The URL can be used to link to this page

CONTRACT 5436 Developer’s Agreement This page is ent-DONOT DISCARD w of your 20180013448 � woa � � `8850 IIIIIII�IIIIIIIVI�IIVIY�IYIIIIIVIIIVIVIIII�VIIIIIIIIIIINI�VI�II�NIIIIII�II IIIIIIIIVIVIIIVIIIIIRIIllsnlllIIIAVIIIIIIIIIVIIILIIIYIIVIIIIVIIIIIIIII Recorded/Filed in Official Records Recorders Office, Los Angeles County, California 01/04/18 AT 01:16PM FEES: 0.00 TAXES: 0.00 OTBER: 0.00 PAID: 0.00 LEADSHEET 201801040920015 00014744913 imumiuii��miNWmm 01 i� 008828380 iuiCounter (Upfront nmiau� Scan) xm � u � RECORDING REQUESTED BY EL SEGUNDO CITY CLERK WHEN RECORDED MAIL TO CITY CLERK *20180013448* CITY OF EL SEGUNDO 350 MAIN STREET EL SEGUNDO, CA 90245 RE: DA Dated 10-3-17 ORD#1556 SPACE ABOVE THIS LINE RESERVED FOR RECORDER'S USE TITLE REVISED & RESTATED DEVELOPMENT AGREEMENT (AREA A) i'l!�� 11 ki 1111 fl�, 11 Thursday, January 04, 2018 1 :16 PM Item(s) Fee Qty Total Recorded Document Count = 1 20180013448 FREE RECORDING 1 $0.00 AB 1168 REDACTION FEE 1 MOO Electronic Recording Fee 1 MOO Micrographics Fee 1 $0.00 Days of Operation Fee 1 $0.00 Indexing 1 $0.00 ADDITIONAL PAGE FEE (REVS 78 $0.00 ADDITIONAL PAGE FEE (STAT 78 $0.00 ADDITIONAL PAGE FEE (IMPR 78 MOO Subtotal $0.00 Total $0 . 00 Customer payment(s): EXHIBIT"A" TO ORDINANCE NO. 1556 . N3 6 RECORDING REQUESTED BY AND WHEN RECORDED MAIL TO: CITY CLERK CITY OF EL SEGUNDO 350 Main Street El Segundo, California 90245 EXEMPT FROM RECORDER'S FEES Pursuant to Government Code § 6103 REVISED AND RESTATED DEVELOPMENT AGREEMENT BY AND BETWEEN THE CITY OF EL SEGUNDO, PES PARTNERS, LLC AND STREET RETAIL, INC. (AREA A) THIS AGREEMENT SHALL BE RECORDED WITHIN TEN DAYS OF EXECUTION BY ALL PARTIES HERETO PURSUANT TO THE REQUIREMENTS OF GOVERNMENT CODE §65868.5 43 TABLE OF CONTENTS 1. Recitals.......................................................................................................................................1 2. l"rtrr°ttr_licet to this Arcerncrrt...........................................................................................1 3. Binding..Effect................................................................. ....................................................a...,,.4 _ 3.1 Constructive Notice and Ace"oplLipcc,.......................................................................4 3.2 1e4,,hts to Assi n.......................................................................................................4 3.3 Liabilities Upon...Transfer.........................................................................................4 ...."...................rr_...................................._ .. ..................... 4. Developrlrcrrt of the 'rerpe•t ......................................................................................................4 m4.1 Permitted Uses........................................................................... ............................4 4.2 Limitations on Uses. ........ ...... ......... 5 4.2.1 Sales°l a (icraeratirt........ ...........................................................................5 4.2.2 Food to Go Restaurant................................................................................ 5 4.2.3 Fast Food Restaurants..................................................................................5 4.2.4 Automobile Sales.........................................................................................5 4.2.5 Farmer's Market ..........................................................................................6 4.2.6 Parkhj ....................................................................................................... 6 4.2.7 Morimnerit Sirw*n............................................................................................6 4.3 F)eve, w ...........................................................................................6 4.3.1 Tenant/Owner Use Space.................................... .....,, ......,...........,.,.,,....6 4.3.2 Limitations on Minimum Square Footave of Buildings and S aase n1)' ............................. 4.3.3 Transfer of Development Rights..................................................................6 4.4 13t,riILIi I 10,t411dmai•cls. .................................................................................................7 4.5 1 e ,� s. .1 . _ ...........LIre (;or�elitic N-k�; l "" _.... rtt titrrrs Mrti. rticrr°r Meas., Dedications ..............................................................................................................7 4.6 Use of Easements.................................................................................................... 7 5. Vcstarr ;...srl"Qeve o 2 ncnt...1 i ts.................................................................................................7 __._ 5.1 Mplicable 1�trlcs... ...................................................................................................7 5.2 l;ntitlerrient to Develop............................... ............................ ..........................7 5.3 SUbsemiew l.:nactincrlts ...........................................................................................8 5,4 l°trttrre ............. ,..,........,,,,.,,.,,...8 5.4.1 Minor Modifications tolIr.oieel....................................................................8 5.4.2 Modillcatioll ol'mll)rmefj.ecttt.._ le115........................................ 5.4.3 Modifications Requiring Amendment to this Agreement............................8 5.5 Plan Review ..................... ,.,........ ......,.,.,.9 5.6 ml inn i caf:M..I oy nlITol?"le pmt. ...................................................................................... 10 5.7 Term .................................................................................................................. 10 5.8 lssmime cel"BrrildiriQ Permits.................................................................................10 5.9 Satisfrrcticrri of M itit»aticrrr Measures and Conditions ............................................10 __..... _...__ . 11 . 5.10 Moratorium.................................................... .......................................................10 5.11 l'erlcarnr,trIcc 01"(;itv 1'latmirt artcl Btrild'im-, Safety Director Duties.................... 11 6, Devcl(Mer A�,recrncrits ............................... ............................................................................11 6.1 General.................................................................................................................. 11 6.2 Develooincntlrccs.................................................................. ....................,,,11 ii 6.3 Mmiii{coamce Ob|i .....................................-_ ............ -........ ---.-_ l] 6/4of-Map(s) aiiL OtherPrOect ......-----..--_. ......--...... ]l 6.5 Sales and Use]�ax-_... ....................... .-._.........._-................... ..... -.....}l 6.6 Future Construction Activities........ --........... ._.._._......_.~...................l2 6.7 Park Place Extension ...............-----... ........................ .........~---... 12 6.7.1 Park Place Extension Requircmciit...... ..........-- .......... -_--............l2 6.7.2 Park Place Extension Funding............................................................]3 6.7.3 lrrcvncublcOffers to Dedicate ------------------_---l3 6.7.4 PumliD . ............................................................- ................... 14 6.7.5 6si1iog and Construction of the Park Place Extension...--_...........-................... ............ - ..... 15 6.7.6Pudk Place Extension ofPark Place ---l5 6.7.7 (��ty /\ckn0vwled1�eW 'bifities mid Izeco[daiiom _---------.--.-.---_-------.l5 6.8 ........ ... .........l5 7. .......................................................... .......................... ......16 7.1 ['xnnedited Processi g..... .............. -. ....... -...... ............ ......-..--.--.-- ... l6 7.2un� ---- ...... 7.3 Processing During Third P:rtv Litigation......... _........-.-..........-.......... ....l6 @. tispeomioii ...........----........... ............... .......... ...... ......------- ....l6 g. Faith Compliance.........-- .......... -- .........._._~..._.......... l7 9] Review o[Co[Pp1i�aoce..............................................................-...................... 17 4.2 Good ..................................... -.-......-- ...... - ...........--. l7 9.3 Information to be Provided .........--................--_---. ........... 17 9/4 Notice of NOii-Conndiaulmo; Cnre ......._.. ....... ...-......... ....... l7 9.5Determination of�� [�Ql ........ - ...... -----_---_-~.. l7 4.6 Failure ofPeriodic Review......................... ...__ ......... .,............................ l8 10. !e ,De}ays---.------------_....._......._..~...-,.._---.---.. l@ l]. l}ufan] ................. ....... -........ .-......... ........... ............ ---_--_.-........ l8 ll.] Default ..... .................................... . ........ .-.----_-__....._...-.......... l8 11.2 Content ofNotice of Violation............ -................. ...... ......... ............. -- ]A 11.3Remedies for .......-........-..-_-------------------. 19 12. _-........................-------_-__.._........_..._.... 19 99 12.1 Mortg ge Not ......... ..........--......^..........,.~... ........._..... 14 12.2 lZeomst forNotiue to Mo ................................................ ...... ---- .... l4 12.3 Time to Cure.............................................---------- ........- lg 12/4 (.'VneRi,dits .................................----........ _.............. ...-.~............... ....20 12.5 13apkrUptcy........................-_- ........ .......-......... ...........'....... ........ - ....-.20 12.6Disaffirmation-..---.._..-._...........-.-..-.--.-_._._,-__,..',20 13. Certificate ............................................. ---- ...... _...._......._...........20 14. Adnmioislr�i1ixoo[/\u-ecineli1.....................-....... ...... --- ........ ~^^~'~^^^^~^~'^`^^~'''2] 14.1 ADpeal of Staff Determinations...................._.............--..-- ........ --.2l 14.2 eruoruida........................................................-......_--- .......-_2] 14.3 Cert i fic.ate of Performance............................................ ....._........... ........... ...2l 15. Amendment orTcrozitxatioilhyMVtLWl ('0nSC0t...... - .......... ---_--.....-._...._..2} iii 16. .....................,'............. ,---21 16.1 Indemnification.......................... -- ......... _.___..........~,..-....... ........._ 21 16.2 [)elciiscof .................—._..__..--...................,................_...... 22 17. Time of Essence .... —.—..........----__..-..-..,.........~.._.......... — ................ ....22 }@. ..... __........ __,,_^,,,~.,,.^ ......,—..— ........_— ......... ----------22 19. ��,,,,�.��,,,,.�� —��,,.��,,. 22 20. Eot��/es.��[ecc0cU(........................ ...... ........._..—__...._......_......... ......... ..................23 21. {�oniiti ..............................~..............................—~-- ...... — .......--...23 27. Waiver.....................................................---_----_.—.__._._-............ ......._....23 23. SeveraH[itv...... ...... -----------_--_—......._.. .........-...._............._...~. 23 24. Relaioouhii) of the ._...-.._........ ............... ........-----------. ...... —. 23 25. NoThird Part Beneficiaries...................--- ...... —_—.—..................._.....,...... .24 26. 1�ccp[(lati8m0f -------.—...-----.--------..?4 27. Botvvccu (��ynud ...................................................—_......_—__.24 28. Rules of Construction...... . ........... ...... ----_._._...^._._..............................24 29. Joint ....... —........... ._.~-.._........ ....... -..—_........ ------ ...... --.74 30. Governing Law and Venue~............ ................ --------------_----_—_.24 31. Att$mley9^ Fees....................... ---- ........ —__......... ........ .......................—.—.........24 32. .......... .... ........._..__.-._.......~...~.................... --.------ ...... —.24 33. Dates ............................... ......... —..... ......—..........~..... ................?4 34. Not uPublic Dedication..................— ...... _...-.........._.............—....—....~. .....25 iv REVISED AND RESTATED DEVELOPMENT AGREEMENT This Revised and Restated Development Agreement (the "Agreement") is made and entered into by and between the CITY OF EL SEGUNDO,a municipal corporation(referred to hereinafter as "City"),PES PARTNERS, LLC, a California limited liability company and STREET RETAIL, INC. (itxd'ivi(otially and collectively referred to hereinafter as "Developer") as of this W" day of 0 , 2017. City and Developer are referred to hereinafter individually as "Party" and collectively as "Parties". In consideration of the mutual covenants and agreements contained in this Agreement, City and Developer agree as follows: 1. lZeciWs. This Agreement is made with respect to the following facts and for the following purposes, each of which is acknowledged as true and correct by the Parties: 1.1 Pursuant to Government Code Section 65865 et seq., City is authorized to enter into a binding contractual agreement with any person having a legal or equitable interest in real property for the development of such property. 1.2 Developer is the owner of that Property which is more particularly described in EXHIBIT A,which is attached hereto and incorporated herein by this reference(the"Property" or"Area A"). 1.3 Developer and/or Developer's Predecessors in Interest have entered into a Development Agreement with the City regarding the Property and six amendments thereto as well as an Operating Memorandum with regard to the Development Agreement. A summary of each of the previous approvals, the related entitlements and the recording information is more particularly described in EXHIBIT B, which is attached hereto and incorporated herein by this reference. 1.4 The City certified a Final Environmental Impact Report for Environmental Assessment No. 631 (SCH No.2003121037)(the"EIR"), and approved the Mitigation Monitoring Plan for the EIR; General Plan Amendment No. 03-4, Zone Change No. 03-2, Zone Text Amendment No. 04-1, Subdivision No. 03-7 (Vesting Tentative Tract No. 061630), and the Original Development Agreement No. 03-1 (the foregoing are collectively referred to as the "Original Project"). Concurrently with the City's approval of the Original Project, as part of General Plan Amendment No. 03-5, Zone Change 03-3, and Zone Text Amendment No. 04-1,the City redesignated and rezoned other property in the vicinity of the Property with a "Commercial Center (C-4)" land use and zoning designation (the "Other C-4 Property.") This area is approximately 85.8 acres. 1.5 The City prepared Addendums for the Second and Fifth Amendments to the Development Agreement. It was determined that no other CEQA documentation was required for the First, Third, Fourth and Sixth Amendments to the Development Agreement. u 4 1.6 The Development Agreement relates to the development of a total of 51.70 gross/46.60 net (after street dedication) acres. The Development is broken up into two Phases. Phase IA is commonly known as Plaza El Segundo and is approximately 3 3.5 5 acres. Phase 1B is commonly known as The Point and is approximately 18.15 acres. The total square footage allowed prior to this Agreement was 498,442 gross square feet that includes large retail stores, specialty retail stores, sit-down restaurants and other uses (the "Project"). Phase IA currently consists of approximately 379,495 square feet. Phase 1B currently consists of approximately 117,914 square feet. 1.7 This Revised and Restated Development Agreement authorizes up to an additional 18,850 square feet to be developed in either Phase 1A or Phase 1B in accordance with the provisions of this Development Agreement for up to a total gross square footage of 517,292 square feet. Additionally, this Agreement makes other changes that will help insure the success of the shopping centers by allowing additional uses and eliminating specific square footage requirements of allowed uses to provide more flexibility in the mix of tenants allowed in the Property. 1.8 The trip caps established by the original approvals will remain in place. Additionally, Developer and City have agreed to a percentage limit of non-taxable uses in each shopping center to insure the City continues to receive a tax benefit from the project. 1.9 By this Agreement, each Party desires to obtain the binding agreement of the other Party to develop the Property in accordance with the Project Approvals,Applicable Rules and this Agreement. In consideration thereof, City agrees to limit the future exercise of certain of its governmental and proprietary powers to the extent specified in this Agreement. Developer agrees to waive its rights, if any, to challenge legally the limitations on density and use imposed upon development of the Property and other restrictions and obligations set forth in this Agreement and the Project Approvals. 1.10 City and Developer have acknowledged and agreed that the consideration that is to be exchanged pursuant to this Agreement is fair, just and reasonable and that this Agreement is consistent with the General Plan of City. 1.11 This Agreement is intended to provide flexible entitlements, within the parameters set forth herein and subject to the terms and conditions hereof, to meet the changing market demands that are likely to occur throughout the buildout of the Project. 1.12 The proposed Project uses are consistent with the City's General Plan, as amended, (the "General Plan"). 1.13 Development of the Project has, and will continue to, further the comprehensive planning objectives contained within the General Plan, and will result in public benefits, including, among others, the following: 1.13.1 Fulfilling long-term economic and social goals for City and the 2 community; 1.13.2 Providing fiscal benefits to City's general fund in terms of increased employment and utility, business license, property and other tax revenues, which are anticipated to exceed $1,000,000 annually; 1.13.3 Providing both short-term construction employment and long-term permanent employment within City; 1.13.4 Phasing the construction of public infrastructure improvements with private development; 1.13.5 Eliminating blighted areas and providing an attractive urban destination; 1.13.6 Facilitating environmental remediation on and around the Property; 1.13.7 Funding planned circulation element improvements at no cost to the City; and 1.13.8 Creating significant offsite public improvements, including streets, signals, medians and landscaping. 1.14 On August 24, 2017, the Planning Commission of the City commenced a duly noticed public hearing on this Agreement, as well as the related Zone Text Amendment and Site Plan for the increased square footage (collectively "Project Approvals"), and considered the Addendum that was prepared for these matters. At the conclusion of the hearing recommended that the City Council approve this Agreement, the related Zone Text Amendment, Site Plan and Addendum. 1.15 On September 19, 2017, the City Council of the City ("City Council") commenced a duly noticed public hearing on this Agreement, as well as the related Zone Text Amendment and Site Plan for the increased square footage, and considered the Addendum that was prepared for these matters. Prior to approving this Agreement by Ordinance No. 1556 (the "Enabling Ordinance"), the City Council adopted Resolution No. 5053 approving the Addendum. 1.16 Section 15 of the Original Development Agreement provides for amendment of the Development Agreement upon mutual consent of the parties and in accordance with the procedures established by the Development Agreement Act. The City Council found that this Revised and Restated Agreement has been adopted in conformance with the procedures of the Development Agreement Statute set forth in Government Code §§ 65865, et seq. 2 1_11 oy tQ fti.i .A.gre��1lew. All of the Property shall be subject to this Agreement. 3 3. 1 indim-, L 41;ect;. The burdens of this Agreement are binding upon, and the benefits of the Agreement inure to the City and the Developer and each successive successor in interest thereto and constitute covenants that run with the Property. Any and all rights and obligations that are attributed to the Developer under this Agreement shall run with the land. 3.1 Constructive Notice and Accouince. Every person who acquires any right,title or interest in or to any portion of the Property in which the Developer has a legal interest is,and shall be,conclusively deemed to have consented and agreed to be bound by this Agreement, whether or not any reference to this Agreement is contained in the instrument by which such person acquired such right,title or interest. 3.2 16,0its to Ass4oi. Developer may assign or transfer its rights and obligations under this Agreement with respect to the Property,or any portion thereof,to any person at any time during the term of this Agreement without approval of the City. 3.3 1li.r apc�MITu,,"I„Jm (g:. Upon the delegation of the duties and obligations ..i.��. �t i� ...i. under this Agreement and the sale, transfer or assignment of all or any portion of the Property, Developer will be released from its obligations under this Agreement with respect to the Property, or portion thereof, so transferred arising subsequent to the effective date of such transfer, if(i) Developer has provided to the City prior or subsequent written notice of such transfer and (ii) the transferee has agreed in writing to be subject to all of the provisions hereof applicable to the portion of the Property so transferred by executing an Assignment and Assumption Agreement in the form of EXHIBIT C attached hereto and incorporated herein by reference. Upon any transfer of any portion of the Property and the express assumption of Developer's obligations under this Agreement by such transferee, the City agrees to look solely to the transferee for compliance by such transferee with the provisions of this Agreement as such provisions relate to the portion of the Property acquired by such transferee. Any such transferee shall be entitled to the benefits of this Agreement as"Developer”hereunder and shall be subject to the obligations of this Agreement applicable to the parcel(s) transferred. A default by any transferee shall only affect that portion of the Property owned by such transferee and shall not cancel or diminish in any way Developer's rights hereunder with respect to any portion of the Property not owned by such transferee. The transferee shall be responsible for satisfying the good faith compliance requirements set forth in Section 9 below relating to the portion of the Property owned by such transferee, and any amendment to this Agreement between the City and a transferee shall only affect the portion of the Property owned by such transferee. 4. Develop nerd of f till 11ror)er°ty. The following provisions shallgovern the subdivision, development and use of the Property. The limitations imposed within this Agreement are primarily intended to ensure that the Project remains principally retail in nature, while allowing additional uses that complement the retail tenant base in order to maintain a thriving retail center with minimal vacancies. 