is the sole basis for recovering delay damages and explicitly waives any right to calculate daily damages for office overhead, profit, or other purported loss, using different formulas including, without limitation,the Eichleay Formula. 6-6.4 WRITTEN NOTICE AND REPORT If the Contractor desires payment for a delay or an extension of time, it will give the Engineer written notice of such request not later than the time limit set forth in the Proposal for submitting a claim after the event or occurrence giving rise to a delay claim. Failure to submit a written request within such amount of time will result in the Contractor waiving its delay claim. II-B-16 Agreement No. 5551 Any claim for payment or an extension of time must be in the form required by the "Claims" sections of these Specifications. In no event will the City grant the Contractor an extension of time if the delay is within the Contract Time as identified by the Contract Documents. 6-7 ".�CS�I�� m�l�' �;"��1➢'f 1��C'�t��.� 6-7.2 "4��C�.�. I��"`� �l�L� ��k�f�1�� (:�t.J�� Subsection 6-7.2 of the Greenbook is deleted in its entirety and replaced with the following: City Hall is open from Monday thru Thursday 7am-Spm,and on alternate Fridays 7am- Spm. It is closed on the following holidays: � New Year's Day Martin Luther King, Jr. Day President's Day Memorial Day Independence Day Labor Day Veterans' Day Thanksgiving Day Friday after Thanksgiving Day Christmas Eve Christmas Day New Year's Eve Working on Fridays when City Hall is closed is acceptable. If the Contractor,however, requests an inspection a day when City Hall is closed,then the Contractor will have to reimburse the City for the costs of inspection. The Contractor must request such an inspection at least 48 hours in advance. City inspections during hours when City Hall is closed are subject to inspection overtime fees to be paid for by the Contractor.Friday work that does not require inspection can be done without an inspection fee and must be discussed with City staff before its occurrence. If the Contractor does construction on a Friday or a day when City Hall is closed,that day is counted as a project working day. On workdays, Contractor's activities will be confined to the hours between 7:00 am. and 4:00 p.m, unless otherwise stated in the project specifications and plans. Please see Section 6-7.5 below for weekend and holiday work restrictions. 6-7.4 N��i�-l"�° �+"Q��'� II-B-17 Agreement No. 5551 The following Subsection 6-7.4,Night Work, is added to the Greenbook: The City will not permit Work between the hours of 4 p.m. and 7 a.m. of the following day unless specifically provided for in the bid documents or unless the Contractor receives prior written approval. 6-7.5 WEEKEND AND ��OL�DAY WORK The following Subsection 6-7.5, Weekend and Holiday Work, is added to the Greenbook: The Engineer may, but is not required to, allow the Contractor to work on Saturdays, Sundays and City Holidays. 6-8 COMPLETION ACCEPTANCE ��[� "��1��"�`" Subsection 6-8, Completion, Acceptance, and Warranty, of the Greenbook is deleted in its entirety and replaced with the following Subsections 6-8.1, General Guaranty: The Work will be inspected by the Engineer for acceptance upon the Engineer receiving the Contractor's written assertion that the Work is complete. If, in the Engineer's judgment, the Work is complete and is ready for acceptance, the Engineer will accept the Work on behalf of the City in the manner prescribed by the City. The Engineer will recommend approval of the Notice of Completion to the City Council. This will be the date when the Contractor is relieved from responsibility to protectthe Work. All work will be guaranteed by the Contractor against defective workmanship and materials furnished by the Contractor for a period of 1 year from the date the Work was completed. The Contractor will replace or repair any such defective work in a manner satisfactory to the Engineer,after notice to do so from the Engineer,and within the time specified in the notice. If the Contractor fails to make such replacement or repairs within the time specified in the notice, the City may perform this work and the Contractor's sureties will be liable for the cost thereof. 6-8.1 GENERAL GUARANTY The Contractor will remedy any defects in the work and pay for any damage to other work resulting therefrom, which will appear within a period of one year from the date of final acceptance of the work unless a longer period is specified. The owner will give notice of observed defects with reasonable promptness. 6-9 C.�l�.�li��I q:-�,q� ��""��.�,�aR�� II-B-18 Agreement No. 5551 Subsection 6-9, Liquidated Damages, of the Greenbook is deleted in its entirety and replaced with the following: If all the work called for under the contract is not completed before or upon the expiration of the Contract Time, the City will sustain damage. Since it is and will be impracticable to determine the actual damage which the City will sustain in the event of and by reason of such delay, it is therefore agreed that the Contractor will pay to the City the sum specified in the Proposal for each and every calendar day beyond the time prescribed to complete the work not as a penalty, but as a predetermined liquidated damage. The Contractor agrees to pay such liquidated damages as are herein provided, and in case the same are not paid, agrees that the City may deduct the amount thereof from any money due or that may become due to the Contractor under the contract. Unless otherwise specified, liquidated damages will be $250 per calendar day. 6-11 DISPUTES ANDITIT� lm��l��.._�'��m��l;��C:�T�C;: The following Subsection 6-11, Disputes and Claims; Procedure, is added to the Greenbook: 6-11.1 GENERAL Consistent with PCC § 10240.6, "Claim" means a written demand or assertion by the Contractor that seeks an adjustment or interpretation of the terms of the Contract Documents, payment of money, extension of time, or other relief with respect to the Contract Documents, including a determination of disputes or matters in question between the City and the Contractor arising out of or related to the Contract Documents or the performance of the Work, and claims alleging an unforeseen condition or an act, error, or omission by the City, the Engineer, their agents or employees. "Claim" does not mean, and the Claims procedures herein do not apply,to the following: 1„ Claims respecting penalties for forfeitures prescribed by statute or regulations, which a government agency is specifically authorized to administer, settle, or determine. 