Loading...
CONTRACT 4987 Public Works Contract CLOSEDAgreement No. 4987 PUBLIC WORKS CONTRACT BETWEEN THE CITY OF EL SEGUNDO AND JAMES McNARY, dba BINO CONSTRUCTIO This CONTRACT is entered into this Dq day of4aflaa, 2018, by and between the City of El Segundo, a general law city and municipal corporation ( "the City "), and James McNary, dba Bino Construction ( "the Contractor'). A. The Contractor will provide all work listed in the Scope of Work (attached as Exhibit A) (the "Work "). The Contractor agrees to do additional work arising from changes ordered by the City in accordance with the Contract Documents. B. The Contractor and the City agree to abide by the terms and conditions contained in the Contract Documents. C. The Contractor will furnish all of the labor; supplies and materials; equipment; printing; vehicles; transportation; office space and facilities; all tests, testing and analyses; and all matters whatsoever (except as otherwise expressly specified to be furnished by the City) needed to perform and complete the Work and provide the services required of the Contractor by the Contract Documents. D. "Contract Documents" means the this Contract; the Scope of Work attached as Exhibit A, the Contractor's Proposal attached as Exhibit B, the Standard Specifications attached as Exhibit C; Exhibits; Technical Specifications; Notice to Proceed; Change Orders; Notice of Completion; and all ether documents identified in the Contract Documents which together form the contract between the City and the Contractor for the Work. The Contract Documents constitute the complete agreement between the City and the Contractor and supersede any previous agreements or understandings. 2. CONTRACT SUM. The City agrees to pay the Contractor a sum not to exceed Thirty - One Thousand, Sixty -Five Dollars ($31,065) for the Work in the manner set forth in the Contract Documents. The City may adjust this amount as set forth in the Contract Documents. 3. TIME FOR PERFORMANCE. A. The Contractor will fully complete the Work within 20 working days (the "Contract Time. ") Agreement No. 4987 B. The Contract Time will commence when the City issues a notice to proceed. The Contract Documents will supersede any conflicting provisions included on the notice to proceed issued pursuant to this Contract. C. The Contractor may not perform any Work until: The Contractor furnishes proof of insurance as required by the Contract Documents; and ii. The City gives the Contractor a written notice to proceed. D, By signing this Contract, the Contractor represents to the City that the Contract Time is reasonable for completion of the Work and that the Contractor will complete the Work within the Contract Time. E. Should the Contractor begin the Work before receiving written authorization to proceed, any such Work is at the Contractor's own cost and risk. 4. PREVAILING WAGES. Pursuant to Labor Code § 1720, and as specified in 8 California Code of Regulations § 16000, the Contractor must pay its workers prevailing wages. It is the Contractor's responsibility to interpret and implement any prevailing wage requirements and the Contractor agrees to pay any penalty or civil damages resulting from a violation of the prevailing wage laws. See Section 7 -2 of the Standard Specifications. 5. DISPUTES. Disputes arising from this contract will be determined in accordance with the Contract Documents and Public Contracts Code §§ 10240 - 10240.13. 6. THIRD PARTY CLAIMS. In accordance with Public Contracts Code § 9201, the City will promptly inform the Contractor regarding third -party claims against the Contractor, but in no event later than ten (10) business days after the City receives such claims. Such notification will be in writing and forwarded in accordance with the "Notice" section of the Contract Documents. As more specifically detailed in the Contract Documents, the Contractor agrees to indemnify and defend the City against any third -party claim. 7. TAXPAYER IDENTIFICATION NUMBER. The Contractor will provide the City with a Taxpayer Identification Number. 8. PERMITS AND LICENSES. Unless otherwise provided, the Contractor, at its sole expense, will obtain and maintain during the Contract Time, all necessary permits, licenses, and certificates that may be required in connection with the Work. 9. OWNERSHIP OF DOCUMENTS. All documents, data, studies, drawings, maps, models, photographs and reports prepared by the Contractor under the Contract Documents are the City's property. The Contractor may retain copies of said documents 2 Agreement No. 4987 and materials as desired, but will deliver all original materials to the City upon the City's written notice. 10. INDEMNIFICATION. The Contractor agrees to indemnify, defend, and hold the City harmless as set forth in the Contract Documents. The requirements as to the types and limits of insurance coverage to be maintained by the Contractor as required by the Contract Documents, and any approval of such insurance by the City, are not intended to and will not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Contractor pursuant to the Contract Documents, including, without limitation, to the provisions concerning indemnification. 11.INDEPENDENT CONTRACTOR. The City and the Contractor agree that the Contractor will act as an independent contractor and will have control of all work and the manner in which is it performed. The Contractor will be free to contract for similar service to be performed for other employers while under contract with the City. The Contractor is not an agent or employee of the City and is not entitled to participate in any pension plan, insurance, bonus or similar benefits the City provides for its employees. Any provision in this Contract that may appear to give the City the right to direct the Contractor as to the details of doing the work or to exercise a measure of control over the work means that the Contractor will follow the direction of the City as to end results of the work only. 12.AUDIT OF RECORDS. The Contractor will maintain full and accurate records with respect to all services and matters covered under this Contract. The City will have free access at all reasonable times to such records, and the right to examine and audit the same and to make transcript therefrom, and to inspect all program data, documents, proceedings and activities. The Contractor will retain such financial and program service records for at least three (3) years after termination or final payment under the Contract Documents. 13. NOTICES. All communications to either party by the other party will be deemed made when received by such party at its respective name and address as follows: To City City of El Segundo Attn: Director of Public Works 350 Main Street El Segundo, CA 90245 To Contractor James McNary Bino Construction 12101 Van Nuys Blvd. Suite 34 Sylmar, CA 91342 Any such written communications by mail will be conclusively deemed to have been received by the addressee three (3) days after deposit thereof in the United States Mail, postage prepaid and properly addressed as noted above. In all other instances, notices will be deemed given at the time of actual delivery. Changes may be made in the names or addresses of persons to whom notices are to be given by giving notice in the manner prescribed in this paragraph. 3 Agreement No. 4987 14. NO THIRD PARTY BENEFICIARY. This Contract and every provision herein is for the exclusive benefit of the Contractor and the City and not for the benefit of any other party. There will be no incidental or other beneficiaries of any of the Contractor's or the City's obligations under this Contract. 15.INTERPRETATION/VENUE. This Contract was drafted in, and will be construed in accordance with the laws of the State of California, and exclusive venue for any action involving this Contract will be in Los Angeles County. 