The URL can be used to link to this page

CONTRACT 5320 Public Works Contract CLOSED Agreement No. 5320 PUBLIC WORKS CONTRACT BETWEEN THE CITY OF EL SEGUNDO AND STEPHEN DORECK EQUIPMENT RENTALS, INC. ON-CALL WATER SYSTEMS MAINTENANCE AND REPAIR SERVICES PROJECT NO.: PW 17-01 This CONTRACT is entered into this 1st day of May, 2017, by and between the CITY OF EL SEGUNDO, a general law city and municipal corporation ("the City") and Stephen Doreck Equipment Rentals, Inc., a California Corporation ("the Contractor"). 1. WORK. A. The Contractor will provide all work listed in the Contractor's Proposal, attached as Exhibit"A" (the"Work"). The Contractor agrees to do additional work arising from changes ordered by the City in accordance with the Contract Documents. B. The Contractor and the City agree to abide by the terms and conditions contained in the Contract Documents. C. The Contractor will furnish all of the labor; supplies and materials; equipment; printing; vehicles; transportation; office space and facilities; all tests, testing and analyses; and all matters whatsoever (except as otherwise expressly specified to be furnished by the City) needed to perform and complete the Work and provide the services required of the Contractor by the Contract Documents. D. "Contract Documents" means the Contractor's Proposal; this Contract; Standard Specifications, attached as Exhibit "B"; Exhibits; Technical Specifications; Notice to Proceed; Change Orders; Notice of Completion; and all other documents identified in the Contract Documents which together form the contract between the City and the Contractor for the Work. The Contract Documents constitute the complete agreement between the City and the Contractor and supersede any previous agreements or understandings. 2. CONTRACT SUM. The City agrees to pay the Contractor a sum not to exceed Forty Five Thousand dollars ($45,000.00) for the Work in the manner set forth in the Contract Documents. The City may adjust this amount as set forth in the Contract Documents. 3. TIME FOR PERFORMANCE, A. The term of this contract shall be for a period on ONE YEAR AND SIX MONTHS (the "Contract Time."). 1 Agreement No. 5320 B. The Contract Time will commence when the City issues a notice to proceed. The Contract Documents will supersede any conflicting provisions included on the notice to proceed issued pursuant to this Contract. C. The Contractor may not perform any Work until: i. The Contractor furnishes proof of insurance as required by the Contract Documents; and ii. The City gives the Contractor a written, signed, and numbered purchase order and notice to proceed. D� By signing this Contract, the Contractor represents to the City that the Contract Time is reasonable for completion of the Work and that the Contractor will complete the Work within the Contract Time. E. Should the Contractor begin the Work before receiving written authorization to proceed, any such Work is at the Contractor's own cost and risk. 4. PREVAILING WAGES. Pursuant to Labor Code § 1720, and as specified in 8 California Code of Regulations § 16000, the Contractor must pay its workers prevailing wages. It is the Contractor's responsibility to interpret and implement any prevailing wage requirements and the Contractor agrees to pay any penalty or civil damages resulting from a- violation of the prevailing wage laws. See Section 7-2 of the Standard Specifications. 5. DISPUTES. Disputes arising from this contract will be determined in accordance with the Contract Documents and Public Contracts Code §§ 10240-10240.13. 6. THIRD PARTY CLAIMS. In accordance with Public Contracts Code § 9201, the City will promptly inform the Contractor regarding third-party claims against the Contractor, but in no event later than ten (10) business days after the City receives such claims. Such notification will be in writing and forwarded in accordance with the "Notice" section of the Contract Documents. As more specifically detailed in the Contract Documents, the Contractor agrees to indemnify and defend the City against any third-party claim. 7. TAXPAYER IDENTIFICATION NUMBER. The Contractor will provide the City with a Taxpayer Identification Number. 8. PERMITS AND LICENSES. Unless otherwise provided, the Contractor, at its sole expense, will obtain and maintain during the Contract Time, all necessary permits, licenses, and certificates that may be required in connection with the Work. 9. OWNERSHIP OF DOCUMENTS. All documents, data, studies, drawings, maps, models, photographs and reports prepared by the Contractor under the Contract 2 Agreement No. 5320 Documents are the City's property. The Contractor may retain copies of said documents and materials as desired, but will deliver all original materials to the City upon the City's written notice. 10.INDEMNIFICATION. The Contractor agrees to indemnify, defend, and hold the City harmless as set forth in the Contract Documents. The requirements as to the types and limits of insurance coverage to be maintained by the Contractor as required by the Contract Documents, and any approval of such insurance by the City, are not intended to and will not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Contractor pursuant to the Contract Documents, including, without limitation,to the provisions concerning indemnification. 11.INDEPENDENT CONTRACTOR. The City and the Contractor agree that the Contractor will act as an independent contractor and will have control of all work and the manner in which is it performed. The Contractor will be free to contract for similar service to be performed for other employers while under contract with the City. The Contractor is not an agent or employee of the City and is not entitled to participate in any pension plan, insurance, bonus or similar benefits the City provides for its employees. Any provision in this Contract that may appear to give the City the right to direct the Contractor as to the details of doing the work or to exercise a measure of control over the work means that the Contractor will follow the direction of the City as to end results of the work only. 12.AUDIT OF RECORDS. The Contractor will maintain full and accurate records with respect to all services and matters covered under this Contract. The City will have free access at all reasonable times to such records, and the right to examine and audit the same and to make transcript therefrom, and to inspect all program data, documents, proceedings and activities. The Contractor will retain such financial and program service records for at least three (3) years after termination or final payment under the Contract Documents. 13.NOTICES. All communications to either party by the other party will be deemed made when received by such party at its respective name and address as follows: The Citv The Contractor City of El Segundo-Public Works Stephen Doreck 350 Main Street Equipment Rentals, Inc. El Segundo, CA 90245 9075 Telegraph Rd. Attention: Arianne Bola Pico Rivera, CA 90660 Attn: Stephen Doreck Any such written communications by mail will be conclusively deemed to have been received by the addressee three (3) days after deposit thereof in the United States Mail, postage prepaid and properly addressed as noted above. In all other instances, notices will be deemed given at the time of actual delivery. Changes may be made in the names or addresses of persons to whom notices are to be given by giving notice in the manner prescribed in this paragraph. 3 Agreement No. 5320 14.NO THIRD PARTY BENEFICIARY. This Contract and every provision herein is for the exclusive benefit of the Contractor and the City and not for the benefit of any other party. There will be no incidental or other beneficiaries of any of the Contractor's or the City's obligations under this Contract. 15.INTERPRETATION. This Contract was drafted in, and will be construed in accordance with the laws of the State of California, and exclusive venue for any action involving this Contract will be in Los Angeles County. 16.EFFECT OF CONFLICT. In the event of any conflict, inconsistency, or incongruity between any provision of the Contract Documents, precedence will be as follows: A. This Contract; B. The Standard Specifications; and C. Precedence of documents as determined in the Standard Specifications. 17.SEVERABILITY. If any portion of the Contract Documents are declared by a court of competent jurisdiction to be invalid or unenforceable, then such portion will be deemed modified to the extent necessary in the opinion of the court to render such portion enforceable and, as so modified, such portion and the balance of this Contract will continue in full force and effect. 18.AUTHORITY/MODIFICATION. The Parties represent and warrant that all necessary action has been taken by the Parties to authorize the undersigned to execute this Contract and to engage in the actions described herein. This Contract may be modified by written amendment. The City's city manager, or designee, may execute any such amendment on the City's behalf. 19.ACCEPTANCE OF FACSIMILE SIGNATURES. The Parties agree that this Contract, agreements ancillary to this Contract, and related documents to be entered into in connection with this Contract will be considered signed when the signature of a party is delivered by facsimile transmission. Such facsimile signature will be treated in all respects as having the same effect as an original signature. 20.COVENANTS AND CONDITIONS. The parties agree that all of the provisions hereof will be construed as both covenants and conditions, the same as if the words importing such covenants and conditions had been used in each separate paragraph. 21.CAPTIONS. The captions of the paragraphs of this Contract are for convenience of reference only and will not affect the interpretation of this Contract. 22.TIME IS OF ESSENCE. Time is of the essence for each and every provision of the Contract Documents. 4 Agreement No. 5320 IN WITNESS WHEREOF the parties hereto have executed this contract the day and year first hereinabove written. CITY OF EL SEGUNDO STEPHEN DORECK EQUIPMENT a g ral I ity. RENTALS, INC. Gre arpe r e8le h L. Doreck City anager P sident ATTEST: Taxpayer ID No. 20-8858954 a r City,"y ler , . . .... Contractor State License No. 665471-A APPROVED AS TO FORM: Contractor City Business Mar D. sle;? License No. 25624 City Attorney Insurance Reviewed by: 5 Agreement No. 5320 CA1111 11FV111RINIA All J111 i,dIPMR111DOS1111:::i ACKNOW1111 IU ,1111)GIMIEN r State of California County of Los Angeles April 18,2017 before me, Sylvia Sifuentes(Notary Public) On Dale H"m lasie't 1I I[,,od ci J f w i personally appeared Stephen L.Doreck Name(,)of Sqner(s) who proved to me on the basis of satisfactory evidence to be the person( whose name(j) is/AW subscribed to the within instrument and acknowledged to me that he/M/#Nbf executed the same in SYLVIA SIFLIENTES his/110/tHW/ authorized capacity(ill and that by Commission#2081164 his/V#r/tV/# signature(,q) on the instrument the person(b), or the entity upon behalf of which the 1� Notary Public-California Z > Los Angeles County person(A) acted, executed the instrument. Comm. Expires Oct 8, 2!01J8 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signatufc�l Place Notary Seal Alhov. Signature I i I l„! 'ol =f Signature I I OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document Description of Attached Document Title or Type of Document: Document Date: Number of Pages, Signer(s)Other Than Named Above: Capacity(ies) Claimed by Signerl Signer's Name: Signer's Name: I Corporate Officer Title(s); Corporate Officer—Title(s): Individual I Individual SEEM 1 Partner—❑Limited General Tor)of thumb here 1 Partner—: I Limited I I General Top of IhL]fTib hole Attorney in Fact I Attorney in Fact Trustee I Trustee I Guardian or Conservator I Guardian or Conservator Other I I Other: Signer Is Representing: Signer Is Representing: ©2009 National Notary Association•Nationa'Nolary org•1-800-US NOTARY(1-800-076-6B27) Item h5907 THE FINAL PREMIUM IS Agreement No. 5320 PREDICATED ON THE FINAL CONTRACT AMOUNT FAITHFUL PERFORMANCE BOND ON-CALL WATER SYSTEMS MAINTENANCE AND REPAIR SERVICES PROJECT NO.: PW 17-01 Bond No.2256108 Bond Fee: $648.00 Stephen Doreck Equipment Rentals,Inc. ("PRINCIPAL") and North American Specialty Insurance Companv , a corporation incorporated under the laws of the State of New Hampshire and licensed by the State of California to execute bonds and undertakings as sole surety,as surety("SURETY"),are held and firmly bound unto the CITY OF EL SEGUNDO ("CITY") in the sum of Fotiv Five"1"11ousand ($45.000.00),lawful money of the United States,which may be increased or decreased by a rider hereto executed in the same manner as this bond, for the payment of which sum PRINCIPAL and SURETY bind themselves, their successors, and assigns, jointly and severally, by this instrument. PRINCIPAL or SURETY will apply this bond for the faithful performance of any and all of the conditions and stipulations set forth in this bond,SPECIFICATIONS NO.PW 17-01,and the public works contract executed with such Specifications. In the case of any default in the performance of the conditions and stipulations of this undertaking,it is agreed that PRINCIPAL or SURETY will apply the bond or any portion thereof, to the satisfaction of any damages, reclamation, assessments,penalties, or deficiencies arising by reason of such default. BOND CONDITIONS 1. PRINCIPAL will construct the public improvements identified in SPECIFICATIONS NO. PW 17-01, a copy of which is on file with CITY's Engineering Division ("Public Project"). Such performance will be in accordance with CITY's plans and profiles (CITY DRAWING FILE NO. PW 17-01) which are made a part of this bond when said plans and profiles are approved by the City Council and filed with CITY's Engineering Division. CITY has estimated the required amount of the bond as shown above. 2. PRINCIPAL's work on the Public Project will be done in accordance with CITY's plans and specifications and with any permit issued by CITY. Should PRINCIPAL fail to complete all required work within the time allowed,CITY may,at its sole discretion,cause all required work to be done and the parties executing the bond will be firmly bound for the payment of all necessary costs therefor. 3. PRINCIPAL will guarantee its work against any defective work, labor, or materials on the Public Project for a period of one (1) year following the Public Project's completion and acceptance by CITY. I-E-1 Agreement No. 5320 4. This bond is conditioned upon and guarantees due compliance with all applicable law including, without limitation,the El Segundo Municipal Code (`SSMC"). 5. SURETY, for value received, agrees that no changes, extensions of time, alteration or modification of SPECIFICATIONS NO. PW 17-01 or of the obligation to be performed will in any way affect its obligation on this bond, and it waives notice of any such change, extension of time, alteration or modification of the contract documents or of the obligation to be performed. 6. This bond consists of this instrument; the plans and specifications identified above; and the following two (2) attached exhibits all of which are incorporated herein by reference: A. A certified copy of the appointment,power of attorney,bylaws or other instrument entitling or authorizing the persons executing this bond to do so; & A certificate issued by the county clerk for the county in which SURETY's representative is located conforming with California Code of Civil Procedure § 995.640 and stating that SURETY's certificate of authority has not been surrendered, revoked, cancelled, annulled,or suspended,or in the event that it has,that renewed authority has been granted; and 7. Should PRINCIPAL perform its obligations within the time allowed, PRINCIPAL's obligation will be void upon the acceptance of the performance by CITY; otherwise this obligation will remain in full force and effect. [SIGNATURES ON FOLLOWING PAGE] I-E-2 Agreement No. 5320 SIGNED AND SEALED this 17th day of April 120 17 , StepherVIDoreck Equipment Rentals,Inc, North Arneng ' P,e-cialt 13sufar&e. ornpZInly al� ) J 's PRESI 6 k X ["�'TY's N&W �Wf Arturo Ayala,Attorney-in-Fact Yee PRINCIPAL's SECRETARY SURETY's SECRETARY ,/)a 6/0 V,kint mm-t4,s PRINCIPAL's MAILING ADDRESS: SURIETY's MAILING ADDRESS: 9075 Telegraph Road 6 Hutton Center Drive,Suite 850 Pico Rivera,CA 90660 Santa Ana,CA 92707 ................... ................................. .................................... NOTE: (1) ALL signatures must be acknowledged by a notary public. Return one(1)original to City Clerk's Office. (2) Bond shall be effective for one(1)year after acceptance of the job. I-E-3 Agreement No. 5320 CA1111 1F'�'011rk111Q1A ,&111 111 �UR1F:P0S1111:::., ACIIKII�40WIll�IEIIII!)GIM�Ell�41"I"1 State of California ^ Coun� ��=Angeles N ° On April|8,2Ol7 _ before me. Sr(viuSiumLus . � vDale � x�ins.Ft Name=w Title mthe 011icer � personally appeared Catherine R. Doceck And Pablo Vi omontc« °a~e(w*«'one^* ' who proved to me on the basis of satisfactory evidence tohothe p*mun(y) whooe name(q) ia/AW � subscribed to the within instrument and acknowledged ` to me that he/MlYfflWy executed the same in � � hio/W/th/d8 authorized oapaoi(y(id , and that by � COMMIssion#2081164 hio/Vyr/tht# signature(q) on the instrument the � Not Public California pomon(A), or the entity upon behalf of which the ` mnxngomuuommy pemon(p) acted, executed the instrument. > ,..Comm. Expires Oct | certify under PENALTY OF PERJURY undar1hu ' laws o4 the State of California that the foregoing paragraph is true and correct. h^ WITNESS my hand and official seal, x Piece 5iOmaU � mw~um^w� ^ OPTIONAL --- ` Though the Information»mo"mmxrevmred by law, xmay prove valuable to persons relying on the document � and could prevent ooudumo/removal and nm/moomon/or this mm,to another document. Description ofAttached Document ' Title o,Type o/ Document: Document Dave: ' Number of Pages 8gnor(s)Other Than Named Above:____-- ------_- Capacity(iem) Claimed by Signer(s) � � Signer's Name Signe�xNume� ' 3 CnrporamOfficer--`loo(s) !Corporate Officer--Thle(a):�_____________� individual I|mg*iuuo| MEMO / Partne,—uumited c|{enem| Top of thurrib here /|Partner—/ /umiteu 1 General Top m��here ' I Attorney in Fact i Attorney mFact � Trustee � !Trustee � | Guardian or Conservator |Gvordian or Conservator omec | )Other: ______�____ ___ _ '^ Signo, Is Representing: Signer Is Representing: 41'�^��`*~��^�`,xp��~�w+m``�,�^��=+^�+x^p*.��^�a��w�`x�*^ Q 2009 Nalmnal Nolary Assoc,ahon-NalmniiNolairy org 1-000-US NOTARY(1-800-1376-6827) Item H5907 CALIFORNIA ALL-RURPOSE ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the do cu m en t to w hich this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA County of Orange � On April 17th, 2017 b�nnoma. Shaunn� RozoUaDavom Notary Public, � �� Insert Name m Notary exactly asu appears un the official seal personally appeared Arturo Ayala _ -Name(s)maig«v# ' who proved to ma on the basis of satisfactory evidence to bo the pomonha whose name(n) is/are subscribed hothe | within instrument and acknowledged tomedhathe/she/they 1 executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the S COMM.#21.596:17 person(s), or the entity upon behalf of which the person(s) 0 acted, executed the instrument. Notary Public-California ORANGE COUNTY U. My Comm.FJI�Wo,htt 11,2020 | certify under PENALTY OF PERJURY under the |avvo of the State of California that the foregoing paragraph is true and correct. Witness Signature/ �''�,�`��1�� Place wma�Seal*bmm u/o°w��mwma�pumm ��dMn� �o�eK�T��norn -- .