2. Claims respecting personal injury, death, reimbursement, or other compensation arising out of or resulting from liability for personal injury or death. 3, Claims respecting a latent defect, breach of warranty, or guarantee to repair. 4. Claims respecting stop notices. If a Claim is subject to the Change Order procedures,the Claim arises upon the issuance of a written final decision denying in whole or in part the Contractor's Change Order Request. If a Claim is not subject to the Change Order Procedures, the Claim arises when the Contractor discovers, or reasonably should discover, the condition or event giving rise to the Claim. II-B-19 Agreement No. 5551 6-11.2 FORM A Claim must include the following: 1. A statement that it is a Claim and a request for a decision. 2, A detailed description of the act, error, omission, unforeseen condition, event or other condition giving rise to the Claim. 3. If the Claim is subject to the Change Order procedures, a statement demonstrating that a Change Order Requesx was timely submitted and denied. 4. A detailed justification for any remedy or relief sought by the Claim, including to the extent applicable, the following: a) If the Claim involves extra work, a detailed cost breakdown claimed. The breakdown must be provided even if the costs claimed have not been incurred when the Claim is submitted. b) To the extent costs have been incurred when the Claim is submitted,the Claim must include actual cost records (including, without limitation, payroll records, material and rental invoices) demonstrating that costs claimed have actually been incurred. c) To the extent costs have not yet been incurred at the time the Claim is submitted, actual cost records must be submitted on a current basis not less than once a week during any periods costs are incurred. A cost record will be considered current if submitted within seven(7)calendar days of the date the cost reflected in the record is incurred. At the Engineer's request, claimed extra costs may be subject to further verification procedures (such as having an inspector verify the performance of alleged extra work on a daily basis). 5. If the Claim involves an error or omission in the Contract Documents: a) An affirmative representation that the error or omission was not discovered before submitting a bid for the Contract; and b) A detailed statement demonstrating that the error or omission reasonably should not have been discovered by the Contractor, its Subcontractors and suppliers, before submitting a bid for the Contract. 6. If the Claim involves an extension of the Contract Time,written documentation demonstrating the Contractor's entitlement to a time extension. 7. If the Claim involves an adjustment of the Contract Sum for delay, written II-B-20 Agreement No. 5551 documentation demonstrating the Contractor's entitlement to such an adjustment. 8. A personal certification from the Contractor that reads as follows: "I � _m,,�..A,�._.._�,...... � BEING THE ......�..........................._.............................._.. �MUST BE AN OFFICER) OF _ (CONTRACTOR NAME), DECLARE UNDER PENALTY OF PERJURY UNDER CALIFORNIA LAW, AND DO PERSONALLY CERTIFY AND ATTEST THAT I HAVE THOROUGHLY REVIEWED THE ATTACHED CLAIM FOR ADDITIONAL COMPENSATION OR EXTENSION OF TIME, AND KNOW ITS CONTENTS, AND SAID CLAIM IS MADE IN GOOD FAITH; THE SUPPORTING DATA IS TRUTHFUL AND ACCURATE; THAT THE AMOUNT REQUESTED ACCURATELY REFLECTS THE CONTRACT ADJUSTMENT FOR WHICH THE CONTRACTOR BELIEVES CITY IS LIABLE; AND, FURTHER, THAT I AM FAMILIAR WITH CALIFORNIA PENAL CODE § 72 AND CALIFORNIA GOVERNMENT CODE § 12650, ET SEQ., PERTAINING TO FALSE CLAIMS, AND FURTHER KNOW AND UNDERSTAND THAT SUBMITTING OR CERTIFYING A FALSE CLAIM MAY LEAD TO FINES, IMPRISONMENT,AND OTHER SEVERE LEGAL CONSEQUENCES." � 6-11.3 CLAIMS SUBMITTED TO ENGINEER Within thirty (30) calendar days after the circumstances giving rise to a Claim occur, the Contractor will submit its Claim to the Engineer for a decision. Regardless of any Claim submittal, or any dispute regarding a Claim, unless otherwise directed by the Engineer, the Contractor will not cause any delay, cessation, or termination of the Work,but will diligently proceed with the performing the Work in accordance with the Contract Documents. Except as otherwise provided, the City will continue to make payments in accordance with the Contract Documents. 6-11.4 �'��[P� I�" �[��''�1 ��°��" �,fISITE TO OTHER REMEDY The Contractor certifies that it is familiar with PCC § 10240.2 and understands and agrees that submitting a Claim in accordance with these Specifications is an express condition precedent to the Contractor's right to otherwise pursue a claim whether through alternative dispute resolution or by litigation. Should the Contractor fail to , submit a claim in accordance with these Specifications, including the time limits set forth herein, it will waive any right to a remedy, whether in law or equity, it might otherwise have pursuant to the Contract Documents or applicable law. 6-11.5 DECISION ON CLAIMS The Engineer will promptly review Claims submitted by the Contractor in accordance II-B-21 Agreement No. 5551 with these Specifications. Should the Engineer require additional supporting evidence to evaluate the claim, the Engineer will request such additional information in writing. Any such requested data will be furnished not later than ten (10) calendar days after the Contractor receives the Engineer's request. The Engineer will render a decision not later than thirty (30) days after either receiving the Claim or the deadline for furnishing additional supporting data, whichever is later. If the Claim amount is more than $50,000, the time period will be extended to sixty (60) days. If the Engineer fail's to render a decision within the time period established herein, then the Claim will be deemed denied. The Engineer's decision will be final and binding unless appealed in accordance with these Specifications. The Engineer's decision on a Claim will include a statement substantially as follows: "This is a decision pursuant to the General Specifications of your contract. If you are dissatisfied with the decision, and have complied with the procedural requirements for asserting claims, you may have the right to alternative dispute resolution or litigation. Should you fail to take apprapriate action within thirty (30) calendar days of the date of this decision, the decision'will become final and binding and not subject to further appeal." 