16. EFFECT OF CONFLICT. In the event of any conflict, inconsistency, or incongruity between any provision of the Contract Documents, precedence will be as follows: A. This Contract; B. The Standard Specifications; and C. Precedence of documents as determined in the Standard Specifications, 17. SEVERABILITY. If any portion of the Contract Documents are declared by a court of competent jurisdiction to be invalid or unenforceable, then such portion will be deemed modified to the extent necessary in the opinion of the court to render such portion enforceable and, as so modified, such portion and the balance of this Contract will continue in full force and effect. 18.AUTHORITY /MODIFICATION. The Parties represent and warrant that all necessary action has been taken by the Parties to authorize the undersigned to execute this Contract and to engage in the actions described herein. This Contract may be modified by written amendment. The City's city manager, or designee, may execute any such amendment on the City's behalf. 19.ACCEPTANCE OF FACSIMILE SIGNATURES. The Parties agree that this Contract, agreements ancillary to this Contract, and related documents to be entered into in connection with this Contract will be considered signed when the signature of a party is delivered by facsimile transmission. Such facsimile signature will be treated in all respects as having the same effect as an original signature. 20. COVENANTS AND CONDITIONS. The parties agree that all of the provisions hereof will be construed as both covenants and conditions, the same as if the words importing such covenants and conditions had been used in each separate paragraph. 21. CAPTIONS. The captions of the paragraphs of this Contract are for convenience of reference only and will not affect the interpretation of this Contract. 22. TIME IS OF ESSENCE. Time is of the essence for each and every provision of the Contract Documents. 0 Agreement No. 4987 IN WITNESS WHEREOF the parties hereto have executed this contract the day and year first hereinabove written. CITY OF EL SEGUNDO a g enefi l lawx;ity, c rag , rpen) City icr ATTEST: APPROVED AS TO FORM: cevich AsssX, rit City Attorney Insurance Reviewed by: mmM. 5 JAMES McNARY dba Bino Construction MOM No. b Agreement No. 4987 FAITHFUL PERFORMANCE BOND Bond No. 609004854 Bond Fee: $931.95 James McNary, dba Bino Construction, as principal ( "PRINCIPAL ") and Ohio Casualty Insurance Company, a corporation incorporated under the laws of the State of New Hampshire and licensed by the State of California to execute bonds and undertakings as sole surety, as surety ( "SURETY "), are held and firmly bound unto the CITY OF EL SEGUNDO ( "CITY ") in the sum of THIRTY -ONE THOUSAND, SIXTY -FIVE DOLLARS ($31,065), which is a minimum one hundred percent (100 %) of the contract amount, lawful money of the United States, which may be increased or decreased by a rider hereto executed in the same manner as this bond, for the payment of which sum PRINCIPAL and SURETY bind themselves, their successors, and assigns, jointly and severally, by this instrument. PRINCIPAL or SURETY will apply this bond for the faithful performance of any and all of the conditions and stipulations set forth in this bond, SPECIFICATIONS NO. PW 14 -17: PARK VISTA SENIOR HOUSING SLIDING DOORS/DECK IMPROVEMENTS, and the public works contract executed with such Specifications. In the case of any default in the performance of the conditions and stipulations of this undertaking, it is agreed that PRINCIPAL or SURETY will apply the bond or any portion thereof, to the satisfaction of any damages, reclamation, assessments, penalties, or deficiencies arising by reason of such default. BOND CONDITIONS 1. PRINCIPAL will construct the public improvements identified in SPECIFICATIONS NO. PW 14 -17: PARK VISTA SENIOR HOUSING SLIDING DOORS/DECK IMPROVEMENTS, a copy of which is on file with CITY's Engineering Division ( "Public Project "). Such performance will be in accordance with CITY's plans and profiles which are made a part of this bond. 2. PRINCIPAL's work on the Public Project will be done in accordance with CITY's plans and specifications and with any permit issued by CITY. Should PRINCIPAL fail to complete all required work within the time allowed, CITY may, at its sole discretion, cause all required work to be done and the parties executing the bond will be firmly bound for the payment of all necessary costs therefor. 3. PRINCIPAL will guarantee its work against any defective work, labor, or materials on the Public Project for a period of one (1) year following the Public Project's completion and acceptance by CITY. 4. This bond is conditioned upon and guarantees due compliance with all applicable law including, without limitation, the El Segundo Municipal Code ( "ESMC "). 5. SURETY, for value received, agrees that no changes, extensions of time, alteration or modification of SPECIFICATIONS NO. PW 14 -17: PARK VISTA SENIOR HOUSING SLIDING Agreement No. 4987 DOORS/DECK IMPROVEMENTS or of the obligation to be performed will in any way affect its obligation on this bond, and it waives notice of any such change, extension of time, alteration or modification of the contract documents or of the obligation to be performed. 6. This bond consists of this instrument; the plans and specifications identified above; and the following two (2) attached exhibits all of which are incorporated herein by reference: A. A certified copy of the appointment, power of attorney, bylaws or other instrument entitling or authorizing the persons executing this bond to do so; B. A certificate issued by the county clerk for the county in which SURETY's representative is located conforming with California Code of Civil Procedure § 995.640 and stating that SURETY's certificate of authority has not been surrendered, revoked, cancelled, annulled, or suspended, or in the event that it has, that renewed authority has been granted; and 7. Should PRINCIPAL perform its obligations within the time allowed, PRINCIPAL's obligation will be void upon the acceptance of the performance by CITY; otherwise this obligation will remain in full force and effect. SIGNED AND SEALED this t9el _ day of January , 2tl ,. (L PRINCIPAL'S PRESIDENT SI Rf,V, ' "'s ATTORNEY -IN -FACT Aksel Firat PRINCIPAL's MAILNN( ,A -WH SS: SURETY's MAILING ADDRESS: 12101 Van Nuvs Blvd_ IJnit 34 62 Manle Avery e _, Svlmar. CA 91342 Keene. NH 4'11 NOTE: (1) ALL signatures must be acknowledged by a notary public. Return two (2) originals to City Clerk's Office. (2) Bond shall be effective for one (1) year after acceptance of the job. Agreement No. 4987 LABOR AND MATERIALS BOND Bond No. 609004854 Bond Fee: $931.95 James McNary, dba Bino Construction, as principal ( "PRINCIPAL ") and Ohio Casualty Insurance Company, a corporation incorporated under the laws of the State of New Hampshire and licensed by the State of California to execute bonds and undertakings as sole surety, as surety ( "SURETY "), are held and firmly bound unto the CITY OF EL SEGUNDO ( "CITY ") in the sum of THIRTY -ONE THOUSAND, SIXTY -FIVE DOLLARS ($31,065), lawful money of the United States, which may be increased or decreased by a rider hereto executed in the same manner as this bond, for the payment of which sum PRINCIPAL and SURETY bind themselves, their successors, and assigns, jointly and severally, by this instrument. This bond is conditioned upon and guarantees payment by PRINCIPAL to contractors, subcontractors, and persons renting equipment; payment by PRINCIPAL and all PRINCIPAL'S subcontractors for all materials, provisions, provender, or other supplies, and equipment used in, upon, for or about the performance of the work contemplated in SPECIFICATIONS NO. PW 14 -17: PARK VISTA SENIOR HOUSING SLIDING DOORS/DECK IMPROVEMENTS ( "Public Project "), the public works contract executed for such Public Project, and for all work or labor of any kind performed for the Public Project. In the case of any default in the performance of the conditions and stipulations of this undertaking, it is agreed that PRINCIPAL or SURETY will apply the bond or any portion thereof, to the satisfaction of any damages, reclamation, assessments, penalties, or deficiencies arising by reason of such default. BOND CONDITIONS 1. PRINCIPAL will construct the public improvements identified in SPECIFICATIONS NO. PW 14 -17: PARK VISTA SENIOR HOUSING SLIDING DOORS /DECK IMPROVEMENTS, and the public works contract executed for such Specifications, copies of which is on file with CITY's Engineering Division ( "Public Project "). Such performance will be in accordance with CITY's plans and profiles which are made a part of this bond when said plans and profiles are approved by the City Council and filed with CITY's Engineering Division. 