-........ -.....—........ `- ..........................................................................'............... -..................... OPTIONAL Though the law, it prove valuable ��oun the document and could prevent 0audu/ent'removal and reattachment ufthe form to another document. Description mf Attached Document K Title or Type nfDocument: U Foithfu| PerformonoeBond -- - -- ----------- Document Date: <}4/f7y2017 NumbarofPages: Three Signor(o) Other Than Named Above: � Cmpao|ty(|ma) C|o|nnmd byS|gner(a) Signer's Name: AdunuAva|a Signer's Name: [] Individual [] Individual 0 Partner El Limited El General El Partner El Limited El General 9 Attorney in Fact El Attorney in Fact n Trustee Trustee EM =11 Milo" F1 Guardian or Conservator Top of thumb here E] Guardian or Conservator Top of thumb here F1 Other: F] Other: Signer is Representing: Signer is Representing: Bond No.2256108 NAS SURETY GROUP NORTH AMERICAN SPECIALTY INSURANCE COMPANY WASHINGTON INTERNATIONAL INSURANCE COMPANY WBSTyORT INSURANCE CORPORATION GENERAL POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS,THAT North American Specialty laws of the State of New Hampshire,and having its principal office in the City of Manchester,New Hampshire and Washington International Insurance Company a corporation organized and existing under the laws of the State of New Hampshire and having its principal office in the City of Schaumburg, Illinois,and Westport Insurance Corporation,organized under the laws of the State of Missouri,and having its principal office in the City of Overland Park,Kansas each does hereby make,constitute and appoint: DANIEL mucnAaAY.xnnURoArALx,ANDREW vmArEaBonY.DWIGHT nxILLY.a:mzmmAaozoLLoonTRnM and MICHAEL CAsT»uwaoA JOINTLY OaSEVERALLY --' Its true and lawful Attomey(s)-in-Fact,mmake,execute,seal and deliver,for and on its behalf and as its act and deed,bonds mother writings obligatory iu the nature of a bond on behalf of each of said Companies,as surety,on contracts of suretyship as are or may be required or permitted by law,regulation,contract or otherwise,provided that^o bond o,undertaking vr contract or suretyship executed under this authority shall exceed the amount of: ONE HUNDRED TWENTY FIVE MILL ION($125,000,000.00)DOLLARS This Power o{Attorney is granted and io signed hr facsimile undu and by the authority nf the following Resolutions adopted hy the Boards nf Directors vy North American Specialty Insurance Company uodYVuobiogtoulntem*bouallnvunmuoCo at meetings duly called and held on March 24,2000 and Westport Insurance Corporation by written consent of its Executive Committee dated July 18,2011. "RESOLVED,that any two o[the President,any Senior Vice President,any Vice President,any Assistant Vice President, the Secretary vzany Assistant Secretary be,and each or any of them hereby is authorized to execute a Power of Attorney qualifying the attorney named in the given Power of Attorney to execute on behalf of the Company bonds,undertakings and all contracts of surety,and that each or any of them hereby io authorized m attest mthe execution of any such Power"f Attorney and m attach therein the seal of the Company; and dio FURTHER RESOLVED,that the signature vr such officers and the seal oy the Company may he affixed m any such Power o[Attorney v,many certificate relating thereto hy facsimile,and any such Power of Attorney or certificate bearing such facsimile signatures or facsimile seal shall be binding upon the Company when ov affixed and bu the future with regard m any bond,undertaking or contract of surety m which diouuacbvd.^ o By Steven,.Anderson,w"^.",*",wi^=,",W".m°m."""^.o^^"""/^°.""",^c^°»=' FRO &n=�,m=r�m=,",^�^^=*" w=wty Insurance Company a Senior Vice President",Westport Insurance Corporation By M/�^�,*.�'",�,°r�°u�,�v��gw"�w�"*""*�="�m=p=, ��|� � "=c°"w" nn WITNESS WHEREOF,North American Specialty Insurance Company,Washington International Insurance Company and Westport Insurance Corporation have caused their official seals to be hereunto affixed,and these presents to be signed by their authorized officers this this 5th day of Doo°mto, ,%O 16 North American Specialty Insurance Company Washington International Insurance Company State vfIllinois Westport Insurance Corporation County o[Cook o»: 0u this_5th_day oy December .2» u�before me,u Notary Public personally appeared..............Steven P.Anderson L_.Senior Vice President vf Washington Company and Senior Vice President of North American Specialty u`,omuue Company and Senior Vice President of Westport Insurance Corporation and_Michael A, Ito Senior Vice President of Washington International Insurance Company and Senior Vice President of North American Specialty Insurance Company and Senior Vice President of Westport Insurance Corporation,personally known to me,who being hrnoo duly sworn,acknowledged that they signed the above Power of Attorney uo officers of and acknowledged said instrument mhe the voluntary act and deed nf their respective companies. NY =NOTAHYPUBLI M.Kenny,Nutarl/P bUc \ 1, Jeffrey Goldberg . the duly elected Vice President and Assistant Secretary of North American Specialty Insurance Company,Washington International Insurance Company and Westport Insurance Corporation do hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney given by said North American Specialty Insurance Company,Washington International Insurance Company and Westport Insurance Corporation which io still in full force and effect. OV WITNESS WHEREOF,Ihave set my hand and affixed the seals o{the Companies this rDb day of April 20 17 Agreement No. 5320 . " HUGH NGUYEN PROPERTY RECORDS BIRTH AND DEATH RECORDS CLERK-RECORDER MARRIAGE LICENSES/RECORDS PASSPORTS FICTITIOUS BUSINESS NAMES " NOTARY REGISTRATION ORANGE COUNTY ARCHIVES CERTIFICATE,,,,,OF„ADMITTED SURETY INSURER Certificate pursuant to 995.640(a)Code of Civil Procedure State of California County of Orange I, Hugh Nguyen, County Clerk-Recorder of the County of Orange, State of California, in and for said County, DO HEREBY CERTIFY THAT No rd i American Snecialty hisur mice Company has been issued a Certificate of Authority as an Admitted Surety Insurer by the State of California Insurance Commissioner who authorized the Insurer to transact Surety Insurance in the State of California and that based on the records in this office, that authority has not been surrendered, revoked, cancelled, annulled or suspended. In Testimony Whereof, I execute this certificate and have hereunto set my hand and affixed the seal of said County this 17th day of April, 2017. Hugh*77�o unty Clerk-Recorder p (Purple Seal) ti Laura Martinez, Deputy Clerk-Recorder rNTV,. NORTH COUNTY BRANCH OFFICE ORANGE COUNTY SOUTH COUNTY BRANCH OFFICE HISTORIC DOWNTOWN FULLERTON HALL OF RECORDS LAGUNA HILLS CIVIC CENTER 201 N. HARBOR BOULEVARD 12 CIVIC CENTER PLAZA, ROOM 101 24031 EL TORO ROAD FULLERTON, CALIFORNIA 92832 SANTA ANA, CALIFORNIA 92701 LAGUNA HILLS, CALIFORNIA 92653 (714) 834-2500 ♦ FAX (714) 834-2675 ♦ WWW.00RECORDER.COM ♦ WWW.00ARCHIVES.COM THE FINAL PREMIUM IS Agreement No. 5320 PREDICATED ON THE FINAL CONTRACT AMOUNT LABOR AND MATERIALS BOND ON-CALL WATER SYSTEMS MAINTENANCE AND REPAIR SERVICES PROJECT NO.: PW 17-01 Bond No. 2256108 Bond Fee: Included in Performance Bond Stephen Doreck Equipment Rentals, Inc. as principal ("PRINCIPAL") and N,1h American Specialty Insurance Company a corporation incorporated under the laws of the State of New Hampshire and licensed by the State of California to execute bonds and undertakings as sole surety,as surety("SURETY"),are held and firmly bound unto the CITY OF EL SEGUNDO ("CITY") in the sum of Forty hive IIliotisatld ($45,000.00), lawful money of the United States, which may be increased or decreased by a rider hereto executed in the same manner as this bond,for the payment of which sum PRINCIPAL and SURETY bind themselves, their successors, and assigns, jointly and severally,by this instrument. This bond is conditioned upon and guarantees payment by PRINCIPAL to contractors, subcontractors,and persons renting equipment;payment by PRINCIPAL and all PRINCIPAL'S subcontractors for all materials,provisions,provender,or other supplies,and equipment used in, upon, for or about the performance of the work contemplated in ON-CALL WATER SYSTEMS MAINTENANCE AND REPAIR SERVICES PROJECT,SPECIFICATIONS NO.PW 17-01 ("Public Project"), the public works contract executed for such Public Project, and for all work or labor of any kind performed for the Public Project.In the case of any default in the performance of the conditions and stipulations of this undertaking, it is agreed that PRINCIPAL or SURETY will apply the bond or any portion thereof,to the satisfaction of any damages,reclamation, assessments,penalties,or deficiencies arising by reason of such default. BOND CONDITIONS 1. PRINCIPAL will construct the public improvements identified in SPECIFICATIONS NO. PW 17-01, and the public works contract executed for such Specifications,copies of which is on file with CITY's Engineering Division("Public Project"). Such performance will be in accordance with CITY's plans and profiles (CITY DRAWING FILE NO. PW 17-01), which are made a part of this bond when said plans and profiles are approved by the City Council and filed with CITY's Engineering Division. 2. PRINCIPAL will pay all contractors, subcontractors, and persons renting equipment. 3. PRINCIPAL will pay for all materials and other supplies,for equipment used in, I-F-1 Agreement No. 5320 on, for or about the performance of the Public Project, and will pay for all work and labor thereon. 4. This bond is conditioned upon and guarantees due compliance with all applicable law including, without limitation, the El Segundo Municipal Code (`SSMC"). 5. SURETY, for value received, agrees that no changes, extensions of time, alteration or modification of SPECIFICATIONS NO. PW 17-01, or of the obligation to be performed will in any way affect its obligation on this bond, and it waives notice of any such change, extension of time, alteration or modification of the contract documents or of the obligation to be performed. 6. This bond consists of this instrument; the plans and specifications identified above; and the following TWO (2) attached exhibits all of which are incorporated herein by reference: A. A certified copy of the appointment, power of attorney, bylaws or other instrument entitling or authorizing the persons executing this bond to do so; and B. A certificate issued by the county clerk for the county in which SURETY's representative is located conforming with California Code of Civil Procedure § 995.640 and stating that SURETY's certificate of authority has not been surrendered,revoked,cancelled, annulled,or suspended,or in the event that it has, that renewed authority has been granted. 7. Should PRINCIPAL perform its obligations within the time allowed, PRINCIPAL's obligation will be void upon the acceptance of the performance by CITY; otherwise this obligation will remain in full force and effect. [SIGNATURES ON FOLLOWING PAGE] I-F-2 Agreement No. 5320 SIGNED AND SEALED this 17th day of April 2017 StepjlfO Dqreck Equipment Rent Is, Inc. North Arn riWi Speci ly.trisurance Company �1,�INQIPAL's 1 FSIDE e�t_IRET)I's VRKE�f *WAtum Ayala,Attorney-in-Fact C." PRJNCIPAL's SECRETARY SURETY's SECRETARY �41210 Vlrlc"41 6� PRINCIPAIL's MAILING ADDRESS: SURIFTY's MAILING ADDRESS: 9075 Telegraph Road 6 Hutton Center Drive,Suite 850 Pico Rivera,CA 90660 Santa Ana,CA 92707 NOTE: (1) ALL signatures must be acknowledged by a notary public. Return one(1) original to City Clerk's Office. (2) Bond shall be effective for one (1) year after acceptance of the job I-F-3 Agreement No. 5320 CALNIIII::','ORI41A ,ALL- UIIIRPOSE AC111KINOW III DGMIEN 111i State of California County of Los Angeles On April 18,2017 before me, Syk,kt Sifuluntics(Notary Public) cafe Here Insert Name and rifle or ibe O—Ilice—, tr personally appeared Catherine R. Doreck And Pablo Viramontes Name(s)of Siquer(s) jt who proved to me on the basis of satisfactory evidence to be the personl whose name(j) is/i A"I subscribed to the within instrument and acknowledged SYLVIA SIFLIENTES to me that helMlYNY executed the same in 081161 PENTES t 081 Commission#2 164 Z hisAMAIW authorized capacity(M), and that by Notary Public-California Z his/Ij(hirrAll signaturel on the instrument the Z Los Angeles County > My Comm, Expires Oct 8, 2018 person , or the entity upon behalf of which the persi acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. S WITNESS my hand and official seal. Place Nolay Seal Above Mi", v Public OPTIONAL ....... .. . ....... Though the information below is not required by law,it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages Signer(s)Other Than Named Above Capacity(ies) Claimed by Signers) Signer's Name: Signer's Name: L-j Corporate Officer Title(s):Corporate Officer Title(s) ------ Individual i (Individual NEE 1 Partner—1 Limited j General Top of thumb Isere 1 Partner I Limited A General Top of lhurrib nene Attorney in Fact F!Attorney in Fact Trustee I Trustee e Guardian or Conservator I I Guardian or Conservator Other: I 01hel Signer Is Representing: Signer Is Representing: la U"M i:,1L d,A,4,�4 q,'*Aq,1,0 4,W'.X "X X, Q 2009 National Notary Association•NationaiNotary org•1-600-US NOTARY(1-800-fl71 Item M5907 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA County of Orange On April 17th, 2017 before me, Shaunna Rozelle Ostrom Notary Public, Date Insert N2Me of Notary exactly as it appears on the official seal personally appeared Arturo Ayala who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) SHAUNNA ROZELLE OSTR acted, executed the Instrument. COMM.#21596:17 Notary Public-Califoinia I certify under PENALTY OF PERJURY under the laws of ORANGE COUNTY LL the State of California that the foregoing paragraph is true IVIYCOMM.Expireshil 11,2020 and correct. Witness my and ff I '.i�seal Signatur Place Notary Seal Above of Nolar'y Pu`bll`8� �Sh'a"ur�!�n`a� Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of the form to another document. Description of Attached Document Title or Type of Document: Labor and Materials Bond Document Date: 04/17/2017 Number of Pages: Three Signer(s) Other Than Named Above� Capacity(ies) Claimed by Signer(s) Signer's Name: Arturo AVala Signer's Name: 1771 Individual F1 Individual El Partner El Limited El General El Partner El Limited El General 9 Attorney in Fact El Attorney in Fact n Trustee E] Trustee F-1 Guardian or Conservator E] Guardian or Conservator Top of thumb here F] Other: n Other: Signer is Representing: Signer is Representing� � � Bond No.2256108 NAS SURETY OUP NORTH AMERICAN SPECIALTY INSURANCE COMPANY WASHINGTON INTERNATIONAL INSURANCE COMPANY STPOT INSURANCE CORPORATION GENERAL POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS,THAT North American Specialty Insurance Company,a corporation duly organized and existing under laws of the State of New Hampshire,and having its principal office in the City of Manchester,New Hampshire and Washington International Insurance Company a corporation organized and existing under the laws of the State of New Hampshire and having its principal office in the City of Schaumburg, Illinois,and Westport Insurance Corporation,organized under the laws of the State of Missouri,and having its principal office in the City of Overland Park,Kansas each does hereby make,constitute and appoint: DANIEL HUCKABAY,ARTURO AYALA,ANDREW WATERBURY,DWIGHT REILLY,SHAUNNA ROZELLE OSTROM and MICHAEL CASTANEDA ......................... JOINTLY OR SEVERALLY Its true and lawful Attorney(s)-in-Fact,to make,execute,seal and deliver,for and on its behalf and as its act and deed,bonds or other writings obligatory in the nature of a bond on behalf of each of said Companies,as surety,on contracts of suretyship as are or may be required or permitted by law,regulation,contract or otherwise,provided that no bond or undertaking or contract or suretyship executed under this authority shall exceed the amount of ONE HUNDRED TWENTY FIVE MILLION($125,000,000.00)DOLLARS This Power of Attorney is granted and is signed by facsimile under and by the authority of the following Resolutions adopted by the Boards of Directors of North American Specialty Insurance Company and Washington International Insurance Company at meetings duly called and held on March 24,2000 and Westport Insurance Corporation by written consent of its Executive Committee dated July 18,2011. "RESOLVED,that any two of the President,any Senior Vice President,any Vice President,any Assistant Vice President, the Secretary or any Assistant Secretary be,and each or any of them hereby is authorized to execute a Power of Attorney qualifying the attorney named in the given Power of Attorney to execute on behalf of the Company bonds,undertakings and all contracts of surety,and that each or any of them hereby is authorized to attest to the execution of any such Power of Attorney and to attach therein the seal of the Company; and it is FURTHER RESOLVED,that the signature of such officers and the seal of the Company may be affixed to any such Power of Attorney or to any certificate relating thereto by facsimile,and any such Power of Attorney or certificate bearing such facsimile signatures or facsimile seal shall be binding upon the Company when so affixed and in the future with regard to any bond,undertaking or contract of surety to which it is attached." C. « rrN es .f1�#p6N11YfdPararaim'Ire, ^^ ,,it coo r.,andaranaa,`rrrinr tirrm N t'4J" f ('Oal � "�,Nt,7� aowlcard�+�h o wr widn"glirn Naawl TiTwipma l liviuraroic Company 5�L &Senior Vaee President orriorth American Specialty Insurance Company �8�3 ter. 17 ° i &Senior Vice President of Westport Insurance Corporation 5 Mikc,V,l i"Se^nka'lice Povsiclvm r�a r'� N' aaNning,toar laet�co•nutianuaN hrnraa•aa'dtt t."rrmprrary lldddUlNlitllra,o•ar &Senior Vice President of North Anarrlc,rrar"+dvvc•Valfy,hr.wrraaauce Company &Senior Vice President of Wrrw,tpru t Nnsuranve Coirpora ioun IN WITNESS WHEREOF,North American Specialty Insurance Company,Washington International Insurance Company and Westport Insurance Corporation have caused their official seals to be hereunto affixed,and these presents to be signed by their authorized officers this this 5th day of.............. December 20 16 North American Specialty Insurance Company Washington International Insurance Company State of Illinois Westport Insurance Corporation County of Cook ss: On this 5th day of December ,201 before me,a Notary Public personally appeared Steven P.Anderson ,Senior Vice President of Washington International Insurance Company and Senior Vice President of North American Specialty Insurance Company and Senior Vice President of Westport Insurance Corporation and_Nilichael A. Ito Senior Vice President of Washington International Insurance Company and Senior Vice President of North American Specialty Insurance Company and Senior Vice President of Westport Insurance Corporation,personally known to me,who being by me duly sworn,acknowledged that they signed the above Power of Attorney as officers of and acknowledged said instrument to be the voluntary act and deed of err respective companies. OENOTAHYMPIUSLICSS10IN CK,IEASNLTANTY EE'A OL MV COM F IWNOIS M.Kenny,Notary Public I, Jeffrey Goldberg the duly elected Vice President and Assistant Secretary of North American Specialty Insurance Company,Washington ..............................................................