4.1 Permitted 1Jscs. The permitted and conditionally permitted uses of the Property are those set forth in the City's Municipal Code for the Commercial Center(C-4) zone. 4 4.2 Limitations on Uses. 4.2.1 Each of the allowable uses in the C-4 Zone can be categorized as either"Sales Tax Generating" or"Non-Sales Tax Generating," as defined herein. While the City recognizes that Non-Sales Tax Generating Uses are essential to maintaining a viable tenant mix, the City desires to maximize the overall percentage of Sales Tax Generating Uses on the Property. Accordingly, Developer, and its successors and assigns, agree that, at all times during the term of this Agreement, the uses on the Property will be maintained in accordance with the following proportions. For purposes of the calculation, the percentage is based on total gross leasable area. AREA Sales Tax Generating Non- Uses Sales Tax Generating Uses ..... Phase I—Plaza El Segundo 80 % minimum 20% maximum Phase 1B —The Point 65%minimum 35%maximum For purposes of this section, "Sales Tax Generating Uses" includes retail sales uses (including grocery stores), restaurants and cafes, bars, and micro-breweries. "Non-Sales Tax Generating Uses" includes financial institutions, day spas, fitness centers, farmers' markets, offices of all types, personal services, recreational facilities, public assembly/assembly halls (including theaters and museums), billiard establishments, and veterinary services. The City's Finance Director, in his/her discretion, will determine whether any use not specifically listed here should be classified as Sales Tax Generating or Non-Sales Tax Generating. The Finance Director's determination may be appealed to the City Council. Any such appeal must be made in writing and delivered to the City Clerk within ten calendar days of the Director's decision. 4.2.2 Food to Go Restaurant. "Food to go"restaurants(defined in Section 15-1-6 of the El Segundo Municipal Code) shall not be allowed anywhere on the Property as a permitted or conditionally permitted use. 4.2.3 Fast Food Restaurants. Unless such use is incidental to the primary business of an occupant of a building, "Fast food" restaurants are prohibited in Phase IA within 150 feet of Sepulveda Boulevard and in Phase 1B within ninety (90) feet of Sepulveda Boulevard or Rosecrans Avenue. "Fast food"restaurant is defined as"A restaurant where customers purchase food and beverages and either consume the food and beverages on the premises within a short period of time or take the food and beverages off the premises. Typical characteristics of a fast food restaurant include, without limitation, the purchase of food and beverages at a walk-up window or counter, no table service by a server, payment for food and beverages prior to consumption, and the packaging of food and beverages in disposable containers. A restaurant is not considered a fast food or take-out restaurant solely on the basis of incidental or occasional take-out sales. 4.2.4 Automobile Sales. The indoor sale of automobiles and, as an 5 accessory use to the sale of automobiles, the sale of automobile accessories and automobile parts shall be permitted in Phase 1B, provided such use does not exceed 5,000 square feet of leasable floor area and provided that automobile repair and maintenance uses shall not be permitted. 4.2.5 Farmer's Market. A certified Farmer's Market, at which farmers and other vendors sell produce, baked goods, dairy products and other food and retail goods directly to consumers, is permitted to operate in the parking lot of Phase 1. A musician may be present, with amplified sound. The market will typically operate one day per week and only between the hours of 8:00 a.m. and 3:00 p.m., with set-up between 7 a.m. and 8:00 a.m. and clean- up between 3 p.m. and 4 p.m. The Farmer's Market is not allowed to operate on the same day as the Farmer's Market that operates in Downtown El Segundo. A site plan that includes the location of the Farmer's market must be reviewed and approved to the satisfaction of the Director of Planning and Building Safety. 4.2.6 I'a1°kinm,. The total number of parking spaces provided on an individual parcel need not comply the El Segundo Municipal Code,provided that the total number of parking spaces within the entire Phase 1 Shopping Center conform to the El Segundo Municipal Code and provided that such parking spaces remain collectively available and accessible to all tenants of the Phase 1 Shopping Center and their customers, employees and invitees. 4.2.7 N101I1:11ne11t Si�41i. For the 65 foot monument sign along the Allied Way street frontage for the area currently known as "The Edge," copy relating to tenant identification shall be limited to that portion of the sign below 3 5 feet in height. All copy on the sign above 35 feet shall be restricted to identification of the shopping center itself. 4.3 I-)evcic pinciit Sti11ichii-,c[s. All design and development standards that shall be applicable to the Property ("Development Standards") are set forth in the El Segundo General Plan, the El Segundo Municipal Code, the Applicable Rules, the Project Approvals, and this Agreement. Additionally, the following restrictions apply: 4.3.1 Tenant/Owner Use Space. No single use within the Project shall exceed 125,000 square feet of gross floor area in size. 4.3.2 Limitations on Min mum,Square Footage of,l�iiiIcIim_,s and Space— I?lime 1 m 0 1y. A maximum of 75,000 square feet of the allowable building area in the Phase IA area can be developed and/or utilized for uses that occupy less than 4,000 square feet of building space each. With respect to such 75,000 square feet, a maximum of 8 building pads may be less than 4,000 square feet each. As used in this Agreement, the term "building pad" means the total ground floor area of any individual building constructed on the Property. 4.3.2.1 There is no limitation on the number of uses that may occupy less than 4,000 square feet in Phase 1B. 4.3.3 Transfer of„Development I�i�l�ts. The Developer shall have the right to transfer floor area between parcels that are created within Area A as a part of the Project 6 Approvals so long as no parcel exceeds a floor area ratio of 0.6:1. Such transfers of floor area shall be recorded against the properties involved in the transfer of floor area in accordance with the requirements of the C-4 Zoning. The Planning and Building Safety Director or designee must review the application for transfer of floor area to ensure conformity with the requirements of this Section 4.3.3. This review shall not be subject to a public hearing process. Transfer of floor area from properties located outside of Area A to any parcel within Area A is strictly prohibited. 4.4 BUildiMI Staridat-ds. All construction on the Property shall adhere to the California Building Code, the California Electrical Code, the California Mechanical Code, the Uniform Sign Code, the Uniform Code for Abatement of Dangerous Buildings, and Uniform Administrative Code in effect at the time an application for a building permit is submitted and to any federal or state building requirements that are then in effect(collectively the"Building Codes"). 4.5 Fees, w Exactions, Mitigation Measures Conditions„, Reservations and l)sMdica(„i_ops. All fees, exactions,mitigation measures, conditions,reservations and dedications of land for public purposes that are applicable to the Project or the Property are set forth in the Applicable Rules, the Project Approvals and this Agreement. Additionally, Developer shall pay all applicable fees that are in effect at the time that fees are required to be paid pursuant to Section 6.2 of this Agreement. This Section shall not be construed to limit the authority of City to charge normal and customary application, processing, and permit fees for land use approvals, building permits and other similar permits, which fees are designed to reimburse City's actual expenses attributable to such application, processing and permitting and are in force and effect on a City- wide basis at such time as said approvals and permits are granted by City. 4.6 Use of Easements. Notwithstanding the provisions of the Applicable Rules, easements dedicated for vehicular and pedestrian use shall be permitted to include easements for underground drainage, water, sewer, gas, electricity, telephone, cable, environmental remediation and other utilities and facilities so long as they do not unreasonably interfere with pedestrian and/or vehicular use. 5. Vestim, o6”Dcv(Jl )Uncut l i hts. 5.1 pplieabie Rules. The Applicable Rules shall consist of the following: 5.1.1 The General Plan, as it exists on the Effective Date; 5.1.2 The City's Municipal Code, including the Zoning Code, as the Municipal Code exists on the Effective Date; 5.1.3 Such other laws, ordinances, rules,regulations, and official policies governing permitted uses of the Property, density, design, improvement, and construction standards and specifications applicable to the development of the Property in force at the time of the Effective Date, which are not in conflict with this Agreement. 5.2 L'iititleineiit to Develon. The Developer is hereby granted the vested right 7 to develop the Project on the Property subject to the Applicable Rules, the Project Approvals and any future approvals applied for by the Developer and granted by the City for the Project or the Property (the "Future Approvals"). 5.3 S,,rbscoLIC11t 1,iiactnieaits. Any change in the Applicable Rules, including, without limitation, any change in any applicable General Plan or specific plan, zoning, or subdivision regulation, adopted or becoming effective after the Effective Date, including, without limitation, any such change by means of an ordinance, initiative, resolution, policy, order or moratorium, initiated or instituted for any reason whatsoever and adopted by the/city Council,the Planning Commission or any other board, agency, commission or department of the City, or any officer or employee thereof, or by the electorate, as the case may be (collectively the "Subsequent Rules"), which would, absent this Agreement, otherwise be applicable to the Property, shall not be applied by the City to any part of the Property. 5.4 Future Approvals. 5.4.1 Minor Modifications to Pmicct. Developer may make minor changes to the Project and Project Approvals ("Minor Modifications") without amending this Agreement upon the administrative approval of the City of El Segundo Director of Planning and Building Safety (the "City Planning and Building Safety Director") or designee, provided that such modifications are consistent with the Development Standards, Applicable Rules and Project Approvals. The City shall not unreasonably withhold or delay approval of any Minor Modification. The City shall have the right to impose reasonable conditions in connection with Minor Modifications,provided,however,such conditions shall not(a)be inconsistent with the Applicable Rules, the Project Approvals or with the development of the Project as contemplated by this Agreement; (b) directly or indirectly, unreasonably hinder, delay, impede, obstruct, interfere with, or place unreasonably burdensome or restrictive measures or requirements upon development of the Project or the Property or any portion thereof; or (c) impose additional dedications, infrastructure or public improvement obligations, fees, or exactions in excess of those identified in the Applicable Rules, the Project Approvals, or this Agreement. 5.4.2 Modification of Proicct At.hz�oyals. It is contemplated by City and Developer that Developer may, from time to time, pursuant to Section 5.4.1 seek amendments to one or more of the Project Approvals. Any such amendments are contemplated by City and Developer as being within the scope of this Agreement as long as they are authorized pursuant to this Section 5.4.2 and shall, upon approval by City, continue to constitute the Project Approvals as referenced herein. The Parties agree that any such amendments shall not constitute an amendment to this Agreement nor require an amendment to this Agreement. 5.4.3 Modifications l caiiirijw Ainctidinem to tli:!.`�. t�oa:.nient. Any proposed modification to the Project which results in any of the following shall not constitute a Minor Modification but rather shall constitute a Major Modification and shall instead require an amendment to this Agreement pursuant to Section 15 below: (a) Any decrease in the required building setbacks as set forth 8 in the C-4 Zone; (b) Any increase in the total developable square footage of the entire Property in excess of the maximum FAR allowed under the C-4 Zone; (c) Any increase in height of buildings or structures on the Property above 65 feet; (d) Any decrease in the minimum required lot area as set forth in the C-4 Zone; (e) Any decrease in the minimum required lot frontage as set forth in the C-4 Zone; (f) Except as set forth in Section 4.3.3 above, any change to the requirements of the transfer of development rights as set forth in the C-4 Zone; (g) Any increase in the maximum number of A.M. and P.M. peak hour vehicle trips for the Project as specified in the conditions of approval and Mitigation Monitoring and Reporting Program(MMRP),unless a subsequent traffic report has been prepared to the reasonable satisfaction of the City's Planning and Building Safety Director that identifies potential impacts and proposes feasible mitigation measures to mitigate such impacts and otherwise complies with CEQA; (h) Any change in use to a use which is not permitted under this Agreement; (i) Any deviation from the uses and development standards or limitations set forth in Sections 4.1, 4.2 and 4.3 of this Agreement, except to the extent such Sections specifically provide for the City Council to approve of alternative uses or square footage requirements; and (j) Any material modification to Developer's obligation to dedicate the public roadways to the City as provided in the conditions of approval and the MMRP. Other than the Major Modifications listed above, all other modifications to the Project shall be considered"Minor Modifications". 5.5 Plan Review. Plans for each building on the Property, including plans for signage, trash enclosures and screening and landscaping shall be reviewed and approved by the City Planning and Building Safety Director prior to issuance of a building permit; provided however,that,notwithstanding anything to the contrary contained in the Applicable Rules,the sole purpose of such review shall be to verify consistency with the Development Standards,Applicable Rules and Project Approvals. The City Planning and Building Safety Director shall approve all features which are consistent with the Development Standards, Applicable Rules or Project 9 Approvals or are otherwise specifically approved by this Agreement and shall have no authority to disapprove or conditionally approve any features or matters which are consistent with or otherwise have been specifically approved by the Agreement. 5.6 'I`iraaial ol'�. evelopa�ent. In 11ardce Coiislructioii C.o.,.....v.....C1,i.ty of(:''�ailldlrillo (Pardee), 37 Cal.3d 465 (1984), the California Supreme Court held that the failure of the parties therein to provide for the timing or rate of development resulted in a later-adopted initiative restricting the rate of development to prevail against the parties' agreement. City and Developer intend to avoid the result in Pardee by acknowledging and providing that Developer shall have the right, without obligation, to develop the Property in such order and at such rate and times as Developer deems appropriate within the exercise of its subjective business judgment subject to the terms of this Agreement. In furtherance of the Parties' intent, as set forth in this Section, no future amendment of any existing City ordinance or resolution, or future adoption of any ordinance, resolution or other action,that purports to limit the rate or timing of development over time or alter the sequencing of development phases,whether adopted or imposed by the City Council or through the initiative or referendum process, shall apply to the Property. However, noting in this Section shall be construed to limit City's right to enforce Developer's obligation pursuant to this Agreement to provide all infrastructure required by the project Approvals and this Agreement. 5.7 Term. This Agreement shall be in effect for a period of 20 years from the Effective Date of the Enabling Ordinance. However, Developer or City shall be entitled to, by written notice to the other Party prior to the Agreement's expiration,one(1)five(5)-year extension, provided that the requesting Party is not in material default of its obligations hereunder at such time. 5.8 Issuance of Bi6ldim Permits. No building permit, final inspection or Certificate of Occupancy will be unreasonably withheld, conditioned, or delayed from the Developer if all infrastructure required to serve the portion of the Property covered by the building permit, final inspection or Certificate of Occupancy is in place or is suitably guaranteed to be completed (by covenant, bond, letter of credit or otherwise) to the reasonable satisfaction of the City prior to completion of construction and all of the other relevant provisions of the Project Approvals, Future approvals and this Agreement have been satisfied. 5.9 atlsl actlora of"lt9iti ' taora Mca501VS arad (.'oaadatiorIs. In the event that any of the mitigation measures or conditions required of Developer hereunder have been implemented by others, Developer shall be conclusively deemed to have satisfied such mitigation measures or conditions, consistent with CEQA. If any such mitigation measures or conditions are rejected by a governmental agency with jurisdiction, the Developer may implement reasonably equivalent substitute mitigation, consistent with CEQA, to the City's satisfaction, in lieu of the rejected mitigation measures or conditions. Such substitution shall be deemed to be a Minor Modification pursuant to Section 5.4.1 above. 5.10 Moratoriaisaa. The City shall not impose a moratorium on the Property 10 unless such is necessary to protect a significant threat to the health, safety and welfare of the City. 5.11 Peribrinaiiee of City 1�1aM7.!rr '.._,111(1:.m..D. I�ilciirll _Sal :. ire t�l.:._I .liic . If the City determines at any time during the term of this Agreement that the duties to be performed by the City Planning and Building Safety Director under this Agreement will be performed by one or more staff members other than the Planning and Building Safety Director, the City shall endeavor to notify the Developer of such change. The City shall ensure that a person or persons are designated at all times to carry out the duties of the Planning and Building Safety Director set forth in this Agreement. 6. I)emyme1.o- er:...A cincilts. 6.1 (.epe,t;rl. The Developer shall comply with (i) this Agreement, (ii) the Project Approvals, including without limitation all mitigation measures required by the determination made pursuant to the California Environmental Quality Act, and (iii) all Future Approvals for which it is the applicant or a successor in interest to the applicant. 6.2 1)c%�elonnietit Fees. Subject to the provisions of Section 4.4 above, Developer shall pay the development fees in effect at such time that building permits are issued for the Project. The Developer shall be entitled to credits against the City's traffic mitigation fees to the extent off-site traffic improvements that are required by the Project Approvals are included in any subsequent traffic fee mitigation program adopted by the City pursuant to Government Code Section 66000 et seq. Such credits shall be based upon the actual audited costs and shall only be granted to the extent such improvements are constructed in accordance with all applicable state and local laws. The Developer waives any and all rights it may have to challenge development fees that are currently applicable to development within the City and the City's right to amend its current development fees and/or impose additional development fees. However, the Developer retains the legal right to challenge the amount of any such amended or increased development fees to the extent such are not in compliance with the requirements of Government Code Section 66000 et seq. as well as its right to receive credits against such amended or increased fees. 6.3 1" aiii(emincc t)bl4,nrtioris. The Developer shall maintain all portions of the Property in its possession or control, and any improvements thereon, in a first class clean,neat and orderly manner. The Parties' respective maintenance obligations shall survive any termination or expiration of this Agreement. 6.4 Term of Mop(s) and OthgL..Project Approvals. Pursuant to California Government Code Sections 66452.6(a) and 65863.9, the term of any subdivision or parcel map that has been or in the future may be processed on all or any portion of the Property and the term of each of the Project Approvals shall be extended for a period of time through the scheduled termination date of this Agreement as set forth in Section 5.7 above. 6.5 Sales and Use Tax. (a) In the event the contract price for any work on the Project is 11 valued at five million dollars ($5,000,000,000) or more, Developer agrees to report, on a State Board of Equalization Tax Return,any purchases of tangible personal property made in connection with the finishing of and/or installation of materials, or fixtures for the Project, when such purchases were made without sales or use tax due. Developer shall indicate the City as a registered job site location on the State Board of Equalization Tax Return. In such event, Developer shall also obtain a permit or a sub-permit from the State board of Equalization indicating the City as the registered job site location, in accordance with State Board of Equalization Operations Memorandum No. 1023. (b) Developer further agrees that if Developer retains contractors or subcontractors to perform a portion of work in the Project, and said contracts or subcontracts are valued at five million dollars ($5,000,000) or more, said contracts or subcontracts shall contain the provisions set forth in Subsection(a) above. (c) The Director of Finance of the City is authorized to relieve Developer, and Developer's contractors and subcontractors, from the requirements set forth in this Section 6.5 upon proof to the reasonable satisfaction of the Director of Finance that Developer and/or its contractors or subcontractors have made good faith efforts to obtain said permit or sub- permits, but were denied the same by the State Board of Equalization. 6.6 Future Construction Activities. Future development in the C-4 Zone will likely involve the construction of significant public infrastructure improvements (including, without limitation, public roadways and utilities). The Developer, owners and occupants of the Property are hereby on notice that such construction activities may result in reduced access to the Property and other temporary physical and financial negative impacts to the Property and the uses thereon due to traffic re-routing, noise, dust, vibration and other normal and temporary construction related impacts. Developer and owners of the Property agree not to file any claims or legal or equitable actions against the City, or against other developers in the C-4 Zone, relating to, or arising from, temporary negative impacts associated with the construction of public improvements; nor shall Developer or the owners of the Property seek to enjoin the construction activities or seek damages based upon or arising out of alleged or actual temporary business interruption to or temporary business financial losses incurred by the Developer, owners or occupants of the Property. The Developer and owners of the Property agree to include a similar provision in all future leases, or future amendments to current leases and the City shall be listed as a third-party beneficiary to such provision. This provision shall survive the termination of this Agreement and shall remain in effect for a period of 30 years from the effective date of this Agreement. 