2. PRINCIPAL will pay all contractors, subcontractors, and persons renting equipment. 3. PRINCIPAL will pay for all materials and other supplies, for equipment used in, on, for or about the performance of the Public Project, and will pay for all work and labor thereon. 4. This bond is conditioned upon and guarantees due compliance with all applicable law including, without limitation, the El Segundo Municipal Code ( "ESMC "). 5. SURETY, for value received, agrees that no changes, extensions of time, alteration or modification of SPECIFICATIONS NO. PW 14 -17: PARK VISTA SENIOR HOUSING SLIDING DOORS /DECK IMPROVEMENTS, or of the obligation to be performed will in any way affect its obligation on this bond, and it waives notice of any such change, extension of time, alteration or modification of the contract documents or of the obligation to be performed. Agreement No. 4987 6. This bond consists of this instrument; the plans and specifications identified above; and the following TWO (2) attached exhibits all of which are incorporated herein by reference: A. A certified copy of the appointment, power of attorney, bylaws or other instrument entitling or authorizing the persons executing this bond to do so; and B. A certificate issued by the county clerk for the county in which SURETY's representative is located conforming with California Code of Civil Procedure § 995.640 and stating that SURETY'S certificate of authority has not been surrendered, revoked, cancelled, annulled, or suspended, or in the event that it has, that renewed authority has been granted. 7. Should PRINCIPAL perform its obligations within the time allowed, PRINCIPAL's obligation will be void upon the acceptance of the performance by CITY; otherwise this obligation will remain in full force and effect. ��mm� SIGNED AND SEALED this ,day of —°1 2 ' 1 �� r � 016 � T NC1P ' L s PRESIDE 46JRE fVs Attoniey -In -Fact Aksei 1 it t PRINCIPAL's MAILING ADDRESS: SURETY's MAILING ADDRESS: 12101 Van Nuys 11vd_ Unit 34 62 Maple Avenue rr1q cA 91342 Keene, NH 03431 NOTE: (1) ALL signatures must be acknowledged by a notary public. Return two (2) originals to City Clerk's Office. (2) Bond shall be effective for one (1) year after acceptance of the job. Agreement No. 4987 F ) On this day of in the year , I I kti " ss. tore me, ublic State of du] commissioned and sworn personally appeared col�rlTY of ���� � y basis of satisfactory vidence to be ' p y pp red _ -.• . ,„ „ , „m „personally known to me (or proved to me on the ry } the person(s) whose name is /are �iii3"sC�rila�„ip the within instrument, and aclmowledged to me that he /she/they executed the same in his /her /their authorized capacity(ies), and that by it@h /the v. ' nature() on the instrument the person(s), or the entity upon behalf of ►vhich the person(s) acted, executed the instrument. WITNESS my hand and official seal. �m1 ° AT`11 „ A( ” ��; "',�� �,N (sea]) Notary Public, State of_ My commission expires STATE OF ) On this day of in the year ss. before me, a COUNTY OF 1 Notary Public, State of , duly commissioned and worn, personally appeared , personally known to me (or proved to me on the basis of satisfactory evidence) to be the person(s) whose name is/are subscribed to the within instrument, and acknowledged to me that he/she/they executed the same in his /her /their authorized capacity(ies), and that by his /her /their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. WITNESS my hand and official seal, (Seal) Notary Public, State of My commission expires ,.__ STATE OF .. On this day of in the year , ss, before me, a COUNTY OF ) Notary , duly commissioned and swom, basis of satisfactory evidence) to be the person(s) whose name is/are subscribed w personally known to me kn proved to me on the Nota Public, State o personally appeared ry p bed to the within instrument, and acknowledged to me that he /she /they executed the same in his /her /their authorized capacity(ies), and that by his /her /their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. WITNESS my hand and official seal, (Seal) Notary Public, State of My commission expires THIS POWER OF ATTORNEY IS NOT VALID UNLESS IT IS PRINTED ON RED BACKGROUND. This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the ft%gt¢'TgyMeR4V.h49$;ated. Certificate No, 7188617 American Fire and Casualty Company Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS: That American Fire & Casualty Company and The Ohio Casualty Insurance Company are corporations duly organized under the laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the "Companies "), pursuant to and by authority herein set forth, does hereby name, constitute and appoint, Aaron West: Aksel Firat; Buck Ford; James Bounds; Jason Ford all of the city of Scottsdale state of Az each individually if there be more than one named, its true and lawful attorney -in -fact to make, execute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and her surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of Iho lof i1paniii in their own proper persons. IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 24th day of November 2015 American Fire and Casualty Company ofa,r�r ,��,ro„1➢ °y �aatrd Aedit� � a� tiP� 0 71 , �, a l� r „���,N� t The Ohio Casualty Insurance Company Liberty Mutual Insurance Company 1906 1912' 1991 r� West rnerlcan Insurance Company David M°. a �... ........ - ....... ... re ” Assistant Secretary STATE OF PENNSYLVANIA ss Y COUNTY OF MONTGOMERY 0 On this 24th day of November 2015 before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of American Fire and y Casualty Company, Liberty Mutual Insurance Company, The Ohio Casualty Insurance Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. > IN WITNESS WHEREOF, I have hereunto subscribed mya and affixed my notarial seal at Plymouth Meeting, Pennsylvania, on the day and year first above written. as a PA COMMONWEALTH IO PENNSYLVANIA Mm 13 4, M x ' Notarial S eal ic N Past allota y Publ B y Tere sa res 1 la, No�tG a...%. r y P / u 4b l�ic 0) Plymouth Tw P. Montgomery County n ' , �. L r. My Commission Expires March 28 2017 vr Member, Pennsylva.. Q nia Assoaation of Notanes ' ny 0' ; This Power of Attorney is made and executed pursuant to all c bW authority of the following By -laws and Authorizations of American Fire and Casualty Company, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows: Ld) ARTICLE IV — OFFICERS — Section 12. Power of Attorney. Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject r to such limitation as the Chairman or the President may prescribe, shall appoint such attorneys -in -fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys -in -fact, subject to the limitations set forth in their respective y powers of attorney, shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed, such instruments shall be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attorney -in -fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority. C ARTICLE XIII — Execution of Contracts — SECTION 5. Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president, 2 and subject to such limitations as the chairman or the president may prescribe, shall appoint such attorneys -in -fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys -in -fact subject to the limitations set forth in their v respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation — The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such attorneys -in- fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Authorization — By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds, shall be valid and binding upon the Company with the same force and effect as though manually affixed. I, Gregory W. Davenport, the undersigned, Assistant Secretary, of American Fire and Casualty Company, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 2-Tta day of e r a 20�_ i1rx 906 .tr u uaidlydod" 111 � ';r�wr woru i�w' r a r e r M+ By: R r Gregory W. Davenport, Assistant Secretary 118 of 200 LMS 12873,,,,122013 'Agreement No. 4987 CALIFORNIA ALL- PURPOSE ACKNOWLEDGMENT CIVIL CODE §1189 A notary public or other officer completing this certificate verifies only the identity of tjre individual who sign tlw�e document to which this . certificate i,-, attached, and not the truthfulness, accuracy, or validity of that document. State of California County Of On d....__, before me, _1 Date personally appeared 2/1 —c Here Insert Name and Title of the Officer, of Signer o,)- who proved to me on the basis of satisfactory evidence to be the person(4--whose name(s) is/are ,subscribed to the within instrument and acknowledged to me that hels[leAfTey executed the same in his/her/their authorized capacity(ies)-pand that ley ljjsfiwy theif signature(s)-on the instrument the penson(s), or the entity upon behalf of which the person(s)acted, executed the instrument. Place Notary Seal Above OP770MAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this.form to an unintended document. Description of Attached Do a e t Title or T�pe of D nument* r LL—' document V :)o� 2----- it D-ate* Number of Pages: 3_ Sign h er Than Named Above; . C.6paedyl(ies) Claint4'byrSigner(s) ❑ Corporate -M ❑ Partner — ❑ ❑ Individual ❑ Trustee ❑ Other. Signerls — Title(s): O.Attomey i !0 ❑ GuamW or Signers 19�eorate Officer — Title(s): ❑ Partner — 0 Limited ❑ General ❑ Individual ❑ Attorney in -Fact ❑ Trustee ❑ Guardian or Conservator Signer Is 02014 National Notary Association • vLww.NationaINotary.orq • 1-800-US NOTARY (1-800-876-6827) ltem#5'907 CALIFORNIA ALL - PURPOSE ACKMOWLEDGMEMT I Agreement No. 4987 CIVIL CODE & 1180 A notary Public, Of other officer completing this certificate vorifies only the idenflly of the individual Who Signed the document to wjjjGfj this certificate is attached, and not tho tTV111fUlness, accuracy, or validity, of that document. State of Cali onnia On 3/ (,1, 'before me, Date personally appeared /,o Here Insert Name and Title of the Officer. of who proved to me on the basis of satisfactory evidence to be tho,persorl 8) whose names) is/air subscribed to the within instrument and acknowledged to me that I1e/sfT6rMFY executed the same in hisftr/tfietrauthorized capacity(je*, And that lay hisAterftairsignature(s) on the instrument theperson(sy, or the entity upon behalf of which the person(s) acted, executed the instrument. DANIEL KIRK BAKER ACCommission 0 2131693 Notary Public - California z Los Angeles County MY Comm Nves Oct 25, 2019 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official eal. 21, Signature /11v'l Signature of Notaiy Public Place Notary Seal Above OP HONo� • Though this section is optionat completing this information can deter alteration of the document or fraudulent reattachment of this .form to an unintended document. Description of Attached Docum nt Title or T of Document: Dociumen Date: Number of Pages: c. Signer(d) Other Than Named Above: , Q*W�qfty(ies) CIa1W "by,:8i' gner(q) Signers-Naf; ❑ Corporate ❑ Partner — 0 Individual ❑ Trustee ❑ Other. Signerls Ref ❑ Limited 0 G&Rdral- O.Attomey in Fact El Guardian or jGbf Signer's Name: ❑ Corporate Q .0- PaKI-ler - 0 timited ❑ General Individual ❑ Attorney in-Fact Guardian or Conservator 0 Other - Signer Is Representing: ,_ yrt 02014 National Notary Association - "mw.NationalNotary.org - 1-800-US NOTARY (1-800-876-6827) Itern#5'907 Agreement No. 4987 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 �"s�m.w`�r�'x �. mh iu�. ri' �Ci�✓ a$.✓•w �; L3" b�' a�w". rcR��>�A�.k£,h�M'�t",A�a����.�W 'i�i.',e�'"-'lT. 'SaA„�:+" e��hi''.�.".a's' r"ib �.�%.+� "5ei'�WU�'X�.�. �:1��".�.'d'�"'u% ,A'��v�:ti.. r A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California / ) County of _...,5 A� a�/P3 _ ) On ('221-01.201k before me, Date personally appeared Erick Sanchez De La Fuente, Notary Public Here Insert Name and Title of the Officer of Signer(s) who proved to me on the basis of satisfactory evidence to be the . personto whose nameK is /4(°e subscribed to the within instrument and acknowledged to me that he/sWA4bAy executed the same in his/I eW-authori ed capacity(i , and that by his/ signature(A on the instrument the person, or the entity upon; behalf of whine person acted, executed the instrument. RICK SANCHE DE Ldp IUL t commissio 0 2062584 Notary Put* - Codo(nia Los ArigWes Coonity ; n �omm, Expires far 28,20 t certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my Signature „"” official Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this f r to a unintended docu ent. Description of Attached Document � C— e aq a—c�` Title of Pages: IS meat, Signer(s) Other Than Named AV ate: l 2-Oq- YP _ 7 .._�.........._........_ Document D Capacity(ies) Claimed by Signer(s) Signer's Name: Corporate fficer�" ( ❑ Partner — ❑ Limited ❑ General al ❑ Individual ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: �_............ Signer Is Representing: Signer's Name: ❑ Corporate Officer LLPartner — ❑ Limite d El IndividT El Trustee ❑ Other: Signer Is X Title(s): ❑ General ttorney in Fact Z r Conservator Representing: 02014 National Notary Association • www.NationalNotary.org • 1- 800 -US NOTARY (1- 800 - 876 -6827) Item #5907 Agreement No. 4987 FAITHFUL PERFORMANCE BOND Bond No. 609004854 Bond Fee: $931.95 James McNary, dba Bino Construction, as principal ( "PRINCIPAL ") and Ohio Casualty Insurance Company, a corporation incorporated under the laws of the State of New Hampshire and licensed by the State of California to execute bonds and undertakings as sole surety, as surety ( "SURETY "), are held and firmly bound unto the CITY OF EL SEGUNDO ( "CITY ") in the sum of THIRTY -ONE THOUSAND, SIXTY -FIVE DOLLARS ($31,065), which is a minimum one hundred percent (100 %) of the contract amount, lawful money of the United States, which may be increased or decreased by a rider hereto executed in the same manner as this bond, for the payment of which sum PRINCIPAL and SURETY bind themselves, their successors, and assigns, jointly and severally, by this instrument. PRINCIPAL or SURETY will apply this bond for the faithful performance of any and all of the conditions and stipulations set forth in this bond, SPECIFICATIONS NO. PW 14 -17: PARK VISTA SENIOR HOUSING SLIDING DOORS/DECK IMPROVEMENTS, and the public works contract executed with such Specifications. In the case of any default in the performance of the conditions and stipulations of this undertaking, it is agreed that PRINCIPAL or SURETY will apply the bond or any portion thereof, to the satisfaction of any damages, reclamation, assessments, penalties, or deficiencies arising by reason of such default. BOND CONDITIONS 1. PRINCIPAL will construct the public improvements identified in SPECIFICATIONS NO. PW 14 -17: PARK VISTA SENIOR HOUSING SLIDING DOORS/DECK IMPROVEMENTS, a copy of which is on file with CITY's Engineering Division ( "Public Project "). Such performance will be in accordance with CITY's plans and profiles which are made a part of this bond. 2. PRINCIPAL's work on the Public Project will be done in accordance with CITY's plans and specifications and with any permit issued by CITY. Should PRINCIPAL fail to complete all required work within the time allowed, CITY may, at its sole discretion, cause all required work to be done and the parties executing the bond will be firmly bound for the payment of all necessary costs therefor. 3. PRINCIPAL will guarantee its work against any defective work, labor, or materials on the Public Project for a period of one (1) year following the Public Project's completion and acceptance by CITY. 4. This bond is conditioned upon and guarantees due compliance with all applicable law including, without limitation, the El Segundo Municipal Code (`SSMC "). 