6-11.6 APPEAL OF ENGINEER'S DECISION Should the Contractor dispute the Engineer's decision,then the Contractor must appeal that decision to the City's Pixblic Works Director within thirty (30) calendar days of receiving the Engineer's decision. The Public Works Director w�ill address disputes or claims within thirty (30) calendar days after receiving such request and all necessary supporting data. The Public Works Director's decision on the dispute or claim will be the City's final decision. If the Contractor disputes the Public Works Director's decision, then the Contractor must demand alternative dispute resolution in accordance with this Section and the PCC within thirty (30) calendar days of the City's final decision. 6-11.7 MEDIATION If the City and the Contractor agree, disputes between the parties may be submitted to non-binding mediation. If the parties cannot agree to an alternative form of inediation, then mediation will be administered by the American Arbitration Association("AAA") under its Construction Industry Mediation Rules, unless the use of such rules are waived by mutual stipulation of both parties. The parties may, but are not required to be, represented by counsel in mediation. II-B-22 Agreement No. 5551 The requirement for mediation will not alter or modify the time limitations otherwise provided for claims and no conduct or settlement negotiation during mediation will be considered a waiver of the City's right to assert that claim procedures were not followed. 6-11.8 ARBITRATION If the City and Contractor do not agree to mediation, then a disputes will be submitted to neutral non-binding (except as provided herein) arbitration. Arbitration will be conducted in accordance with PCC § 10240.3. Any decision rendered by an arbitrator will be consistent with PCC § 10240.8. The eXclusive venue for any arbitration will be in Los Angeles County. The expenses and fees of the arbitrators and the administrative fees, if any, will be divided among the parties equally. Each party will pay its own counsel fees, witness fees, and other expenses incurred for its own benefit. 6-11.9 1�"[i(��l ,�I`�,i�i°�"�L�°I"�(�I`�I D9:�f�G�� BEC{�C�F�� 31�1C.�C�+fi�m� The decision rendered by the arbitrator will become binding upon the parties unless appealed to the Los Angeles County Superior Court pursuant to PCC § 10240.12 within thirty (30) calendar days of the decision. If subsequent litigation results in an award to the party appealing the arbitration that is less than or equal to that of the arbitration decision,or if the litigation results in a decision in favor of the nonappealing party,then the party appealing the arbitration will pay the nonappealing party's attorney's fees and court costs. 6-11.10 APPEAL TO SUPERIOR COURTy WAIVER OF JURY TRIAL Should a party timely object to the arbitration decision, it may file a petition with the Los Angeles County Superior Court in accordance with California Code of Civil Procedure ("CCP") §§ 1285, et seq.Notwithstanding the limitations set forth in CCP § 1286.2, the court may vacate, correct, or adjust an arbitration award, and enter judgment in accordance with CCP § 1287.4, for any legal or equitable basis including, without limitation, error of law. The court will apply the substantial evidence standard of review when considering the appeal of an objecting party. BY EXECUTING THESE CONTRACT DOCUMENTS, THE CONTRACTOR AGREES TO HAVE DISPUTES OR CONTROVERSY CONCERNING THE CONSTRUCTION, INTERPRETATION, PERFORMANCE, OR BREACH OF THESE CONTRACT DOCUMENTS, INCLUDING CLAIMS FOR BREACH OF CONTRACT OR ISSUES OF BAD FAITH DECIDED IN ACCORDANCE WITH THIS SECTION 6-11. BOTH THE CITY AND THE CONTRACTOR WAIVE THEIR RIGHT TO A JURY TRIAL FOR THESE DISPUTES OR ISSUES. II-B-23 Agreement No. 5551 6-11.11 ��3��a �:��:.�d1�IV��. ��f�()�.��"� Claims made by a Contractor for one or more of the following are subject to the claim resolution process set forth in Public Contract Code section 9204: (A) A time extension, including, without limitation, for relief from damages or penalties for delay assessed by the city under a contract for a public works project. (B) Payrr�ent by the city of money or damages arising from work done by, or on behalf of,;the contractor pursuant to the contract for a public works project and payment for which is not otherwise expressly provided or to which the claimant is not otherwise entitled. (C) Payment of an amount that is disputed by the city. 7-2 LABOR 7-2.2 PREVAILING WAGES Subsection 7-2.2, Prevailing Wages, of the Greenbook is deleted in its entirety and replaced with the following: The Contractor will post at appropriate conspicuous points at the site of the project a schedule showing determinations of the Director of Industrial Relations of the prevailing rate of per diem wages. It will be the Contractor's responsibility to obtain copies ofj the prevailing rate of per diem wages. One source that may be used is the California Department of Industrial Relations website which is currently located at www.dir.ca.gov, or by calling the Prevailing Wage Unit at (415) 703-4774. Attention is directed to Labor Code §§ 1777.5, 1777.6 and 3098 concerning the employment of apprentices by the Contractor or any subcontractor. Labor Code § 1777.5 requires