__...._........ International Insurance Company and Westport Insurance Corporation do hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney given by said North American Specialty Insurance Company,Washington International Insurance Company and Westport Insurance Corporation which is still in full force and effect. IN WITNESS WHEREOF,I have set my hand and affixed the seals of the Companies this 17th day of.....................Aprtl .20 17 .leffirt'("6uirlduer;,>.Vice Prc"gilort& 1ecretary is Ydlr'Wslainvlgdufo darLe onbaduabaa(filiwiaoce C:mnpy;paoyr& Ploiib Arne nerun Speeiahy fnstuaaocrr t:aoarqutrr pr u.Vice t'reso,deta A..!.Io.rnt%iicnelmy of 11°e!lotrwl dnsuoenl,o cogr.rrotinu AgreNgie jjo. 5320 STATE OF CALIFORNIA DEPARTMENT OF INSURANCE SAN FRANCISCO Amended Certificate of Authority THIS IS TO CERTIFY,That,pursuant to the Insurance Code of the State of California, North American Specialty Insurance Company of Manchester, New Hampshire, organized under the laws of New Hampshire, subject to its Articles of Incorporation or other fundamental organizational documents, is hereby authorized to transact within this State,subject to all provisions of this Certificate, the following classes of insurance: Fire,Marine,Surety,Disability,Plate Glass,Liability,Workers'Compensation, Boiler and Machinery,Burglary,Sprinkler,Automobile,and Aircraft as such classes are now or may hereafter be defined in the Insurance Laws of the State of California. THIS CERTIFICATE is expressly conditioned upon the holder hereof now and hereafter being in full compliance with all, and not in violation of any,of the applicable laws and lawful requirements made under authority of the laws of the State of California as long as such laws or requirements are in effect and applicable,and as such laws and requirements now are, or may hereafter be changed or amended. IN WITNESS WHEREOF,effective as of the 23rd day of December, 1996, I have hereunto set my hand and caused my official seal to be affixed this 23rd day of December, 1996. Fee $92.00 Chuck Quackenbush Insurance Commissioner Rec.No. Filed 10/8/96 By Victoria S.Sidbury Deputy Certification I, the undersigned Insurance Commissioner of the State of California, do hereby certify that I have compared the above copy of Certificate ofAuthority with the duplicate of original now on file in my office,and that the same is a full, true, and correct transcript thereof, and of the whole of said duplicate, and said Certificate of Authority is now in full force and effect. IN WITNESS WHEREOF,I have hereunto set my hand and caused my official seal to be affixed this 26th day of June,2008. Steve Poizner Insurance Commissioner By P" ,k I 'A w6i, Pauline D'Andrea Agreement No. 5320 HUGH NGUYEN PROPERTY RECORDS BIRTH AND DEATH RECORDS CLERK-RECORDER MARRIAGE LICENSES/RECORDS PASSPORTS FICTITIOUS BUSINESS NAMES NOTARY REGISTRATION ORANGE COUNTY ARCHIVES Cl R"1'lFICAT E OF ADM[,.1.""E'D SURETY l S1JRI`lZ Certificate pursuant to 995.640(a)Code of Civil Procedure State of California County of Orange I, Hugh Nguyen, County Clerk-Recorder of the County of Orange, State of California, in and for said County, DO HEREBY CERTIFY THAT North American Stweialty Instirmice "oinnativ has been issued a Certificate of Authority as an Admitted Surety Insurer by the State of California Insurance Commissioner who authorized the Insurer to transact Surety Insurance in the State of California and that based on the records in this office, that authority has not been surrendered, revoked, cancelled, annulled or suspended. In Testimony Whereof, I execute this certificate and have hereunto set my hand and affixed the seal of said County this 17th day of April, 2017. Hugh gn( c „ Orange County Clerk-Recorder (Purple Seal) ca Laura Martinez Deputy Clerk-Recorder .. NORTH COUNTY BRANCH OFFICE ORANGE COUNTY SOUTH COUNTY BRANCH OFFICE HISTORIC DOWNTOWN FULLERTON HALL OF RECORDS LAGUNA HILLS CIVIC CENTER 201 N. HARBOR BOULEVARD 12 CIVIC CENTER PLAZA, ROOM 101 24031 EL TORO ROAD FULLERTON, CALIFORNIA 92832 SANTA ANA, CALIFORNIA 92701 LAGUNA HILLS, CALIFORNIA 92653 (714) 834.2500 ♦ FAX (714) 834-2675 • WWW.00 RECORD ER.COM ♦ WWW.00ARCHIVES.COM Agreem .T5t20 City of El Segundo ®n-Call Water Systems Maintenance and Repair Services, Project Igo. PW 17-01 Company Name: Stephen Do reek Equipment Rentals Inc. Address: 9075 Telegraph Road .................... City/State/Zip: ico Rivera, CA 90660 Designated Contact: Pablo Viramontes ....................._ Email: steve @doreckconstruction.com Phone#: 562) 949-4949 Cell Phone#: 909) 770-2169 Provide rates for all labor classifications applicable to the quoted service. Item descriptions encompass the scope of services described in the City solicitation letter dated May 11, 2016, and any subsequent additional information issued by the City for this request. Provide rates for weekday after-hours, weekend and holiday work.* Compensation at the hourly rate will begin when work commences. If an Item number does not apply, please enter "Not Applicable" on the hourly rate line for that item. Please use the following format. Additional blank rows/lines have been added to the end of the table for your use if needed. 1. Labor REGULAR OVERTIME OVERTIME OVERTIME ITEM WEEKDAY WEEKEND HOLIDAY NO. CLASSIFICATION HOURLY HOURLY HOURLY HOURLY RATE RATE RATE* RATE 1 Superintendent 87.57 117.21 146.84 206.12 2 Foreman 94.73 127.68 160.63 226.52 3 Pipefitter/Pipelayer 76.26 100.69 125.11 173.95 4 Laborer 71 .74 94.07 116.41 161 .07 5 Truck Driver 70.58 92.37 114.16 157.75 6 Welder 121 .00 143.00 198.00 253.001 III, i„ V �,,, tl+ SIN '` G .ark m 7 Minimum Hours if an �� 8 9 _:nj 350 Main Sheet, El Segundo, CA 90245-3813 (310)524-2300 Agreement No. 5320 REGULAR OVERTIME OVERTIME OVERTIME ITEM HOURLY WEEKDAY WEEKEND HOLIDAY NO. CLASSIFICATION RATE HOURLY HOURLY HOURLY RATE RATE* RATE 10 Describe Discount Payment Terms if Applicable(e.g. discount on materials purchased from bidder, etc.): ..............;3-0-.................- .......... .....................-..................................................... Notes: If Saturday and Sunday overtime hourly rates differ, please note the hourly rates on a separate sheet for applicable Items. Basis for establishing cost for tools and equipment rental rates will not exceed those listed for the same or similar equipment in the California State Department of Transportation publication of Labor Surcharge and Equipment Rates effective for the period of usage. 350 Main Street, El Segundo, CA 90245-3813 (310)524-2300 Agreement No. 5320 Example Water Main Project ........... ITEM UNIT NO. DESCRIPTION UNIT QTY PRICE IN AMOUNT FIGURES .................................... ............. Construct 8-inch D.J.P. (Class 52) Water Main including all fittings and appurtenances,traffic control, public safety and convenience, utility I potholing,trench excavation,pipe LF 1 100 163.00 $16,300.00 bedding, trench backfill,trench resurfacing, and temporary and permanent traffic stripping and markings. Construct Fire Hydrant connection complete including hydrant lateral, all fittings and appurtenances, hydrant, 2 gate valve,trench backfill, trench EA 1 $ 13,95000 $ 13,950.00 resurfacing, traffic control,public safety and convenience, and temporary and permanent traffic striping and markings. Construct 1-inch Water Service Connection, remove existing meter, install new meter, and connect to existing customer service including, all fittings and appurtenances,traffic 3 control,public safety and convenience, EA 2 $4,675.00 $9,350.00 utility potholing,trench excavation, I pipe bedding,trench backfill, trench resurfacing,and temporary and permanent traffic striping and markings, repair existing landscape/hardscape/ concrete in kind. 4 Pressure testing, chlorination, and LS 1 $2,500.00 $2,500.00 disinfection of 100 LF of pipeline. Total Bid (Item 1 through 4) $42,100.00 350 Main Street, El Segundo, CA 90245-3813 (310)524-2300 Agreement No. 5320 DESIGNATION OF SUBCONTRACTORS ON-CALL WATER SYSTEMS MAINTENANCE AND REPAIR SERVICES PROJECT NO.: PW 17-01 Company Name: Stephen Doreck Equipment Rentals, Inc. BIDDER will perform the majority of the work and proposes to subcontract certain portions of the work which are in excess of one-half of one percent (1/2 of I%)of the bid and to procure materials and equipment from suppliers and vendors as follows: Name of Sub- Description of Subcontractor contractor portion of License Work Estimated Number Address Subcontracted $Amount o ....� __.�...... .......... _............................� _............-...._...-....... ��... i _... .........................-..... .w..w................w.................. 350 Main Street, E!Segundo, CA 90295-3813 (310)529-2300 Agreement No. 5320 REFERENCES Company Name: Stephen Doreck Equipment Rentals, Inc. The following are the names, addresses, and telephone numbers for public agencies for which BIDDER has performed similar work as the prime contractor or major subcontractor within the past five (5)years: 1. Project Title: WEST SIDE WATER— SEWER REPLACEMENT Location: MADISON — OHIO CITY OF SOUTH GATE 8650 CALIFORNIA AVE. SOUTH GATE, CA 90280 Name and address of owner KEN TANG 805) 653-6597 Name and current telephone number of person familiar with project Type of Work: Wzt-�P_r Mqt irk Contract amount: $$4,467,897.62 Date completed: 2/2013 Amount of work done by my/our firm under contract$��y��, �- Did your firm have any financial interest in Project?--je S 2. Project Title: DUCTILE IRON PIPE Location: WESTERN AVE. - ROLLING HILLS RD CITY OF TORRANCE 20500 MADRONA AVE. TORRANCE, CA 90503 Name and address of owner EMMANUEL MARTIN 310) 618-3059 Name and current telephone number of person familiar with project Type of Work: hzt'k , Contract amount: $$1,574,419.11 Date completed: 12/2012 Amount of work done by my/our firm under contract$ Did your firm have any financial interest in Project? ' 3. Project Title: SMALL MAIN REPLACEMENT PROJECT PHASE 1 350 Main Street, El Segundo, CA 90295-3813 (310)524-2300 Agreement No. 5320 Location: GARFIELD AVE. & MINNESOTA CITY OF PARAMOUNT 16400 COLORADO PARAMOUNT, CA 90723 Name and address of owner CHRISTOPHER S. CASH 562) 220-2000 Name and current telephone number of person familiar with project Type of Work: \�Zkll_r Contract amount: $$1,196,462.76 Date completed: 11/2013 Amount of work done by my/our firm under contract$ 116l b L1 b 2 Did your firm have any financial interest in Project? ` e-5 4. Project Title: CAST IRON MAIN REPLACEMENT Location: ATLANTIC AVE. LONG BEACH WATER DEPARTMENT 1800 E.WARDLOW ROAD LONG BEACH, CA 90807 Name and address of owner AB RENDON 562)570-2341 Name and current telephone number of person familiar with project: Type of Work: wj'Ae"r �k&x r Contract amount: $$ 3,161,479.20 Date completed: 09/2014 Amount of work done by my/our firm under contract$ Did your firm have any financial interest in Project? ykl5 5. Project Title: WATER MAIN REPLACEMENT Location: ESHELMAN AVE. — PCH TO LOMITA CITY OF LOMITA 24300 NARBONNE AVE. LOMITA, CA 90717 Name and address of owner TOM SHABAZI 310) 325-7110 Name and current telephone number of person familiar with project: Type of Work: wtAtz�- MA77A I'\ Contract amount: $$1,699,398.00 Date completed: 3/2014 350 Main Street, El Segundo, CA 90245-3813 (310)524-2300 Agreement No. 5320 Amount of work done by my/our firm under contract a � Did your firm have any financial interest in Project? d ' Bidder may attach additional reference pages if necessary. The following are the names, addresses, and telephone numbers for all brokers and sureties from whom BIDDER intends to procure insurance bonds: Commercial Surety Bond Agency 1411 N. Batavia St., Suite 201 Orange, CA 92867 714) 516-1232 714) 516-9563 Fax 350 Main Street, El Segundo, CA 90245-3813 (310)524-2300 Agreement No. 5320 INSURANCE REQUIREMENTS [MUST BE SUBMITTED WITH PROJECT PROPOSAL] ON-CALL WATER SYSTEMS MAINTENANCE AND REPAIR SERVICES PROJECT NO.: PW 17-01 Company Name: Stephen Doreck Equipment Rentals, Inc. To be awarded this contract, the successful bidder must procure and maintain the following types of insurance with coverage limits complying,at a minimum,with the limits set forth below: Type of Insurance Limits Commercial general liability: $2,000,000 Business automobile liability: $1,000,000 Workers compensation: Statutory requirement Commercial general liability insurance must meet or exceed the requirements of ISO-CGL Form No. CG 00 01 11 85 or 88. The amount of insurance set forth above must be a combined single limit per occurrence for bodily injury, personal injury, and property damage for the policy coverage. Liability policies must be endorsed to name the City, its officials,and employees as"additional insureds"under said insurance coverage and to state that such insurance will be deemed"primary" such that any other insurance that may be carried by the City will be excess thereto. Such endorsement must be reflected on ISO Form No. CG 20 10 11 85 or 88, or equivalent. Such insurance must be on an "occurrence," not a"claims made," basis and will not be cancelable or subject to reduction except upon thirty (30) days prior written notice to the City. Insurer will agree in writing to waive all rights of subrogation against the City, its officers, officials, employees and volunteers for losses arising from work performed by Contractor for the City. Automobile coverage must be written on ISO Business Auto Coverage Form CA 00 01 06 92, including symbol 1 (Any Auto). The Consultant must furnish to the City duly authenticated Certificates of Insurance evidencing maintenance of the insurance required under this Agreement, endorsements as required herein, and such other evidence of insurance or copies of policies as may be reasonably required by the City from time to time. Insurance must be placed with admitted insurers with a current A.M. Best Company Rating equivalent to at least a Rating of"A:VII." Certificate(s) must reflect that the insurer will provide thirty (30)day notice of any cancellation of coverage. The Consultant will require its insurer to modify such certificates to delete any exculpatory wording stating that failure of the insurer to mail written notice of cancellation imposes no obligation,and to delete the word"endeavor"with regard to any notice provisions. The City requires California Worker's Compensation Coverage with the associated Waiver. Out-of- state coverage will not be accepted in lieu of the California coverage, because the work is being performed in the State of California. By signing this form, the bidder certifies that it has read, understands, and will comply with these insurance requirements if it is selected as the City's consultant. Failure to provide this insurance will render the bidder's proposal"nonresponsive." Date w Bidder's Sinature Pablo Viramontes/Vice President 350 Maur Street, El Segundo, CA 90245-3813 (310)524-2300 Agreement No. 5320 CALIFORNIA ALL-PURPOSE ACKNOIRILEDGMEN7 '1,�7,U State of California 0 County of Los Angoles On 03/28/2017 before me, Sylvia Sifuentes(Not ry Public} ............... personally appeared ........... Pablo Viramontes xu who proved to me on the basis of satisfactory lM evidence to be the person(j) whose name(j) is/AW subscribed to the within instrument and acknowledged to me that he/*H/0# executed the same in SYLVIA SIFUENTES hisAI&I'Affil authorized capacity(M), and that by . Commission#2081164 Notary Public.-California " Z2 his/Vfir/tV#t signature(,J) on the instrument the rW z Los Angeles County " person(t), or the entity upon behalf of which the My Comm.Expires Oct 8, 20181 person(A) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing 1 paragraph is true and correct. WITNESS my hand and official seal. Q: < OPTIONAL Signatur Though the information below is not required by law,it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s)Other Than Named Above: ........ Capacity(ies) Claimed by Signer(s) Signer's Name: Signer's Name: Corporate Officer—Title(s): Corporate Officer Title(s): ......... Individual -_Individual J Partner—:J1 Limited ---.General Top t viurnib hare 7j Partner—---;Limited -i General Top of lnurnb nere Attorney in Fact Attorney in Fact Trustee Trustee D Guardian or Conservator El Guardian or Conservator Other. ❑Other: Signer Is Representing: Signer Is Representing: s 2C,09 Naiona,Notary AS aaaizw-uatianawoiary erg-I-8(30-US NOTARY(7-8C0-a76-6827) "em-SE07 Agreement No. 5320 SCOPE OF SERVICES 1-0. WATER SYSTEMS MAINTENANCE AND REPAIR SCOPE OF SERVICES: The services requested would be similar to the water system maintenance and repair services provided by the contractor in the normal course of business. All work performed under this contract shall be for water facilities owned and operated by the City of El Segundo. The Contractor must respond to emergency sites within 45 minutes. 1-1. The Services are to be provided on an "as needed and when requested" basis and include, but not be limited to,the following City needs: a. Repairs of water main lines, service laterals, fire hydrants, water valves, water meters, air valves, blow-offs, pumps, etc. b. Potholing of existing utilities c. Trenching and subgrade preparations d. Water meter box and valve cover adjustments e. Surface restoration f. Disposal of removals g. Traffic Control h. NPDES Compliance i. Dewatering of excavations j. Temporary by-pass services k. Water Quality testing and disinfection 1. Fire hydrant flushing m. Site remediation and cleaning n. Welding o. Estimating and providing written quotes regarding repairs or installations to the Project Manager 1-2. The above is not intended as an exhaustive list. The scope of work will be determined on an as requested basis. It is expected that the successful contractor will be able to make good repairs any portion of the City facilities' water systems on an emergency basis. 1-3. The service company's principal business shall be the installation; repair, service, inspection and testing of water systems. 1-4. The service company shall own and operate a fully licensed independent or fully licensed franchised company, and shall be fully experienced to service, repair, inspect and test all of the water systems installed in the City. 350 Main Street, El Segundo, CA 90245-3813 (310)524-2300 ARMANDO ORTIZ Agreement No. 5320 9075 Telegraph Road Pico Rivera, CA 90660 (562) 949-4949 SUMMARY OF QUALIFICATIONS • Over 30 years of construction experience in multiple phases of underground utilities • Proven ability to focus on project budgets while meeting customer needs • Skilled in all aspects of both wet and dry utility installation • Excellent analytical, research, problem-solving, and technical skills • Supervise field employees ranging from crew sizes of 4 to as many as 35 • Certified In OSHA 30,First Aid, Competent Person Training, Confined Space PROFESSIONAL EXPERIENCE STEPHEN DORECK EQUIP. RENTALS, INC. Pico Rivera, CA Project Superintendent 03/07 to Present • Completed a project for the City of South Gate, which consisted of installing,testing and re- connecting approximately 21,000 L.F. of 8"DIP. It also included 84 fire hydrants, 556 water services ranging from 1"to 2", and complete trench restoration. • Completed a project for the City of Alhambra, which consisted of installing, testing and re- connecting approximately 4,040 L.F. of 12"DIP. It also included 9 fire hydrants, 52 water services ranging from 1"to 2" and trench restoration. Also supervised paving subcontractor with street rehabilitation which consisted of approx. 