5. SURETY, for value received, agrees that no changes, extensions of time, alteration or modification of SPECIFICATIONS NO. PW 14 -17: PARK VISTA SENIOR HOUSING SLIDING Agreement No. 4987 DOORS /DECK IMPROVEMENTS or of the obligation to be performed will in any way affect its obligation on this bond, and it waives notice of any such change, extension of time, alteration or modification of the contract documents or of the obligation to be performed. 6. This bond consists of this instrument; the plans and specifications identified above; and the following two (2) attached exhibits all of which are incorporated herein by reference: A. A certified copy of the appointment, power of attorney, bylaws or other instrument entitling or authorizing the persons executing this bond to do so; B. A certificate issued by the county clerk for the county in which SURETY'S representative is located conforming with California Code of Civil Procedure § 995.640 and stating that SURETY's certificate of authority has not been surrendered, revoked, cancelled, annulled, or suspended, or in the event that it has, that renewed authority has been granted; and 7. Should PRINCIPAL perform its obligations within the time allowed, PRINCIPAL's obligation will be void upon the acceptance of the performance by CITY; otherwise this obligation will remain in full force and effect. SIGNED AND SEALED this day of � � �' ..r 20 ,, = w ......�.� DRESS: SURETY's MAILING ADDRESS: AL's 'PRESll:�'1�NT ,r..m PRINCIPAL's MAILING AD S11'REaTY" AI''i1N": -FACT Akse Firat 12101 Van Nuvs Blvd. Unit m 4 62 Maple Aventh Svinnar CA, 91.342 _ Keene.,...M14 (1 All NOTE: (1) ALL signatures must be acknowledged by a notary public. Return two (2) originals to City Clerk's Office. (2) Bond shall be effective for one (1) year after acceptance of the job. Agreement No. 4987 Cerfficate Pursuant to w Civil � xtIl , ire r �t for Y Of Ind California A ti �r at o a C"Oi9°hT'1i`Nf i4t lc' x M1�6 Etl 4b $48k�sw$ V- 'OYJ� +" .,t. °� d VCf i x 011 l w 4t4,a�a� +;.h1 axeq,44,�; � 1,41fx��r, I $ �a ti p r lily rti rl wr the � i. C CLERK Agreement No. 4987 LABOR AND MATERIALS BOND Bond No. 609004854 Bond Fee: $931.95 James McNary, dba Bino Construction, as principal ( "PRINCIPAL ") and Ohio Casualty Insurance Company, a corporation incorporated under the laws of the State of New Hampshire and licensed by the State of California to execute bonds and undertakings as sole surety, as surety ( "SURETY "), are held and firmly bound unto the CITY OF EL SEGUNDO ( "CITY ") in the sum of THIRTY -ONE THOUSAND, SIXTY -FIVE DOLLARS ($31,065), lawful money of the United States, which may be increased or decreased by a rider hereto executed in the same manner as this bond, for the payment of which sum PRINCIPAL and SURETY bind themselves, their successors, and assigns, jointly and severally, by this instrument. This bond is conditioned upon and guarantees payment by PRINCIPAL to contractors, subcontractors, and persons renting equipment; payment by PRINCIPAL and all PRINCIPAL'S subcontractors for all materials, provisions, provender, or other supplies, and equipment used in, upon, for or about the performance of the work contemplated in SPECIFICATIONS NO. PW 14 -17: PARK VISTA SENIOR HOUSING SLIDING DOORS/DECK IMPROVEMENTS ( "Public Project "), the public works contract executed for such Public Project, and for all work or labor of any kind performed for the Public Project. In the case of any default in the performance of the conditions and stipulations of this undertaking, it is agreed that PRINCIPAL or SURETY will apply the bond or any portion thereof, to the satisfaction of any damages, reclamation, assessments, penalties, or deficiencies arising by reason of such default. BOND CONDITIONS 1. PRINCIPAL will construct the public improvements identified in SPECIFICATIONS NO. PW 14 -17: PARK VISTA SENIOR HOUSING SLIDING DOORS /DECK IMPROVEMENTS, and the public works contract executed for such Specifications, copies of which is on file with CITY's Engineering Division ( "Public Project "). Such performance will be in accordance with CITY's plans and profiles which are made a part of this bond when said plans and profiles are approved by the City Council and filed with CITY's Engineering Division. 2. PRINCIPAL will pay all contractors, subcontractors, and persons renting equipment. 3. PRINCIPAL will pay for all materials and other supplies, for equipment used in, on, for or about the performance of the Public Project, and will pay for all work and labor thereon. 4. This bond is conditioned upon and guarantees due compliance with all applicable law including, without limitation, the El Segundo Municipal Code (`SSMC "). 5. SURETY, for value received, agrees that no changes, extensions of time, alteration or modification of SPECIFICATIONS NO. PW 14 -17: PARK VISTA SENIOR HOUSING SLIDING DOORS /DECK IMPROVEMENTS, or of the obligation to be performed will in any way affect its obligation on this bond, and it waives notice of any such change, extension of time, alteration or modification of the contract documents or of the obligation to be performed. Agreement No. 4987 6. This bond consists of this instrument; the plans and specifications identified above; and the following TWO (2) attached exhibits all of which are incorporated herein by reference: A. A certified copy of the appointment, power of attorney, bylaws or other instrument entitling or authorizing the persons executing this bond to do so; and B. A certificate issued by the county clerk for the county in which SURETY's representative is located conforming with California Code of Civil Procedure § 995.640 and stating that SURETY'S certificate of authority has not been surrendered, revoked, cancelled, annulled, or suspended, or in the event that it has, that renewed authority has been granted. 7. Should PRINCIPAL perform its obligations within the time allowed, PRINCIPAL's obligation will be void upon the acceptance of the performance by CITY; otherwise this obligation will remain in full force and effect. * 4— SIGNED AND SEALED this day of -iing= 2016. 1 l�l CIPAL's PRESID NT Ss 1 s A Co�Hr� y 0r -1 � - -4 Aksel Fira PRINCIPAL's MAILING ADDRESS: SURETY's MAILING ADDRESS: 12101 van Nuys Blvd. Unit 34 62 Maple Avenue Svlmar. CA 91342 Keene. NH 03431 ���� - NOTE: (1) ALL signatures must be acknowledged by a notary public. Return two (2) originals to City Clerk's Office. (2) Bond shall be effective for one (1) year after acceptance of the job. Agreement No. 4987 Certificate t to 995.640(a) 1 1 MAN C, l � , County Clerk of the County of — l`r. �": •� Mate of California, in and for said County DO HEREBY C,ERITIF - "� THXT flg��t u L MP by the C 'Iifornia Insuranco, Goo igll tt a 9" �.�� aG W u "�i.:auTe,,,y insurance In the r�k,�, a a��flr° jryz{.�° CiB�IarUT20ntOf s 6it); Oct, iUirrtd�'(d, i�rBOYe�(, canceled, annufieo, or susPe"Qea in 'j;estimolly I 'imie f, I have hereunto sat my hand and a cted the Seal of I R 1 Z� .»��— said County on �.•�� 6 C 4"4- COUNTY CLERK �.'","���.