the Contractor or subcontractor employing tradesmen in any apprenticeship occupation to apply to the joint apprenticeship committee nearest the site of the public works project and which administers the apprenticeship program in that trade for a certificate of approval. The certificate will also fix the ratio of apprentices to journeymen that will be used in the performance of the contract. The ratio of apprentices to journeymen in such cases will not be less than one to five except: a) When employment in the area of coverage by the joint apprenticeship committee has exceeded an average of 15 percent in the ninety (90) calendar days before the request for certificate, or b) When the number of apprentices in training in the area exceeds a ratio of one to five, or II-B-24 Agreement No. 5551 c) When the trade can show that it is replacing at least 1/30 of its membership through apprenticeship training on an annual basis state-wide or locally, or d) When the Contractor provides evidence that the Contractor employs registered apprentices on all of his contracts on an annual average of not less than one apprentice to eight journeymen. The Contractor is required to make contributions to funds established for the administration of apprenticeship programs if the Contractor employs registered apprentices or journeymen in any apprenticeable trade on such contracts and if other contractors on the public works site are making such contributions. The Contractor and any subcontractor will comply with Labor Code §§ 1777.5 and 1777.6 in the employment of apprentices. Information relative to apprenticeship standards, wage schedules and other requirements may be obtained from the Director of Industrial Relations, ex-officio the � Administrator of Apprenticeship, San Francisco, California, or from the Division of Apprenticeship Standards and its branch offices. 7-2.3 PAYROLL RECORDS � Subsection 7-2.3, Payroll Records, of the Greenbook is deleted in its entirety and replaced with the following: Every Contractor and subcontractor will keep an accurate certified payroll records showing the name, occupation, and the actual per diem wages paid to each worker employed in connection with the Work. The record will be kept open at all reasonable hours to the inspection of the body awarding the contract and to the Division of Labor Law Enforcement. If requested by the City, the Contractor will provide copies of the records at its cost. 7-3 INSURANCE Subsection 7-3, Insurance, of the Greenbook is deleted in its entirety and replaced by the following Subsections 7-3.1, General, and 7-3.2, Indemnification and Defense: 7-3.1 GENERAL Contractor must procure and maintain for the duration of the contract the following insurance coverages and limits against claims for injuries to persons or damage to property that may arise from or in connection with the performance of the work covered by this agreement by the Contractor, its agents, representatives, employees or subcontractors: II-B-25 Agreement No. 5551 COVERAGE PER ISO FORM COMBINED OCCURRENCE SINGLE LIMIT Comprehensive General Liability CL 00 02 O1 85 or 88 $2,000,000 Business Auto CA 00 O1 O1 87 $1,000,000 Workers' Compensation Statutory Contractor will provide endorsements or other proof of coverage for contractual liability. Combined single limit per occurrence will include coverage for bodily injury,personal injury, and property damage for each accident. If Commercial General Liability Insurance or other form with a general aggregate limit is used, the policy will be endorsed such that the general aggregate limit will apply separately to this contract and a copy of the endorsement provided to the City. Liability policies will contain, or be endorsed to contain the following provisions: GENERAL LIABILITY AND AUTOMOBILE LIABILITY: The City, its officers, officials, employees, agents, and volunteers will be covered as insureds as respects: liability arising out of activities performed by or on behalf of the Contractor; products and completed operations of the Contractor; premises owned, occupied or used by the Contractor; or automobiles owned, leased, hired or borrowed by the Contractor. The coverage will contain no special limitations on the scope or protection afforded to the City, its officers, officials, employees, agents, or volunteers. The Contractor's insurance coverage will be primary insurance as respects the City, its officers, officials, employees, agents, and volunteers. Any insurance or self-insurance maintained by the City, its officers,officials, employees, agents,and volunteers will be excess of the Contractor's insurance and will not contribute with it. The insurer will agree in writing to waive all rights of subrogation against the City, its officers,officials,employees and volunteers for losses arising from work performed by the Contractor for the City. Any failure to comply with reporting provisions of the policies will not affect coverage provided to the City, its officers, officials, employees, agents and volunteers. The Contractor's insurance will apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. WORKER'S COMPENSATION: II-B-26 Agreement No. 5551 The insurer will agree to waive all rights of subrogation against the City, its officers, officials, employees and volunteers for losses arising from work performed by the Contractor for the City. ALL COVERAGES; Each insurance policy required by this subsection will be endorsed to state that coverage will not be suspended,voided, cancelled by either party,reduced in coverage or in limits except after thirty(30)calendar days written notice by certified mail,return receipt requested, has been given to: CITY CLERK City of EI Segundo 350 Main Street El Segundo, CA 90245 Notwithstanding the foregoing, the endorsement may state that insurance may be cancelled upon ten (10) calendar day notification for non-payment of premium. The Contractor will provide the City with updated proof of insurance should the Contract Time extend beyond the policy expiration date. All liability insurance will be on an occurrence basis. Insurance on a claims made basis . will be rejected. Any deductibles or self-insured retentions will be declared to ancl approved by City. The insurer will provide an endorsement to City eliminating such deductibles or self-insured retentions as respects the City, its officials, employees, agents, and volunteers. Except for Workers Compensation Insurance, Contractor will furnish to City certificates of insurance and endorsements on forms acceptable to the City's City Attorney, duly authenticated, giving evidence of the insurance coverages required in this contract and other evidence of coverage or copies of policies as may be reasonably required by City from time to time. Endorsements must be supplied on ISO Form No. CG 20 10 11 85, or equivalent. Certificate/endorsement for Workers Compensation Insurance will be furnished on State Comp Fund or other industry standard form. Except for worker's compensation insurance, all insurance required herein will be placed with insurers with a Best's Rating of not less than A:VII. Worker's compensation insurance policies will meet the requirements of California law. All subcontractors employed on the work referred to in this contract will meet the insurance requirements set forth for Contractor. Contractor will furnish certificates of insurance and endorsements for each subcontractor at least five days before the subcontractor entering the job site, or Contractor will furnish City an endorsement including all subcontractors as insureds under its policies. Except as provided in Subsection 6-10, the Contractor will save, keep and hold harmless the City, its officers, officials, employees, agents and volunteers from all II-B-27 Agreement No. 5551 damages, costs or expenses in law or equity that may at any time arise or be claimed because of damages to property, or personal injury received by reason of or in the course of performing work, which may be caused by any willful or negligent act or omission by the Contractor or any of the Contractor's employees, or any subcontractor. The City will not be liable for any accident, loss or damage to the work before its completion and acceptance, except as provided in Subsection 6-10. The cost of such insurance will be included in the various items of work in the Contractor's bid and no additional compensation for purchasing insurance or additional coverage needed to meet these requirements will be allowed. In the event that any required insurance is reduced in coverage, cancelled for any reason, voided or suspended, Contractor agrees that City may arrange for insurance coverage as specified, and Contractor further agrees that administrative and premium costs may be deducted from payments due to the Contractor. Contractor will not be allowed to work until alternate coverage is arranged. Coverage will not extend to any indemnity coverage for the active negligence of the additional insured if the agreement to indemnify the additional insured would be invalid under Civil Code § 2782(b). 7-3.2 T�1�:�EMNIFICA"�"I:{:,D1'� t�1�� .�1:��`l,N�ai! In addition to the provisions of Subsection 7-3 of the Greenbook as between the City and Contractor,Contractor will take and assume all responsibility for the work as stated herein or shown on the plans. The Contractor will bear all losses and damages directly or indirectly resulting to it, to the City, its officers,employees, and agents,or to others on account of the performance or character of the work, unforeseen difficulties, accidents, traffic control, job site maintenance, or any other causes whatsoever. The Contractor will assume the defense of and indemnify and save harmless the City of El Segundo, its officers,employees,and agents,from and against any and all claims, losses, damage, expenses and liability of every kind, nature, and description, directly or indirectly arising from the performance of the contract or work, regardless of responsibility for negligence, and from any and all claims, losses, damage, expenses, and liability, howsoever the same may be caused, resulting directly, or indirectly from the nature of the work covered by the contract, regardless of responsibility for negligence, to the fullest extent permitted by law. In accordance with Civil Code § 2782, nothing in this Subsection 7-3.2 or in Subsection 7-3 of the Standard Specifications will require defense or indemnification for death, bodily injury, injury to property, or any other loss, damage or expense arising from the sole negligence or willful misconduct of the City, or its agents, servants or independent contractors who are directly responsible to the City, or for defects in design furnished by such persons. Moreover, nothing in this Subsection 7-3.2 or in Subsection 7-3 will apply to impose II-B-28 Agreement No. 5551 on the Contractor,or to relieve the City from, liability for active negligence of the Cityw The City does not, and will not, waive any rights against the Contractor which it may have by reason of the aforesaid hold harmless agreements because of the acceptance by the City, or deposit with City by Contractor, of any insurance policies described in Subsection 7-3 of the Special Provisions. This hold harmless agreement by the Contractor will apply to all damages and claims for damages of every kind suffered, or alleged to have been suffered by reasons of any o,f the aforesaid operations of Contractor, or any subcontractor, regardless of whethex or not such insurance policies are determined to be applicable to any of such damages or claims for damages. No act by the City, or its representatives in processing or accepting any plans, in releasing any bond, in inspecting or accepting any work, or of any other nature, will in any respect relieve the Contractor or anyone else from any legal responsibility, obligation or liability he might otherwise have. 7-5 PERMITS The following paragraph is added to Subsection 7-5 of Greenbook: The Contractor will apply for permits required by the City.These permits will be issued on a"no-fee" basis. However,the Contractor must pay for and obtain all other permits from other governmental and utility agencies necessitated by their operations. All bonding fees,(overweight and oversized vehicle permit fees)inspection permit fees or other fees charged or required for such permits must be paid by the Contractor.These costs will be included in the bid item provided. If no bid item is included, costs will be included in the various items of work, and no additional payment will be allowed. 