6.7 Par „„ P lace Extension. The Second Amendment to the Original Development Agreement contained provisions which provided as follows: 6.7.1 Park Place Extension Requirement. Concurrently with the City's approval of the original Project Approvals, the City also redesignated and rezoned the Other C-4 Property with a "Commercial Center (C-4)" land use and zoning designation. In connection with the development of the Other C-4 Property, Developer has acknowledged that, as an integral part 12 u. of being permitted to fully develop the Other C-4 Property,Park Place(a four-lane east-west street) will be required to be extended from its existing terminus at Nash Street to connect with Park Place in Area A(the"Park Place Extension"). To affirm Developer's commitment to develop Park Place as an integral part of the development of the Other C-4 Property if Developer or an affiliate acquires and develops substantially all of the Other C-4 Property, City has requested and Developer has agreed that as Developer, or any affiliate of Developer, acquires portions of the Other C-4 Property, to the extent such acquired portions of the Other C-4 Property include segments of the right-of-way for the Park Place Extension(the"Park Place Segments"),Developer or its affiliate shall cause the Park Place Segments to become the subject of an irrevocable offer of dedication to the City. 6.7.2 Park Place Extension Funding. In addition to agreeing to cause the Park Place Segments to become the subject of an irrevocable offer of dedication in accordance with the provisions of Recital 6.7.1 above, Developer has agreed, subject to the satisfaction of the "Park Place Extension Conditions Precedent" (as hereinafter defined)and certain other conditions (set forth is the remainder of this section 6.7 below), to fund up to Two Million Four Hundred Eighteen Thousand Dollars ($2,418,000) (the "Park Place Extension Fund") to City in order to permit City to undertake the activities to extend Park Place which includes (a) that portion of the Park Place Extension(the"Honeywell Park Place Segment")that is currently owned by Honeywell International("Honeywell"),(b)that portion of the Park Place Extension(the"Chevron Park Place Segment")that is currently owned by Chevron Corporation("Chevron")and(c)that portion of the Park Place Extension(the"Union Pacific RR Park Place Segment")that is currently owned by the Union Pacific Railroad. The approximate locations of the Honeywell Park Place Segment, the Chevron Park Place Segment and the Union Pacific RR Park Place Segment are depicted on EXHIBIT D attached hereto and incorporated herein by reference. In order to secure Developer's obligation to make the Park Place Extension Fund payment, Developer has agreed to cause Developer's affiliate, Rosecrans-Sepulveda Partners, 4, LLC's ("RSP 4") to execute the "RSP 4 Deed of Trust" (as hereafter defined) in favor of City covering approximately 8.76 acres of the Other C-4 Property currently owned by RSP 4 (the "RSP 4 Property"). In addition, in order to ensure that Developer complies with its Park Place Extension Fund obligation, Developer has agreed that a condition precedent to Developer's right to receive a Certificate of Occupancy for any building in the Other C-4 Property shall be RSP 4's execution of the RSP 4 Deed of Trust. 6.7.3 Irrevocable Offers to Dedicate. To the extent Developer, or any affiliate of Developer, acquires any portion of the Other C-4 Property and such acquired portion contains any portion of the designated right-of-way for Park Place, Developer shall execute, or cause its affiliate to execute, an irrevocable offer to dedicate such designated right-of-way portion of Park Place to the City. As used in this Section 6.7, the term "affiliate" shall mean an entity controlling, controlled by or under common control with the entity to which the term applies, whether by ownership, contract or voting control. In addition, the term "affiliate" shall mean any entity that was a member of RSP 2,which was a predecessor in interest to Developer("Member"), which Members included Mar El Segundo, LLC, a Delaware limited liability company, CCA Sepulveda,LLC,a California limited liability corporation,Continental Rosecrans-Sepulveda,Inc., a California corporation, Daniel Romano, an individual, and any affiliate of any Member. The term "affiliate" shall also include, individually, Richard Lundquist, Allan Mackenzie, Robert 13 Comstock and Daniel Crosser. Notwithstanding the foregoing,no irrevocable offer to dedicate shall be accepted by City until (a) the alignment of the right-of-way for the Park Place Extension has been approved by the City Engineer and any other governmental agencies having jurisdiction over such right-of-way and (b) City has initiated such steps as may be required to acquire the right-of- way for those portions of the Park Place Extension, including, without limitation, those portions owned by existing railroads, pipeline easement holders, utilities and/or other third parties whose rights could impact or interfere with the construction and use of the Park Place Extension, that have not otherwise been offered for dedication to City (cumulatively, the "Park Place Extension Conditions Precedent"). 6.7.4 Developer's Funding of City's Acquisition of the Honeywell, Chevron and Union Pacific RR Park Place Segments; Security for Developer's Performance. Subject to the satisfaction of the Park Place Extension Conditions Precedent and to all applicable governmental permits and requirements (federal, state and/or local) including, without limitation, compliance with CEQA and laws relating to hazardous materials, having been obtained and/or satisfied with respect to the approval, design, remediation and construction of the Park Place Extension and a funding plan for the design and construction of the Park Place Extension having been approved by City (which funding plan may include Developer's payment of the Park Place Extension Fund in accordance with the provisions of this Section 6.7 and any other dedications and payments as Developer, or any Developer affiliate, may agree to in connection with the development of Area B), Developer agrees, upon the (a) commencement by City of acquisition of the right-of-way for the Honeywell Park Place Segment, the Chevron Park Place Segment and/or the Union Pacific RR Park Place Segment, and (b) award of a construction contract to extend Park Place to pay, within thirty (30) days of Developer's receipt of a written request from City, to City that portion of the Park Place Extension Fund to the extent City requires all or any portion of such Fund in order to complete its acquisition of the Honeywell, Chevron and/or Union Pacific RR Park Place Segment(s). In order to secure the obligation of Developer to make the Park Place Extension Fund payment,Developer shall cause RSP 4 to execute and record a Deed of Trust secured by the RSP 4 Property, such Deed of Trust to be in a form mutually and reasonably agreed upon by City and RSP 4 (the "RSP 4 Deed of Trust") and shall only be subject to the encumbrances identified on EXHIBIT E attached hereto and incorporated herein by reference. Developer shall cause an ALTA title policy in the amount of$2,418,000 to be issued to the City for the RSP 4 Deed of Trust. In order to ensure RSP 2's performance in accordance with the provisions of this Section 6.7.4, no Certificate of Occupancy shall be issued by City for any building in Phase 1 B until RSP 4 has executed and recorded the RSP 4 Deed of Trust and the title policy has been issued to the City. In addition, Developer agrees to use reasonable business efforts to cause Honeywell, subject to the Park Place Conditions Precedent, to irrevocably offer to dedicate the Honeywell Park Place Segment to the City. RSP hereby acknowledges that the dedications and payments referenced in Section 6.7.3 and 6.7.4 of this Agreement may not represent the entire share of the costs that Developer or its affiliates may be ultimately required to pay towards the extension of Park Place. 6.7.5 1 WrW I li /l i� ��c it loo the Qes4oi, a+1cciLlisition and Construction of the Park Place,Extension. The Parties agree to continue to work together to identify and seek to 14 secure funding and/or financing sources for the design, acquisition and construction of the Park Place Extension. 6.7.6 Use of Park Place Extension Funds for Construction of Park Place. To the extent the entire Park Place Extension Fund is not required to be used by City for the acquisition of the Honeywell, Chevron and/or Union Pacific RR Segments, any funds remaining shall be paid to City by Developer within thirty (30) days of Developer's receipt of a written request from City confirming the award of a construction contract to extend Park Place;provided, however, to the extent Developer, or any affiliate of Developer, from time to time, acquires all or any portion of the Honeywell, Chevron and/or Union Pacific RR Segments, the Park Place Extension Fund shall be reduced by an amount equal to $30 multiplied by the total number of square feet in the Honeywell, Chevron and/or Union Pacific RR Segments acquired by Developer, or any affiliate of Developer, and irrevocably offered for dedication to the City in accordance with the provisions of Section 6.7.3 above. 6.7.7 Citv Acknowledgement of Transfer of Responsibilities and Recordationof-R'S R 4 Deed of Trust. City acknowledves that the requirements of this Section 6.7 c 1� jtimalg to the 1611 Deed o .Trust liars beep satisfied. The RSP 4 Deed of Trust was recorded as Instrument Number 20120003205 on January 3, 2012 in the County Recorder's Office of Los Angeles County. City further acknowledges that Developer and RSP4 recorded an Amended and Restated Restrictive Covenants and Grant of Easements Agreement whereby RSP 4 agreed to comply with all obligations regarding the Park Place Extension("Revised Restrictive Covenant"). This document was recorded as February 2, 2012 as Instrument Number 20120190609 in the County Recorder's Office of Los Angeles County. The City acknowledges that the obligations set forth in this Section 6.7 are of no further force and effect as it pertains to Developer. The sections are set forth above for purposes of providing a reference for the Revised Restrictive Covenant. 6.8 Tliird-Party A�,,r•eejnerits l�cstrictijw, Uses oto Prot . Developer warrants and represents that it has not and will not enter into any agreements with third-parties, or record any restrictions against the Property, which directly or indirectly limit the potential uses for the Property that are currently permitted pursuant to this Agreement or in the C-4 Zone in any respect, including but not limited to types and/or sizes of structures or businesses, types of uses, or the owners of any businesses allowed on the Property. The Developer may request that the City Council consent to any such restriction which consent may be withheld in the City Council's sole discretion. Without acknowledging that any of the uses identified in (5) and (7) below are permitted pursuant to this Agreement or the C-4 Zone,the provisions of this Section 6.11 shall not apply to, or affect or restrict the terms of. (1) any lease between the Developer and a bona fide tenant of the Property for purposes of restricting competition relating to the tenant's business: (2) any purchase and sale agreement between the Developer and a bona fide retail business/purchaser of one or more parcels of the property for purposes of restricting competition relating to the retailer's business; (3) any agreement or permit between the Developer and any federal, state or regional regulatory agency(not including the County of Los Angeles (except to the extent County permits may be required to drill any wells on the Property and/or to discharge into the sanitary sewer system) or cities), such as, but not limited to the Army Corps of Engineers, the Environmental Protection Agency, the Department of Fish and Wildlife, the Department of Toxic 15 Substances Control, the Public Utilities Commission, the Regional Water Quality Control Board and the California Department of Fish and Game; (4)normal and customary covenants, conditions and restrictions for retail centers (commonly referred to as "CC&R's") so long as such do not restrict the uses that are currently permitted on the Property pursuant to this Agreement or the C- 4 zone; (5) any restrictions on residential, health care, child care, schools, or other similar uses imposed by the current owner of the Property, Honeywell International Inc.; (6) any restrictions on using groundwater underneath the Property for human consumption, irrigation, or other purposes that might bring groundwater into contact with humans; or (7) restrictions prohibiting bowling alleys, arcades, skating rinks, billiard rooms, carnivals or circuses,the sale of used goods or materials, dance halls, bars (not including bars that are an ancillary use to another permitted use); funeral parlors, the sale of paraphernalia for use with illegal drugs, automobile services (including but not limited to service stations), automobile sales, liquidation sales (not including court ordered sales), veterinary services (except as ancillary use to a pet store), tattoo parlors and pawn shops. 7. "it yah?!�-K 1.c1N g°eer e��1.s. 7.1 1",M)e.clitecl Proccssipg. The City shall process, at Developer's expense, in an expedited manner all plan checking, excavation, grading, building, encroachment and street improvement permits, Certificates of Occupancy, utility connection authorizations, and other ministerial permits or approvals necessary, convenient or appropriate for the grading, excavation, construction, development,improvement,use and occupancy of the Project in accordance with the City's accelerated plan check process under the Applicable Rules. Without limiting the foregoing, if requested by Developer, the City agrees to utilize private planners and plan checkers (upon Developer's request and at Developer's cost) and any other available means to expedite the processing of Project applications,including concurrent processing of such applications by various City departments. 7.2 1?rrw cc; im gC ac l cr 4�tiop ai d Assistance. To the extent permitted by law,the City shall reasonably cooperate with the Developer in securing any and all entitlements, authorizations, permits or approvals which may be required by any other governmental or quasi- governmental entity in connection with the development of the Project or the Property. Without limiting the foregoing,the City shall reasonably cooperate with the Developer in any dealings with federal, state and other local governmental and quasi-governmental entities concerning issues affecting the Property. The City shall endeavor to keep the Developer fully informed with respect to its communications with such agencies which could impact the development of the Property. 7.3 Processing Dtiriiiv Tliird 1 ii—ty ij igLgi01i. The filing of any third party lawsuit(s) against the City or the Developer relating to this Agreement,the Project Approvals, any Future Approvals or to other development issues affecting any portion of the Property or the Project shall not hinder, delay or stop the development, processing or construction of the Project, approval of the Future approvals, or issuance of ministerial permits or approvals, unless the third party obtains a court order restraining the activity. 8. Modification/Suspension. Pursuant to Government Code Section 65869.5,in the event that 16 any state or federal law or regulation, enacted after the Effective Date (as defined in Section 18), precludes compliance with any provision of this Agreement, such provision shall be deemed modified or suspended to the extent practicable to comply with such state or federal law or regulation, as reasonably determined necessary by City. Upon repeal of said law or regulation or the occurrence of any other event removing the effect thereof upon the Agreement, the provisions hereof shall be restored to their full original effect. 9. Demonstrationm of Good Faith Compliance. 9.1 review 01` COMD14111ce. In accordance with Government Code Section 65865.1, this Section 9 and the Applicable Rules, once each year, on or before each anniversary of the Effective Date ("Periodic Review"), the City Planning and Building Safety Director shall review the extent of the Developer's good faith substantial compliance with the terms and provisions of this Agreement as well as the performance by the City of its obligations under this Agreement. 9.2 Oood Faifli Coinolktiic'c. During each Periodic Review,the Developer shall demonstrate by written status report that, during the preceding twelve (12) month period, that it has been in good faith compliance with this Agreement. For purposes of this Agreement, the phrase "good faith compliance" shall mean that the Developer has demonstrated that it has acted in a commercially reasonable manner(taking into account the circumstances which then exist)and in good faith in and has substantially complied with the Developer's material obligations under this Agreement. 9.3 Informationm to„mbeITITProvidcL"l t.oa„ .I eve lop"c,' The City shall deliver to the Developer a copy of all staff reports prepared in connection with a Periodic Review, any prior staff reports generated during the review period, written comments from the public and, to the extent practical, all related exhibits concerning such Periodic Review, but in no event later than six (6) business days prior to the City Planning and Building Safety Director's submittal of a report setting forth his or her determination as to the results of the Periodic Review. Subject to the provisions of Section 14.1 below, upon the Developer's request, the Developer shall be given a full and adequate opportunity to be heard orally and in writing regarding its performance and, at its option, the city's performance under the Agreement prior to the completion of the City Planning and Building Safety Director's Periodic Review. 9.4 Notice Of Noxi-Cc nioliaice, Cure l ivdits. Subject to the provisions of Section 14.1 below, if at the completion of any Periodic Review, the City Planning and Building Safety Director reasonably concludes on the basis of substantial evidence that as to any parcel or parcels comprising the Property (i) the Developer has not demonstrated that it is in good faith compliance with this Agreement, and (ii) that the Developer is out of compliance with a specific substantive term or provision of this Agreement, then the City Planning and Building Safety Director may issue and deliver to the Developer a written Notice of Violations set forth in Section 11.1 below. 9.5 Determination of Develooer's C'(.minharice. If the City Planning and 17 Building Safety Director determines that the Developer has demonstrated that it is in good faith compliance with this Agreement, the City Planning and Building Safety Director's determination shall be deemed final and non-appealable. If the Developer appeals to the Planning Commission a determination by the City Planning and Building Safety Director that the Developer is not in compliance with this Agreement and the Planning Commission determines that the Developer has demonstrated that it is in good faith compliance with this Agreement, the Planning Commission's determination shall be deemed final and non-appealable. If the Developer appeals to the City Council a determination by the Planning Commission that the Developer is not in compliance with this Agreement and the City Council determines that the Developer has demonstrated that it is in good faith compliance with this Agreement, the City Council's determination shall be deemed final and non-appealable. 9.6 Failure of Periodic Review. The City's failure to review, at least annually, compliance by the Developer with the terms and conditions of this Agreement shall not constitute or be asserted by any Party as a breach by any other Party of this Agreement. 10. FActmibleQelays. Performance by any Party of its obligations hereunder shall be excused during any period of"Excusable Delay," as hereinafter defined, provided that the Party claiming the delay gives notice of the delay to the other Party as soon as reasonably possible after the same has been ascertained. For purposes hereof, Excusable Delay shall mean delay that directly affects, and is beyond the reasonable control of, the party claiming the delay, including without limitation: (1) act of God; (b) civil commotion: (c) riot: (d) strike,picketing or other labor dispute; (e) shortage of materials or supplies; (f) damage to work in progress by reason of fire, flood, earthquake or other casualty; (g) reasonably unforeseeable delay caused by a reasonably unforeseeable restriction imposed or managed by a governmental entity other than City; (h) litigation brought by a third party attacking the validity of this Agreement, a Project Approval, a Future Approval or any other action necessary for development of the Property, (i) delays caused by any default by City or the Developer hereunder, or 0)delays due to the presence or remediation of hazardous materials. The term of this Agreement shall be extended by any period of Excusable Delay. 11. Default Provisions. 11.1 l.)CffiL►lt. Either Party to this Agreement shall be deemed to have breached this Agreement if it materially breaches any of the provisions of this Agreement and the same is not cured within the time set forth in a written notice of violation(the "Notice of Violation") from the non-breaching Party to the breaching Party,which period of time shall not be less than ten(10) days for monetary defaults, and not less than sixty (60) days for non-monetary defaults from the date that the notice is deemed received, provided if the breaching Party cannot reasonably cure a non-monetary default within the time set forth in the notice, then the breaching Party shall not be in default if it commences to cure the default within such time limit and diligently effects such cure thereafter. If the City determines that a default may have occurred,the City shall give written notice to the Developer of its intention to terminate this Agreement and comply with the notice and public hearing requirements of Government Code Sections 65867 and 65868. At the time and place set for the hearing on termination, the Developer shall be given an opportunity to be heard. 18 If the City Council finds based upon the evidence that the Developer is in breach of this Agreement, the City Council may modify or terminate this Agreement. 11.2 Content„mmof Notice of Violation. Every Notice of Violation shall state with specificity that it is given pursuant to this Section of the Agreement, the nature of the alleged breach, (including references to the pertinent provisions of this Agreement), the portion of the Property involved, and the manner in which the breach may be satisfactorily cured. The notice shall be deemed given in accordance with Section 19 hereof. 11.3 Remedies for Breach. The Parties agree that the remedies for breach of this Agreement shall be limited to the remedies expressly set forth in this section. Developer's remedies for any breach of this Agreement by City shall be limited to injunctive relief and/or specific performance. 12. Mort, 4ge ri„ rjpctioii. This Agreement shall not prevent or limit the Developer, in any manner, at Developer's sole discretion, from encumbering the Property or any portion thereof or any improvements thereon by any mortgage, deed of trust or other security device. The City acknowledges that the lender(s) providing such financing ("Mortgagee") may require certain Agreement interpretations and agrees,upon request,from time to time,to meet with the Developer and representatives of such lender(s)to provide within a reasonable time period the City's response to such requested interpretations. The City will not unreasonably withhold its consent to any such requested interpretation,provided that such interpretation is consistent with the intent and purposes of this Agreement. Any Mortgagee of a mortgage or a beneficiary of a deed of trust or any successor or assign thereof, including without limitation the purchaser at a judicial or non judicial foreclosure sale or a person or entity who obtains title by deed-in-lieu of foreclosure on the Property shall be entitled to the following rights and privileges: 12.1 Morwa c Not Rendered lrivalid. Neither entering into this Agreement nor a breach of this Agreement shall defeat, render invalid, diminish, or impair the priority of the lien of any mortgage or deed of trust on the Property made in good faith and for value. No Mortgagee shall have an obligation or duty under this Agreement to perform the Developer's obligations, or to guarantee such performance, prior to taking title to all or a portion of the Property. 12.2 Request for Notice to Mort2a2ee. The Mortgagee of any mortgage or deed of trust encumbering the Property, or any part thereof, who has submitted a request in writing to the City in the manner specified herein for giving notices, shall be entitled to receive a copy of any Notice of Violation delivered to the Developer. 