�,�. Deputy County Clerk Agreement No. 4987 STATE OF Arizona ) On this day of fall uAry, in the yeaar ss, before me„ Megan Runde a COUNTY OF Maricopa ) 'rotary Public, State of Arizona duly commissioned and sworn, . personally appeared Aksel Firat: , personally known to me (or proved to me on the basis of satisfactory evidence) to be the person(s) whose name is /are subscribed to the within instrument, and acknowledged to me that he/she/they executed the same in his /her /their authorized capacity(ies), and that by his /her /their_s ngtura:( n a" i 'tr ment the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. WITNESS my hand and official seal. Notary Public Slate of Arizona My commission expires 6L2.QZ1017 STATE OF s9. COUNTY OF . personally appeared basis of satisfactory evidence) to he /she/they executed the same in or the entity upon behalf of which be the On this day of before me, Notary Public, whose name is /an the person(s) acted, WITNESS my hand and official seal. Notary Public, State of My commission expires in the year (Seal) State of duly commissioned and swam, , personally known to me (or proved to me on the subscribed to the within instrument, and acknowledged to me that and that by his /her /their signature(s) on the instrument the person(s), (Seal) STATE OF On this day of in the year ) ss. before me, a COUNTY OF Notary Public, State of , duly commissioned and swam, personally appeared , personally known to me (or proved to me on the basis of satisfactory evidence) to be the person(s) whose name Were subscribed to the within instrument, and acknowledged to me that he/she /they executed the same in his /her /their authorized capacity(ies), and that by his /her /their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. WITNESS my hand and official seal. Notary Public, State of My commission expires STATE OF On this day of ss. before me, COUNTY OF ) Notary Public, State of w_. personally appeared basis of satisfactory evidence) to be the person(s) whose name is/are subscribed to the (Seal) in the year , —, duly commissioned and sworn, personally known to me (or proved to me on the vithin instrument, and acknowledged to me that he /shelthey executed the same in his /her /their authorized capacity(ics), and that by his/her /their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. WITNESS my hand and official seal. (Seal) Notary Public, State of My commission expires THIS POWER OF ATTORNEY IS NOT VALID UNLESS IT IS PRINTED ON RED BACKGROUND. This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in theAglmemtlia Dt Met 4@6ilated. Certificate No. 7188616 American Fire and Casualty Company Liberty Mutual Insurance Company The Ohio Casualty Insurance Company WestAmerican Insurance Company POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS: That American Fire & Casualty Company and The Ohio Casualty Insurance Company are corporations duly organized under the laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the "Companies "), pursuant to and by authority herein set forth, does hereby name, constitute and appoint, Aaron West: Aksel Firat: Buck Ford; James Bounds; Jason Ford all of the city of Scottsdale state of AZ each individually if there be more than one named, its true and lawful attorney -in -fact to make, execute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 24th day of November 2015 American Fire and Casualty Company q ^lxtsg n'GY11$ r� A „q�hptp �` ��� �n The Ohio Casualty Insurance Company 1906 1919 1991 191 2 a „ Liberty Mutual Insurance Company West merjoan Insurance Company David M. Car "Assistant Secretary � STATE OF PENNSYLVANIA ss ey” COUNTY OF MONTGOMERY On this 24th day of 1e November 2015 before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of American Fire and y Casualty Company, Liberty Mutual Insurance Company, The Ohio Casualty Insurance Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. IN WITNESS WHEREOF, I have hereunto subscribed ni name and affixed my notarial seal at Plymouth Meeting, Pennsylvania, on the day and year first above written. ?pw I P COMMONWEALTH OF PENNSYLVANIA { tmraua�w,t '' Notarial Seal 'N ea Teresa Pastella, Notary Public By: i q`rq° Plymouth Twp., Montgomery County Teresa Pastella, Notary Public L My Commission Expires March 28, 2017 p Cb k1 Member, Pennsylvania Association or Notaries YA1, t t5 . i This Power ofAttorney is made and executed pursuant to an y authority of the following By -laws and Authorizations ofAmerican Fire and Casualty Company, The Ohio Casualty Insurance N Company, Liberty Mutual Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows: s ARTICLE IV— OFFICERS —Section 12. Power of Attorney. Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject 6. r to such limitation as the Chairman or the President may prescribe, shall appoint such attomeys -in -fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, C acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys -in -fact, subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so 5 executed, such instruments shall be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attorney -in -fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority. ARTICLE XIII — Execution of Contracts — SECTION 5. Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, shall appoint such attomeys -in -fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys -in -fact subject to the limitations set forth in their • respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation — The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such attorneys -in- fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Authorization — By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds, shall be valid and binding upon the Company with the same force and effect as though manually affixed. I, Gregory W. Davenport, the undersigned, Assistant Secretary, ofAmerican Fire and Casualty Company, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attomey of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this , �"'"" 4 i nra rx� o �rx idrr """" arr irp 1906 1919 1912 1991 µ u rr s a r .. LMS, -12873,_122013 2 9 tA-day of, a,,? t4 ar ,20 /(,_ By: Gregory W', Davenport, Assistant Secretary 119 of 200 Agreement No. 4987 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this celifficate verifies only the identity of file individual Who signed the document to which this certificate is attached, and not the truffifulnesSy, a(XUracy, or` validity of that document, State of California ,County of 6,, /I On before me A ,2( . .... Date A A Here Insert Name andTit/P of f'hn _n(t6^,Y personally appeared M of Signerfs) who proved to me on the basis Of satisfactory evidence to be tho,person(e) whose name(s) is/are , subscribed to the within instniment and acknowledged to' me that he/shcAhey executed the same in hishier/theirauthorized capacity(jes) and that by his/her/thetrsignature(syon the instrument the person( s); or the entity upon behalf of which the person(s)-acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of Califomia that the foregoing paragraph is true and correct. C, DANIEL'KIRK BAKER WETNESS I d and official seal. I 'alj Corhmission # 21-31693 Notary Public - California z Los Angeles County Signature My Comm Expires Oct 25, 2019 Signature of Notary public Place Notary Seal Above 7 OP7701VAL Though this section is optionat completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Dour U ent Title or Type of Document, Z2 Document Date.- �_'/ Number of Pages: _ _-2— Si Signe*) Other Than Above CIa1nf&by,Sig'ner(s) Signer's Name: Signer's Name: ❑ Corporate Officer —Title( El Partner — ['Lim ❑ Individual El ❑ Attomey in Fact ❑ Trustee E ❑ Guardian or Conservator ❑ Other. Signer Is Representing: Signer Is 02014 National Notary "Association, • %&ww.NationalNotary.orq • 1-800-US NOTARY (1-800-876-6827) Item #5907 Agreement No. 4987 CALIFORNIA ALL- PU13POSE ACKNOWLEDGMENT CIVIL CODE § 1159 notary public or other officer completing this certificate verifies only the identity of the individual who sign(�d the document to which this. certificate is attached,, and not the truttaldness, accuracy, or validity of that doeurrient, ) Co of On oCairforni a On before me, .. . L �,,.. Officer,' Date b Here Insert Name and Title of the O� . _ F° °� . -� � personally appeared " ° of who proved to me on the basis of Sa isfactory evidence to be the, person( °, wflose names) is/ar ., subscribed to the within instrument arid acknowledged to me that 11e1"shrt executed the same in hisff.erfthel"uthori ed capacity(im), and that by his/f-rerfthelrsignatur+ (s) on the instrument the person(s), or the entity upon behalf of which the person,( acted, executed the instrument.. DANIEL KIRK BAKER Commission #r 2.31693 Notary Public • California z Los Angeles County r My Comm Fwnires Oct 25, 2019 I certify under PENALTY OF PERJURY under the laws of the State of Califomia that the foregoing paragraph is true and correct. WITNESS my hand and official seat» Si nature';a Signature of Notary Public Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this.form