7-8 "�"f��.l� '�1'�`i�� MAINTEN,��I��i°� 7-8.1 WORK SITE MAINTENANCE Subsection 7-8.1, General, of the Greenbook is deleted in its entirety and replaced with the following Subsections 7-8.1.1, General, and 7-8.1.2, Watering. 7-8.1.1 GENERAL On any construction project requiring trenching within public streets and for which total trenching is in excess of 500 feet, the Contractor will be required to sweep the worksite utilizing a street sweeper machine approved by the City Engineer a minimum of once daily. 7-8.1.2 WATERING Water for dust control caused by Contractor's operations or the passage of traffic [I-B-29 Agreement No. 5551 through the work will be applied as necessary or as directed by the Engineer. Water for the above or other purposes may be obtained from any approved source. If the Contractor chooses to use a City fire hydrant upon placing a refundable $350 damage deposits and $100 non-refundable Activation Fee,the Engineer will cause a temporary hydrant meter to be installed at a location convenient to the site of the work. All water used from the hydrant will be metered and charged to the Contractor at the prevailing rate plus the current daily meter rental rate. The Contractor will be charged a $15 reconnect fee if the Contractor wishes the City to move the meter to a different hydrant. Costs of water to be used will be included in,the cost of various bid items. 7-8.6 ��1 �t�� Y�)��C�I.J°I'C�� ;�,�C��i"�"��e)�� 7-8.6.1 GENERAL The following paragraphs are added to Subsection 7-8.6.1 of the Greenbook: The following requirements are added to establish storm water and urban runoff pollution prevention controls. (a) Storm or construction generated water containing sediment such as, construction waste, soil, slurry from concrete/asphalt concrete saw cutting operations, cleanup of concrete transit mixers or other pollutants from construction sites and_parking areas will be retained or controlled on site and will not be permitted to enter the storm drain system. (b) Temporary sediment filtering systems such as sandbags, silt fences, or gravel berms will be utilized to trap sediment so that only filtered water enters the City's storm drain system. Proper clean up and disposal of settled sediment and the filtering system will be the responsibility of the Contractor. (c) Discharge of concrete transit mixer wash water on to approved dirt areas (sub- grade area designated for new concrete construction for example) is acceptable. Discharge on to private property, parkway areas, or the street is not permitted. (d) Plastic or other impervious covering will be installed where appropriate to prevent erosion of an otherwise unprotected area, along with any other runoff control devices deemed appropriate by the City. (e) Excavated soil stored on the site will be covered in a manner that minimizes the amount of sediments running into the storm drain system, street or adjoining properties. (� No washing of construction or other industrial vehicles and equipment will be allowed adjacent to a construction site. During the rainy season (October 15 to April 15), Contractor will keep at the construction site sufftcient materials and labor to install temporary sediment filtering systems and other water pollution II-B-30 Agreement No. 5551 prevention control measures. These control measures will be in place and maintained by the Contractor on a daily basis on days when construction is not in progress due to rain. (h) All costs associated with water pollution control will be borne by the Contractor.Any expense incurred by the City to expeditiously respond to storm drain contamination resulting from Contractor's failure to implement water pollution control measures;will be charged to the Contractor. 7-9 PROTECTION AND RESTORATION OF EXISTING IMPROVEMENTS The following paragraphs are added to Subsection 7-9 of the Greenbook: Where existing traffic striping,pavement markings, and curb markings are damaged or their reflectively reduced by the Contractor's operations, such striping or markings will also be considered as existing improvements and the Contractor will replace such improvements. Relocations, repairs, replacements, or re-establishments will be at least equal to the existing improvements and will match such improvements in finish and dimensions unless otherwise specified. 7-10 SAFETY The following Subsections 7-10.6, Traffic and Access, 7-10.7, Street Closures, Detours,and Barricades,and 7-10.8,Protection of the Public,are added the Greenbook: Unless otherwise specified all traffic control will be performed in accordance with the Work Area Traffic Control Handbook(WATCH)Latest Edition,published by Building News. 7-10.6 TRAFFIC AND ACCESS The Contractor will notify the occupants of all affected properties at least 48 hours before any temporary obstruction of access. Vehicular access to property line will be maintained except as required for construction for a reasonable period of time. No overnight closure of any driveway will be allowed except as permitted by the Engineer. At least one(1)twelve(12)foot wide traffic lane will be provided for each direction of travel on all streets at all times except as permitted by the Engineer. The traffic lanes will be maintained on pavement, and will remain unobstructed.All work requiring that a lane be closed or a lane moved right or left will be noticed to the traveling public by use of City approved lighted arrow boards. Clearances from traffic lanes will be five (5)feet to the edge of any excavation and two (2)feet to the face of any curb,pole, barricade,delineator,or other vertical obstruction. II-B-3l Agreement No. 5551 One four (4) foot wide paved pedestrian walkway will be maintained in the parkway area on each side of all streets.The clearance from the pedestrian walkway to any traffic lane will be five (5) feet. Pedestrians and vehicles will be protected from all excavations, material storage, and/or obstructions by the placement of an adequate number of lighted barricades (minimum two (2)) at each location, one (1) at each end of the obstruction or excavation), which will have flashing lights during darkness. Barricades will be Type I or Type II per Section 7-3 and lights will be Type A per Section 7-6 of the "Work Area Traffic Control Handbook" (WATCH). 