12.3 ti' tlg „'s "1"inYe to Cray°. The city shall provide a copy of any Notice of Violation to the Mortgagee within ten(10)days of sending the Notice of Violation to the Developer. The Mortgagee shall have the right, but not the obligation, to cure the default for period of thirty (30) days after receipt of such Notice of Violation. Notwithstanding the foregoing, if such default shall be a default which can only be remedied by such Mortgagee obtaining possession of a Property, or any portion thereof, and such Mortgagee seeks to obtain possession, such Mortgagee shall have until thirty(30)days after the date of obtaining such possession to cure or,if such default 19 cannot reasonably be cured within such period, to commence to cure such default, provided that such default is cured no later than one (1) year after Mortgagee obtains such possession. 12.4 (;m"mtjre l igLits. Any Mortgagee who takes title to all of the Property, or any part thereof,pursuant to foreclosure of the mortgage or deed of trust,or a deed in lieu of foreclosure, shall succeed to the rights and obligations of the Developer under this Agreement as to the Property or portion thereof so acquired; provided, however, in no event shall such Mortgagee be liable for any defaults or monetary obligations of the Developer arising prior to acquisition of title to the Property by such Mortgagee, except that any such Mortgagee shall not be entitled to a building permit or occupancy certificate until all delinquent and current fees and other monetary or non- monetary obligations due under this Agreement for the Property, or portion thereof acquired by such Mortgagee, have been satisfied. 12.5 Bankruotcv. If any Mortgagee is prohibited from commencing or prosecuting foreclosure or other appropriate proceedings in the nature of foreclosure by any process or injunction issued by any court or by reason of any action by any court having jurisdiction of any bankruptcy or insolvency proceedings involving the Developer, the times specified in Section 12.3 above shall be extended for the period of the prohibition, except that any such extension shall not extend the term of this Agreement. 12.6 Disaffirmation. If this Agreement is terminated as to any portion of the Property by reason of(i)any default or(ii) as a result of a bankruptcy proceeding, this Agreement is disaffirmed by a receiver, liquidator, or trustee for the Developer or its property, the City, if requested by any Mortgagee, shall negotiate in good faith with such Mortgagee for a new development agreement for the Project as to such portion of the Property with the most senior Mortgagee requesting such new agreement. This Agreement does not require any Mortgagee or the City to enter into a new development agreement pursuant to this Section. 13. ;Sto l i„IT( lmmta ilITegt:e. At any time and from time to time, the Developer may deliver written notice to City and City may deliver written notice to the Developer requesting that such Party certify in writing that, to the knowledge of the certifying Party (i) this Agreement is in full force and effect and a binding obligation of the Parties, (ii)this Agreement has not been amended, or if amended, the identity of each amendment, and (iii) the requesting Party is not in breach of this Agreement, or if in breach, a description of each such breach. The Party receiving such a request shall execute and return the certificate within thirty (30) days following receipt of the notice. The failure of the City to deliver such a written notice within such time shall constitute a conclusive presumption against the City that, except as may be represented by the Developer, this Agreement is in full force and effect without modification, and that there are no uncured defaults in the performance of the Developer. The City Planning and Building Safety Director shall be authorized to execute, on behalf of the City, any Estoppel Certificate requested by the Developer. City acknowledges that a certificate may be relied upon by successors in interest to the Developer who requested the certificate and by holders of record of deeds of trust on the portion of the Property in which that Developer has a legal interest. 20 14. Administration o6" 14.1 Alacnl c;rl`Stal°I;"Dctc°r waie:�tc, r Any decision by City staff concerning the interpretation or administration of this Agreement of development of the Property in accordance herewith may be appealed by the Developer to the Planning Commission, and thereafter, if necessary, to the City Council pursuant to the El Segundo Municipal Code. The Developer shall not seek judicial review of any staff decision without first having exhausted its remedies pursuant to this Section. Final determinations by the City Council are subject to judicial review subject to the restrictions and limitations of California law. 14.2 Operatinj Nlet Noranda. The provisions of this Agreement require a close degree of cooperation between City and Developer. During the Term of this Agreement, clarifications to this Agreement and the Applicable Rules may be appropriate with respect to the details of performance of City and Developer. If and when, from time to time, during the term of this Agreement, City and Developer agree that such clarifications are necessary or appropriate, they shall effectuate such clarification through operating memoranda approved in writing by City and Developer,which, after execution, shall be attached hereto and become part of this Agreement and the same may be further clarified from time to time as necessary with future written approval by City and the Developer. Operating Memoranda are not intended to and shall not constitute an amendment to this Agreement but are mere ministerial clarifications, therefore public notices and hearings shall not be required. The City Attorney shall be authorized, upon consultation with, and approval of, the Developer, to determine whether a requested clarification may be effectuated pursuant to this Section or whether the requested clarification is of such character to constitute an amendment hereof which requires compliance with the provisions of Section 15 below. The authority to enter into such operating memoranda is hereby delegated to the City Planning and Building Safety Director, and the City Planning and Building Safety Director is hereby authorized to execute any operating memoranda hereunder without further City Council action. 14.3 Certificate of Performance. Upon the completion of the Project, or the completion of development of any parcel within the Project, or upon completion of performance of this Agreement or its earlier revocation and termination, the City shall provide the Developer, upon the Developer's request, with a statement ("Certificate of Performance") evidencing said completion or revocation and the release of the Developer from further obligations hereunder, except for any ongoing obligations hereunder. The Certificate of Performance shall be signed by the appropriate agents of the Developer and the City and shall be recorded in the official records of Los Angeles County, California. Such Certificate of Performance is not a notice of completion as referred to in California Civil Code Section 3093. 15. A.mendrnent or Termination by Mutual Consent. Except as otherwise set forth herein,this Agreement may only be amended or terminated, in whole or in part,by mutual consent of City and the Developer, and upon compliance with the provisions of Government Code Section 65867. 16. Indemnification/Defense. 16.1 Indemnification. The Developer shall indemnify, defend with counsel 21 reasonably acceptable to the City, and hold harmless the City and its officers, employees and agents from and against any and all losses, liabilities, fines, penalties, costs, claims, demands, damages, injuries or judgments arising out of, or resulting in any way from, the Developer's performance pursuant to this Agreement except to the extent such is a result of the City's negligence or intentional misconduct. Developer shall indemnify, defend with counsel reasonably acceptable to the City, and hold harmless the City and its officers, employees and agents from and against any action or proceeding to attack, review, set aside, void or annul this Agreement or the Project Approvals or any provisions thereof,including without limitation the CEQA determination and rezoning relating to the Other C-4 Property which is not otherwise the subject of this Agreement. 16.2 DO'ciise ol'ALyeeln iI. If the City accepts Developer's indemnification and defense as provided in Section 16.1 above, the City agrees to and shall timely take all actions which are necessary or required to uphold the validity and enforceability of this Agreement and the Applicable Rules. This Section 16 shall survive the termination of this Agreement. 17. Time of Essence. Time is of the essence for each provision of this Agreement of which time is an element. 18. Effective Date. This Agreement shall become operative on the date the Enabling Ordinance approving this Revised and Restated Development Agreement becomes effective (the "Effective Date")pursuant to Government Code Section 36937. 19. l�ticc.s. Any notice shall be in writing and given by delivering the same in person or by sending the same by registered or certified mail,return receipt requested,with postage prepaid, by overnight delivery, or by facsimile to the respective mailing addresses, as follows: If to City: City of El Segundo 350 Main Street El Segundo, CA 90245 Attention: City Clerk With a Copy to: Hensley Law Group 3655 Torrance Boulevard Suite 300 Torrance, California 90503 Attention: Mark D. Hensley, Esq. If to Developer: Street Retail Inc. Debbie Colson Senior Vice President, Legal Operations 1626 E. Jefferson Street Rockville, MD 20852-404 22 With a Copy to: Jeffrey S. Berkes Vice President Federal Realty Investment Trust 356 Santana Row, Suite 1005 San Jose, CA 95128 With a Copy to: Wallin, Kress, Reisman& Kranitz, LLP 2800 Twenty-Eighth Street, Suite 315 Santa Monica, CA 90405 Attention: Lisa E. Kranitz, Esq. Either City or Developer may change its mailing address at any time by giving written notice of such change to the other in the manner provided herein at least ten days prior to the date such change is affected. All notices under this Agreement shall be deemed given, received, made or communicated on the earlier of the date personal delivery is effected or on the delivery date or attempted delivery date shown on the return receipt, air bill or facsimile. 20. Umirc At_,re nietit. This Agreement contains the entire agreement between the Parties regarding the subject matter hereof, and all prior agreements or understandings,oral or written, are hereby merged herein. This Agreement shall not be amended, except as expressly provided herein. This Agreement specifically supersedes each of the recorded documents listed in EXHIBIT B hereto. 21, Conditions-o,!' pp oy�il. The Conditions of Approval from all previous approvals have been revised and restated and are attached hereto as EXHIBIT F, which is attached hereto and incorporated herein by reference. These Conditions supersede the conditions attached to all previous approvals. 22. Waiver. No waiver of any provision of this Agreement shall constitute a waiver of any other provision, whether or not similar; nor shall any such waiver constitute a continuing or subsequent waiver of the same provision. No waiver shall be binding, unless it is executed in writing by a duly authorized representative of the Party against whom enforcement of the waiver is sought. 23. S yerability. If any provision of this Agreement is determined by a court of competent jurisdiction to be invalid or unenforceable, the remainder of this Agreement shall be effective to the extent the remaining provisions are not rendered impractical to perform, taking into consideration the purposes of this Agreement. 24. Rel itis zll l mill cls`„t]1c Parties. Each Party acknowledges that, in entering into and performing under this Agreement, it is acting as an independent entity and not as an agent of any other Party in any respect. Nothing contained herein or in any document executed in connection herewith shall be construed as creating the relationship of partners,joint ventures or any other association of any king or nature between City and Developer,jointly or severally. 23 25. No Third Part Bemieliciaric5. This Agreement is made and entered into for the sole benefit of the Parties and their successors in interest. No other person or party shall have any right of action based upon any provision of this Agreement. 26. Recordation of Am:!'reeinemmt amid Aineimclinents. This Agreement and any amendment thereof shall be recorded with the County Recorder of the County of Los Angeles by the City Clerk of City. 27. °cac1l;eratiomm Between (.'ity w� c lie\/etom�em-. City and Developer shall execute and deliver to the other all such other and further instruments and documents as may be reasonably necessary to carry out the purposes of this Agreement. Upon satisfactory performance by Developer, and subject to the continuing cooperation of the Developer,City will commence and in a timely manner proceed to complete all steps necessary for the implementation of this Agreement and development of the Project or Property in accordance with the terms of this Agreement. 28. IZmmlcs 01't.O11Stm°r.mctic_mm1. The captions and headings of the various sections and subsections of this Agreement are for convenience of reference only, and they shall not constitute a part of this Agreement for any other purpose or affect interpretation of the Agreement. Should any provision of this Agreement be found to be in conflict with any provision of the Applicable Rules or the Project Approvals or the Future Approvals, the provisions of this Agreement shall control. 29. Joipt I''re miratim..rn. This Agreement shall be deemed to have been prepared jointly and equally by the Parties, and it shall not be construed against any Party on the ground that the Party prepared the Agreement or caused it to be prepared. 30. Govc:n,iimw, I z'iw m tid Vem�mmc. This Agreement is made, entered into, and executed in the County of Los Angeles, California, and the laws of the State of California shall govern its interpretation and enforcement. Any action, suit or proceeding related to, or arising from, this Agreement shall be filed in the appropriate court having jurisdiction in the County of Los Angeles. 31. :t.t.w;rm�cvm,' laces. In the event any action, suit or proceeding is brought for the enforcement or declaration of any right or obligation pursuant to, or as a result of any alleged breach of, this Agreement, the prevailing Party shall be entitled to its reasonable attorneys' fees and litigation expenses and costs, and any judgment, order or decree rendered in such action, suit or proceeding shall include an award thereof. Attorneys' fees under this section shall include attorneys' fees on any appeal and any post- judgment proceedings to collect or enforce the judgment. This provision is separate and several and shall survive the merger of this Agreement into any judgment on this Agreement. 32. "Mintem'parts. This Agreement may be executed in multiple counterparts, each of which shall be deemed an original, but all of which constitute one and the same instrument. 33. Weekend/Holiday Dates. Whenever any determination is to be made or action to be taken 24 on a date specified in this Agreement, if such date shall fall upon a Saturday, Sunday or holiday observed by federal savings banks in the State of California, the date for such determination or action shall be extended to the first business day immediately thereafter. 34. Not a l'Liblic Deck atioti. Except as otherwise expressly provided herein, nothing herein contained shall be deemed to be a gift or dedication of the Property,or of the Project,or any portion thereof, to the general public, for the general public, or for any public use or purpose whatsoever, it being the intention and understanding of the Parties that this Agreement be strictly limited to and for the purposes herein expressed for the development of the Project as private property. The Developer shall have the right to prevent or prohibit the use of the Property, or the Project, or any portion thereof, including common areas and buildings and improvements located thereon,by any person for any purpose which is not consistent with the development of the Project. Any portion of the Property conveyed to the City by the Developer as provided herein shall be held and used by the City only for the purposes contemplated herein or otherwise provided in such conveyance, and the City shall not take or permit to be taken (if within the power or authority of the City) any action or activity with respect to such portion of the Property that would deprive the Developer of the material benefits of this Agreement, or would in any manner interfere with the development of the Project as contemplated by this Agreement. IN WITNESS WHEREOF, Developer and City of El Segundo have executed this Development Agreement on the date first above written. CITY: City of El Segundo, a municipal corporation By: ....... ATTEST lt r ,,� ,. (':.rf Clerk (. v.. APPROVED AS TO FORM: By:_ 1 Y Attorney 25 „ CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE§ 1189 ........ .............. A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached,and not the truthfulness,accuracy,or validity of that document. State of California ) County of ............... before me, Date Here Insert Name and Title of the Officer personally appeared Name(s)"of SNgnr( ') ......................................... who proved to me on the basis of satisfactory evidence to be the persor)(s) whose narmq(!§� Ware— subscribed to the within instrument and acknowledged to me that-heJ;s),:I/lfiey executed the sau"ne in for fhb'entty upon behalf which the persoand n,actd"d9 execruted the qi strUmekn t instrument the per on(s)„ I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph PCATRICIAHARADA AU is true and correct. A ggbl c -Caslorn a WITNESS my hand and official mseal, Notary Pu ` r Los Angeles County Signature Imty Comm.Vires May 23,2018 Sigtl Pure of t ,ot ry P« o y 9 ...- Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document t , , t: t��wu � " ,m Tithe or Type of Documenf ;t ,D� ooq u•"m, en�t .. Date: , Number of Pages: Signer(s) Other Than Named Above: Capacity(ies)Claimed by Signer(s) Signer's Name: Si g ............................ ner's Name:............. ❑Corporate Officer — Title(s); ❑Corporate Officer — Title(s): _ ...... ❑ Partner — ❑ Limited ❑General ❑Partner — ❑Limited ❑General ❑ Individual ❑Attorney in Fact ❑Individual ❑Attorney in Fact ❑Trustee ❑Guardian or Conservator ❑Trustee ❑Guardian or Conservator ❑Other: ❑ Other: Signer Is Representing; Signer Is Representing: ............. ©2014 National Notary Association www.NationalNotary.org • 0-US NOTARY(1-800-876-6827) 1-80 Item#5907 DEVELOPER: PESP PES PARTNERS, LLC, a Delaware limited liability company By: Street Retail, Inc., a Maryland corporation Its: anagu .............. ice-President el" ey Western Region STREET STREET RETAI I_ INC., a Maryland corporation ,'141!r4 Y Be'l. cs, Vice-President Western Region 26 I CALIFORNIA ' - CERTIFICATE PURPOSE L I A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California } County of ail l ' -. :.,�° } On j)("'I ..) " before me, t� � , tj I r personally te , , -Pi ;r . who proved o men the basis o satis yfactory evidence to be the person(s). �g whose name(s) Is/are subscribed to the within instrument and acknowledged to me that he/shetthey executed the same in his/her/their authorized capacity(ies), and that by his/herttheir signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. STELA SANTtt,LAN WITNESS my hand and official seal. Notary Public -California Z Santa Clara County �a Commission#2157788 m ( j y app" a.'t itify Comm.Expires Jul 10.2020 Notary Public'Signature (Notary Public Seal) " a OPTIONAL INFORMATION INSTRUCTIONS FOR COMPLETING THIS FORM ADDITIONAL O 7Yats form complies wish current Cal#br is statutes regarding notary wording and DESCRIPTION OF THE ATTACHED DOCUMENT !'fneeded,should be completed and attached to the document.Acknowledgments from other stater may be completed for docwmenta being sent to shot state so long as the wording roes not require the California notary to violate California notary law. (nide or description of attached document) « State and County information must be the State and County where the document signer(s)personally appeared before the notary public for acknowledgment, * Date ofnntarixatiou roust be the date that the sig aer(s)personally appeared whieb Mb or description of attached document continued) must also be the sanuc date three addtnoawledgment is completed. e The notary public roust print his or her name as it appears within lois or her Number of Pages Document Data commission followed by a coma and them your title(notary public). . print the name(s) of document sign (s) who personally appear at the tithe of notariaxmtiom. CAPACITY CLAIMED BY THE SIGNER 0 Indicate the coorroret singular or p'lund frames by erasing off incorrect forms(i.e. ❑ Individual(s) ''sire is lava)or circling the comer fortes,'Failure to correctly indicate this information may.lead to rejection of document recording, ❑ Corporate Officer o no notary seat impression must be clear and photographically reproducible, Impression must not cover text or lines,if seal impression stuu 1ps,re-sraal if a sufficient permits,otherwise complete a different acknowledgment forte. I • Signattue of the notary public moist match sloe signature on Erle with sire office of ❑ Partner(s) the earattaty clerk, ❑ Attorney-in-Fact 0 Additional infoonnation is not required but could help to ensure this ❑ Trustee(s) acknowledgment is not misused or attached to a '. t document. Other * Indicate title or type of attached document,number of pages and date, ❑ 0 Indicate the capacity claimed by the signer,If the claimed capacity is a corporate officer,indicate the title I(i.e.CJ ft,CFCs,Secretary). 2015 Version www.NotaryClasses.com 800-673-9865 " Securely attacb this document to the signed document with a staple. EXHIBIT A LEGAL DESCRIPTIONS The Plaza El Segundo Propertv—Phase 1A Lots 1 through 17 of Vesting Tract No. 61630, in the City of El Segundo, County of Los Angeles, State of California, as per map filed in Book 1370, Pages 41 through 51, of Maps, in the Office of the County Recorder of said County. The Point Propertv—Phase 1B Parcel 1 of the Certificate of Compliance, in the City of El Segundo, County of Los Angeles, State of California, Recorded July 29, 2013, as Instrument No. 20131105767 of the Official Records, in the Office of the County Recorder of said County. 27 EXHIBIT B APPROVAL HISTORY AND RECORDING INFORMATION RECORDED RECORDING APPROVING DOCUMENT RELATED ENTITLEMENTS DOCUMENT INFORMATION .......................................... - -- Original 05-0797875 Ordinance 1382 • DA 03-1 Development (4/6/2005) Resolution 4415 o GPA 03-04, 03-05 Agreement * ZC 03-2, 03-3 * ZTA 04-1 • Subdivision 03-7 (VTM 061630) ......... ........ • EA 631- EIR Operating 20071901777 Not Applicable + Relating to small tenants of less than Memorandum (8/14/07) 4,000 SF No. 1 First 20072256909 Ordinance 1406 v DA Amendments only— Amendment (10/2/2007) a Modifies allowed uses o EA 763 - No CEQA Required Second 20080507797 Ordinance 1417 s DA Amendments Amendment (3/25/2008) Resolution 4542 o Amend property description by increasing acreage 0 Increases allowed development 0 Modifies Allowed Uses • $25,000 contribution downtown sign program o Park Place provisions a ZTA 08-1 * EA 768-Addendum ................. .......,. ......... ........................,.... Third 20100414500 Ordinance 1430 w DA Amendments only Amendment (3/26/2010) m Modifies allowed uses • No CEQA Required Fourth 20101433737 Ordinance 1446 9 DA Amendments Amendment (10/7/2010) • Modifies allowed uses o ZTA e No CEQA Required Fifth 20131572447 Ordinance 1481 + DA Amendments Amendment (11/6/2013) Resolution 4838 Amend property description by adding acreage o Increases allowed development o Modifies existing uses O Smaller tenant standards applicable to Phase 113 without limitation on size e ZTA 12-04 o ADJ 13-03 (curb/driveway width; shared loading space) _................. ......I............. ..................................... 