297,900 S.F. of 1.5"to 2.0" grind and overlay. • Completed a project for the City of Torrance, which consisted of installing, testing and re- connecting approximately 5,100 L.F. of 12"DIP. It also included 8 fire hydrants, bore and jack 117 L.F. of 20" steel casing under an active oil bank, 12 water services ranging from 1" to 2"and trench restoration. Also supervised paving subcontractor on street rehabilitation which consisted of approx. 6,556 S.Y. of 2" grind and overlay. • Additional project references are available upon request. ROBERT CASTONGIA CONSTRUCTION Downey, CA Project Foreman 06/04 to 02/07 • Supervised work crews to ensure that projects assigned were completed on time and under budget. Completed projects for various agencies, such as City of Downey, City of Torrance, City of Garden Grove and West Basin Municipal Water District. • Additional project references are available upon request. VALVERDE CONSTRUCTION,INC. Santa Fe Springs, CA Project Foreman 03192 to 05/04 • Supervised work crews to ensure that projects assigned were completed on time and under budget. Completed projects for various agencies, such as City of Downey, City of Pico Rivera, City of South Gate and Suburban Water Company. • Additional project references are available upon request. MACCO CONSTRUCTION Los Angeles, CA Project Leadman 10/86 to 02/92 • Assisted with supervising work crews to ensure that projects assigned were completed on time and under budget. Completed projects for various agencies, such as GTE, Pacific Bell, Sprint and GTE Single Source Provider. • Additional project references are available upon request. JOHN DANESKY Agreement No. 5320 9075 Telegraph Road Pico Rivera, CA 90660 (562)949-4949 SUMMARY OF QUALIFICATIONS Over 30 years of construction experience in multiple phases of underground utilities o Proven ability to focus on project budgets while meeting customer needs Skilled in all aspects of both wet and dry utility installation * Excellent analytical,research,problem-solving, and technical skills Supervise field employees ranging from crew sizes of 4 to as many as 35 Certified In OSHA 30,First Aid, Competent Person Training, Confined Space PROFESSIONAL EXPERIENCE ......................._........................................ ...._ .. .. _ ... STEPHEN DORECK EQUIP. RENTALS,INC. Pico Rivera,CA Project Superintendent 03/07 to Present • Completed a project for the City of South Gate, which consisted of installing, testing and re- connecting approximately 21,000 L.F. of 8"DIP. It also included 84 fire hydrants, 556 water services ranging from I"to 2", and complete trench restoration. • Completed a project for the City of Alhambra, which consisted of installing,testing and re- connecting approximately 4,040 L.F. of 12"DIP. It also included 9 fire hydrants, 52 water services ranging from 1"to 2"and trench restoration. Also supervised paving subcontractor with street rehabilitation which consisted of approx. 297,900 S.F. of 1.5"to 2.0" grind and overlay. • Completed a project for the City of Torrance, which consisted of installing, testing and re- connecting approximately 5,100 L.F. of 12"DIP. It also included 8 fire hydrants, bore and jack 117 L.F. of 20" steel casing under an active oil bank, 12 water services ranging from 1" to 2"and trench restoration. Also supervised paving subcontractor on street rehabilitation which consisted of approx. 6,556 S.Y. of 2"grind and overlay. • Additional project references are available upon request. ROBERT CASTONGIA CONSTRUCTION Downey, CA Project Foreman 06/04 to 02/07 • Supervised work crews to ensure that projects assigned were completed on time and under budget. Completed projects for various agencies, such as City of Downey, City of Torrance, City of Garden Grove and West Basin Municipal Water District. • Additional project references are available upon request. VALVERDE CONSTRUCTION, INC. Santa Fe Springs, CA Project Foreman 03/92 to 05/04 • Supervised work crews to ensure that projects assigned were completed on time and under budget. Completed projects for various agencies, such as City of Downey, City of Pico Rivera, City of South Gate and Suburban Water Company. • Additional project references are available upon request. MACCO CONSTRUCTION Los Angeles,CA Project Leadman 10/86 to 02192 a Assisted with supervising work crews to ensure that projects assigned were completed on ul under budget. Completed is 1_various GITI Dom..:-r.. T2o11 tllile arl u11UG1 vU geL. t,V111p1GlGU projects 1V1 Vcu`lo 1.iJ agencies, such a$ V iL, L U..111.."%'11, Sprint and GTE Single Source Provider. 0 Additional project references are available upon request. RICK HERNANDEZ Agreement No. 5320 9075 Telegraph Road Pico Rivera, CA 90660 (562) 949-4949 SUMMARY OF QUALIFICATIONS • Over 30 years of construction experience in multiple phases of underground utilities • Proven ability to focus on project budgets while meeting customer needs • Skilled in all aspects of both wet and dry utility installation * Excellent analytical,research,problem-solving, and technical skills • Certified In OSHA 30, First Aid, Competent Person Training, Confined Space PROFESSIONAL EXPERIENCE STEPHEN DORECK EQUIPMENT RENTALS,INC. Pico Rivera, CA Project Manager 08/2013 to Present • Responsible for managing various construction projects simultaneously to ensure production and completed on time. Performed work Long Beach Water Department, which consisted of replacing 54" and 36" valves utilizing line stops. Supervised the installation of 3,100 lineal feet of 36" CML & C for Three Valleys Municipal Water District. It also included open cutting the trench, backfilling and compacting, pressure testing, chlorination and bacteria sampling, and complete trench restoration. • Additional project references are available upon request SPINELLO CONSTRUCTION,INC. Pomona, CA Project Manager 01/00 to 07/2013 • From 02/2011 to 07/2013 completed a long term project for the City of Arlington,VA,which consisted of installing a 36"water main. It also included open cutting the trench, backfilling and compacting,pressure testing, chlorination and bacteria sampling, and complete trench restoration.Responsible for all RFI's, change orders and all extra work associated with project. • From 06/2009 to 01/2011 completed a long term project for the City of Compton, CA,which consisted of installing various sizes of water mains ranging from 6"to 12". It also included open cutting the trench, backfilling and compacting,pressure testing, chlorination and bacteria sampling, and completed trench restoration. Worked with KEC Engineering,who was a 3`d party consultant for City of Compton, in completing the project on time and under budget. Responsible for all RFI's, change orders and all extra work associated with project. • From 03/2007 to 05/2009 completed a long term project for the Denver Water Company located in Denver, CO., which consisted of installing various sizes of water mains ranging from 6"to 24". It also included open cutting the trench, backfilling and compacting;pressure testing, chlorination and bacteria sampling, and complete trench restoration. Responsible for all RFI's, change orders and all extra work associated with project. • From 04/2004 to 02/2007 completed a long term project for the City of Pomona, which consisted of installing various sizes of water mains ranging from 6"to 24". It also included open cutting the trench, backfilling and compacting, pressure testing, chlorination and bacteria sampling, and complete trench restoration. Worked with RBI Consulting,who was a 3`d party consultant for the City of Pomona, CA, in completing the project on time and under budget. Responsible for all BFI's, change orders and all extra work associated with project. • Additional project references are available upon request. Agreement No. 5320 VALVERDE CONSTRUCTION,INC. Santa Fe Springs, CA Project Manager/Estimator 06/91 to 03/04 • Scheduled work crews to ensure completion on time and under budget for various customers such as GTE, Pacific Bell and Sprint. Was primarily responsible for dry utility division. • Estimated projects for various customers. Contributed to a 15% growth in the dry utility division from year to year. • Additional project references are available upon request. Agreement No. 5320 STEPHEN DORECK EQUIPMENT RENTALS, INC. GENERAL ENGINEERING CONTRACTOR License No.A665471 9075 Telegraph Road Pico Rivera,CA 90660 T 562.949.4949 F 562.261.5038 On-Call Service References City of Lomita 24300 Narbonne Avenue Contact:Tom Shahbazi Lomita,CA 90717 (310)325-7110 Long Beach Water Department 1800 E.Warlow Road Contract: Ab Rendon Long Beach,CA"90807 (562) 570-2340 City of Pico Rivera 6615 Passons. Blvd. Contact: Ana Ananda Pico River, CA 90660 (562) 801-4220 City of Torrance 20500 Madrona Avenue Contact: Allen Berndt Torrance,CA 90503 (310) 618-3069 City of Paramount 15300 Downey Avenue Contact: Norm Mamea Paramount, CA 90723 (562)220-2085 Agreement No. 5320 STEPHEN DORECK EQUIPMENT RENTALS, INC. GENERAL ENGINEERING CONTRACTOR License No.A665471 9075 Telegraph Road Pico Rivera,CA 90660 T 562.949.4949 F 562.261.5038 March 28,2017 City of El Segundo 350 Main Street El Segundo,CA 90245 Re: On Call Water System Maintenance and Repair Service, Project No. PW 17-01 Emergency Call Out Procedures: A listing of on-call personnel is given to customer to use at time of emergency. We are on a 24/7 call out system. Once the initial call is initiated,we will mobilize within the required time to assess the situation and repair the damage. The primary contact will be our Superintendent, Rick Hernandez. Repair Service Methodoloev: We take pride in providing our customer with a quick response in order to meet their demands. We have various personnel with extended years of experience to deal with all types of emergencies that may come up. One some occasions,there might be need to bring in a specialty subcontractor,ie.Welder, and which they might not be readily available. In this instance we would secure the jobsite and provide the customer with a temporary solution to the emergency. We will then schedule with both the customer and the specialty subcontract the time for the permanent repair to be completed. If you should have any questions regarding this please feel free to contact me at 562-949-4949. Thank You Pablo Viramontes AgreernE' W6. D'-32V"' ................. N n 10 al 10 10 V4 Ld li Ld(D 0 0 cm LO CY 0 M uJ M. to U. g' z LLJ �'-I 0 15; 1. .3-0 2 CL LLI 0' t4 22 S -ju 0 0 .... y 0..i 4A.1.,....,'.�. ~ I ........... ZZ: Ul LU 0 LL. 0 U U., U u 0 u u u u 3 . 7- u 9 IL , 0 t 0 U 0 LD 0 u 0 u 0' z L) 0 L) L) 0 z u LU 0 Q v E� �.....,.,0,....,., N N N N.,..N N N,....N.. .N.,...,fJ... eV N I O I..,...N,.,.,.�N N N N N......,.,.�-tea....,...,... r 1 � _..—G, c, 'r, Agreement No. 5320 iA o ;:n c5 Lri c; m Ln Ln t� -4-� •I- (� m -4- to m z co b m 'D m rq q LQ to cq L'i o�l :S c5 as 6 d (3� F- o co oo m 'n m 'D Z '2 N N co M l i y I I I I II Lu z O z 0 C4 D U) cy M LU 0 <> wz w z m, -Ei O w o w 01 Ld KE U0 is L>u Og s -4 a. i 0 Lu -R u c4 uj > LLJ z O'l rz uj c4 uj w 01 0 F w w w Ol F 0 Z) 0 z > v. u. L� m, w Z IL Z Z Z Z i 0 LLI 0 Ol w w w w 0 0 0 0 01:1 0 0 0 0 0 OII a 0 0 u ............. M!z 0 mm cQ 9 9 9 9 9 "V T T 7- -A A 0 2 Z; a 5 1 s i- SDE EQUIPMENT RENTALS 20ement No. 5320 As of MARCH 2017 Item No. Backhoe's Hr/Rate Day/Rate Idle Rate/Hr BH310 John Deere 310 65.00 520.00 2600 BH410 John Deere 410 75.00 600.00 30.00 BH580 Case 580 Super M 60.00 480.00 24.00 BH140 Komatsu WD140 62.00 496.00 24.80 BHCWL Compaction Wheel 30.00 240.00 12.00 BHBRK 750 FT/LB Breaker 60.00 480.00 24.00 MANT BACKHOE- MAINTAIN 120.00 960.00 48 Job Trucks W/Tools JT050 1/2 Ton 12.50 100.00 5.00 JT075 3/4 Ton w/fuel tank 14.50 116.00 5.80 JT100 1 Ton w/tools 18.75 150.00 7.50 DTBOB Dump Truck-Bobtail 50.00 400.00 20.00 DT10W Dump Truck- 10 Wheel 95.00 760.00 38.00 AR5TN Asphalt Roller-5 Ton 40.00 320.00 16.00 AR3TN Asphalt Roller-3 Ton 19.00 152.00 7.60 Misc. Equipment WTI 80 Water Truck- 1800-2000 Gallon 50.00 400.00 20.00 AC175 Air Compressor- 175/185CFM W/Jhammer& Points 18.75 150.00 7.50 MEBTO Boring Tool 15.63 125.00 n/a METP2 Trash Pump/hoses-2" 8.13 65.00 3.25 MECOS Cut off saw 7.88 63.00 n/a Cut off saw blades 8.60 Each n/a FLATR Forklift-All Terrain 31.25 250.00 12.50 CMWAK Compactor-Hand (Wacker) 11.88 95.00 4.75 CMVPL Compactor-Vibra Plate 10.63 85.00 4.25 MEGN5 Generator-5KW 7.50 60.00 n/a MECGN Chipping Gun 4.75 38.00 n/a Point 6.00 n/a El Segundo-On Call Service Agreement 052516 1 of 2 SDE EQUIPMENT RENTALS reement No. 5320 As of MARCH 2017 MEHTM Hot Tap Machine- V-2" 18.75 150.00 7.50 MEWLD Welder-170 AMP 5.63 45.00 n/a Torch Set 85.00 n/a MEHTP Hydrostatic Test Pump 9.38 75.00 n/a MESTP Stomper-Arrow 125.00 50.00 Compaction plate 35.00 n/a DTMVT Move Trailer 12.50 n/a MESPM Submursible- Pump 36.00 Per Day n/a MESAW Concrete Saw 120.00 48.00 Traffic Plates 17.43 139.44 69.72 Water Wagon 7.50 60 18"Grinder Attachment 46.00 375 187.5 Traffic Control TCARW Arrowboard -Solar 12.50 100.00 5.00 TCSGN Signs w/stand-Large 3.50 ea n/a TCDEL Delineators 0.35 ea n/a TCLTW Light Tower 65.00 3.25 El Segundo-On Call Service Agreement 052516 2 of 2 Agreement No. 5320 EXHIBIT B SECTION II - GENE I�AI, 11:,o)4.111 EINIEC TS. CITY OF EL SEGUNDO PUBLIC WORKS DEPARTMENT GENERAL SPECIFICATIONS 1. REGISTRATIONw OF CONTRACTORS No bid will be accepted from a Contractor who has not been licensed in accordance with the provisions of the laws of the State of California relating to licensing of contractors,for the type of work to be performed under this Contract. 2. INSURANCE AND CITY BUSINESS LICENSE Contractor and Sub-Contractors will obtain appropriate insurance and a City Business License before execution of the construction contract. 3. EMERGENCY INFORMATION The names, addresses and telephone numbers of the CONTRACTOR and subcontractors, or their representatives, will be filed with the City Engineer and the City Police Department BEFORE PERFORMING WORK. 4. FURNISHING OF WATER Water necessary for the prosecution of the work as herein specified will be furnished by the City in the following manner: The CONTRACTOR will deposit with the City Water/Wastewater Division the sum of Three Hundred Dollars ($ 350.00) to insure against damage to a 2 '/z" Fire Hydrant water meter which will be furnished and installed by the City at a point convenient to the site of the work. This deposit will be refunded to the CONTRACTOR upon completion of the Project if, after removal and inspection of said meter by the City, it is found to be in satisfactory condition. In event of damage to this meter while under the jurisdiction of the CONTRACTOR, all or any part of said deposit may be retained by the City. An non-refundable Activation Fee of One Hundred Dollars ($100.00) will be charged upon activation of the temporary meter. 5. CALIFORNIA - OCCUPATIONAL SAF]"I 'Y &HEALTH ADMINISTRATION All work performed under this contract will be done in strict compliance with the Cal- OSHA Rules and Regulations, latest edition. II-A-1 Agreement No. 5320 EXHIBIT B 6. SOUND CONTROL The Contractor will comply with all local sound control and noise level rules, regulations and ordinances that apply to any work performed pursuant to the contract. Each internal combustion engine, used for any purpose on the Project or related to the Project, will be equipped with a muffler of a type recommended by the manufacturer. No internal combustion engine will be operated on the Project without said muffler. The use of loud signals will be avoided in favor of light warnings except those required by safety laws for the protection of personnel. 7. AIR POLLUTION CON`114,)I, The Contractor is put on notice that he must abide by all existing rules and regulations of the SCAQMD (South Coast Air Quality Management District), relating to all operations or equipment which discharge visible emissions or solid or liquid particles to the atmosphere. 8. WORKER UNIFORMS All workers under the employment of the Contractor or his/her Sub-Contractor will wear an orange vest or an orange shirt while working in the public right-of-way. II-A-2 Agreement No. 5320 EXHIBIT B CITY OF EL SEGUNDO PUBLIC WORKS DEPARTMENT GENERAL PROVISIONS 0-0 STANDARD SPECIFICATIONS 0-1 GENERAL Except as modified by these Standard Specifications,the provisions of the latest edition of the "Standard Specifications for Public Works Construction" ("Greenbook") and its supplements prepared and promulgated by the Southern California Chapters of the American Public Works Association and the Associated General Contractors of America, constitute the Standard Specifications for this project. 0-2 NUMBERING OF SECTIONS The numbering contained within the Standard Specifications of the Contract Documents is intended to correspond with Greebook numbering. 1-2 DEFINITIONS The following subsection is added to Subsection 1-2 of the Greenbook. 1-2.1 ADDITIONAL DEFINITIONS Acceptance—The date on which the City Council accepts the Work as complete. Architect,Design Engineers, Soils Engineer,Structural Engineers-Advisors employed by the City. City Council - The body constituting the awarding authority of the City. Compensable Delay--a delay entitling the Contractor to an adjustment of the Contract Sum and an adjustment of the Contract Time in accordance with this Agreement. Due Notice-A written notification,given in due time,of a proposed action where such notification is required by the contract to be given a specified interval of time (usually 48 hours or two working days) before the commencement of the contemplated action. Notification may be from Engineer to Contractor or from Contractor to Engineer. Engineer - The City Engineer, or designee, as defined in the Greenbook. Unless otherwise provided, all correspondence and decisions made relative to the contract will be by the City Engineer or his designated representative. Page 1 of 34 Agreement No. 5320 EXHIBIT B PCC—California Public Contract Code. Prompt - The briefest interval of time required for a considered reply, including time required for approval of a governing body. Public Works Director—The City's Public Works Director, or designee. ❑ (Check if applicable) State Standard Specifications - State of California Standard Specifications, dated July 1992, Business and Transportation Agency, Department of Transportation Working Days-A working day is defined as any day,except Saturdays, Sundays, legal holidays and days when work is suspended by the Engineer, as provided in Subsection 6-3 and days determined to be non-working in accordance with Subsection 6-7, "Time of Completion." 1-3 ABBREVIATIONS The following Subsection is added to Subsection 1-3 of the Greenbook. 1-3.1 The following abbreviations are added to Subsection 1-3 of the Greenbook: AAN American Association of Nurserymen AGC Associated General Contractors of America AISC American Institute of Steel Construction APWA American Public Works Association ASME American Society of Mechanical Engineers IEEE Institute of Electric and Electronic Engineers NEC National Electric Code Green Book The most current edition of the Standard Specification for Public Works Construction, and subsequent supplements prepared by Southern California Chapters of AGC and APWA WATCH Work Area Traffic Control Handbook SPPWC Standard Plans for Public Works Construction by the American Public Works Association current edition and subsequent supplements ASA American Standard Association CITY City of El Segundo 2-0 SCOPE AND CONTROL OF WORK The following subsections 2-1.1 and 2-1.2 are added to the Greenbook. 