7-10.7 STREET CLOSURES ��F;'I"�'4�1�,�. c�,1`�� .�1.�k�.��°��;� Street closures will not be allowed except as specifically permitted by the Engineer.. The Contractor will prepare any traffic control or detour plans that may be required as directed by the Engineer. Lane transitions will not be sharper than a taper of thirty(30) to one (1). Temporary traffic channelization will be accomplished with barricades or delineators. Temporary striping will not be allowed unless specifically permitted by the Engineer. The Contractor will prepare any plans that may be required for temporary striping to the satisfaction of the Engineer.In no event will temporary striping be allowed on finish pavement surfaces, which are to remain. Where access to driveway or street crossings need to be maintained, minimum 1 1/4 inch thick steel plating will be used to bridge the trench. All steel plating will have temporary asphalt concrete 1:12 minimum sloped ramps to assist vehicles to cross comfortably over the plates and have a non-skid surface. Plates subject to vehicle high traffic speeds and in residential areas will be secured by welding at the discretion of the Engineer. 7-10.8 PROTECTION OF THE PUBLIC It is part of the service required of the Contractor to make whatever provisions are necessary to protect the public. The Contractor will use foresight and will take such steps and precautions as his operations warrant to protect the public from danger, loss of life or loss of property, which would result from interruption or contamination of public water supply, interruption of other public service, or from the failure of partly completed work or partially removed facilities. Unusual conditions may arise on the Project which will require that immediate and unusual provisions be made to protect the public from danger or loss of life, or damage to life and property, due directly or indirectly to prosecution of work under this contract. Whenever, in the opinion of the Engineer, an emergency exists against which the Contractor has not taken sufficient precaution for the public safety, protection of utilities and protection of adjacent structures or property, which may be damaged by II-B-32 Agreement No. 5551 the Contractor's operations and when, in the opinion of the Engineer, immediate action will be considered necessary in order to protect the public or property due to the Contractor's operations under this contract, the Engineer will order the Contractor to provide a remedy for the unsafe condition. If the Contractor fails to act on the situation immediately, the Engineer may provide suitable protection to said interests by causing such work to be done and material to be furnished as, in the opinion of the Engineer, may seem reasonable and necessary. The cost and expense of said labor and material, together with the cost and expense of such repairs as are deemed necessary, will be borne by the Contractor. All expenses incurred by the City for emergency repairs will be deducted from the progress payments and the final payment due to the Contractor. Such remedial measures by the City will not relieve the Contractor from full responsibility for public safety. 7-15 1��,��[��)L�°� �c�:TL:f��aL�., The following Subsection 7-15, Hazardous Material, is added to the Greenbook: For any excavation, which extends more than four feet below existing grade, the Contractor will promptly, and before the conditions are disturbed, notify the Engineer, in writing, of. l) any material that the Contractor believes may be hazardous waste, as defined in Health and Safety Code § 25117,which is required to be removed to a Class I, Class II, or Class III disposal site in accordance with provisions of existing law, 2) subsurface or latent physical conditions at the site differing from those indicated, or 3) unknown phy�sical conditions at the site of any unusual nature,different materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract Documents. After receiving notice from the Contractor, the Engineer will promptly investigate any condition identified by the Contractor as being hazardous. The rights and obligations of the City and the Contractor with regard to such conditions (including, without limitation, the procedures for procuring change orders and filing claims) will be specified by the provisions of Subsection 3-4 (Changed Conditions)of the Greenbook. If a dispute arises between the City and the Contractor whether the conditions materially differ, involve hazardous waste, or cause a change in the Contractor's cost or time required for performance of the work, the Contractor will not be excused from any scheduled completion date provided for by the contract, but will proceed with all work to be performed under the contract. The Contractor will retain all rights provided by Subsection 3-5, Disputed Work, of the Greenbook. If the Engineer determines that material called to the Engineer's attention by the Contractor is hazardous waste, or if the Engineer otherwise discovers the existence of hazardous waste, the Contractor will be responsible for removal and disposal of the hazardous waste by qualified personnel and appropriate equipment in the manner required by law as directed by the Engineer, subject to the provisions of Section 3 II-B-33 Agreement No. 5551 (Changes in Work) of the Greenbook. 