28 • VAR 13-01 (retaining wall over 6 feet and fill in excess of 6 feet) w AUP 13-04(Master AUP for alcohol) • EA -Addendum ................................. ........................ . Sixth NOT RECORDED Ordinance 1499 (adopted 9 DA Amendments Amendment 12/16/14) * Modifies allowed uses • ZTA 14-02 Uses • EA 1075—No CEQA Required 29 EXHIBIT C ASSIGNMENT AND ASSUMPTION AGREEMENT 30 Recording Requested By and When Recorded Mail To: Street Retail, Inc. Boris Ipekar, Legal Counsel 1626 East Jefferson Street Rockville, MD 20852 ASSIGNMENT AND ASSUMPTION AGREEMENT This ASSIGNMENT AND ASSUMPTION AGREEMENT ("Agreement") is made and entered into by and among PES Partners, LLC, a Delaware limited liability company ("PESP") and Street Retail, Inc., a Maryland Corporation ("Street") ("Assignors"), and, a ("Assignee"). (" g "). ........................................................ RECITALS A. The City of El Segundo("City")and Assignor entered into that certain Revised and Restated Development Agreement dated , 20 (the"Development Agreement"), with respect to the real property located in the City of El Segundo, State of California more particularly described in Exhibit attached hereto (the "Project Site"), and B. Assignor has obtained from the City certain development approvals and permits with respect to the development of the Project Site, including without limitation, approval of for the Project Site (collectively, the "Project Approvals"). C. Assignor intends to sell, and Assignee intends to purchase that portion, of the Project Site more particularly described in Exhibit "B" attached hereto (the "Transferred Property"). D. In connection with such purchase and sale, Assignor desires to transfer all of the Assignor's right, title, and interest in and to the Development Agreement and the Project Approvals with respect to the Transferred Property. Assignee desires to accept such assignment from Assignor and assume the obligations of Assignor under the Development Agreement and the Project Approvals with respect to the Transferred Property. THEREFORE, the parties agree as follows: 1. As ig "ii"'�rept. Assignor hereby assigns and transfers to Assignee all of Assignor's right, title, and interest in and to the Development Agreement and the Project Approvals with respect to the Transferred Property. Assignee hereby accepts such assignment from Assignor. 31 2. Assitinntiop. Assignee expressly assumes and agrees to keep, perform, and fulfill all the terms, conditions, covenants, and obligations required to be kept, performed, and fulfilled by Assignor under the Development Agreement and the Project Approvals with respect to the Transferred Property, including but not limited to those obligations specifically allocated to the Transferred Parcel as set forth on Exhibit"C" attached hereto. 3. 11s11%ctive Date. The execution by City of the attached receipt for this Agreement shall be considered as conclusive proof of delivery of this Agreement and of the assignment and assumption contained herein. This Agreement shall be effective upon its recordation in the Official Records of Los Angeles County, California, provided that Assignee has closed the purchase and sale transaction and acquired legal title to the Transferred Property. 4. Remainder-cel`Proicct. Any and all rights or obligations pertaining to such portion of the Project Site other than the Transferred Property are expressly excluded from the assignment and assumption provided in sections 1 and 2 above. IN WITNESS WHEREOF,the parties hereto have executed this Agreement as of the dates set forth next to their signatures below. "ASSIGNOR" PESP PES PARTNERS, LLC, a Delaware limited liability company By: Rosecrans-Sepulveda Partners 3, LLC, a Delaware limited liability company Its: Sole Member By: Street Retail, Inc., a Maryland corporation Its: Manager By:. ......................................... ....................... Jeffrey S. Berkes, Vice President— Western Region STREET STREET RETAIL, INC., a Maryland corporation By: Jeffrey S. Berkes, Vice President—Western Region 32 "ASSIGNEE" a Date: By: Its: 33 11113 6 RECEIPT BY CITY The attached ASSIGNMENT AND ASSUMPTION AGREEMENT is received by the City of El Segundo on this day of CITY OF EL SEGUNDO BY: .................................................................................... Planning and Building Safety Director or Designee 34 5436 EXHIBIT D PARK PLACE SEGMENTS ............ WWMW' W AWW QYUW-44 akWW, AW SOMOV NaW RR PAW MAW SCa"rS ROSEMAN$ a A" mom wm 4 A* por AtLIEV OA AL40 4k $7mT WAL p SEPULVEDA IYOULEVARD 123WOMW MOM V-OX AM Emsm*EWA - to"a J.�M �MUMA 4-90 AM Enolmatring,inc. b"oku"mo OJ4 AM E lagolAuLloo solwilloliuw 01144sl4i 35 EXHIBIT E ENCUMBRANCES TO WHICH THE RSP 4 DEED OF TRUST MAY BE SUBJECT The RSP 4 Deed of Trust may only be encumbered by the exceptions identified in Section A of Schedule B (Items 1 through 5), and Section B of Schedule B (Items A, B, C.1 through C.5), of that certain preliminary title report issued by Commonwealth Land Title Company on November 7, 2007 (File No. 06158316-27). 36 EXHIBIT F CONDITIONS 37 EXHIBIT "D" TO RESOLUTION NO. 5053 EXHIBIT"F"TO REVISED AND RESTATED DEVELOPMENT AGREEMENT CONDITIONS OF APPROVAL The following conditions are binding upon the property owner(s) and their successors in interest, including without limitation occupants of the property. 1. All mitigation measures in the Environmental Impact Report (SCH No. 2003121037) for Environmental Assessment No. 631, Development Agreement No. 03-1, General Plan Amendment No. 03-4 & 03-5, Zone Change No. 03-2 & 03-3, Zone Text Amendment No. 04- 1, and Subdivision No 03-7,which are reflected in the Mitigation Monitoring and Reporting Program for the Sepulveda/Rosecrans Site Rezoning Reduced Traffic Generation Alternative and Plaza El Segundo Development Reduced Traffic Generation Alternative are incorporated by this reference into these conditions of approval. DEFINITIONS 2. Unless the contrary is stated or clearly appears from the context,the following definitions will govern the construction of the words and phrases used in these conditions. A. "P.B.S. Director"means the City of El Segundo Director of Planning and Building Safety, or designee. B. "EIR" means the Final Environmental Impact Report for the proposed Sepulveda/Rosecrans Site Rezoning and Plaza El Segundo development project(SCH No. 2003121037), El Segundo, California. C. "ESMC"means the El Segundo Municipal Code. D. "Development Agreement" or "Agreement" refers to the Revised and Restated Development Agreement. E. "Project Area"refers to each of the developable lots on the Plaza El Segundo development Project Site as shown on Vesting Tentative Tract Map No. 061630 in the City of El Segundo, County of Los Angeles, State of California, filed on June 6, 2012, Book 1370, pages 41-51, and refers to Lot 1 of Lot Line Adjustment No. 13-04 as reflected in that Certificate of Compliance, in the City of El Segundo, County of Los Angeles, State of California,recorded on July 29,2013,as Instrument No. 2013-1105767, of official records in the office of the County Recorder of said County. F. "Project Site"refers to the 51.7 gross/46.60 net(after street dedications)acre site generally located south of Hughes Way, east of Sepulveda Boulevard, west of Douglas Street, and north of Rosecrans Avenue. G. "Project Site Phase 113" refers to the 13.050 gross/12.63 net acre site as shown as Lot 1 of the Lot Line Adjustment No. 13-04 as reflected in that Certificate of Compliance, in the City of El Segundo,County of Los Angeles, State of California,recorded on July 29,2013, as Instrument No. 2013-1105767, of official records in the office of the County Recorder of said County, generally located south of the Union Pacific Railroad, east of Sepulveda Boulevard, west of Douglas Street and north of Rosecrans Avenue. 5436 H. "Phase 1A" refers to the portion of the Project Area located north of the Union Pacific Railroad right-of-way. I. "Phase 113" refers to the portion of the Project Area located south of the Union Pacific Railroad right-of-way. J. "Sepulveda/Rosecrans Rezoning Site" refers to the approximately 110 acres generally located south of Hughes Way, east of Sepulveda Boulevard, west of Douglas Street, and north of Rosecrans Avenue which is the subject of a General Plan and Zoning Code Amendment that is being considered concurrently with the land use entitlements for the Project Area and the Project Site. 2. Except as otherwise specified in these Conditions of Approval, conditions must be satisfied before the issuance of a Building Permit for each building within the Project Area. AESTHETICS Lit1....tim 3. Before the issuance of the first Building Permit in the Project Area,the applicant must submit a Lighting Master Plan for the Project Area for the review and approval of the P.B.S.Director and the Police Chief. A Lighting Plan (construction drawings) and Photometric Study, consistent with the Lighting Master Plan must be reviewed and approved by the P.B.S. Director and the Police Department before the issuance of each Building Permit and must be installed before the issuance of each Certificate of Occupancy in the Project Area. The Lighting Plan and Photometric Study must demonstrate that the proposed project allows minimum off-site illumination but still complies with Police Department safety requirements. 4. The Lighting Master Plan must include,without limitation: a. Specific details for Foot-candle intensity; b. Specific lighting detail for parking areas and structures; pedestrian walkways; and access ways in and around buildings; c. On-site light fixtures that have been designed to direct the light downward and internal to the proposed project site to minimize off-site illumination; d. Specific detail regarding the location,type and height of lighting devices; e. Specific detail to illustrate compliance with the ESMC; and, ,) 43 f. Weather and vandal resistant covers on lighting fixtures. S. Before the issuance of each Certificate of Occupancy, the applicant must provide evidence to the P.B.S. Director and the Police Chief that outdoor lighting design has been installed in compliance with the approved Lighting Master Plan for the building that is the subject of the Certificate of Occupancy. Materials 1111d Design 6. Before the issuance of the first Building Permit in the Project Area,the applicant must submit Final Working Drawings to the P.B.S. Director for design review. The applicant must provide a Building Materials Sample Board of the materials, colors, and elevation drawings to be utilized to the P.B.S.Director for review and approval.The design review must include, without limitation,the following design guidelines: a. All colors, textures, and materials on exterior elevation(s) must be coordinated to achieve a continuity of design; b. Exterior building materials must be compatible with developments in the vicinity; c. At least two primary exterior building materials (including, without limitation, stucco, stone, rock, and brick) must be used throughout the Plaza El Segundo proj ect; d. The buildings must have contrasting accent features. Building materials must be of non-reflective coatings and glazings; e. The plans must demonstrate substantial compliance with plans and conditions approved and on file with the Planning and Building Safety Department. Any subsequent modification to the project as approved must be referred to the P.B.S. Director for a determination regarding the need for Planning Commission review of the proposed modification in accordance with the provisions of the Development Agreement; f. All buildings must be in accordance with the Project Area's Conditions,Covenants and Restrictions (CC&R's); g. All buildings must utilize energy efficient floor plans and controlled HVAC and heat generating equipment to reduce energy use for cooling and ventilation; h. All roof-mounted mechanical equipment and communications devices must be hidden behind building parapets or screens to screen these devices from off-site ground level view; i. Ground level mechanical equipment, refuse collectors, storage tanks, monitoring wells, generators, and other similar facilities must be screened from view with 4, 3 1 6 dense landscaping and walls of materials and finishes compatible with adjacent buildings; j. Service, storage, maintenance, utilities, loading, and refuse collection and other similar areas must be located out of the view of public roadways and buildings and screened by dense landscaping and solid walls,unless the PBS Director determines such is not practicable. No chain link fences may be used for such screening; k. Walls along the north property boundary of the Project Site and walls used to screen service and storage areas must be of the same materials, colors, and finishes as adjacent buildings or compatible finishes and colors; I. A six-foot high solid wall must be constructed along the southern property line of Lot 15 of Vesting Tentative Tract Map No. 061630 for at least a length of 200 feet from the eastern edge of the Sepulveda Boulevard right-of-way. A six-foot high wall or a fence constructed of vinyl chain link or other material must be constructed along the remaining property lines of the Project Area abutting the Union Pacific Railroad right-of-way with screening of the right-of-way with the use of landscaping, including, without limitation, vines, hedges and/or trees to the satisfaction of the P.B.S. Director. A six-foot high chain link fence or other material aesthetically compatible with existing fencing or walls in the Project Area must be constructed along the northern property line of Project Site Phase 1B abutting the Burlington Northern Santa Fe Railroad right-of-way to the satisfaction of the P.B.S. Director. Additionally, screening of the right of way with the use of landscaping, including, without limitation, vines,hedges and/or trees is required to the satisfaction of the P.B.S. Director. An eighteen-inch high, three-strand barbed wire fence may be placed upon the top of the chain link fence for the entire length of this fence (approximately 1,690 feet). in. Chain-link fences are not permitted, except as described above, and as temporary construction fencing; n. Building design will meet the City's standards for the attenuation of interior noise; o. All service areas must be located so that service vehicles have clear and convenient access and do not disrupt vehicular and pedestrian circulation; p. No loading will be permitted directly from public streets,except in designated areas as approved by City P.B.S. Director; q. All on-site utility systems including without limitation, water, electricity, gas, sewer and storm drains, must be installed underground; r. No Certificate of Occupancy may be issued unless there is substantial compliance with the aforementioned development standards and, s. The Project Area site plan must be revised to provide sidewalks or other designated pathways following direct and safe routes from the Park Place right-of-way to buildings H through A-7, from the Park Place right-of-way to Pad D, and from the Sepulveda Boulevard right-of-way to Building No. 2, and any other building that may developed that is set back more than 200 feet from a public right-of-way, subject to the review and approval of the P.B. S. Director. The Project Area site plan must provide sidewalks or other designated pathways following direct and safe routes from the Sepulveda Boulevard public right-of-way and the Rosecrans Avenue public right-of-way to the entrances of the buildings and the plaza in front of the buildings, subject to the review and approval of the P.B.S. Director. 1,81:ai18caninu .and lrri Aj!i n 7. Before the issuance of the first Building Permit in the Project Area,the applicant must submit a Master Landscape and Irrigation Plan for the Project Area. The Master Landscape and Irrigation Plan must be reviewed and approved by the City P.B.S. Director, the Director of Recreation and Parks, and the Police Chief. Landscaping for each building in the Project Area must be installed in accordance with the approved Master Landscape and Irrigation Plan before the issuance of each Certificate of Occupancy. The Master Landscape and Irrigation Plan must include, without limitation,the following: a. All landscaped areas must be provided with a permanent automatic watering or irrigation system; b. All on-site landscaped areas must be maintained by the owner in a neat and clean manner at all times; c. All landscaped areas must be designed to ensure efficient access to fire hydrants; d. Dual plumbing must be installed for reclaimed water irrigation; e. All landscaped areas must be irrigated with reclaimed water to the extent reclaimed water is available for use in the Project Area. Until such time as reclaimed water is made available,potable water may be utilized for irrigation; f. All landscaping and irrigation must comply with the City's Water Conservation regulations and Zoning Code requirements; g. All landscaping must be designed to enhance site security in accordance with Police Department policies; h. All public rights-of-way abutting the site must be landscaped; i. Landscaping that includes trees, vines, and or hedges must be incorporated along property line walls and fences for screening purposes. j. All landscaped areas must include a majority of mature landscaping,including trees that are a minimum 24-inch box size; and, k. Landscaping must be installed along property perimeters and evenly distributed throughout the employee/customer parking areas. 8. Before the issuance of the first Building Permit in the Project Area, the applicant must provide a Landscape Plan and Architectural Plan(i.e. construction drawings),consistent with the Master Landscaping Plan, to the P.B.S. Director, Director of Recreation and Parks, and the Police Chief for review and approval. The Landscape Plan and Architectural Plan must demonstrate that errant nighttime illumination is generally screened from other potentially sensitive uses,through building design and landscape treatments. Before the issuance of the first Building Permit in the Project Site Phase 113, the applicant must provide a Landscape and Irrigation Plan and an Architectural Site Plan (i.e., construction drawings) consistent with the Master Landscaping Plan, to the P.B.S. Director, Director of Recreation and Parks, and the Police Chief for review and approval that includes the use of trees, hedges, and or vines along the eastern boundary from Rosecrans Avenue to the Union Pacific Railroad. The plant material must be placed west and in front of the property line wall or fence. The Landscape Plan must utilize decorative pavement material in the plaza and for the pedestrian entrances to the plaza. The Landscape Plan and Architectural Plan must demonstrate that errant nighttime illumination is generally screened from other potentially sensitive uses, through building design and landscape treatments. 9. Where feasible (as determined by the P.B.S. Director), the applicant must comply with the City's Water Conservation Program as set forth in the ESMC and the City's Guidelines for Water Conservation in Landscaping. Before the issuance of each Building Permit in the Project Area, the applicant's Landscape Plans must be submitted to the P.B.S. Director for review and approval. Suns 10. Before the issuance of the first Building Permit in the Project Area,the applicant must submit to the P.B.S.Director for review and approval an overall Master Sign Program for the Project Area. Before the issuance of a Certificate of Occupancy for each building within the Project Area, the applicant must submit construction sign plans substantially consistent with the approved Master Sign Program for the review and approval of the P.B.S. Director. Before the issuance of a Certificate of Occupancy, signs must be installed in accordance with the approved Master Sign Program. The overall Master Sign Program must include, without limitation: a. Compliance with the ESMC; b. Notwithstanding any other provisions in the ESMC, no freestanding or pole signs, except as described in this Condition No. 10 and Condition No. 11 below, are permitted along the Rosecrans Avenue frontage of the Project Area; c. All signs must be architecturally compatible with the proposed buildings; d. All signs must be compatible with the aesthetic objectives of the General Plan; e. No sign must impede traffic or pedestrian safety; and f. Height limitation of signs referred to in this Condition No. 10 shall be measured from the average adjacent street elevation. 11. Before the issuance of a Finial Certificate of Occupancy for the first building in the Project Area, the applicant must construct and maintain a monument sign at the northeast corner of Sepulveda Boulevard and Rosecrans Avenue announcing the entrance to the City. The sign is subject to review and approval by the City Council. The sign should be compatible with the design of the Master Sign Program for the Plaza El Segundo development project. AIR QUALITY 12. During grading and construction,dust control measures must be required in accordance with the City's Dust Control Ordinance (Chapter 7-3 of the ESMC). Grading must be discontinued during first-stage smog alerts and suspended when wind velocity exceeds 15 miles per hour. All hauling trucks must have loads covered or wetted and loaded below the sideboards to minimize dust. 13. The South Coast Air Quality Management District (SCAQMD) has promulgated rules and applicable standards including,without limitation,the following: Rule 402-Nuisances;Rule 403 - Fugitive Dust; and Rule 2202 - On-Road Motor Vehicle Mitigation Options. The applicant must use best management practices in compliance with Rule 402 during the operation of construction equipment. Construction activities must be limited between the hours of 7 A.M.to 6 P.M.,Monday through Saturday,unless such hours are extended pursuant to a Noise Permit issued by the P.B.S. Director. During the construction phase, all unpaved construction areas must be wetted at least twice daily during excavation, grading, and construction and temporary covers for stockpiles must be used to reduce dust emissions by as much as 50 percent. The applicant must ensure that all materials transported off-site will be either sufficiently watered or securely covered in compliance with Rule 403. Resultant peak daily exhaust emissions from diesel- and gasoline-powered construction equipment must be monitored to control emission levels that exceed SCAQMD screening thresholds. During construction, trucks and vehicles in loading or unloading queues must keep their engines off, when not in use, to reduce vehicle emissions. Construction activities must be phased and scheduled to avoid emission peaks,and construction must be discontinued during first- and second-stage smog alerts. On-site vehicle speed during construction must be limited to 15 mph. Before issuance of a Grading Permit for each Project Area, the applicant must provide a Construction Management Plan to the P.B.S.Director for review and approval relative to compliance with the appropriate SCAQMD standards during the construction phase. Daily records of construction hours and activities must be maintained by the applicant throughout the construction phase. BUILDING CODES 14. The applicant must comply with the applicable requirements of the California Building and Fire Codes as adopted by the ESMC that are in effect at the time an application for a building permit is submitted. ENERGY 15. Before the issuance of a Building Permit in the Project Area, the applicant must provide an Energy Conservation Plan to the P.B.S. Director for review and approval. The Energy Conservation Plan must incorporate energy conservation features in accordance with the requirements of the City and State. Before the issuance of each Certification of Occupancy, the applicant must provide evidence to the P.B.S. Director that the approved energy conservation features have been installed and will be maintained. 