2-1.1 ACCESS TO PROJECT SITE Not later than the date designated in the current Contract Schedule submitted by the Contractor, the City will provide access to the real property and facilities upon which Page 2 of 34 Agreement No. 5320 EXHIBIT B the Work is to be performed, including access to real property and facilities designated in the Contract Documents for the Contractor's use. 2-1.2 OWNERSHIP AND USE OF CONTRACT DOCUMENTS. The Contract Documents and all copies furnished to or provided by the Contractor are the City's property and may not be used on other work. 2-3 SUBCONTRACTS Subsection 2-3 Subcontractors of Greenbook is deleted in its entirety and replaced with the following subsection. 2-3.1 GENERAL Except as provided in PCC §§ 4100 et. seq., each bidder will file with its bid the name and location of the place of business of each subcontractor who will perform work or labor or render service to the prime contractor in or about the construction of the work or improvement, or a subcontractor licensed by the State of California who, under subcontract to the prime contractor, specifically fabricates and installs a portion of the work or improvement according to detailed drawings contained in the plans and specifications, in an amount in excess of one-half of one percent of the prime contractor's total bid. Only one subcontractor will be listed for each portion of the work, which portion will be defined in the bid. In each instance, the nature and extent of the work to be sublet will be described. The failure of the Contractor to specify a subcontractor, or the listing of more than one subcontractor for the same portion of the work, constitutes an agreement by the Contractor that it is fully qualified to perform that portion itself and that it will perform that portion itself. The Contractor must have the City Council's written consent to substitute a subcontractor other than that designated in the original bid, to permit any subcontract to be assigned or transferred, or to allow a subcontract to be performed by other than the original subcontractor. Subcontracting of work for which no subcontractor was designated in the original bid, and which is more than one-half of one percent of the work, will be allowed only in cases of public emergency or necessity, and then only after a finding reduced to writing as a public record of the City Council setting forth the facts constituting the emergency or necessity. Violation of any of the above provisions will be considered a breach of the Contract, and the City may terminate the Contractor's control over the Work,cancel the contract, or assess the Contractor a penalty of not more than ten percent of the subcontract involved. All persons engaged in the work, including subcontractors and their employees will be Page 3 of 34 Agreement No. 5320 EXHIBIT B considered as employees of the Contractor. The Contractor will be solely responsible for and have control over construction means, methods, techniques, sequences, procedures,and the coordination of all portions of the Work.The City will deal directly with, and make all payments to, the prime Contractor. When subcontracted work is not being prosecuted in a satisfactory manner, the Contractor will be notified to take corrective action. The Engineer may report the facts to the City Council. If the City Council so orders, and on receipt by the Contractor of written instructions from the Engineer,the subcontractor will be removed immediately from the Work. That subcontractor will not again be employed on the Work. If licensure or proper licensure is controverted,then proof of licensure pursuant to this section must be made by production of a verified certificate of licensure from the Contractors' State License Board which establishes that the individual or entity bringing the action was duly licensed in the proper classification of contractors at all times during the performance of any act or contract covered by the action.Nothing in this subdivision requires any person or entity controverting licensure or proper licensure to produce a verified certificate. When licensure or proper licensure is controverted, the burden of proof to establish licensure or proper licensure is on the licensee. 2-3.2 ADDITIONAL RESPONSIBILITY Add the following to Subsection 2-3.2 Additional Responsibility: The Contractor will submit experience statements for each subcontractor who will perform contract work that amounts to more than ten percent(10%) of the Work. 2-4 CONTRACT BONDS The following paragraph is added to Subsection 2-4 of the Greenbook. The Faithful Performance Bond and the Labor and Materials Bond must be paid up and in effect for one year after the acceptance of the job by the City in accordance with the guarantee required by Subsection 6-8.1. 2-5 PLANS AND SPECIFICATIONS Subsection 2-5.1 of the Greenbook is replaced by the following subsection. 2-5.1 GENERAL The Contractor will maintain the following at the Work site: 1. One as-built copy of the Plans and Specifications, in good order and marked to record current changes and selections made during construction. As-built plans Page 4 of 34 Agreement No. 5320 EXHIBIT B are to be submitted to the City representative for approval prior to acceptance of the project as complete. 2. The current accepted Contract Schedule, 3. Shop Drawings, Product Data, and Samples. 4. Approved permits from other agencies, including Cal-OSHA permits for trench shoring. 5. All other required submittals. The Plans, Specifications, and other Contract Documents will govern the Work. The Contract Documents are intended to be complementary and cooperative and to describe and provide for a complete project. Anything in the Specifications and not on the Plans, or on the Plans and not in the Specifications, will be as though shown or mentioned in both. Payment for any items on the plans for which there are no specific bid item will be included in the various items of work or in any item to which it is appurtenant. If the Contractor performs any work which it knows or should know involves an error, inconsistency, or omission without notifying and obtaining written consent from the Engineer, the Contractor will be responsible for the resulting losses, including, without limitation,the costs of correcting defective work. 2-5.2 l lUX'I::"1DENCE OF CONTRACT 1r 0CtJMGV'1 'l'S The following paragraph is added to subsection 2-5.2 of the Greenbook: As the figured dimensions shown on the plans and in the specifications of the Contract may not in every case agree with scaled dimensions, the figured dimensions will be followed in preference to the scaled dimensions, and plans to a large scale will be followed in preference to the plans to a small scale. Should it appear that the work to be done,or any of the matters relative thereto,are not sufficiently detailed or explained in the Contract, the Contractor will apply to the Engineer for such further explanations as may be necessary, and will conform thereto as part of the Contract so far as may be consistent with the terms thereof. Any items shown on drawings and not mentioned in the specifications will be of like effect as if shown or mentioned in both. 2-5.5 ACCURACY OF PLANS AND SPECIFICATIONS Although it is believed that much of the information pertaining to conditions and existing utilities that may affect the cost of the Work will be shown on the Plans or indicated in the Specifications,the City does not warrant the completeness or accuracy Page 5 of 34 Agreement No. 5320 EXHIBIT B of such information. The Contractor will carefully study and compare each of the Contract Documents with the others and with information furnished by the City and will promptly report in writing to the Engineer any errors, inconsistencies, or omissions in the Contract Documents or inconsistencies with applicable law observed by the Contractor. The Contractor will take field measurements, verify field conditions, perform soil investigations, and carefully compare with the Contract Documents such field measurements, conditions, and other information known to the Contractor before commencing the Work. Errors, inconsistencies, or omissions discovered at any time will be promptly reported in writing to the Engineer. 2-8 RIGHT-OF-WAY The following subsection is added to Subsection 2-8 of the Greenbook. 2-8.1 ADDITIONAL WORK AREAS AND FACILITIES When the Contractor arranges for additional temporary work areas and facilities, the Contractor will provide the City with proof that the additional work areas or facilities have been left in a condition satisfactory to the owner(s)of said work areas or facilities before acceptance of the work. 2-9 SURVEYING Subsection 2-9.3, Survey Service, is deleted in its entirety and replaced by the following subsection: 2-9.3 SURVEY SERVICE 2-9.3.1 CONSTRUCTION SURVEYING The Contractor will provide for all construction surveying required to layout, monitor and complete the work. The surveying will be performed by a Land Surveyor or Civil Engineer authorized to practice land surveying by the State of California. The Project Benchmark is shown on the plans. The Contractor will establish all necessary control lines based on the plans and record information on file with the County of Los Angeles Surveyor and the Engineer. It is the responsibility of the Contractor to protect the survey control as shown on the plans.If the survey control is destroyed or disturbed during construction,the Contractor will provide for resetting them and file appropriate documents with the County of Los Angeles at the direction of the Engineer. Page 6 of 34 Agreement No. 5320 EXHIBIT B Computations, survey notes, and other data used to accomplish the work will be neat, legible and accurate. Copies of all computations, survey notes, and other data (electronic format may be required) will be furnished to the Engineer before beginning work that requires their use. 2-9.3.2 MEASUREMENT AND PAYMENT Construction Survey — Unless a separate bid item is provided, payment will be considered included in the other items of the bid and no additional payment will be made therefore. 3-3.2.2 BASIS FOR ESTABLISHING COSTS ES TAB................................... Subsection 3-3.2.2 (c), Tool and Equipment Rental is modified where the second and third paragraphs are replaced with "Regardless of ownership, the rates to be used in determining the equipment usage costs will not exceed those listed for the same or similar equipment in the California State Department of Transportation publication of Labor Surcharge and Equipment Rates effective for the period of usage." 3-3.2.3 MARK UP Subsection 3-3.2.3, Mark Up, is deleted in its entirety and replaced by the following subsection: (a) Work by Contractor. The following percentages will be added to the Contractor's costs and will constitute the markup for all overhead and profits. 1) Labor,,,,,,,,.,,......-.............-.........---20 2) Materials ............................................15 3) Equipment Rental...............................15 4) Other Items and Expenditures............15 To the sum of the costs and markups provided for in this subsection, 1 percent will be added as compensation for bonding.No other formula,e.g.,the Eichleay or other method, may be used to calculate daily damages for office overhead, profit, or other purported loss. (b) Work by Subcontractors. When all or any part of the extra work is performed by a Subcontractor, the markup established in 3-3.2.3(a)will be applied to the Subcontractor's actual cost of such work. A markup of 10 percent on the first $5,000 of the subcontracted portion of the extra work and a markup of 5 percent on work added in excess of$5,000 of the subcontracted portion of the extra work may be added by the Contractor. (c) In the event that City becomes liable to Contractor for compensable delays,City agrees to pay Contractor the daily Contractor Delay Damages set forth in the Page 7 of 34 Agreement No. 5320 EXHIBIT B Bid Form or Contractor's actual daily delay damages, whichever is less, for each day of Compensable Delay as provided for by these Contract Documents. 3-3.3 I)AI1 ,Y REPORTS BY CON"I'RA(,"l'Olt Add the following paragraph to subsection 3-3.3, Daily Reports by Contractor: If disagreement continues regarding extra work,the Contractor may seek compensation in accordance with the Claims procedure. Daily Reports required by this subsection must be made part of the Claim as supporting data for the Claim. 3-4 CHANGED CONDITIONS Subsection 3-4, Changed Conditions, is deleted in its entirety and replaced with the following subsection: If the Contractor encounters concealed or unknown conditions that differ materially from those anticipated or expected ("changed conditions"), the Contractor will immediately notify the Engineer in writing of such changed conditions(upon discovery and before disturbing such changed conditions),as provided in Subsection 6-11,so that the Engineer can determine if such conditions require design details that differ from those design details shown in the Contract Documents.Notwithstanding the thirty (30) day time period set forth in Subsection 6-11.3, the Contractor will be liable to the City for any extra costs incurred as a result of the Contractor's failure to promptly give such notice. Changed conditions will include, without limitation, the following: I. Subsurface or latent physical conditions differing materially from those represented in the Contract Documents; 2. Unknown physical conditions of an unusual nature differing materially from those ordinarily encountered and generally recognized as inherent in work of the character being performed; and 3. Material differing from what is represented in the Contract which the Contractor believes may be hazardous waste as defined in California Health& Safety Code § 25117 that is required to be removed to a Class I, II, or III disposal site in accordance with applicable law. The Engineer will promptly investigate conditions that appear to be changed conditions. The Engineer's decision, and any dispute regarding that decision, will be made in accordance with Section 6-11 except that the Engineer will render a decision promptly. Any information provided pursuant to INFORMATION AVAILABLE TO BIDDERS Page 8 of 34 Agreement No. 5320 EXHIBIT B is subject to the following provisions: 1. The information is made available for the Bidders' convenience and is not a part of the Contract. 2. The City has not determined the accuracy or completeness of such information and all such information is made available to Bidders without any representation or warranty by the City whatsoever as to its accuracy, completeness, or relevancy. 1 Bidders will independently evaluate such information for their use and will be solely responsible for use or interpretation of such information. Any such use or interpretation will not be the basis of any claim against the City. 3-5 DISPUTED WORK Subsection 3-5 is deleted in its entirety and replaced by the following subsection. If the Contractor and the City do not reach agreement on disputed work, the City may direct the Contractor to proceed with the work.Any payment for the disputed work will be determined pursuant to the claims procedures in these Standard Specifications. Although not to be construed as proceeding under extra work provisions,the Contractor will keep and furnish records of disputed work as required by the Contract Documents. 4-1.3 l SPI"(`.M."1(=N I�EQ „�11Z1 1 1Ia f`FS Subsection 4-1.3, Inspection Requirements, is deleted in its entirety and replaced by the following subsections. 4-1.3.1 GENERAL Unless otherwise specified, inspection at the source of production for such materials and fabricated items as bituminous paving mixtures, structural concrete, fabricated metal products, cast metal products, welding, reinforced and unreinforced concrete pipe, application of protective coatings, and similar shop and plant operations is not required. A certificate of compliance, signed by an authorized officer of the producer, certifying compliance with the contract documents will be submitted for all of the following materials: steel pipe, sizes less than 18 inches;vitrified clay pipe; asbestos cement pipe; cast iron pipe; reinforced concrete pipe; non-reinforced concrete pipe; and PVC sewer and water pipe; subject to sampling and testing by City. Standard items of equipment, such as electric motors, conveyors, plumbing fittings and fixtures, lumber, plywood, and so on, are subject to inspection at the job site. All other equipment items will be inspected and tested in accordance with the contract documents. Page 9 of 34 Agreement No. 5320 EXHIBIT B The City does not provide full time inspection. The Contractor will provide 24-hour minimum notice for each inspection required by the work unless other arrangements have been agreed upon, in writing, with the City Engineer. Any inspection required outside of normal working hours and days, including holidays,will be at the Contractor's cost at rates established by the City. 4-1.6 1",ADE NAMES OR FQtJALS Whenever any material, product, equipment, or service is specified by brand,trade, or proprietary name,the item so specified will be deemed to be followed by the words"or equal". For the City's consideration of a proposed "equal" item, the Bidder will submit, a minimum of ten (10) calendar days bef'ore the date of the bid opening, documentation of the particulars of the proposed "equal item". At a minimum, the submitted documentation will include: • Written request with explanation of why the product should be considered as an equal product. • Material specifications. • Technical specifications. • Test data. Samples. ■ Comparison chart of key specifications of the "equal" item against similar specifications of the specified item. ■ Work locations and reference telephone numbers of at least three (3) locations where the proposed "equal" item has been recently installed under similar conditions. b Warranty data. The Bidder will be notified by the Engineer whether or not the proposed "equal" product is acceptable to the City five (5) calendar days before the date of the bid opening. Failure to submit all required documentation and/or submittal of incomplete documents may result in the City's rejection of the proposed "equal" product without further consideration. 5-2 PROTECTION The following subsection is added to Subsection 5-2 of the Greenbook. 5-2.1 INCORRECT LOCATION OF UTILITIES If the Contractor, while performing the Work, discovers utility facilities not identified correctly or not shown in the contract plans or specifications by the City,the Contractor will immediately notify the City and utility owner in writing. Page 10 of 34 Agreement No. 5320 EXHIBIT B 5-4 RELOCATION The following subsection is added to Subsection 5-4 of the Greenbook, 5-4.1 RESPONSIBILITY OF UTILITY REMOVAL OR RELOCATION The City will be responsible to arrange for the removal,repair, or relocation of existing utilities located within the project limits if such utilities are not correctly identified in the contract plans or specifications by the City. The City will have the sole discretion to perform repairs or relocation work or permit the Contractor to do such repairs or relocation. 