to an unintended document. Description of /Attached Do u t �° l Title or T of I YPe �urrl nt .:. ,, ,� �. lr ,✓r "� I ocunie,mt Date. Number of Pages: Slgnels) Other Than .Named Above. , / Cap ity(ies ) Clairtit "by, Signers) 0 Cotporate +ff ❑ Partner — O ❑ Individual ❑ Trustee ❑ Other_ Signer.ls Repre n:ttbd- ,Q General ❑ e Attom InW ec ❑ Guardian or Cc Signer's Name: ❑ Corporate Oi ❑ Partnor —r- ❑ Trustee Signer f -tfted O General ❑ Attorney in -Fact ❑ Guardian or Conservator 02014 National Notary Association • Knww.NationalNota or 1 -800 -USN NOTARY 1- 800 - 876 -- 6827) n'• 9 ' ( 7) Item #5907 Agreement No. 4987 EXHIBIT IT A SCOPE OF %W)RK FOR dp;rlltK VISTA SICa:NKMt MOUSING ,SUIIA?Q;r DOtDdtS(DECK IMPROVEMENTS PVV 10 17 Ile C'onrtratcku. Mno C'ourst.rtuctiorL An dl pro %We aadll m ateri do labor mid equipment to tntodiry Me e.xi.sting slidi g door r cruWr %%ays and Be Wine holds at the sl°odkg doors hmide p)ur N 2N. and 221 . The 8hree units am locaated sat Pak Vkfa Sa rdw Housing UmqAn tdae dap j E. HoII� Avenue in the C ky of f=l Segy unacllo. CA 9tt245f d�uaapwt, =taspac c'i Cq�' tie cvpoc. Cis ar uaal t_'a�la tll "n.ae[iora f.0.udtaaa %%mi to be pc rd'arrunwd in e=h crp °Bhw three° units per dm win,',,' and b; getaeraad cQarl5inv tiota IlarawN'ms where draalt inns are non- descropted. Move aura contents ,as needed. Renim e existing shdbig a lass door drotaa opening. prepare I "raarning, and e.xterior,ttocco as needed Ar u°eiva,taulWioua on w" dour. nmv Ilaa,hings. and %%eaodierprootarasa, prov ide ao ood and Ilraardwar"e to ruccu strtuct the I°rattaaed opening as needed to a accotararaodate as raaisk door iiastaadlaatiorr. Coaastrtrct a raked base at door threshold as part ol°the pd•aunh * recoastrtwdoa as needed, lhv% ide and ins all perimeter dom anwd threshold base stain I'da.snhys. Inastaall one aleN% sliding glass a.dmw (provided he the ciar (It'll: 5� ��taaa�drap. Patch iurterior door peg °prtaetca dry "all ton totuch up prince and pa¢ivat tau notch c%istialg as cloNe .as paossibIc. Apo) 60 dfas. base paper„ scratch„ prRnvn. and knish titt cco texaw s to uaaaatcala existing tc°mture as cdosc as possible„ f °reach up prime the area% saucer paatched anrea. Apply Sikat I A joint se;.d r aat door parhneier; tea include threshold base. Apply Imo cmats of Dunn Edwards eatcrior,ttucc:aa loam to match existing color as close as possible. c C:'lmn up and lisp rse orwris. Interior Reconstruction ftaterior reconstrvedor ivpaahs that are unrehied to the door instaaldatioro will be billed hourly at as rate od "Sd: 51iour. as as maxi nunar aarron, t or4 hoes per rnnT C°orttraactor`s Lump Sturn hied plus the aadditA aal p , hours at S 45 hoar liar is wHor a °cco s rta.c6oat shall pro\ ide ¢err aapl ttaattc ri0.als. ealaripnae nL toodS.. labor. and incidentals required to entirely coaapjete the prgjec,t to the C ki "s saatisl actiona.. V aadditimml Mum my aaee&cd pier the ivaterio° reconsw ucdon, Contractor shall request City aapprovnI for aarsti� work be\ond the Brest lour hours pay;r unit. \i'ork. is to be per brnaed by personnel with the proper cent Pcaticrras for the eotastruuc:tion. "'o"k .sh Il omur our Monday thrmyl Tla.u.uaes&y bean een the horn, of S mn mW 4 praa and "~01 Be resadenN mW Puk VWaa Senior i octsaaajs aapprovaa! and comdinmioa in aadNunce for Agreement No. 4987 eonstrtuettapn areccs%" Rcppak-'rclikice any City 1proproeay epaaarraa gd dwhg le prUMct h CIV .�aaairehctkn. - Adhere to req uirernents of ch; agreemerm Pre%aailNg"ages we rrMAicsuNe and AaH be, inckidecl in the bkk Uherc tap SH X54 requh- enwtrt,s as necc.ss'ary. hillornmaution is a%a.akaahk at Wmltpp % }.%t%w aht,a'au,r�aY% pprrlplu �w,sarp, �I'n� °t,6.lalutml HWs o%er 525A M0 rwraptu N a Pa 111 n"ancc Bond and Labor aund ,Maakrials Bond trlllona aawird, BWs ova SH.t)N :,UwN also he aacw:awnpma Ad by as ltb% BW And up wi 1pia.l subrnittatl. C..lwntraaetwpr : ahaalll ppraWiw C pproot°awp`reaptairCd in;aura.nee Cndrwr.;crvaent ancll 4rousinesw license up>awua m%arrd. Cowraactawr shall obtain a 1%,'o-Av ll3rnolwpQ Permit ar W au No-doe II'aubhc \ \r'orks Encroa all -inl.m lOrnmit prior to beginning a.onstrarcYion. linslpectiwpns hor lwernrits shdH be called in pa Ow Planing p_3tniVa% Salty DeNurtrmment r• eapuirenmcnts. Antrarctm shall ppram% We C ly wall" Y leas, Ar.-tl -epght (0) hours to arnh" cr Requests lot, Ilrmtwsu attautiapum Or change order' recpareMts. C:°oratractur shr. H nett pmwecd "kh my constmetion pier %%hie h a air.ua c order request has p. mn rrmdc auWH a L'ha:rrTe OtAcr° Agreement tit has been comp 4ted, G=ive percent aprow Wd aarnouumt %%ill be rettainal tuntii A punch list itenm arc conmpp uad on the pprcpgect ar.nd all ppc rnaitS are Sierrucci Off. Per the C:ly :"%ttaprwjs OPice. the �bpkm inn, St,aNnICratS are stricken Vi °%pine the a;oua incaat section o l3irmo C on,Mtrtaw:tiwp& ovs, ostirnaate aerial NOT included, in the project sco pc - Absent µwars. ne'aNuence Or %%�iphbl misc:oaae..luet. the maximum aarnou�nt for which G3ino C.`a:rn��atrar.ction cal he Yellen reVoamAhk is liarmh al to the aact.arap coo of die %work pper•Amnicd. CHmet agrees and rarrapa:rsurnds b5 wQrmhg. than; Bino Cl mstrtredon wHl no be respponkible Ar any ants and vwr apaarrr.nr.r.es "hich exceed the % alue of the conmtr »r,c t - '\o acdoia related tap this contrauc:t a;lar.r.11 he co,"mmeed pew Hino C°cwnmstrr.actkm or awwwr a ner w %car~ - To time Vulles, own permi nd by li w dw o%%•mx a,ml their auegems slm,n.wll inderma dN, ppraptca. d0ond and hold IraarrmalesN Biraap Construction fironmm rand aagaainsr ,all cllaaiuror,. daniareees, losses and expenses brought by rosiderm s or guats ;termmmirm<Y Protm work pper l`cwrnmed unda r this ea;OMaW so Ong as IBino Construction is rm,ot audyraa ged negl.igeni Gp% a court a rconjiment visa. Rdon,. or the o%% nor or propeny nwnaager° has ppre%ioudy aapppprowed the completion ulAvork in aaccordr.ance %wath the Contract alocunmews Wachnments: limo C,'un:suruction Cost Estitrtate bhe Conn-actor's inirials bclo%% sip;rmi, trMIC1333rtdinQ o arrad aa-reet ient with dle pu-(pwCet scope conditions as stated aabo\e. t. � .... �. .w c� Cotitraactcwr's init.iaall:s or siw. naWre Date Agreement No. 4987 PROPOSAL Contractor's Name Dty c)f B Segundo B0 FORMS Pak Vnsla Senbr Housing Dra0age Modfficafioins PW 14-17 PAGE 4 OF 9 Agreement No. 4987 The BWder shaH hjrni,,O the �Oh)whnq �nfi�wnia0oin 11:aflure to conWWW dWms mH mmo Um BW W bip non req;wAve anS may cause He rqechaiii slipe1% ninaybe aUached as requwed, Nmine and d3fien U khlress� A .I . ... .. 1"a J,1'01�r(1-1w t-,L 44 K 1w,"A41 I CONTRAcraws Whymme mmow, COS) ;k I I L "I Facsimfle Number Enmfl addr&:m; 11 J- 3 COW RAM ORE Ummw PrOwy Qm5kaWn V �j I -3( ctwne . . ...... . 4, Svrna y Conillianyaml Agem who mH prov de the ieMirm! Bonds on I% CoMaU , " V& I I P T" f ,- %,' ,, " �,� \ Named SwWy, V? Al. ,, ',), - ,,, ,,, � ( , , , � L Addess Surety Conl1pany lk0.;4nt eh"JI)II P4w nlb o S Aofeu �t 72 7) Swel L !K 2-4 AS, 1 ype of Fir4r i, P,,411"14e1 sl1l�4 iil ,Cnrpornoor) 6 Coup�zmknn U119@M.'Eid widea the Vaws of k1he of v UM Mo nmms wad whIressews of 1he phwWal Yne"Mefs of Hoe Sm w na"vas mid AMes, of thi, jj rbnc4!m officem of hone corporabon or finiv -A, lot hilly' I 21CIVIN. Th P, . .................... ... . .. ... . .......... . ..... ...... . ....... Chy of El Seginido Paik Visa Son�cj� Hou:!;�nq DaOaqe Uodfficafions RN 1407 ED FORMS FMGE 5 OF 9 Agreement No. 4987 E310DER'S GENERAI �NFOIRUVIAI 1014 (Conth"rued) h4unrlber og years exipchhoma as as cmdracWh in Uss sipw;ific Vype of construcl[iorr wool,,, -2.0 9. Ust a Ilea st ffirce Tvbled pmpos of comparabie sr/e and coirnjp cxRy cumplleted to date owl"ler PAC�� I �V, Ad&um 616 63 7 a, "v c, Ciass of Wad,, IJ Phone A)) 7 armmm , parr (W 1 $1 DOW cwiploWd ISO 4 . .......... . ... Ov,qler J11) i bl A, Adch PSS C'0111tact ObssollWork Plwne Contract avimwit pmol t T1 J. Oak comoWad 010IT110r j Address ConMcl Ciass of wod�, Phone j ("Onilmd mmum Dola carvilbWd I Men (PALK Ill 1(l U v-,,l 11he nanx, and Wh of Te persmi who wM sup"he WkMw aw pqWm& wwk K"nw hm� p'1. Its fullMinie supervisor an einipioyoc, - . Contract sewices N (�a ? 