16. If a substation will be constructed,the Applicant must develop plans, projected loads, and a master plan for scheduling to the satisfaction of Southern California Edison. FIRE 17. Before the City issues a building permit,the applicant must provide Fire Life Safety Plans to the P.B.S. Director and the Fire Chief for review and approval, which include, without limitation, the following: a. Fire lanes; b. Fire lane signing; c. Fire lane access easements or other recorded documents to the reasonable satisfaction of the City Attorney; d. Fire lane accessibility; e. Gas detection systems; f. Minimum acceptable flow from any fire hydrant must be 2,500 gallon per minute, calculated at 20 psi; g. Sprinklers within structures; h. Underground looped fire mains, sprinklers, fire pumps, and fire alarms; i. Emergency generators; j. Any above ground or underground storage tanks including elevator sumps and condensation tanks; k. Documentation that the on-site fire mains will be maintained; 1. Fire safety precautions during demolition and construction; m. Emergency site access during construction; n. Permanent fire department access; o. Fire hydrant locations; p. Any proposed fire sprinkler and fire alarm systems; and q. Before the issuance of each Certificate of Occupancy, the applicant must demonstrate to the Fire Department that the development complies with the Fire Life Safety Plan, and that any required easements were properly dedicated and recorded. 18. Before the issuance of a Building Permit in the Project Area,the applicant must develop and submit an Evacuation Plan and Procedures for review and approval by the Fire Department. Before the issuance of each Certificate of Occupancy, the applicant must provide evidence to the P.B.S. Director, and the Fire Department that the approved Evacuation Plan and procedures were implemented or are operational as appropriate. 19. The applicant must provide an automatic fire sprinkler system throughout each building, installed in accordance with California Fire Code Chapter 9 and the currently adopted edition of NFPA 13. 20. The applicant must provide an automatic fire alarm system throughout each building, installed in accordance with California Fire Code Chapter 9 and the currently adopted edition of NFPA 72. 21. The applicant must provide a certification from the underground petroleum pipeline owner/operator that the proposed project will not encroach into any foundations or structures within the pipeline right-of-way without the underground petroleum pipeline owner/operator's approval. The certification must be provided with the initial plan review documents. 22. There is a railroad right-of-way on the north side of the Phase 1 B property. Access doors and ladders with a maximum 300-foot spacing must be provided to provide access to the railroad right of way in case of a train derailment or incident to the satisfaction of the Fire Department. The access doors and ladders must have approved Knox Company Knox Padlocks installed. 23. If any fire features are proposed for the project, the applicant must provide the following conditions for any fire feature: a. A barrier must be provided around the fire feature to prevent accidental access to the fire feature. b. The distance between the fire feature and combustible material and furnishings must meet the fire feature's listing and manufacturer's requirements. c. If the fire feature's protective barrier exceeds ambient temperatures, all exit paths and occupant seating must be a minimum 36 inches from the fire feature. 24. Before the issuance of a Grading or Building Permits in the Project Area,the applicant must provide a Construction Safety Plan to the P.B.S. Director and Fire Department for review and approval. The Construction Safety Plan must document construction and staff training procedures to ensure that best management practices during project grading and construction will be utilized. The Construction Safety Plan must identify an awareness program for the subgrade installation of utilities and the potential for worker exposure to related emissions, especially during excavation. Compliance with this measure must be verified by the P.B.S. Director before permit issuance. 25. Before the issuance of each Building Permit in the Project Area, all hydrants determined necessary by the Fire Department and the P.B.S. Director must be installed in accordance with approved plans and specifications. Fire hydrants must be spaced no greater than 300 feet apart. One private hydrant must be provided for each structure and each structure must be sprinklered in accordance with the California Building Code (CBC) and the National Fire Code (NFC). 26. Pursuant to ESMC§§ 15-27A-1,et seq.,and before building permits are issued,the applicant must pay a one-time fire services mitigation fee as provided in City Council Resolution No. 4687. GEOTECHNICAL (GRADING,TOPOGRAPHY, SOILS AND DRAINAGE) 27. Before the issuance of a Grading Permit for the Project Area or a portion thereof, the applicant must prepare and submit a Grading Plan for review and approval by the P.B.S. Director and the Director of Public Works. The Grading Plan must include, without limitation: a. The Grading Plan must demonstrate compliance with applicable provisions of the ESMC and City policies and requirements; b. The Grading Plan must show cross sections for any grading purpose and the location of and extent of existing and planned sewer easements and facilities; c. Grading depths must not encroach upon or damage the existing sewer lines on the property; d. Haul routes for import/export trucks and other heavy construction related vehicles must be approved by the Director of Public Works; o e. No haul routes may travel through the City of Manhattan Beach during A.M. or P.M. peak hours; f. All grading must be accomplished in accordance with the recommendations of an independent Geotechnical and Geological Report to be submitted by the applicant and reviewed and approved by the City; g. The Grading Plan must detail where special restrictions apply due to soil contamination, if applicable; h. Additional information, as required through the plan check process, must be included as appropriate; i. Final grading activities must be coordinated with the City Engineer at the time the Grading Permit is issued; and, j. Compliance with the above measures must be verified by the P.B.S.Director before issuance of each Certificate of Occupancy. HAZARDS 28. Before the issuance of a Grading Permit for the Project Area or a portion thereof, the applicant must submit documentation from the Los Angeles Regional Water Quality Control Board ("LARWQCB") evidencing approval of completion of the Interim Remediation Measures and approval of the Final Remedial Action Plan for the Project Area for the area covered by the Grading Permit. 29. The applicant must comply with any permit requirements imposed by the LARWQCB and/or the Department of Toxic Substances Control ("DTSC"), or any other applicable regulatory agency related to development and/or grading on the site. 30. Before the issuance of a Grading Permit, the applicant must provide any appropriate hazardous materials safety training for all City employees needed to implement the project. If required,the training must be related specifically to safety issues that may arise during site grading and construction due to the soil contamination that may exist in the site. All training must be completed to the reasonable satisfaction of the P.B.S. Director, and the Fire Chief. NOISE 31. During the construction phase of the project, activities will be allowed between the hours of 7 A.M.to 6 P.M.,Monday through Saturday,and prohibited at any time on Sundays and federal holidays, unless such hours are extended pursuant to a Noise Permit issued by the P.B.S. Director. Compliance for the operations phase will meet with the placement, screening, and maintenance standards for all external mechanical equipment. The proposed project must be designed to ensure that noise generated by the proposed project operations does not exceed the City's noise standards, as established by the ESMC, for on-site or off-site receptors. A '113 6 noise monitor must be designated according to the relevant codes. Before issuance of a Grading Permit for each Project Area, the City must designate a Noise Ordinance ComplianceNerification Monitor. Before the issuance of a Building Permit for each Project Area, the applicant's Final Working Drawings must be submitted to the P.B.S. Director for review and approval relative to compliance with the City's Noise Ordinance. POLICE /SAFETY 32. Before the issuance of the first Building Permit,the applicant must submit an overall Security and Crime Prevention Plan,to the P.B.S. Director and the Police Department for review and approval,which must address, without limitation,the following: a. Lighting; b. Addressing(minimum height of 4"to 24"); c. Trash dumpsters (including space for recyclable materials); d. Indoor and outdoor security cameras installed at strategic locations, including employee and other vehicle parking areas; e. Parking lots and structures; f. Fences, walls; g. Security hardware; h. Office; i. On-site security personnel; j. Locker rooms; k. An Evacuation Plan and Procedures; L The employment of security personnel who will monitor and patrol the proposed Project Site, including employee and other vehicle parking areas, and coordinate with public safety officials; in. The installation of lighting in entryways, elevators, lobbies, and parking areas designed to eliminate potential areas of concealment; n. A diagram of the proposed project, which will include access routes, and any information that might facilitate emergency response; o. Compliance with all applicable items on Police Department checklist memo dated April 12, 2004, attached as Exhibit F-1/C-1, with the exception that parking is permitted on the north side of the Project Area between the main row of buildings and the northern property line; and, p. All Security and Crime Prevention Plan measures must be installed in conformance with the approved plans and must be operational before the issuance of a Certificate of Occupancy. 33. Before issuance of the first building permits, the applicant must submit a photometric light study to the Police Department for review and approval. 34.Pursuant to ESMC §§ 15-27A-1,et seq.,and before building permits are issued,the applicant must pay a one-time police services mitigation fee as provided in City Council Resolution No. 4687. 35. The applicant must provide, at no cost to the City of El Segundo, a minimum of 240 square feet of office space to be used by the El Segundo Police Department as satellite office space to provide Police services on the east side of Sepulveda Boulevard. PROJECT DESCRIPTION Plans 36. The City of El Segundo requires development project applicants to prepare and submit Final Working Drawings for review and approval. The applicant must provide Final Working Drawings that comply with Policies and Requirements and these conditions of approval. The Final Working Drawings must indicate proposed uses, building sizes and heights, and the specific location of structures, loading docks, staging areas,parking layout,landscaped areas and recreational amenities. The Final Working Drawings must include vehicular,pedestrian and bicycle access, on- and off-site circulation, and linkage to other key elements in the site vicinity, including the MTA Green Line. The Final Working Drawings must indicate building materials and architectural design elements that will be utilized in the construction of the proposed structures. The Final Working Drawings 'must include information on security lighting and hardware and other detail required for compliance with the City's security, safety and crime prevention standards. The Final Working Drawings must demonstrate compliance with the California Building Code, California Mechanical Code, California Plumbing Code, California Fire Code, California Sign Code, and California Electrical Code, and approved Fire Life Safety Systems. In addition, the Final Working Drawings must clearly indicate the location of all entrances and exits, including emergency vehicle access. All parcel buildings and structures must be located in proximity to the proposed parcel lines such that they meet all requirements for exterior wall and opening protection. Additional information, as required through the plan check process, must be included as appropriate. Before the issuance of a Building Permit for the Project Area, the applicant must coordinate with all applicable City and applicable County agencies to prepare and submit Final Working Drawings to be approved by the P.B.S. Director, the Department of Public Works, the Fire Department and the Police Department. Before the issuance of a Certificate of Occupancy for each building,the applicant must provide evidence to the P.B.S. Director, the Department of Public Works, the Police Department, and the Fire Department that Code and policy requirement conditions have been met. 37. The Plaza El Segundo development project is allowed to develop up to a maximum of 517,292 gross square feet,consisting of a combination of uses as permitted by C-4 Zone and limited by the Development Agreement as long as the total AM, PM peak, daily, and Saturday midday peak trip generation established in the EIR for the project as a whole is not exceeded. 38. The maximum project size may be reduced as determined by the vehicle trip generation for each use. The Sepulveda/Rosecrans Site Rezoning and Plaza El Segundo development project permit the following vehicle trips: MAXIMUMTRIPS RMITTED A .......... PM Daily Salurday Midday Sepulveda/Rosecrans Site Rezoning 1,033 2,346 ..........25,85.9.._ 3'379............. . laza El Segundo.....o w .Development ..� mopment 779 1,477 16,645 2,205 Pro .... sect For Phase 1 - The trip generation shall be determined using the rate set forth in the current edition of the Institute of Transportation Engineers (ITE) Trip Generation Manual for Land Use Code 820 (shopping center)provided that the following conditions are met as further set forth in the Alternative Trip Generation Methodology prepared by Fehr & Peers dated July 11, 2017: 0 The amount of restaurant and entertainment uses does not exceed twenty percent (20%) of the total square footage; 0 No individual fitness use exceeds 10,000 square feet. If an individual fitness use exceeds 10,000 square feet, the trip generation for such use must be determined using the rate for that use as set forth in the current edition of the ITE Trip Generation Manual; 0 No individual office use exceeds 5,000 square feet. If an individual office use exceeds 5,000 square feet, the trip generation for such use must be determined using the rate for that use as set forth in the current edition of the ITE Trip Generation Manual. For Phase I B - The trip generation for each use and building must be determined using the rates as set forth in the current edition of the ITE Trip Generation Manual, as further set forth in the Alternative Trip Generation Methodology prepared by Fehr & Peers dated July 11, 2017. For both Phase 1A and Phase 113 - Trip adjustments for internal capture and pass-by reductions will be in accordance with the adjustments in the Traffic Impact Study in the FEIR (EA No. 63 1) approved on March 1, 2005. Trip adjustments for transit reductions will be in J. accordance with the adjustments in the Traffic Impact Study in the Addendum to the FEIR (EA No. 768) approved on February 19, 2008. 39. In order to keep track of the vehicle trip generation, the applicant shall submit a trip generation chart based on existing uses. The chart shall be updated and submitted to the City for approval each time a vacancy is filled or a tenant space changes ITE Land Use Codes. 40. Uses on the Property shall be limited to the following percentages of Sales Tax Generating versus Non-Sales Tax Generating Uses in each Phase. For purposes of the calculation, the percentage is based on total gross leasable area. .AREAr Sales Tax Generatingw.., ......_............._. .,,W. ..Non-. ............... Uses Sales Tax Generating _.._ ....................... Uses -. Phase IA—Plaza El Segundo 80 /° minimum 2 maximum Phase 1 B The Pointmaximumam ..mm .._..... ... 65%minimum 35% 41. In order to keep track of the sales tax versus non sales tax generating uses,the applicant must keep a chart of uses for each of the three areas which must be updated and submitted to the City for approval each time a vacancy is filled or a tenant space changes uses. For purposes of condition 40 and this condition, "Sales Tax Generating Uses" includes retail sales uses (including grocery stores),restaurants and cafes,bars,and micro-breweries. "Non-Sales Tax Generating Uses" includes financial institutions, day spas, fitness centers, farmers' markets, offices of all types,personal services, recreational facilities, public assembly/assembly halls (including theaters and museums), video arcades, billiard establishments, and veterinary services. The City's Finance Director, in his/her discretion, will determine whether any use not specifically listed here should be classified as Sales Tax Generating or Non-Sales Tax Generating. The Finance Director's determination may be appealed to the City Council. Any such appeal must be made in writing and delivered to the City Clerk within ten calendar days of the Director's decision. 42. The City of El Segundo requires development project applicants to prepare and submit a Construction Management Plan for each Project Area for review and approval by the P.B.S. Director and Director of Public Works. The Construction Management Plan must consider all stages of construction, including grading, dirt hauling, employee travel, materials delivery, etc. The Construction Management Plan is also required for review and approval by the P.B.S. Director and Department of Public Works for the installation of any utilities, including telecommunication utilities, in the public right-of-way. Such a plan must include, without limitation, traffic control measures for any lane closures. The Construction Management Plan must identify the types and approximate number of construction vehicles to be utilized and must provide haul routes,staging area information and needed road or lane closures. The plan must include,but not be limited to construction hours,construction trailer locations, construction and staging areas, construction crew parking, parking/access plan (including truck haul routes), construction methods and schedules. No haul routes are permitted through the City of Manhattan Beach during A.M. and P.M. peak hours. All staging areas must be on-site.During construction,the areas of construction must be enclosed by a six-foot high chain link fence, except those areas that have additional fencing requirements. Gates of site fencing must be located at driveways and must not open over sidewalk/public right-of-way. During construction, trash must be removed from the Project Site regularly and promptly. At the end of each construction day, all open trenches must be completely closed or covered,or secured in accordance with Cal OSHA standards. All gates and access points to the construction area must be locked and/or fully secured at the end of construction each day. The applicant must provide a twenty-four hour, every day contact person/liaison to receive and respond to complaints during construction. 43. Before the issuance of a Grading or Building Permit for the Project Area,the applicant must provide evidence to the P.B.S.Director that grading or any construction on property or within easements not owned or controlled by the applicant has been approved by the property owner or easement holder. Separate Grading and/or Building Permit(s) must be obtained by the applicant with the easement holder as co-applicant, if needed. 44. Before the issuance of a Building Permit for the Project Area, the applicant must submit plans and specifications for any new curbs, sidewalks, driveway approaches, wheelchair ramps, and asphalt concrete (A.C.) pavement, that must be constructed/reconstructed in the public right-of-way for any missing public segments/areas on the perimeter of the Project Site, as reasonably required by the Director of Public Works. Any existing driveways and other paved areas on the perimeter of the Project Site that will not be incorporated into the development must be removed and replaced with standard curb and sidewalk. Before issuance of a Certificate of Occupancy for the building that is the subject of the Building Permit, the applicant must install the required public improvements per the approved plans to the reasonable satisfaction of the Director of Public Works. 45. The applicant must submit either a Lot Line Adjustment or Lot Merger application after the recording of Final Map 061530, to realign the two parcels south of Union Pacific Railroad to match the proposed locations of the buildings to maintain conformity with the development standards in the ESMC. DEDICATIONS AND FEES 46. The applicant must dedicate approximately 3.47-acres of the "Project Site" to the City for the construction of the extensions of Park Place and Allied Way,as required in Development Agreement No. 04-1 and as depicted on Vesting Tentative Map 061630. Such dedication shall occur through and upon recordation of the Final Map. 47. The applicant must dedicate an eight-foot wide easement for use of a bicycle path to be located in the landscaped front setback of the subject property in compliance with the Circulation Element of the General Plan and South Bay Bicycle Plan to the satisfaction of the Public Works Department and the Planning and Building Safety Department. The exact alignment will be determined by the Public Works Department and the Planning and Building Safety Department. The City acknowledges that this dedication has been made. 48. The applicant must dedicate approximately 0.50-acres of the "Project Area" to the city for roadway widening along the east side of Sepulveda Boulevard, as required in Development Agreement No. 03-1 and as depicted on Vesting Tentative Map 061630. An easement may be provided in lieu of a dedication, only if Caltrans will not accept the dedication and will only accept an easement. A dedication may be provided for the Phase IA portion of Sepulveda Boulevard and an easement may be provided for the Phase 1B portion of Sepulveda Boulevard or conversely an easement may be provided for the Phase 1A portion of Sepulveda Boulevard and a dedication may be provided for the Phase 1B portion of Sepulveda Boulevard. Such dedication and/or such easement shall occur through and upon recordation of the Final Map. 49. Pursuant to ESMC §§ 15-27A-1 et seq.,and before building permits are issued,the applicant must pay a one-time parks facilities mitigation fee as provided in City Council Resolution No. 4687. 50. The applicant may modify the location of the parcel boundaries as approved on Vesting Tentative Tract Map No. 061630,consistent with the development standards in the C-4 Zone to accommodate the size and location of the individual buildings,before recordation of Final Tract Map No. 061630, provided a maximum of 20 parcels are created. 51. Before the recording of the Final Map, the applicant must record a lot tie covenant if any buildings are to be constructed across existing lot lines or if any building location does not meet the development standards of the Commercial Center(C-4)Zone due to the location of the existing lot lines. No Certificates of Occupancy shall be granted for any use or structure until the recording of the Final Map. Accordingly, construction that proceeds before the recording of the Final Map is done at the Developer's risk that a Certificate of Occupancy will not be issued. 52. After the recording of the Final Map, the applicant must submit a Lot Line Adjustment application, if necessary, to realign any parcels to match the proposed locations of the buildings to maintain conformity with the development standards in the SSMC. 53. The applicant must maintain all existing easements on the site if the easement is still required by its grantee. 