5-5 DELAYS The following paragraphs are added to Subsection 5-5 of the Greenbook. Actual loss, as used in this Subsection, will be understood to include no items of expense other than idle time of equipment and necessary payments for idle time of workers, cost of extra moving of equipment, and cost of longer hauls. Compensation for idle time of equipment and idle time of workers will be determined by Subsection 5-5.1 and no markup will be added in either case for overhead and profit. The cost of extra moving of equipment and the cost of longer hauls will be paid for as extra work. The following subsection is added to Subsection 5-5 of the Greenbook. 5-5.1 CALCULATING IDLE TIME Equipment idle time will calculated in accordance with Subsection 3-3.2.2 and based upon the actual normal working time during which the delay condition exists, but in no case will exceed 8 hours in any one day. The days for which compensation will be paid will be the calendar days, excluding Saturdays, Sundays and legal holidays, during the existence of the delay. Worker idle time will be calculated in accordance with Subsection 3-3.2.2. 6-1 CONSTRUCTION SCHEDULE AND COMMENCEMENT OF WORK Section 6-1, Construction Schedule and Commencement of Work, is deleted in its entirety and replaced by the following subsections. I re,-Coiisvuction Mcctinc�: After contract award, the City will arrange for a pre-construction meeting to discuss the construction of the project. City will invite utility agencies and the contractor will arrange for all of its sub-contractors to attend the meeting. Page 11 of 34 Agreement No. 5320 EXHIBIT B 6-1.1 CONTRACT SCHEDULE After notification of award and before starting any work, the Contractor will submit a Contract Schedule to the Engineer for review, as required by these Specifications within fifteen (15) days of award. 6-1.2 CONTENT OF CONTRACT SCHEDULE The Contract Schedule, and any updated Contract Schedule, will meet the following requirements: L Schedules must be suitable for monitoring progress of the Work. 2. Schedules must provide necessary data about the time for the Engineer's decisions. 1 Schedules must be sufficiently detailed to demonstrate adequate planning for the Work. 4. Schedules must represent a practical plan to complete the Work within the Contract Time. 5. Schedules must show the critical path method for completing the Work. The Engineer's review of the form and general content of the Contract Schedule and any updated Contract Schedules is only for the purpose of determining if the listed requirements are satisfied, nothing more. 6-1.3 I]l°FEC"TOT' CONTRACT SCHEDULE The Contract Schedule, and any updated Contract Schedules, will represent a practical plan to complete the Work within the Contract Time.Extension of any schedule beyond the Contract Time will not be acceptable. Schedules showing the Work completed in less than the Contract may be acceptable if judged by the Engineer to be practical. Acceptance of such a schedule by the Engineer will not change the Contract Time. The Contract Time, not the Contract Schedule, will control in determining liquidated damages payable by the Contractor and in determining any delay. If a schedule showing the Work completed in less than the Contract Time is accepted, the Contractor will not be entitled to extensions of the Contract Time for Excusable Delays or Compensable Delays or to adjustments of the Contract Sum for Compensable Delays until such delays extend the completion of the Work beyond the expiration of the Contract Time. The Contractor will plan, develop, supervise, control, and coordinate the performance of the Work so that its progress and the sequence and timing of Work activities conform to the current accepted Contract Schedule, The Contractor will continuously obtain from Subcontractors information and data about the planning for and progress of the Work and the delivery of equipment, will coordinate and integrate such information Page 12 of 34 Agreement No. 5320 EXHIBIT B and data into updated Contract Schedules, and will monitor the progress of the Work and the delivery of equipment. The Contractor will act as the expeditor of potential and actual delays, interruptions, hindrances, or disruptions for its own forces and those forces of Subcontractors. The Contractor will cooperate with the Engineer in developing the Contract Schedule and updated Contract Schedules. The Engineer's review and comments about any schedule or scheduling data will not relieve the Contractor from its sole responsibility to plan for, perform, and complete the Work within the Contract Time. Review and comments about any schedule will not transfer responsibility for any schedule to the Engineer or the City nor imply their agreement with(1)any assumption upon which such schedule is based or(2)any matter underlying or contained in such schedule. The Engineer's failure to discover errors or omissions in schedules that have been reviewed, or to inform the Contractor that the Contractor, Subcontractors, or others are behind schedule, or to direct or enforce procedures for complying with the Contract Schedule will not relieve the Contractor from its sole responsibility to perform and complete the Work within the Contract Time and will not be a cause for an adjustment of the Contract Time or the Contract Sum. The Contractor will perform the Work in accordance with the currently accepted Contract Schedule. 6-1.4 COMMENCEMENT OF CONTRACT TIME .......................................................................................................... The Contract Time will commence when the City issues a Notice to Proceed.The Work will start on the date specified in the Notice to Proceed and within a maximum of fifteen (15) days after the date of the Notice to Proceed, and be diligently prosecuted to completion with the time provided in the Specifications. 6-4 DEFAULT BY CONTRACTOR The language in subsection 6-4 is deleted in its entirety and replaced with the following subsections. 6-4.1 GENERAL Should the Contractor fail to begin delivery of material and equipment, to commence the Work within the time specified, to maintain the rate of delivery of material, to execute the Work in the manner and at such locations as specified, or fail to maintain the Work schedule (as determined by the current accepted Contract Schedule) which will ensure the City's interest, or if the Contractor is not carrying out the intent of the Contract, the City may serve written notice upon the Contractor and the Surety on its Faithful Performance Bond demanding satisfactory compliance with the Contract. Page 13 of 34 Agreement No. 5320 EXHIBIT B 6-4.2 TERMINATION OF CONTRACTOR'S CONTROL OVER THE WORK The City may terminate the Contractor's control over the Work without liability for damages when, in the City's opinion, the Contractor is not complying in good faith, has become insolvent, or has assigned or subcontracted any part of the Work without the City's consent. Should such termination occur,the Contractor will be paid the actual amount due based on Contract Unit Prices or lump sums bid and the quantity and quality of the work completed and in place at the time of termination, less damages caused to the City by the Contractor's action or inaction. In the event of such termination of control, the City may do any one, or combination of, the following: 1. Serve written notice upon the Surety on its Faithful Performance Bond demanding satisfactory compliance with the Contract. In such event the Surety will, within 5 days, assume control and perform the Work as successor to the Contractor; 2. The City may perform the Work itself and deduct the cost thereof from any payment due to the Contractor; 3. The City may replace the Contractor with a different contractor to complete the work and deduct the cost thereof from any payment due to the Contractor. Nothing herein will waive, or serve as a limitation upon, any additional remedy the City may have under these Contract Documents or applicable law. 6-4.3 SURETY'S ASSUMPTION OF CONTROL Should the Surety assume any part of the Work, it will take the Contractor's place in all respects for that part, and will be paid by the City for all work performed by it in accordance with the Contract. If the Surety assumes the entire Contract, all money due the Contractor at the time of its default will be payable to the Surety as the Work progresses, subject to the terms of the Contract. If the Surety does not assume control and perform the Work within 5 days after receiving notice of cancellation, or fails to continue to comply, the City may exclude the Surety from the premises. The City may then take possession of all material and equipment and complete the Work by City's forces, by letting the unfinished work to another contractor, or by a combination of such methods. In any event, the cost of completing the Work will be charged against the Contractor and its Surety and may be deducted from any money due or becoming due from the City. If the sums due under the Contract are insufficient for completion, the Contractor or Surety will pay to the City within 5 days of completion, all costs in excess of the sums due. The provisions of this subsection will be in addition to all other rights and remedies available to the City under applicable law. Page 14 of 34 Agreement No. 5320 EXHIBIT B 6-6 DELAYS AND EXTENSIONS OF TIME Subsections 6-6.1 to 6-6.4 are deleted and replaced with the following subsections. 6-6.1 GENERAL If delays are caused by unforeseen events beyond the control of the Contractor, such delays will entitle the Contractor to an extension of time as provided herein, but the Contractor will not be entitled to damages or additional payment due to such delays except as otherwise provided herein. Excusable delay may include: war, earthquakes exceeding 3.5 on the Richter Scale, government regulation, labor disputes outside the contemplation of the parties, strikes outside the contemplation of the parties, fires, floods, changes to the Work as identified herein, or other specific events that may be further described in the Specifications. Delays to the project caused by labor disputes or strikes involving trades not directly related to the project, or involving trades not affecting the project as a whole will not warrant an extension of time. The City will not grant an extension of time for a delay by the Contractor's inability to obtain materials unless the Contractor furnishes to the Engineer documentary proof. The proof must be provided in a timely manner in accordance with the sequence of the Contractor's operations and accepted construction schedule. Should delays be caused by events other than those included herein,the Engineer may, but is not required to, deem an extension of time to be in the City's best interests. 6-6.2 EXTENSIONS OF TIME If granted, extensions of time will be based upon the effect of delays to the critical path of the Work as determined by the current accepted Contract Schedule. Delays to minor portions of the Work that do not affect the critical path will not be eligible for extensions of time. 6-6.3 PAYMENT FORDELAYS TO CONTIZ.AC]"Old Any payment for compensable delay will be based upon actual costs as set forth in Subsection 5-5 excluding,without limitation,what damages,if any,the Contractor may have reasonably avoided. The Contractor understands that this is the sole basis for recovering delay damages and explicitly waives any right to calculate daily damages for office overhead, profit, or other purported loss, using different formulas including, without limitation, the Eichleay Formula. 6-6.4 WRITTEN NOTICE AND REPORT If the Contractor desires payment for a delay or an extension of time, it will give the Page 15 of 34 Agreement No. 5320 EXHIBIT B Engineer written notice of such request not later than the time limit set forth in the Proposal for submitting a claim after the event or occurrence giving rise to a delay claim. Failure to submit a written request within such amount of time will result in the Contractor waiving its delay claim. Any claim for payment or an extension of time must be in the form required by the "Claims" sections of these Specifications. In no event will the City grant the Contractor an extension of time if the delay is within the Contract Time as identified by the Contract Documents. 6-7.2 WI Ri< I)AYS AND WORKING IIOURS City Hall is open from Monday thru Thursday lam -6pm. It is closed every Friday and the following holidays: New Year's Day Martin Luther King, Jr. Day President's Day Memorial Day Independence Day Labor Day Veterans' Day Thanksgiving Christmas Eve Christmas New Year's Eve Working on Fridays when City Hall is closed is acceptable; however, if the Contractor requests an inspection a day when City Hall is closed,then the Contractor will have to reimburse the City for the costs of inspection. The Contractor must request such an inspection at least 48 hours in advance. City inspections during hours when City Hall is closed are subject to inspection overtime fees to be paid for by the Contractor.Friday work that does not require inspection can be done without an inspection fee and must be discussed with City staff prior to its occurrence. If the Contractor does construction on a Friday or a day when City Hall is closed, that day shall be counted as a project working day. On workdays, Contractor's activities will be confined to the hours between 7:00 a.m. and 4:00 p.m. Please see Section 6-7.5 below for weekend and holiday work restrictions. 6-7.4 NIGHT WORK The following paragraph is added to Section 6-7 of the Greenbook: Page 16 of 34 Agreement No. 5320 EXHIBIT B The City will not permit Work between the hours of 4 p.m. and 7 a.m. of the following day unless specifically provided for in the bid documents or unless the Contractor receives prior written approval. 6-7.5 WEEKEND AND HOLIDAY WORK The Engineer may, but is not required to, allow the Contractor to work on Saturdays, Sundays and City Holidays. 6-8 COMPLETION AND ACCEPTANCE Subsection 6-8 is deleted in its entirety and replaced by the following: The Work will be inspected by the Engineer for acceptance upon the Engineer receiving the Contractor's written assertion that the Work is complete. If, in the Engineer's judgment, the Work is complete and is ready for acceptance, the Engineer will accept the Work on behalf of the City in the manner prescribed by the City. The Engineer will recommend approval of the Notice of Completion to the City Council. This will be the date when the Contractor is relieved from responsibility to protect the Work. All work will be guaranteed by the Contractor against defective workmanship and materials furnished by the Contractor for a period of 1 year from the date the Work was completed. The Contractor will replace or repair any such defective work in a manner satisfactory to the Engineer,after notice to do so from the Engineer,and within the time specified in the notice. If the Contractor fails to make such replacement or repairs within the time specified in the notice, the City may perform this work and the Contractor's sureties will be liable for the cost thereof. 6-8.1 GENERAL GUARANTY The Contractor will remedy any defects in the work and pay for any damage to other work resulting therefrom, which will appear within a period of one year from the date of final acceptance of the work unless a longer period is specified.The owner will give notice of observed defects with reasonable promptness. 6-9 1,1O[JIDATIJ) DAMAGES Subsection 6-9, Liquidated Damages, of the Greenbook is deleted in its entirety and replaced by the following subsections. 6-9.1 FAILURE TO COMPLETE WORK ON TIME If all the work called for under the contract is not completed before or upon the Page 17 of 34 Agreement No. 5320 EXHIBIT B expiration of the Contract Time, the City will sustain damage. Since it is and will be impracticable to determine the actual damage which the City will sustain in the event of and by reason of such delay, it is therefore agreed that the Contractor will pay to the City the sum specified in the Proposal for each and every calendar day beyond the time prescribed to complete the work not as a penalty, but as a predetermined liquidated damage. The Contractor agrees to pay such liquidated damages as are herein provided, and in case the same are not paid, agrees that the City may deduct the amount thereof from any money due or that may become due to the Contractor under the contract. Unless otherwise specified, liquidated damages will be $250 per calendar day. 6-11 DISPUTES AND C l,AIMS„ 11R()C°I;MJRl` 6-11.1 GENERAL Consistent with PCC § 10240.6, "Claim" means a written demand or assertion by the Contractor that seeks an adjustment or interpretation of the terms of the Contract Documents, payment of money, extension of time, or other relief with respect to the Contract Documents, including a determination of disputes or matters in question between the City and the Contractor arising out of or related to the Contract Documents or the performance of the Work, and claims alleging an unforeseen condition or an act, error, or omission by the City, the Engineer, their agents or employees. "Claim" does not mean, and the Claims procedures herein do not apply,to the following: 1, Claims respecting penalties for forfeitures prescribed by statute or regulations, which a government agency is specifically authorized to administer, settle, or determine. 2. Claims respecting personal injury, death, reimbursement, or other compensation arising out of or resulting from liability for personal injury or death. 3. Claims respecting a latent defect, breach of warranty, or guarantee to repair. 4. Claims respecting stop notices. If a Claim is subject to the Change Order procedures,the Claim arises upon the issuance of a written final decision denying in whole or in part the Contractor's Change Order Request. If a Claim is not subject to the Change Order Procedures, the Claim arises when the Contractor discovers, or reasonably should discover, the condition or event giving rise to the Claim. 6-11.2 FORM A Claim must include the following: 1. A statement that it is a Claim and a request for a decision. 2. A detailed description of the act, error, omission, unforeseen condition, event Page 18 of 34 Agreement No. 5320 EXHIBIT B or other condition giving rise to the Claim. 3. If the Claim is subject to the Change Order procedures, a statement demonstrating that a Change Order Request was timely submitted and denied. 4. A detailed justification for any remedy or relief sought by the Claim, including to the extent applicable,the following: a) If the Claim involves extra work, a detailed cost breakdown claimed. The breakdown must be provided even if the costs claimed have not been incurred when the Claim is submitted. b) To the extent costs have been incurred when the Claim is submitted,the Claim must include actual cost records (including, without limitation, payroll records, material and rental invoices) demonstrating that costs claimed have actually been incurred. C) To the extent costs have not yet been incurred at the time the Claim is submitted, actual cost records must be submitted on a current basis not less than once a week during any periods costs are incurred. A cost record will be considered current if submitted within 7 days of the date the cost reflected in the record is incurred. At the Engineer's request, claimed extra costs may be subject to further verification procedures (such as having an inspector verify the performance of alleged extra work on a daily basis). 