9-2 LUMP SUM WORK Subsection 9-2, Lump Sum Work, of the Greenbook is deleted in its entirety and replaced with the following: Items for which quantities are indicated as "Lump Sum," "L.S.," or "Job" will be paid for at the price indicated in the Proposal. Such payment will be full compensation for all costs for labor, equipment, materials and plant necessary to furnish, construct and install the lump sum item of wark, complete, in place,and for all necessary appurtenant work, including, but not limited to, all necessary cutting, patching, repair and modification of existing facilities, and cleanup of site. Contractor will furnish three copies of a detailed schedule,which breaks down the lump : sum work into its component parts and cost for each part, in a form and sufficiently detailed as to satisfy Engineer that it correctly represents a reasonable apportionment of the lump sum. This schedule is subject to approval by Engineer as to both the components into which the lump sum item is broken down, and the proportion of cost � attributable to each component. This schedule will be the basis for progress payments for the lump sum work. 9-3 PAYMENT 9-3.2 PARTIAL AND F1NAL PAYMENT Subsection 9-3.2,Partial and Final Payment, of the Greenbook is deleted in its entirety and replaced with the following: The closure date for the purpose of making partial progress payments will be the last working day of each month. The Contractor will prepare the partial payment invoice with measurement of the work performed through the closure date and submit it to the CITY for approval. When work is complete, the Contractor will determine the final quantities of the work performed and prepare the final progress payment, and submit it to the Engineer for approval. , It will take a minimum of thirty-five (35) calendar days from the date of approving the Contractor's invoice to make the payment to the Contractor. However, payments will be withheld pending receipt of any outstanding reports required by the contract documents, or legal release of filed Stop Payment Notices against the Contractor. In addition, the final progress payment will not be released until the Contractor returns the control set of Plans and Specifications showing the as-built conditions. II-B-34 Agreement No. 5551 The full five percent (5%) retention will be deducted from all progress payments. The Contractor will make a payrnent request for the retained amount, for approval by the City, upon field acceptance of the work by the City Engineer. The City Engineer upon field acceptance and receipt of the final as-built plans and any other reports or documents required to be provided by the Contractor will process a recommendation to the City Council for acceptance of the work. Not less than thirty-five (35) calendar days from the City Council acceptance of the work,the Contractor's final payment will be made provided Stop Payment Notices or other claims have not been filed against the Contractor and/or the City by material suppliers, sub-contractors, other governmental agencies, and private property owners. Until these Stop Payment Notices are released and claims are resolved the stop payment/claim amount will be withheld from the ftnal payment. The Contractor, however, may receive interest on the retention for the length of � construction, or receive the retention itself as long as the retention is substituted with escrow holder surety or equal value. At the request and expense of the Contractor, surety equivalent to the retention may be deposited with the State Treasurer,or a State or Federally chartered bank,as the escrow agent, who will pay such surety to the Contractor upon satisfactory completion of the contract. Pursuant to PCC § 22300,the Contractor may sub�titute securities for retention monies held by the City or request that the City place such monies into an escrow account.The Contractor is notified, pursuant to PCC § 22300, that any such election will be at the Contractor's own expense and will include costs incurred by the City to accommodate the Contractor's request. Progress payment paid by the City as contemplated herein,will be contingent upon the Contractor submitting, in addition to any additional documents, an updated Contract Schedule in the form prescribed by these Contract Documents.Failure of the Contractor to submit an acceptable updated Contract Schedule will result in the City withholding partial payment,without liability to the City,until such an acceptable updated Contract Schedule is submitted. Nothing herein will allow the Contractor to suspend or slow progress of the Work. A City Council resolution established a Project Payment Account, encumbered money in the current budget, and assigned that money to the Project Payment Account which is the sole source of funds available for payment of the Contract Sum. Contractor understands and agrees that Contractor will be paid only from this special fund and if for any reason this fund is not sufficient to pay Contractor, Contractor will not be entitled to payment. The availability of money in this fund, and City's ability to draw from this fund, are conditions precedent to City's obligation to make payments to Contractor. 9-3.3 DELIVERED MATERIALS II-B-35 Agreement No. 5551 Subsection 9-3.3 Delivered Materials, of the Greenbook is deleted in its entirety and replaced with the following: Materials and equipment delivered or stored, but not incorporated into the work, will not be approved for progress payments. 100-1 TERMINATION OF AGENCY LIABILITY The following Subsection 100-1, Termination of Agency Liability, is added to the Greenbrook: Before receiving final payment, the Contractor will execute a "Release on Contract" form which will operate as, and will be a release to the City,the City Council,and each member of the City Council and their agencies, from all claims �nd liability to the Contractor for anything done or furnished for, or relating to,the work or for any act of neglect of the City of any person relating to or affecting the work, except the claim against the City for the remainder, if any there be, of the amounts kept or retained as provided in Subsections 9-3 of the Standard Specifications and except for any unsettled claims listed on said form which have been filed in compliance with the requirements for making claims. - END OF SECTION- II-B-36 Agreement No. 5551