54. The applicant must provide reciprocal access agreements, subject to review and approval by the City Attorney,between any parcels that do not have independent direct vehicle access to a public right-of-way. Such agreements must be recorded before issuance of any Certificate of Occupancy for a building on an affected parcel. 55. Before the issuance of a Rough Grading Permit for the Project Area, the applicant must provide funds in trust to the P.B.S. Director to cover the reasonable costs, including City consultants' and legal costs and fees, of the monitoring of the conditions of approval and V. adopted mitigation measures associated with rough grading. Before the issuance of a Final Grading Permit, the applicant must provide funds in trust to the P.B.S. Director to cover the first year costs, including City consultants' and legal costs and fees, of the monitoring of the conditions of approval and adopted mitigation measures, not associated with rough grading. Costs may include, without limitation, costs for traffic reviews, stormwater review, biological resource monitoring, soil remediation review, and review of easements, dedications and other agreements. Costs that would be associated with rough grading do not include costs for traffic reviews and review of easements and dedications. Annually thereafter, the applicant must replenish funds as deemed necessary by the P.B.S. Director to cover the reasonable costs, including City consultants' costs for each year. The P.B.S. Director, at his discretion, may hire a consultant to coordinate and monitor compliance. 56. Before the issuance of a Grading Permit, Building Permit, or Certificate of Occupancy, as the case may be, the applicant must provide evidence to the P.B.S. Director that all adopted mitigation measures have been or will be implemented pursuant to the project's mitigation monitoring plan. Compliance with this measure must be verified by the P.B.S. Director, CONSTRUCTION REQUIREMENTS 57. All work within the City public right-of-way must be in accordance with the latest edition of the Standards Specifications for Public Works Construction and City of El Segundo Standard Specifications. No work must be performed in the public right-of-way without first obtaining a Public Works Encroachment Permit. 58. Before the issuance of a Grading or Building Permit for the Project Area,the applicant must provide evidence to the reasonable satisfaction of the P.B.S. Director that all applicable permits from other agencies have been obtained including, without limitation, LARWQCB, Caltrans, State Water Quality Control Board's National Pollution Discharge Elimination Systems (N.P.D.E.S) Permit, South Coast Air Quality Management District, and Los Angeles County Department of Public Works. 59. Following the receipt of all requisite permits, the applicant must notify the P.B.S. Director of the date that construction will commence. 60. At such time deemed necessary by the P.B.S. Director, the applicant must provide an on-site inspection office trailer for the use of City inspection personnel. STORMWATER(GROUND HYDROLOGY AND GROUND WATER QUALITY) 61. The Los Angeles Regional Water Quality Control Board has promulgated rules and standards including, without limitation, obtaining an NPDES Permit and regulations related to underground and above ground storage tanks. The applicant's compliance with LARWQCB will ensure compliance with the applicable sections of the California Water Code (Section 13260), the Clean Water Act, and the Porter-Cologne Water Quality Control Act. The applicant must ensure that any on-site tanks for use in the storage of fuels, wasted oil, solvents or other chemicals,which are located either above ground or underground,must be placed, constructed and maintained in accordance with the requirements of the LARWQCB. 62. The applicant must adhere to any relevant requirements of the LARWQCB regarding development of the site. The applicant must prepare a Storm Water Pollution Prevention Plan (SWPPP) which will demonstrate best management practices relevant to compliance with LARWQCB requirements and the California General Construction Permit. Before the issuance of a Grading Permit for the proposed project,the applicant must provide a SWPPP to the LARWQCB,the P.B.S. Director and Fire Department for review and approval relative to compliance with the provisions and requirements of the LARWQCB. Before issuance of a Building Permit for each Project Area, the applicant must apply for the appropriate notifications and/or registrations for any on-site storage tanks. The applicant must provide a copy to the City of the Notice of Intent required by the LARWCQB. 63. Before the issuance of a final Grading Permit and/or Building Permit for each building in the Project Area,the applicant must provide a drainage plan for that portion of the Project Area affected that eliminates pollutants to surface runoff as required by NPDES requirements. The drainage plan must be reviewed and approved by the P.B.S. Director and Director of Public Works. Before the issuance of a Certificate of Occupancy for each building, the applicant must demonstrate that the drainage plan has been implemented and is effective to the reasonable satisfaction of the P.B.S. Director and Director of Public Works. 64. Before the issuance of a Building Permit for the Project Area, the applicant must provide evidence to the P.B.S. Director and Director of Public Works that pavement on-site must be adequately applied to prevent soil erosion. Further, paved areas on-site must be regularly maintained (i.e., all cracks repaired and debris removed on a regular basis) to prevent soil erosion.The applicant must install improvements pursuant to the approved plans before final sign-off of the Permit. Before the issuance of a Grading or Building Permit for each building in the Project Area, the applicant must provide evidence to the P.B.S. Director and Director of Public Works that on-site drainage must be directed to existing storm drains.The applicant must install said improvements per the approved plans before final sign-off of the Permit. 65. Before the issuance of any Grading or Building Permit for the Project Area, the applicant must prepare a Standard Urban Stormwater Mitigation Plan(SUSMP)and provide evidence to the P.B.S. Director and Director of Public Works that the project area that is the subject of the Grading or Building Permit complies with City of El Segundo Urban Runoff Pollution Prevention Controls (Title 5 - Health and Sanitation, Chapter 7 - Standards Urban Stormwater Mitigation Plan Implementation of the El Segundo Municipal Code). The applicant must install said improvements per the approved plans before final sign-off of the Permit. 66. Before the issuance of a Grading or Building Permit for each building in the Project Area, the applicant must provide evidence to the P.B.S.Director and Director of Public Works that: a. Collection basins to reduce silts in storm water before runoff drainage to the Los Angeles Flood Control System have been adequately incorporated into the project design; b. On-site catch basins have been designed and constructed to screen out larger matter to prevent flooding of the project site resulting from debris caught in the drainage canal; c. Drainage channels within parking lot and paved areas have been be designed and constructed to direct storm water and/or irrigation run-off to collection basins provided on-site; d. On-site drainage and hydrology improvements have been designed in conformance with applicable standards of the City of El Segundo and the Los Angeles County Department of Public Works,including policies in the Public Safety Element of the City's General Plan; e. The project is in compliance with applicable permit requirements of the Los Angeles County Department of Public Works or Los Angeles County Flood Control District; f. On-site drainage and hydrology improvements have been designed using the necessary hydraulic/hydrology and structural calculations required for permitting by the Los Angeles County of Department of Public Works: and, g. All on-site development is consistent with a Hydrology and Drainage Study and the Final Working Drawings, as approved by the City; and, h. Before the issuance of any subsequent Permit `Final Inspection Approval' for the proposed project, the applicant must provide evidence to the P.B.S. Director and Public Works that all the improvements herein have been constructed in compliance with the appropriate regulations and specifications. TRANSPORTATION/CIRCULATION/PARKING 67. If the Los Angeles Congestion Management Plan (CMP) requires the City to track the debits/credits associated with development in the City, before the issuance of the first Building Permit for the Project Site, the applicant must provide Los Angeles County Congestion Management Plan (CMP) Debit/Credit Calculations, and a Phasing Plan for CMP related improvements, to the P.B.S. Director and Public Works for review and approval. The calculations must include only programs which meet all the minimum criteria (e.g., density) contained in the CMP. Before the issuance of a Certificate of Occupancy for the building, the applicant must provide evidence to the P.B.S. Director that the proposed project CMP debits/credits related improvements were implemented and balanced on the Project Site in accordance with the approved phasing plan. Compliance with this measure must be verified by the P.B.S. Director before permit issuance. As may be applicable, the City will give credit for CMP related improvements towards the applicant's traffic mitigation impact fee, as appropriate. 68. Before the issuance of a Building Permit for the Project Area, the applicant must provide a Pedestrian Access/Circulation Plan to the P.B.S. Director, Recreation and Parks Director, and Police Chief for review and approval. The Plan must identify the location of pedestrian, bicycle accesses and indicate linkage to other key elements in the site vicinity, and within the project itself, including parking areas, building entrances, bicycle racks, recreational elements, etc. The Plan must reflect a safe movement pattern, which does not significantly conflict with vehicular movement and parking access areas. Before the issuance of a Certificate of Occupancy for each Project Area, the applicant must provide evidence to the P.B.S.Director,Recreation and Parks Director,and Police Chief that the approved pedestrian and bicycle access features have been installed and will be adequately maintained per the approved plan. 69. Before the issuance of each Building Permit in the Project Area,the applicant must submit a detailed Traffic, Circulation and Parking Plan, prepared by a licensed traffic engineer, for review and approval by the Director of Public Works,the P.B.S. Director,the Police Chief, the Fire Chief, and the City's Traffic Engineer. Alternatively, such a plan may be submitted for a number of buildings at one time if that group of buildings will be completed within a reasonable time period of each other.The Traffic, Circulation and Parking Plan must include, without limitation,the following: a. An analysis of the estimated traffic generation for the building(s); b. Sight distances for each structure and parking area associated with the building(s); c. An analysis of the traffic volumes at each driveway or intersection associated with the building(s)in order to determine if any offsite improvements are warranted(i.e., deceleration lanes, left-turn pockets, new or modified traffic signals, etc.)that were not analyzed in the EIR due to the approximation of building locations in the EIR; d. Any new traffic signals or modifications to existing traffic signals must be subject to the review and approval of the Los Angeles County Department of Public Works. The applicant must pay the applicable county costs to provide plan check and inspection services; e. The applicant must dedicate any on-site land required to accommodate any required intersection and roadway improvements(e.g., deceleration lanes)and the new Park Place and Allied Way roadway extensions through the recording of the Final Map, which may be after building permit'issuance, but must occur before issuance of a Certificate of Occupancy for any building in the Project Area; f. All truck circulation; g. Customer/employee parking; h. All access points to the project site, which should be aligned with existing driveways and intersections where possible; i. Off-site circulation improvements; j. All median modifications, if necessary; k. All dead end aisles eliminated to satisfy City Codes; 1. All truck turning radii; in. The location of required loading spaces; n. An analysis that shows the location and the timing of construction of the required parking for the building or Project Area; o. Pedestrian crossing areas of the public roadways must be called out on the plans and appropriately designated; p. All parcels and structures must be connected by an accessible route of travel that meets the requirements of Title 24 of the California Building Code and, q. Final site plan approval for each building(s)must be contingent upon fulfillment of the above traffic design review requirements. All Circulation and Parking Plan improvements which require installation must be installed before the issuance of each Certificate of Occupancy for the building(s) which are the subject of the Traffic, Circulation and Parking Plan. Compliance with these requirements must be verified by the Director of Public Works, the P.B.S. Director, the Police Chief, the Fire Chief, and the City's Traffic Engineer before the issuance of a Certificate of Occupancy. 70. The applicant must install"No Parking"and other traffic signs on the Park Place and Allied Way roadway extensions, as required by the Public Works Department. The applicant must install"No Parking"and other traffic signs on Sepulveda Boulevard and Rosecrans Avenue, as required by the Public Works Department. 71. The applicant must provide handicap accessible pedestrian walkways,with a minimum five- foot width. Any roadways dedicated to the City as public roadways may have handicap accessible pedestrian walkways within the public right-of-way instead of locating them on private property. 72. Before the issuance of the first Building Permit for the Project Area, the applicant must submit Final Working Drawings to the P.B.S. Director for review and approval that shows that all handicapped, carpool,vanpool,motorcycle,and bicycle parking and other TDM and TSM physical requirements have been provided as required by the City. All TDM/TSM physical improvements required by City regulations must be installed before the issuance of each Certificate of Occupancy. 73. Before the construction of the portion of the Park Place roadway for the proposed project that would intersect Sepulveda Boulevard and any other improvements on Sepulveda Boulevard, the applicant must secure a Caltrans Encroachment Permit to alter Sepulveda Boulevard as set forth in the EIR. The alterations to Sepulveda Boulevard must be in accordance with relevant Caltrans Encroachment Permit requirements and conditions and must be shown on the Final Working Drawings. The applicant is responsible for the costs of modifications and construction of all the roadway extensions and widenings that will be dedicated to the City. Before the issuance of a "Final Inspection Approval" of the roadway improvements,the applicant must install the intersection improvements. The improvements must be reviewed and approved by the City Traffic Engineer, and P.B.S. Director. 74. Prior to the issuance of a Certificate of Occupancy for any building in the Project Area, the new roadways, including any medians, sidewalks, curbs, and gutters must be constructed in accordance with applicable Department of Public Works construction standards for a public roadway with the minimum dimensions required by the Circulation Element of the El Segundo General Plan,and must comply with applicable requirements of the Americans with Disabilities Act (ADA), as well as City requirements for traffic signage, street lighting, drainage plans, and underground utility service, subject to the review and approval of the Director of Public Works. The applicant must be responsible for the design and construction of the new roadways. 75. Before the City issues a certificate of occupancy for any buildings constructed south of the Union Pacific/Burlington Northern Santa Fe Railroads,the new on-site and off-site roadway improvements, including any medians, sidewalks, curbs, and gutters must be constructed in accordance with applicable Department of Public Works construction standards for a public roadway with the minimum dimensions required by the Circulation Element of the El Segundo General Plan to the satisfaction of the Director of Public Works and the Director of Planning and Building Safety, and must comply with applicable requirements of the Americans with Disabilities Act (ADA), as well as City requirements for traffic signage, street, lighting, drainage plans, and underground utility service, subject to the review and approval of the Director of Public Works. Additionally, the roadway improvements along Rosecrans Avenue must be consistent with the design analyzed in the Addendum to the FEIR, including, but not limited to the lane configurations, deceleration lane design at Village Drive, and lengths of left turn pockets at Rosecrans Avenue and Sepulveda Boulevard and at Rosecrans Avenue and Village Drive. The applicant must be responsible for the design and construction of the new roadways. 76. The applicant must install off-site traffic related mitigation measures as set forth in the EIR and MMRP at the time when amount of building (floor area or vehicle trips) triggers the impact for which the mitigation measure is based, as documented in the required Traffic, Circulation, and Parking Plan. 77. Before the issuance of each Building Permit for the Project Area,the applicant must submit a temporary lane closure plan for review and approval by the Director of Public Work, Fire Chief and Police Chief if lane closures will be required during construction for a particular building to insure construction vehicles, equipment and supplies do not interfere with local emergency response routes and incidences. 78. Driveway entrances must be clearly marked, as well as different areas of the parking lot, to ensure visiting vehicles do not accidentally enter the truck staging area. 79. The applicant must coordinate construction lane closures with the Director of Public Works, Police Chief and Fire Chief. 80. Before the issuance of each Certificate of Occupancy for a building in the Project Area, the applicant must pay a Traffic Impact Mitigation Fee. The amount will be based upon the adopted Traffic Impact Mitigation Fee in effect at the time of issuance of a Certificate of Occupancy. 81. Shower and lockers for employees must be provided in sufficient number, as determined by the P.B.S. Director for each tenant in the Project Area exceeding 50,000 square feet. 82. The applicant must submit a Transportation System Management (TSM) Plan, pursuant to the requirements of Chapter 15-17 of the SSMC within 90 days of issuance of the first Certificate of Occupancy in the Project Area. UTILITIES 83. Before the issuance of the first Building Permit for the Project Area, the applicant must provide a Utility Plan to the P.B.S. Director and Public Works for review and approval. The Utility Plan must demonstrate that all on-site utilities, including fiber optic utility lines from each building to the public right-of-way,are placed underground.The applicant must assume the costs for the relocation of all utilities,without limitation,light poles,electrical vaults,and fire hydrants within the Project Area or Project Site Before the issuance of a Certificate of Occupancy for each building that is the subject of the Building Permit, the applicant must provide evidence to the P.B.S. Director and the Director of Public Works that the approved Utility Plan improvements has been installed and appropriate access provided per the approved plan. 84. Before the issuance of the first Building Permit for the Project Area, the applicant must provide evidence to the P.B.S.Director and the Director of Public Works that proposed utility service improvements will be of a quality reasonably acceptable to the P.B.S. Director. The developer must encourage and promote a high quality,efficient,and sustainable development through the incorporation and utilization of the best and most cost-effective electrical,natural gas, communications, sewage handling, water conservation, and solid waste disposal equipment and systems. Compliance with this measure must be verified by the P.B.S. Director before Building Permit issuance. 85. On-site utilities on private property within the project site, including without limitation, storm drains, stormwater detention basins, water and sewer mains, must be owned and maintained by the developer and a connection point to a public main established. 86. Before the issuance of a building permit, the applicant must obtain utility easements for the utilities located on private property within the Project Area that cross through adjacent private property and/or utilities that are used or shared by two or more parcels. 87. Encroachment Permits for work in the public right-of-way must be obtained from the Engineering Division of the Public Works Department. A Grading Permit is also required when import or export of dirt exceeds fifty cubic yards. 88. Overload permits are required for dirt and material hauling on City streets. 89. No material storage is allowed in the public right-of-way except by Encroachment Permit issued by the Engineering Division of the Public Works Department. If material storage is allowed in the public right-of-way, it must be confined to parkway areas and street parking areas, as long as safe and adequate pedestrian and vehicular passage is maintained at all times as determined by the Engineering Division. Storage beyond these areas in the public right- of-way requires prior approval of the Public Works Director and must be limited to a maximum period of 24 hours. 90. Before the issuance of the first Building Permit for the Project Area, the applicant must submit Street and Public Right-of-Way Improvement Plans for review and approval to the Director of Public Works and P.B.S. Director. Said plans must include any required dedications and sidewalks in accordance with City standards necessary for the building that is the subject of the Permit. Sidewalks are required on both sides of all public streets within the Project Area. Before the issuance of a Certificate of Occupancy for each building that is the subject of the Permit, the applicant must dedicate any required right-of-way and install all sidewalks in accordance with plans and specifications approved by the City.Alternatively, the applicant may submit Street and Public Right-of-Way Improvement Plans, if required, for a Project Area or a number of buildings at one time if that group of buildings will be completed within a reasonable time period of each other. 91. The Los Angeles County Sanitation District requires a Buildover Permit for construction over its sewer easements. The applicant must demonstrate through its Grading Plans in the Project Area that all alterations to final sewer easements, relocation of sewer manholes, and rights of way must be in accordance with relevant Buildover Permit(s) to allow the construction of the proposed project and other project components over any sewer easements. Before the issuance of the affected Grading Permits for the proposed project, the applicant must provide evidence to the P.B.S.Director that any necessary Buildover Permit(s)has been obtained or the easement(s)has been relocated. 92. Before issuance of the first building permit in the Project Area, the applicant must inspect the existing sewer laterals that connect to the City sewer mains in the area with closed circuit television(CCTV)to determine the condition of the existing infrastructure that will serve the project. All reports and copies of CCTV videos must be submitted to the Department of Public Works. 