5. If the Claim involves an error or omission in the Contract Documents: a) An affirmative representation that the error or omission was not discovered before submitting a bid for the Contract; and b) A detailed statement demonstrating that the error or omission reasonably should not have been discovered by the Contractor, its Subcontractors and suppliers, before submitting a bid for the Contract. 6. If the Claim involves an extension of the Contract Time,written documentation demonstrating the Contractor's entitlement to a time extension. 7, If the Claim involves an adjustment of the Contract Sum for delay, written documentation demonstrating the Contractor's entitlement to such an adjustment. 8. A personal certification from the Contractor that reads as follows: "I, ., BEING THE (MUST BE AN ........................... OFFICER) OF (CONTRACTOR NAME), DECLARE Page 19 of 34 Agreement No. 5320 EXHIBIT B UNDER PENALTY OF PERJURY UNDER CALIFORNIA LAW, AND DO PERSONALLY CERTIFY AND ATTEST THAT I HAVE THOROUGHLY REVIEWED THE ATTACHED CLAIM FOR ADDITIONAL COMPENSATION OR EXTENSION OF TIME, AND KNOW ITS CONTENTS, AND SAID CLAIM IS MADE IN GOOD FAITH; THE SUPPORTING DATA IS TRUTHFUL AND ACCURATE; THAT THE AMOUNT REQUESTED ACCURATELY REFLECTS THE CONTRACT ADJUSTMENT FOR WHICH THE CONTRACTOR BELIEVES CITY IS LIABLE; AND, FURTHER, THAT I AM FAMILIAR WITH CALIFORNIA PENAL CODE § 72 AND CALIFORNIA GOVERNMENT CODE § 12650, ET SEQ., PERTAINING TO FALSE CLAIMS, AND FURTHER KNOW AND UNDERSTAND THAT SUBMITTING OR CERTIFYING A FALSE CLAIM MAY LEAD TO FINES,IMPRISONMENT,AND OTHER SEVERE LEGAL CONSEQUENCES." 6-11.3 CLAIMS SUBMITTED TO ENGINEER Within (30) calendar days after the circumstances giving rise to a Claim occur, the Contractor will submit its Claim to the Engineer for a decision.Regardless of any Claim submittal, or any dispute regarding a Claim,unless otherwise directed by the Engineer, the Contractor will not cause any delay, cessation, or termination of the Work, but will diligently proceed with the performing the Work in accordance with the Contract Documents. Except as otherwise provided,the City will continue to make payments in accordance with the Contract Documents. 6-11.4 C LACM 1S PRI;Rl"O[.1ISITE TO OTHER REMEDY The Contractor certifies that it is familiar with PCC § 10240.2 and understands and agrees that submitting a Claim in accordance with these Specifications is an express condition precedent to the Contractor's right to otherwise pursue a claim whether through alternative dispute resolution or by litigation. Should the Contractor fail to submit a claim in accordance with these Specifications, including the time limits set forth herein, it will waive any right to a remedy, whether in law or equity, it might otherwise have pursuant to the Contract Documents or applicable law. 6-11.5 DECISION ON CLAIMS The Engineer will promptly review Claims submitted by the Contractor in accordance with these Specifications. Should the Engineer require additional supporting evidence to evaluate the claim,the Engineer will request such additional information in writing. Any such requested data will be furnished not later than 10 calendar days after the Contractor receives the Engineer's request. The Engineer will render a decision not later than 30 days after either receiving the Claim or the deadline for furnishing additional supporting data, whichever is later. If the Engineer fails to render a decision within the time period established herein, then Page 20 of 34 Agreement No. 5320 EXHIBIT B the Claim will be deemed denied. The Engineer's decision will be final and binding unless appealed in accordance with these Specifications. The Engineer's decision on a Claim will include a statement substantially as follows: "This is a decision pursuant to the General Specifications of your contract. If you are dissatisfied with the decision, and have complied with the procedural requirements for asserting claims, you may have the right to alternative dispute resolution or litigation. Should you fail to take appropriate action within 30 calendar days of the date of this decision,the decision will become final and binding and not subject to further appeal." 6-11.6 APPEAL OF ENGINEER'S DECISION Should the Contractor dispute the Engineer's decision,then the Contractor must appeal that decision to the City's Public Works Director within 30 calendar days of receiving the Engineer's decision. The Public Works Director will address disputes or claims within 30 calendar days after receiving such request and all necessary supporting data. The Public Works Director's decision on the dispute or claim will be the City's final decision. If the Contractor disputes the Public Works Director's decision, then the Contractor must demand alternative dispute resolution in accordance with this Section and the PCC within 30 calendar days of the City's final decision. 6-11.7 MEDIATION If the City and the Contractor agree, disputes between the parties may be submitted to non-binding mediation. If the parties cannot agree to an alternative form of mediation, then mediation will be administered by the American Arbitration Association("AAA") under its Construction Industry Mediation Rules, unless the use of such rules are waived by mutual stipulation of both parties. The parties may, but are not required to be, represented by counsel in mediation. The requirement for mediation will not alter or modify the time limitations otherwise provided for claims and no conduct or settlement negotiation during mediation will be considered a waiver of the City's right to assert that claim procedures were not followed. 6-11.8 ARBITRATION If the City and Contractor do not agree to mediation,then a disputes will be submitted to neutral non-binding (except as provided herein) arbitration. Arbitration will be conducted in accordance with PCC § 10240.3. Any decision rendered by an arbitrator will be consistent with PCC § 10240.8. Page 21 of 34 Agreement No. 5320 EXHIBIT B The exclusive venue for any arbitration will be in Los Angeles County. The expenses and fees of the arbitrators and the administrative fees, if any, will be divided among the parties equally. Each party will pay its own counsel fees, witness fees, and other expenses incurred for its own benefit. 6-11.9 WHEN ARBITRATION DECISION BECOMES BINDING The decision rendered by the arbitrator will become binding upon the parties unless appealed to the Los Angeles County Superior Court pursuant to PCC § 10240.12 within 30 calendar days of the decision.If subsequent litigation results in an award to the party appealing the arbitration that is less than or equal to that of the arbitration decision, or if the litigation results in a decision in favor of the nonappealing party, then the party appealing the arbitration will pay the nonappealing party's attorney's fees and court costs. 6-11.10 APPEAL TO S I_J 111"J l l,':,M C"()I.,I1 T: WAIVER OF JURY TRIAL Should a party timely object to the arbitration decision, it may file a petition with the Los Angeles County Superior Court in accordance with California Code of Civil Procedure ("CCP") §§ 1285, et seq.Notwithstanding the limitations set forth in CCP § 1286.2, the court may vacate, correct, or adjust an arbitration award, and enter judgment in accordance with CCP § 1287.4, for any legal or equitable basis including, without limitation, error of law. The court will apply the substantial evidence standard of review when considering the appeal of an objecting party. BY EXECUTING THESE CONTRACT DOCUMENTS, THE CONTRACTOR AGREES TO HAVE DISPUTES OR CONTROVERSY CONCERNING THE CONSTRUCTION, INTERPRETATION, PERFORMANCE, OR BREACH OF THESE CONTRACT DOCUMENTS, INCLUDING CLAIMS FOR BREACH OF CONTRACT OR ISSUES OF BAD FAITH DECIDED IN ACCORDANCE WITH THIS SECTION 6-11. BOTH THE CITY AND THE CONTRACTOR WAIVE THEIR RIGHT TO A JURY TRIAL FOR THESE DISPUTES OR ISSUES. 6-11.11 E' AF3 626 ( LA1MS: PI�.III, SS Claims made by a Contractor for one or more of the following are subject to the claim resolution process set forth in Public Contract Code section 9204: (A)A time extension,including,without limitation,for relief from damages or penalties for delay assessed by the city under a contract for a public works project. (B)Payment by the city of money or damages arising from work done by, or on behalf of, the contractor pursuant to the contract for a public works project and payment for which is not otherwise expressly provided or to which the claimant is not Page 22 of 34 Agreement No. 5320 EXHIBIT B otherwise entitled. (C)Payment of an amount that is disputed by the city. 7-2 LABOR The following subsections are added to Subsection 7-2 of the Green Book. 7-2.3 PREVAILING WAGES The Contractor will post at appropriate conspicuous points at the site of the project a schedule showing determinations of the Director of Industrial Relations of the prevailing rate of per diem wages. It will be the Contractor's responsibility to obtain copies of the prevailing rate of per diem wages. One source that may be used is the California Department of Industrial Relations website which is currently located at www.dir.ca.gov, or by calling the Prevailing Wage Unit at (415) 703-4774. Attention is directed to Labor Code §§ 1777.5, 1777.6 and 3098 concerning the employment of apprentices by the Contractor or any subcontractor. Labor Code § 1777.5 requires the Contractor or subcontractor employing tradesmen in any apprenticeship occupation to apply to the joint apprenticeship committee nearest the site of the public works project and which administers the apprenticeship program in that trade for a certificate of approval. The certificate will also fix the ratio of apprentices to journeymen that will be used in the performance of the contract. The ratio of apprentices to journeymen in such cases will not be less than one to five except: a) When employment in the area of coverage by the joint apprenticeship committee has exceeded an average of 15 percent in the 90 calendar days before the request for certificate, or b) When the number of apprentices in training in the area exceeds a ratio of one to five, or C) When the trade can show that it is replacing at least 1/30 of its membership through apprenticeship training on an annual basis state-wide or locally, or d) When the Contractor provides evidence that the Contractor employs registered apprentices on all of his contracts on an annual average of not less than one apprentice to eight journeymen. The Contractor is required to make contributions to funds established for the administration of apprenticeship programs if the Contractor employs registered apprentices or journeymen in any apprenticeable trade on such contracts and if other contractors on the public works site are making such contributions. Page 23 of 34 Agreement No. 5320 EXHIBIT B The Contractor and any subcontractor will comply with Labor Code §§ 1777.5 and 1777.6 in the employment of apprentices. Information relative to apprenticeship standards, wage schedules and other requirements may be obtained from the Director of Industrial Relations, ex-officio the Administrator of Apprenticeship, San Francisco, California, or from the Division of Apprenticeship Standards and its branch offices. 7-2.4 RECORD OF WAGES PAID: INSPECTION Every Contractor and subcontractor will keep an accurate certified payroll records showing the name, occupation, and the actual per diem wages paid to each worker employed in connection with the Work. The record will be kept open at all reasonable hours to the inspection of the body awarding the contract and to the Division of Labor Law Enforcement. If requested by the City, the Contractor will provide copies of the records at its cost. 7-3 LIABILITY INSURANCE Subsection 7-3, Liability Insurance, of the Greenbook is deleted in its entirety and replaced by the following subsections. 7-3.1 GENERAL Contractor will procure and maintain for the duration of the contract the following insurance coverages and limits against claims for injuries to persons or damage to property which may arise from or in connection with the performance of the work covered by this agreement by the Contractor, its agents, representatives, employees or subcontractors: COVERAGE PER ISO FORM COMBINE OCCURRENCE D SINGLE LIMIT Comprehensive General Liability CL 00 02 01 85 or 88 $2,000,000 Business Auto CA 00 0101 87 $1,000,000 Workers' Compensation Statutory Contractor will provide endorsements or other proof of coverage for contractual liability. Combined single limit per occurrence will include coverage for bodily injury,personal injury, and property damage for each accident. If Commercial General Liability Insurance or other form with a general aggregate limit is used, the policy will be endorsed such that the general aggregate limit will apply Page 24 of 34 Agreement No. 5320 EXHIBIT B separately to this contract and a copy of the endorsement provided to the City. Liability policies will contain, or be endorsed to contain the following provisions; GENERAL LIABILITY AND AUTOMOBILE LIABILITY: The City, its officers, officials, employees, agents, and volunteers will be covered as insureds as respects: liability arising out of activities performed by or on behalf of the Contractor; products and completed operations of the Contractor; premises owned, occupied or used by the Contractor; or automobiles owned, leased, hired or borrowed by the Contractor. The coverage will contain no special limitations on the scope or protection afforded to the City, its officers, officials, employees, agents, or volunteers. The Contractor's insurance coverage will be primary insurance as respects the City, its officers, officials, employees, agents, and volunteers. Any insurance or self-insurance maintained by the City, its officers, officials, employees, agents, and volunteers will be excess of the Contractor's insurance and will not contribute with it. The insurer will agree in writing to waive all rights of subrogation against the City, its officers,officials,employees and volunteers for losses arising from work performed by the Contractor for the City. Any failure to comply with reporting provisions of the policies will not affect coverage provided to the City, its officers, officials, employees, agents and volunteers. The Contractor's insurance will apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. WORKERS' COMPENSATION: The insurer will agree to waive all rights of subrogation against the City, its officers, officials, employees and volunteers for losses arising from work performed by the Contractor for the City. ALL COVERAGES: Each insurance policy required by this subsection will be endorsed to state that coverage will not be suspended, voided, cancelled by either party,reduced in coverage or in limits except after thirty (30) calendar days written notice by certified mail,return receipt requested, has been given to: CITY CLERK City of El Segundo 350 Main Street El Segundo, CA 90245 Page 25 of 34 Agreement No. 5320 EXHIBIT B Notwithstanding the foregoing, the endorsement may state that insurance may be cancelled upon ten (10) calendar day notification for non-payment of premium. The Contractor will provide the City with updated proof of insurance should the Contract Time extend beyond the policy expiration date. All liability insurance will be on an occurrence basis. Insurance on a claims made basis will be rejected. Any deductibles or self-insured retentions will be declared to and approved by City. The insurer will provide an endorsement to City eliminating such deductibles or self-insured retentions as respects the City, its officials, employees, agents, and volunteers. Except for Workers Compensation Insurance, Contractor will furnish to City certificates of insurance and endorsements on forms acceptable to the City's City Attorney, duly authenticated, giving evidence of the insurance coverages required in this contract and other evidence of coverage or copies of policies as may be reasonably required by City from time to time. Endorsements must be supplied on ISO Form No. CG 20 10 11 85, or equivalent. Certificate/endorsement for Workers Compensation Insurance will be furnished on State Comp Fund or other industry standard form. Except for worker's compensation insurance, all insurance required herein will be placed with insurers with a Best's Rating of not less than A:VII. Worker's compensation insurance policies will meet the requirements of California law. All subcontractors employed on the work referred to in this contract will meet the insurance requirements set forth for Contractor. Contractor will furnish certificates of insurance and endorsements for each subcontractor at least five days before the subcontractor entering the job site, or Contractor will furnish City an endorsement including all subcontractors as insureds under its policies. Except as provided in Subsection 6-10,the Contractor will save,keep and hold harmless the City, its officers,officials,employees,agents and volunteers from all damages,costs or expenses in law or equity that may at any time arise or be claimed because of damages to property,or personal injury received by reason of or in the course of performing work, which may be caused by any willful or negligent act or omission by the Contractor or any of the Contractor's employees, or any subcontractor. The City will not be liable for any accident, loss or damage to the work before its completion and acceptance, except as provided in Subsection 6-10. The cost of such insurance will be included in the various items of work in the Contractor's bid and no additional compensation for purchasing insurance or additional coverage needed to meet these requirements will be allowed. In the event that any required insurance is reduced in coverage,cancelled for any reason, voided or suspended, Contractor agrees that City may arrange for insurance coverage as specified, and Contractor further agrees that administrative and premium costs may be deducted from payments due to the Contractor. Contractor will not be allowed to work until alternate coverage is arranged. Page 26 of 34 Agreement No. 5320 EXHIBIT B Coverage will not extend to any indemnity coverage for the active negligence of the additional insured if the agreement to indemnify the additional insured would be invalid under Civil Code § 2782(b). 