93. If new sewer laterals are required and constructed in the public right-of-way, they must be a minimum of six inches inside diameter. Material must be"vitreous clay pipe." Each lateral must have a six-inch clean-out brought to grade at the property line and securely capped. A B9 size box must be placed around the clean-out for protection. The box must have a cover properly marked with the word "sewer." If in a traffic area, the cover must be traffic approved. All elevations of planned sewer connections must be reviewed and approved by the Director of Public Works before starting construction. Existing sewer laterals must be plugged at the sewer mainline and capped at the property line. Existing six-inch wyes may be reused if approved by the Director of Public Works. Any required sewer laterals must be installed before the issuance of a Certificate of Occupancy for the building to be served. 94. If any off-site upgrades are required due to changes in the proposed peak demands in sewer services, a program for the implementation of the upgrades must be provided to demonstrate capacity availability before occupancy. Before the issuance of a Certificate of Occupancy for each building within a Project Area, the applicant must provide evidence to the P.B.S. Director that adequate sewer capacity is available to accommodate the building that is the subject of such Certificate of Occupancy. Alternatively,the applicant may submit any sewer upgrade plans, if required, for a Project Area or a number of buildings at one time if that group of buildings will be completed within a reasonable time period of each other. 95. If any off-site upgrades are required due to changes in the proposed peak demands in water and wastewater service, a program for the implementation of the upgrades must be provided to demonstrate capacity availability before occupancy. Before the issuance of a Certificate of Occupancy for each building within a Project Area, the applicant must provide evidence to the P.B.S. Director that adequate water and wastewater capacity is available to accommodate the building that is the subject of such Certificate of Occupancy. Alternatively,the applicant may submit any water and wastewater upgrade plans,if required, for a Project Area or a number of buildings at one time if that group of buildings will be completed within a reasonable time period of each other. 96. Before issuance of a first Certificate of Occupancy for any building in the Project Area north of the Union Pacific Railroad right-of-way,the applicant must replace the 15-inch sewer line located to the north of the project site with an 18-inch sewer line as depicted on the Phase 1 Utility Layout plan. Before issuance of a first Certificate of Occupancy for any building in the Project Are south of the Union Pacific Railroad right-of-way,the applicant must prepare an analysis of the existing sanitary system on Rosecrans Avenue and calculate additional flow resulting from the proposed development in to the existing system. If necessary, upgrade the 12" and 15" diameter downstream sanitary sewer pipes on Rosecrans Avenue from point of connection to Aviation Boulevard. 97. Businesses that generate fats, oils, or greases are required to install grease interceptors with a minimum 30-minute retention period on appropriate sewer connections. 98. Before the issuance of a Certificate of Occupancy for each building within the Project Area, the applicant must provide evidence to the P.B.S. Director and the Director of Public Works that the appropriate additional on-site water and wastewater improvements as identified by the El Segundo Water and Wastewater Division,or an equivalent service provider,have been installed. Such additional measures must include separate services for potable and fire water systems, a separate water meter for each building, and potable system to be a combined irrigation and domestic, or separated into domestic and irrigation meters. Separate fire services with double detector check valves and backflow preventers are required. Upon completion of the site plan, the exact size and number of fire lines will be determined. Alternatively,the applicant may submit any improvement plans, if required,for a number of buildings at one time if that group of buildings will be completed within a reasonable time period of each other. 99. If any off-site upgrades are required due to changes in the proposed peak demands for telecommunication services, a program for the implementation of the upgrades must be provided to demonstrate capacity availability before occupancy. Before issuance of a Certificate of Occupancy for each building within the Project Area, the applicant must provide evidence to the P.B.S. Director and the Director of Public Works that adequate facilities are available to accommodate the building that is the subject of such Certificate of Occupancy. Alternatively,the applicant may submit any improvement plans,if required,for a number of buildings at one time if that group of buildings will be completed within a reasonable time period of each other. 100. Before the issuance of a Certificate of Occupancy for each building within the Project Area, the applicant must provide evidence to the P.B.S.Director and the Director of Public Works that any appropriate additional improvements for on-site telecommunication services as identified by Pacific Bell, or an equivalent service provider, have been installed to accommodate the building that is the subject of such Certificate of Occupancy.If the existing facilities serve adjacent properties, the services may require relocation. Alternatively, the applicant may submit any improvement plans, if required, for a number of buildings at one time if that group of buildings will be completed within a reasonable time period of each other. 101. If any off-site upgrades are required due to changes in the proposed peak demands in natural gas service, a program for the implementation of the upgrades must be provided to demonstrate capacity availability before occupancy. Before the issuance of a Certificate of Occupancy for each building within the Project Area,the applicant must provide evidence to the P.B.S. Director and the Director of Public Works that adequate facilities are available to accommodate the building that is the subject of such Certificate of Occupancy. Compliance with this measure must be verified by the P.B.S. Director before permit issuance. Alternatively,the applicant may submit any improvement plans, if required,for a number of buildings at one time if that group of buildings will be completed within a reasonable time period of each other. 102. Before the issuance of a Certificate of Occupancy for each building within the Project Area, the applicant must provide evidence to the P.B.S.Director and the Director of Public Works that any appropriate additional on-site natural gas service improvements as identified by The Gas Company, or an equivalent service provider, have been installed to accommodate the building that is the subject of such Certificate of Occupancy. Compliance with this measure must be verified by the P.B.S. Director and before the issuance of the Certificate of Occupancy. Alternatively,the applicant may submit any improvement plans, if required, for a number of buildings at one time if that group of buildings will be completed within a reasonable time period of each other. 103. If any off-site upgrades are required due to changes in the proposed peak demands for electrical service, a program for the implementation of the upgrades must be provided to demonstrate capacity availability before occupancy. Before the issuance of a Certificate of Occupancy for each building within the Project Area,the applicant must provide evidence to the P.B.S. Director and the Director of Public Works that adequate facilities are available to accommodate the building that is the subject of such Certificate of Occupancy. Alternatively, the applicant may submit any improvement plans, if required, for a number of buildings at one time if that group of buildings will be completed within a reasonable time period of each other. 104. Before the issuance of a Certificate of Occupancy for each building within the Project Area, the applicant must provide evidence to the P.B.S. Director and the Director of Public Works that any appropriate additional on-site electrical service improvements as identified by The Edison Company,or an equivalent service provider,have been installed to accommodate the building that is the subject of such Certificate of Occupancy.Alternatively,the applicant may submit any improvement plans, if required, for a number of buildings at one time if that group of buildings will be completed within a reasonable time period of each other. WATER 105. Before the issuance of the first Building Permit for each building within the Project Area, the applicant must submit Off-site Reclaimed Water Facility Plans to the P.B.S. Director and the Director of Public Works for review and approval. Said plans for the off-site improvements must include an approval from West Basin Municipal Water District, the supplier of reclaimed water. 106. Before the issuance of a Building Permit for each building within the Project Area, the applicant must submit Final Working Drawings that incorporate On-site Irrigation Plans to the P.B.S. Director and the Director of Public Works for review and approval. Such plans must indicate that reclaimed water must be utilized in the irrigation systems for all landscape areas and other uses, as approved by the Department of Public Works, when available from the West Basin Municipal Water District or other supplier of reclaimed water. Such plans must include the installation of a dual water line system on-site to accommodate distribution of potable water for landscaping until reclaimed water for landscaping becomes available for the Project Area. In addition to the utilization of reclaimed water for irrigation, other water conservation features such as low-flow devices and automated shut-offs must be included throughout the Project Site. Water management systems must include both water conservation and wastewater reduction features. 107. Before the issuance of a Certificate of Occupancy for each building within the Project Area, the applicant must provide evidence to the P.B.S. Director and the Director of Public Works that the connection with the City's reclaimed water system has been provided,the approved water management systems and water-saving devices have been incorporated into project development,and that the water facilities have been installed per the approved plans. If the water provider is unable to make reclaimed water available before the issuance of the Certificate of Occupancy, then potable water may be utilized and the Certificate of Occupancy must be issued. 108. The applicant must install a loop water distribution system for the Project Site with service connections to each of the water mains in the streets surrounding the project, subject to the review and approval of the Director of Public Works. Before the issuance of each Building Permit in the Project Area, the applicant must submit a construction phasing plan for the water service, which narrst include,without limitation, how the building wlaiela is the subject of(lie hermit will be connected to the looped water distribution system. "l,"lac looped water system 111rrst pr-Ovide water naairas connection to Rosecrans Avenue on the south and Sepulveda Boulevard to the west. 109. Before the issuance of a Certificate of Occupancy for each building within the Project Area, the applicant must pay the applicable water meter installation fees. Compliance with this measure must be verified by the P.B.S. Director before issuance of the Certificate of Occupancy. 110. Before the issuance of a Building Permit for each building within the Project Area, the applicant must pay the applicable sewer connection fees and charges. Compliance with this measure must be verified by the P.B.S. Director before Permit issuance. 111. Before the issuance of the first Certificate of Occupancy for a building in the Project Area, those areas not already part of County Sanitation District must be annexed to County Sanitation District No. 5. 112. Water meters must be provided for each lot by the applicant in accordance with City policies and approved by the Water Division before installation. This condition does not prohibit the use of private water meters for individual buildings or individual tenancies. PROJECT CONDITIONS THAT APPLY TO PHASE 1B ONLY 113. Up to a maximum of 12,000 gross square feet of restaurant space may open as early as 6:00 a.m. daily for breakfast service. ADMINISTRATIVE USE PERMIT/ALCOHOL SERVICE (FOR PHASE 113) 114. The proposed hours of operation and hours of alcohol service for the restaurants and kiosks, including the outdoor dining patios, are limited to: Sunday through Thursday from 10:00 a.m. to 12:00 a.m. and Friday through Saturday from 10:00 a.m. to 2:00 a.m. Food service must be available in the indoor dining areas and the outdoor patios during the hours of operation and alcohol service. Any change to the hours of operation or the hours that alcohol may be served is subject to review and approval by the Director of Planning and Building Safety, 115. Any subsequent modification to the project as approved in the Administrative Use Permit, including the floor plan and areas where alcohol will be served, and/or the conditions of approval,must be referred to the Director of Planning and Building Safety for approval and a determination regarding the need for Planning Commission review of the proposed modification. 116. The applicant for the Alcohol Beverage Control License must obtain and maintain all licenses required by the Alcoholic Beverage Control Act (Business & Professions Code §§ 23300 et seq.). The applicant must obtain and maintain a Type 41 license or a Type 47 license, whichever is applicable. 117. The restaurant operations must comply with ESMC §§ 7-2-1, el seq. regulating noise and vibration. 118. The Planning and Building Safety Department and the Police Department must be notified of any change of ownership of the approved use in writing within 10 days of the completion of the change of ownership. A change in project ownership may be cause to schedule a hearing before the Planning Commission regarding the status of the administrative use permit. 119. The applicant for the Alcohol Beverage Control License must comply with all regulations of the Alcoholic Beverage Control Act and the regulations promulgated by the Alcoholic Beverage Control Board including,without limitation,the regulations set forth in 4 Cal.Code of Regs. §§ 55, et seq. 120. The applicant for the Alcohol Beverage Control License must post a sign in a clear and conspicuous location listing a phone number at which a responsible party may be contacted during all open hours of the establishment to address any concerns of the community regarding noise in the restaurant, patio and parking lot. Said contact's name and phone number must also be available through the restaurant staff at all times. 121. The applicant for the Alcohol Beverage Control License must, at all times, display a Designated Driver sign of at least ten inches by ten inches (10" X 10") in the bar and restaurant dining areas at eye level. The sign must be worded in a way that reminds patrons who are consuming alcohol to designate a non-drinking driver. 122. There cannot be exterior advertising of any kind or type, including advertising directed to the exterior from within, promoting or indicating the availability of alcoholic beverages. Interior displays of alcoholic beverages which are clearly visible to the exterior constitute a violation of this condition. 123. All employees serving alcoholic beverages to patrons must enroll in and complete a certified training program approved by the State Department of Alcoholic Beverages Control (ABC) for the responsible sales of alcohol. The training must be offered to new employees on not less than a quarterly basis. 124. Any and all employees hired to sell alcoholic beverages must provide evidence that they have either: a. Completed training from the State of California Department of Alcoholic Beverage Control (ABC), Long Beach/Lakewood District Office administered Licensee Education on Alcohol and Drugs(LEAD)Program; or, b. Completed an approved equivalent (LEAD) training program administered by the ABC, Long Beach/Lakewood District Office to ensure proper distribution of alcoholic beverages safely, responsibly and to adults of legal age. Any future employee designated to sell alcoholic beverages on behalf of the licensee or applicant must obtain a certificate proving completion of the (LEAD)training; and c. The licensee or applicant must confirm with the Planning and Building Safety Director, or designee, within fifteen (15) days of the Director's decision as to the approval of the application, or by final project approval,that a date certain has been scheduled with the local ABC Office to complete the LEAD training program. d. Within thirty (30) days of taking said course,the employees, or responsible employer must deliver each required certificate showing completion to the Police Department. 125. The applicant for the Alcohol Beverage Control License must have readily identifiable personnel to monitor and control the behavior of customers inside the building premises. Staff must monitor activity outside in the parking lot and any adjacent property under the establishment's control to ensure the areas are generally free of people and are cleared of patrons and their vehicles one-half hour after closing. 126. If complaints are received regarding excessive noise, parking availability, lighting, building access, and the like associated with the restaurants and the outdoor patio areas,the City may, in its discretion, take action to review the Administrative Use Permit, including without limitation, adding conditions or revoking the permit. 127. The outdoor dining/seating areas must comply with ESMC § 15-2-16. 128. The applicant for the Alcohol Beverage Control License must install security cameras for monitoring and recording activity,which include,without limitation:cash handling/counting areas, the manager's office,the safe, all access doors, and any other areas deemed necessary by the Police Department. Monitoring and recording equipment must be stored in a secure area(e.g.,manager's office). 129. Before a building permit is issued, a schematic plan of the camera system must be submitted and approved by the Police Chief, or designee. The camera specification notes must be included on the schematic plan. 130. Before a building permit is issued, the minimum camera requirements must be listed on the building plans with the camera specifications and include the following: a. All security surveillance cameras must be installed to record video in color. b. Security cameras, especially those viewing customers as they enter the business or stand at cash registers, must capture the individual from the waist to the top of the head, straight on. c. Security surveillance cameras must be positioned low enough so that caps/hats or other disguises(typically used when committing a crime)will not obstruct the view of the individual's face. This will provide the best possible picture for the identification of the individual during the investigation process. d. The maximum mounting height is 8 feet. e. The recording equipment must capture video digitally and must record a minimum of (21) days for each security surveillance camera. Security surveillance camera recordings must be made available to law enforcement agencies for investigation purposes upon request. f. A schematic plan of the proposed camera locations must be submitted and approved by the Police Chief, or designee. g. The "Camera Specification Notes"must be included on the schematic plan page. h. A security surveillance camera plan must provide the following minimum items: (1) One camera facing each point of sale station (2); one camera facing the safe (it may be possible to cover the safe and the point of sale station closest to it); and (3) one camera at the main entry door capturing customers as they exit. 131. The buildings cannot be occupied by more persons than allowed by the California Building Code, as adopted by the ESMC. 132. The buildings and any outdoor seating must comply with California Building and Fire Code requirements, as adopted by the ESMC ADJUSTMENT (FOR PHASE 1B) 133. The applicant must post clear signs at each of the required loading spaces designating them as loading spaces during the hours of 6:00 a.m.to 10:00 a.m. The signs must clearly prohibit employee and/or customer parking during those hours. The applicant may extend the loading hours beyond 10:40 a.m. at his discretion. The parking spaces must be marked clearly to delineate the parking and loading spaces to the satisfaction of the Director of Planning and Building Safety. 134. Any subsequent modification to the project as approved in this Adjustment, including the plans and/or the conditions of approval, must be referred to the Director of Planning and Building Safety for approval and a determination regarding the need for Planning Commission review of the proposed modification. VARIANCE (FOR PHASE 1B) 135. Before the City issues building permits,the applicant must submit detailed plans of the two retaining walls along the north property line adjacent to the UPRR right-of-way. The retaining walls and their non-retaining portions cannot exceed 12 feet in height, with the exception that a metal open work fence up to a maximum of 42 inches in height may be installed on top of the walls 136. Any subsequent modification to the project as approved in this Variance, including the plans and/or the conditions of approval, must be referred to the Director of Planning and Building Safety for approval and a determination regarding the need for Planning Commission review of the proposed modification." INDEMNIFICATION 137. The Developer must defend, indemnify and hold the City and its elected and appointed officials, officers, employees and agents harmless from and against any claims, legal or equitable actions, damages, costs(including,without limitation,attorney's fees), injuries,or liability of whatsoever kind or nature, arising from the City's approval of the project, including but not limited to the CEQA determination and/or the Development Agreement approval and all approvals from the time of the approval of the Original Development Agreement through and including the Revised and Restated Development Agreement. Should the City be named in any suit, or should any claim be brought against it by suit or otherwise, whether the same be groundless or not, arising out of any City approval relating to the Revised and Restated Development Agreement or any approvals issued in conjunction therewith, the applicant agrees to defend the City (at the City's request and with counsel satisfactory to the City) and will indemnify the City for any judgment rendered against it or any sums paid out in settlement or otherwise. For purposes of this section"the City"includes the City of El Segundo's elected officials, appointed officials, officers, and employees. 138. PES Partners, LLC and Street Retail,Inc. must acknowledge receipt and acceptance of the Project Conditions by executing the acknowledgement below. By signing this document, PES Partners, LLC and Street Retail, Inc. certify that they have read, understood, and agree to the Project Conditions listed in this document and represents and warrants that it has the authority to execute this document on behalf of the property owner and acknowledges that the conditions set forth above shall run with the land and be binding upon all owners and occupants of the land. PESP PES PARTNERS, LLC, a Delaware limited liability company By: Street Retail, Inc., a Maryland corporation Its: Manager fly Jet] icPresident Western kcgilM STREET STREET RETAIL, INC., a Maryland corporation Jeffrey SIIV e . Vrc� :-President A Western I cg,oll {If Corporation or similar entity, needs two officer signatures or evidence that one signature binds the company)