7-3.2 IN1 FtVINIF ICATION AND DFI°l'NSI In addition to the provisions of Subsection 7-3 of the Greenbook as between the City and Contractor, Contractor will take and assume all responsibility for the work as stated herein or shown on the plans. The Contractor will bear all losses and damages directly or indirectly resulting to it,to the City, its officers, employees, and agents,or to others on account of the performance or character of the work, unforeseen difficulties, accidents, traffic control, job site maintenance, or any other causes whatsoever. The Contractor will assume the defense of and indemnify and save harmless the City of El Segundo, its officers, employees, and agents,from and against any and all claims, losses, damage, expenses and liability of every kind, nature, and description, directly or indirectly arising from the performance of the contract or work, regardless of responsibility for negligence, and from any and all claims, losses, damage, expenses, and liability, howsoever the same may be caused, resulting directly, or indirectly from the nature of the work covered by the contract, regardless of responsibility for negligence, to the fullest extent permitted by law. In accordance with Civil Code § 2782, nothing in this Subsection 7-3.2 or in Subsection 7-3 of the Standard Specifications will require defense or indemnification for death, bodily injury, injury to property, or any other loss, damage or expense arising from the sole negligence or willful misconduct of the City, or its agents, servants or independent contractors who are directly responsible to the City, or for defects in design furnished by such persons. Moreover, nothing in this Subsection 7-3.2 or in Subsection 7-3 will apply to impose on the Contractor, or to relieve the City from, liability for active negligence of the City. The City does not, and will not, waive any rights against the Contractor which it may have by reason of the aforesaid hold harmless agreements because of the acceptance by the City, or deposit with City by Contractor, of any insurance policies described in Subsection 7-3 of the Special Provisions. This hold harmless agreement by the Contractor will apply to all damages and claims for damages of every kind suffered, or alleged to have been suffered by reasons of any of the aforesaid operations of Contractor, or any subcontractor, regardless of whether or not such insurance policies are determined to be applicable to any of such damages or claims for damages. No act by the City, or its representatives in processing or accepting any plans, in releasing any bond, in inspecting or accepting any work, or of any other nature, will in any respect relieve the Contractor or anyone else from any legal responsibility, obligation or liability he might otherwise have. Page 27 of 34 Agreement No. 5320 EXHIBIT B 7-5 PERMITS The following paragraph will be added to Subsection 7-5 of Greenbook: The Contractor will apply for permits required by the City Building Safety Division. These permits will be issued on a"no-fee"basis.However,the Contractor must pay for and obtain all other permits from other governmental and utility agencies necessitated by their operations. All bonding fees,(overweight and oversized vehicle permit fees) inspection permit fees or other fees charged or required for such permits must be paid by the Contractor.These costs will be included in the bid item provided. If no bid item is included, costs will be included in the various items of work, and no additional payment will be allowed. 7-8.1 CLEANUP AND DUST CONTROL Subsection 7-8.1, Cleanup and Dust Control, of the Greenbook is deleted in its entirety and replaced by the following subsections. 7-8.1.1 GENERAL On any construction project requiring trenching within public streets and for which total trenching is in excess of 500 feet, the Contractor will be required to sweep the worksite utilizing a pick-up type street sweeper a minimum of once daily. 7-8.1.2 WATERING Water for the laying of dust caused by Contractor's operations or the passage of traffic through the work will be applied as necessary or as directed by the Engineer. Water for the above or other purposes may be obtained from any approved source. If the Contractor chooses to use a City fire hydrant upon placing deposits and fees as described in this contract, the Engineer will cause a meter to be installed. All water used from the hydrant will be metered and charged to the Contractor at the prevailing rate plus the current daily meter rental rate. The Contractor will be charged a $15 reconnect fee if the Contractor wishes to move the meter to a different hydrant. Costs of water to be used will be included in the cost of various bid items. 7-8.6 WATER POLLUTION CONTROL The following requirements are added to establish storm water and urban runoff pollution prevention controls. (a) Storm or construction generated water containing sediment such as, construction waste, soil, slurry from concrete/asphalt concrete saw cutting operations, clean up of concrete transit mixers or other pollutants from Page 28 of 34 Agreement No. 5320 EXHIBIT B construction sites and parking areas will be retained or controlled on site and will not be permitted to enter the storm drain system. (b) Temporary sediment filtering systems such as sandbags, silt fences, or gravel berms will be utilized to trap sediment so that only filtered water enters the City's storm drain system. Proper clean up and disposal of settled sediment and the filtering system will be the responsibility of the Contractor. (c) Discharge of concrete transit mixer wash water on to approved dirt areas (sub-grade area designated for new concrete construction for example) is acceptable. Discharge on to private property,parkway areas, or the street is not permitted. (d) Plastic or other impervious covering will be installed where appropriate to prevent erosion of an otherwise unprotected area, along with any other runoff control devices deemed appropriate by the City. (e) Excavated soil stored on the site will be covered in a manner that minimizes the amount of sediments running into the storm drain system, street or adjoining properties. (f) No washing of construction or other industrial vehicles and equipment will be allowed adjacent to a construction site.During the rainy season(October 15 to April 15), Contractor will keep at the construction site sufficient materials and labor to install temporary sediment filtering systems and other water pollution prevention control measures. These control measures will be in place and maintained by the Contractor on a daily basis on days when construction is not in progress due to rain. (h) All costs associated with water pollution control will be borne by the Contractor. Any expense incurred by the City to expeditiously respond to storm drain contamination resulting from Contractor's failure to implement water pollution control measures will be charged to the Contractor. 7-9 I'Mb 11"C"I°ION AND RESTORATION OF F`X I'STI NG I MPI�QVE M1�1" TS. The following requirements are added to Section 7-9: Where existing traffic striping,pavement markings,and curb markings are damaged or their reflectively reduced by the Contractor's operations, such striping or markings will also be considered as existing improvements and the Contractor will replace such improvements. Relocations, repairs, replacements, or re-establishments will be at least equal to the existing improvements and will match such improvements in finish and dimensions unless otherwise specified. Page 29 of 34 Agreement No. 5320 EXHIBIT B 7-10 PUBLIC CONVENIENCE AND SAFETY The following requirement is added to Section 7-10: Unless otherwise specified all traffic control will be performed in accordance with the Work Area Traffic Control Handbook(WATCH)Latest Edition,published by Building News. 7-10.1 TRAFFIC AND ACCESS The Contractor will notify the occupants of all affected properties at least 48 hours prior to any temporary obstruction of access. Vehicular access to property line will be maintained except as required for construction for a reasonable period of time. No overnight closure of any driveway will be allowed except as permitted by the Engineer. At least one(1)twelve (12)foot wide traffic lane will be provided for each direction of travel on all streets at all times except as permitted by the Engineer. The traffic lanes will be maintained on pavement, and will remain unobstructed. All work requiring that a lane be closed or a lane moved right or left will be noticed to the traveling public by use of City approved lighted arrow boards. Clearances from traffic lanes will be five(5)feet to the edge of any excavation and two (2)feet to the face of any curb,pole,barricade,delineator,or other vertical obstruction. One four (4) foot wide paved pedestrian walkway will be maintained in the parkway area on each side of all streets.The clearance from the pedestrian walkway to any traffic lane will be five (5) feet. Pedestrians and vehicles will be protected from all excavations, material storage, and/or obstructions by the placement of an adequate number of lighted barricades (minimum two (2)) at each location, one (1) at each end of the obstruction or excavation), which will have flashing lights during darkness. Barricades will be Type I or Type II per Section 7-3 and lights will be Type A per Section 7-6 of the "Work Area Traffic Control Handbook" (WATCH). 7-10.2 STREET CLOSURES, 1)FTOURS,BARRICADES Street closures will not be allowed except as specifically permitted by the Engineer. The Contractor will prepare any traffic control or detour plans that may be required as directed by the Engineer.Lane transitions will not be sharper than a taper of thirty(30) to one (1). Temporary traffic channelization will be accomplished with barricades or delineators. Temporary striping will not be allowed unless specifically permitted by the Engineer. The Contractor will prepare any plans that may be required for temporary striping to the satisfaction of the Engineer.In no event will temporary striping be allowed on finish Page 30 of 34 Agreement No. 5320 EXHIBIT B pavement surfaces, which are to remain. Where access to driveway or street crossings need to be maintained, minimum 1 1/4 inch thick steel plating will be used to bridge the trench. All steel plating will have temporary asphalt concrete 1:12 minimum sloped ramps to assist vehicles to cross comfortably over the plates and have a non-skid surface. Plates subject to vehicle high traffic speeds and in residential areas will be secured by welding at the discretion of the Engineer. 7-10.5 PROTECTION OF THE PUBLIC It is part of the service required of the Contractor to make whatever provisions are necessary to protect the public. The Contractor will use foresight and will take such steps and precautions as his operations warrant to protect the public from danger, loss of life or loss of property, which would result from interruption or contamination of public water supply, interruption of other public service, or from the failure of partly completed work or partially removed facilities. Unusual conditions may arise on the Project which will require that immediate and unusual provisions be made to protect the public from danger or loss of life, or damage to life and property, due directly or indirectly to prosecution of work under this contract. Whenever, in the opinion of the Engineer, an emergency exists against which the Contractor has not taken sufficient precaution for the public safety, protection of utilities and protection of adjacent structures or property, which may be damaged by the Contractor's operations and when, in the opinion of the Engineer,immediate action will be considered necessary in order to protect the public or property due to the Contractor's operations under this contract, the Engineer will order the Contractor to provide a remedy for the unsafe condition. If the Contractor fails to act on the situation immediately,the Engineer may provide suitable protection to said interests by causing such work to be done and material to be furnished as, in the opinion of the Engineer, may seem reasonable and necessary. The cost and expense of said labor and material, together with the cost and expense of such repairs as are deemed necessary, will be borne by the Contractor. All expenses incurred by the City for emergency repairs will be deducted from the progress payments and the final payment due to the Contractor. Such remedial measures by the City will not relieve the Contractor from full responsibility for public safety. 7-15 HAZARDOUS MATERIAL The following Subsection will be added to Section 7 of the Greenbook: For any excavation, which extends more than four feet below existing grade, the Contractor will promptly, and before the conditions are disturbed, notify the Engineer, in writing, of 1) any material that the Contractor believes may be hazardous waste, as defined in Health and Safety Code § 25117,which is required to be removed to a Class Page 31 of 34 Agreement No. 5320 EXHIBIT B I, Class 1I, or Class III disposal site in accordance with provisions of existing law, 2) subsurface or latent physical conditions at the site differing from those indicated, or 3) unknown physical conditions at the site of any unusual nature,different materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract Documents. After receiving notice from the Contractor,the Engineer will promptly investigate any condition identified by the Contractor as being hazardous. The rights and obligations of the City and the Contractor with regard to such conditions (including, without limitation, the procedures for procuring change orders and filing claims) will be specified by the provisions of Subsection 3-4 (Changed Conditions) of the Greenbook. If a dispute arises between the City and the Contractor whether the conditions materially differ, involve hazardous waste, or cause a change in the Contractor's cost or time required for performance of the work, the Contractor will not be excused from any scheduled completion date provided for by the contract, but will proceed with all work to be performed under the contract. The Contractor will retain all rights provided by Subsection 3-5, Disputed Work, of the Greenbook. If the Engineer determines that material called to the Engineer's attention by the Contractor is hazardous waste, or if the Engineer otherwise discovers the existence of hazardous waste, the Contractor will be responsible for removal and disposal of the hazardous waste by qualified personnel and appropriate equipment in the manner required by law as directed by the Engineer, subject to the provisions of Section 3 (Changes in Work) of the Greenbook. 9-2 LUMP SUM WORK Subsection 9-2, Lump Sum Work, of the Greenbook is deleted in its entirety and replaced by the following: Items for which quantities are indicated as "Lump Sum," "L.S.," or "Job" will be paid for at the price indicated in the Proposal. Such payment will be full compensation for all costs for labor, equipment, materials and plant necessary to furnish, construct and install the lump sum item of work,complete,in place, and for all necessary appurtenant work, including, but not limited to, all necessary cutting, patching, repair and modification of existing facilities, and clean up of site. Contractor will furnish three copies of a detailed schedule,which breaks down the lump sum work into its component parts and cost for each part, in a form and sufficiently detailed as to satisfy Engineer that it correctly represents a reasonable apportionment of the lump sum. This schedule is subject to approval by Engineer as to both the components into which the lump sum item is broken down, and the proportion of cost attributable to each component. This schedule will be the basis for progress payments for the lump sum work. Page 32 of 34 Agreement No. 5320 EXHIBIT B 9-3.2 PARTIAL AND FINAL PAYMENTS The text of Subsection 9-3.2 of the Standard Specifications is hereby deleted and replaced with the following: The closure date for the purpose of making partial progress payments will be the last working day of each month. The Contractor will prepare the partial payment invoice with measurement of the work performed through the closure date and submit it to the CITY for approval. When work is complete, the Contractor will determine the final quantities of the work performed and prepare the final progress payment, and submit it to the Engineer for approval. It will take a minimum of thirty-five (35) calendar days from the date of approving the Contractor's invoice to make the payment to the Contractor. However, payments will be withheld pending receipt of any outstanding reports required by the contract documents, or legal release of filed Stop Payment Notices against the Contractor. In addition, the final progress payment will not be released until the Contractor returns the control set of Plans and Specifications showing the as-built conditions. The full five percent (5%) retention will be deducted from all progress payments. The Contractor will make a payment request for the retained amount, for approval by the City, upon field acceptance of the work by the City Engineer. The City Engineer upon field acceptance and receipt of the final as-built plans and any other reports or documents required to be provided by the Contractor will process a recommendation to the City Council for acceptance of the work.Not less than thirty-five (35) calendar days from the City Council acceptance of the work,the Contractor's final payment will be made provided Stop Payment Notices or other claims have not been filed against the Contractor and/or the City by material suppliers, sub-contractors, other governmental agencies, and private property owners. Until these Stop Payment Notices are released and claims are resolved the stop payment/claim amount will be withheld from the final payment. The Contractor, however, may receive interest on the retention for the length of construction, or receive the retention itself as long as the retention is substituted with escrow holder surety or equal value. At the request and expense of the Contractor, surety equivalent to the retention may be deposited with the State Treasurer,or a State or Federally chartered bank,as the escrow agent, who will pay such surety to the Contractor upon satisfactory completion of the contract. Pursuant to PCC § 22300,the Contractor may substitute securities for retention monies held by the City or request that the City place such monies into an escrow account.The Page 33 of 34 Agreement No. 5320 EXHIBIT B Contractor is notified, pursuant to PCC § 22300, that any such election will be at the Contractor's own expense and will include costs incurred by the City to accommodate the Contractor's request. Progress payment paid by the City as contemplated herein,will be contingent upon the Contractor submitting, in addition to any additional documents, an updated Contract Schedule in the form prescribed by these Contract Documents.Failure of the Contractor to submit an acceptable updated Contract Schedule will result in the City withholding partial payment,without liability to the City, until such an acceptable updated Contract Schedule is submitted. Nothing herein will allow the Contractor to suspend or slow progress of the Work. A City Council resolution established a Project Payment Account, encumbered money in the current budget, and assigned that money to the Project Payment Account which is the sole source of funds available for payment of the Contract Sum. Contractor understands and agrees that Contractor will be paid only from this special fund and if for any reason this fund is not sufficient to pay Contractor, Contractor will not be entitled to payment. The availability of money in this fund, and City's ability to draw from this fund, are conditions precedent to City's obligation to make payments to Contractor. 9-3.3 DELIVERED MATERIALS Materials and equipment delivered or stored, but not incorporated into the work, will not be approved for progress payments. 100-1 TERMINATION OF AGENCY LIABILITY Before receiving final payment, the Contractor will execute a Release on Contract" form which will operate as,and will be a release to the City,the City Council, and each member of the City Council and their agencies, from all claims and liability to the Contractor for anything done or furnished for, or relating to, the work or for any act of neglect of the City of any person relating to or affecting the work, except the claim against the City for the remainder, if any there be, of the amounts kept or retained as provided in Subsections 9-3 of the Standard Specifications and except for any unsettled claims listed on said form which have been filed in compliance with the requirements for making claims. -END OF SECTION- Page 34 of 34