12,. A firranciall s atemervt rrir other iirffoirnafion and mforcinces sufficlicni(Ily coniprellhensave W jpernfin an applrapsalll of Your c'unenl Nnanchl candithn may be mc;kmd by Me Von= 13, Name of thic peirson who inspected Me site of Me pfolposed Wodr for line Wd(k r [)ate pup hla4:recliollll: J- CRy of El Segundc� \JUSt j PW 14-17 BO FORMS PAGE 6 OF 9 Agreement No. 4987 PROPOSAL PARK VISTA SEMOR V QU&ING DRXINAGE MATDINS PROJECT BIDDER'S STATEMEN r OF PAST CONTRACT DiSQUAILVMCATION Please state Wl instainces of being disquafified, removed, ou° otherwise prevented from buddlirng on, or completing, a federal, state, or local government project dune to a wuo &aUorn of a paw or safety re u.ul aUon. 1. u....lave you ewer been disqu Ifified from any goverinirneirit contract? Yes ® No 0, 2, if yes„ ex1,:)l M the ciroumst nce : Are you registered in accordance with Labor Code § 1725.5 [Note- failure to register Irequ res the duty to reject your bbd as Irnonresuaorislve]? Yes No 0 v P budder ncn�rntu uro.,...wn City Park�Vist Senior �"ir�ii�sr ����i�u,r�n Iu °un Mr�d�r�wniioa"Ilr PW n1CIc:. Agreement No. 4987 INSURANCE REQUIREMENTS i w I 10 1,,.)e awarded this contract, the successful bidder r"nust PI'Mire and rnaintain the following tyloes of insurance with coverage hirnits complying, at a minli-nurri, with the limits set forth below: Fype of lnsurance Limits Commercial general! Habihty: $2,000,000 ::.:,jusiness ai.Aornobile liability S1,0W000 Workers compensation Statutory requirement, Commercial general li�ibillty insurance must meet or exceed the requirements of lSO- CGL F::orm No. CG 00 01 11 85 or 88. 'Fl,-ie arnount of insurance set forth above rriust be a coinbined single limit per OCCUrrence for bodily injury, personal injury, and property damage for the policy covemge, t iability policies must be endorsed to narne tl,-ie City, its officials, and en-iployees as -additional insureds'" under said insurance coverage and to state that sucl"i insurance will be deerned "primary" such that any otl,-ier insurance that may be carried by tl',ae City will be excess thereto. SLIcl`-u endorsei nent must be reflected on l F::arrin N(..). CIG 20 10 11 85 or 88, or equivalent. Such insurance ITIUst be on an I°OCCL.Irrence," riot a "claims r-nade," basis and will not be cancelable or, subject to reduction except UpOrl thirty (30) days prior written notice to the City. A,(,atomobile, coverage must be writteri on lSO Business Auto Coverage Form CA 00 01 06 92, incl;.jding syrrilbol I (Any ALItO). I he Consultartt must furnish to the City dWy aUthenticated Cer-16ficates of Insurance evidencing rnaintenance of the il'ISL.Irance required Under. this Agreement, endorsei nents as required herein, and SUch other evidence of insurance or copies of policies as may be reasonably required by the City from time to time. Insurance 119LISt be placed with admitted insurers with a current A.M. Best Company Grating equivalent to at least a Batting of "A:Vll." Certificate(s) must reflect tl"ial: the insurer will provide thirty (30) day notice of any cancellation of coverage. "The Consultant will require, its insurer to modify such certificates to delete any exculpatory wording stating that failure of the irisurer to imail written notice of can(.:. ellation imposes no oli:)llgaflon, and to delete the word 'erideavor" with regard to any notice provisions. By signing this form, the 1:)idder certifies that it ihaas read, uriderstands. and will COMPly with these ii )surance requirements if it is selected as the City's consultant. Failure to provide this insui ance will render the bidder's proposal "nonresponsive." ......... . Date City of D Segundo u�Im k, \hs1 a Seii*jii V Wusii, r(J Drai�naqo, NkAficaMns a: 11,,V 1..a.. 17 . ........ .... .. Bidder . .. PAGE 8 OF 9 Agreement No. 4987 -drop, (AS REQURED BY LABOR CODE § 1860) p arn aware of Labor Code § 3700 wMch requires every emp�oyeir to be insuired against habihty for workers' COMpeinsalion, or' to undertake seff-insurance in accordance with the p,x-ovs� ioins of said C ode, and t MH ('OrT)[)UY WrOl SUch provisuons before commencing the perfoirrnarice of the tZrk of this Contract, Contractor By llll,All(- 21 C i� y or E: I SE:cP � ndo Dminage B0 FORNIS �::IAGE 9 OF 9 Agreement No. 4987 E X ICI 011' 13 Name: Floriza Rivera Company: -..._ Public Works Department City of El Segundo Phone number: 310 524 2361 Fax number: E -mail: friveraAelsegundo.org> cc: No. of pages:mm 4 December 20, 2015 Dear Floriza, Attached, please find an estimate for 615 E. Holly Ave. El Segundo, CA 90245. Upon approval please sign the last estimate approval page and returned the entire document to us by email to james @binoconstruction.com, or fax (323) 935 -5960. Should you have any questions, please call us at (323) 935 -4800 or e-mail me at james @binoconstruction.com, or fax (323) 935 -5960. James McNary Sino Construction 818 231 8563 Page 1 of 4 Agreement No. 4987 E ST1 A "rE December 20, 2015 ESTHO122015 Attn.: Floriza Rivera Project Address: 615 E. Holly Ave. El Segundo, CA 90245 Price Sliding Door Installation -- Recommendations: General Construction Labor - work to be performed per drawing and by general construction practices where drawings are non- descripted. Move area contents as needed. • Remove existing sliding glass door from opening. • Prepare framing and exterior stucco as needed for reinstallation of new door, new flashings, and weatherproofing. • Provide wood and hardware to reconstruct the framed opening as needed to accommodate a raised door installation. • Construct a raised base at door threshold as part of the framing reconstruction as needed. Provide and install perimeter door and threshold base seal flashings, Install one new sliding glass door (provided by the city of El Segundo). Patch interior door perimeter drywall then touch up prime and paint to match existing as close as possible. Apply 60 lbs. base paper, scratch, brown, and finish stucco textures to match existing texture as close as possible. Touch up prime the new stucco patched area. Apply sika I joint sealer at door perimeter; to include threshold base. Price Per Door: Apply two coats of Dunn Edwards exterior stucco paint to match existing color as close as possible. $ 9,855.00 Clean up and dispose of debris. Interior Reconstruction Interior reconstruction repairs that are unrelated to the door Per Hour Price: installation will be billed hourly. $ 125.00 Page 2 of 4 Agreement No. 4987 Notes: * This estimate does not include any new concrete, rail modifications, drop ceiling tiles, wall repairs, or anything unforeseen not listed in the scope of work above. We reserve the right to install all electrical access components in the most efficient and accessible manner available based on our final determination if not drawing is provided and ADA requirements are met. 0 The client understands that any and all estimate fees herein may change if engineering /structural /architectural drawings modify the job scope. e Lead times apply for all material orders. 0 Bino Construction will comply with the following Labor Compliance Requirements on all public projects upon estimate approval: (Prevailing Wage, SB85, SB 854, Labor Code sections 1771.1(a) & 1725.5, Public Works Contractor Registration Program, Electronic Certified Payroll Records to Labor Commissioner, and other requirements described on the direct links provided: http://www.dir.ca.govIPublic-WorbISB854.html. 0 Does not include rekeyinQ services. _ Total Estimate: $ 9,855.00 Page 3 of 4 Agreement No. 4987 Comments: All of the above work to be completed in a substantial and workman like manner according to standard construction practices and codes. Any alteration or deviation from the above specification involving extra cost of material or labor will only be executed upon written orders for the same and will become an extra charge over the sum mentioned above. The cost ofpermits and permit processing is not included. Contractor to be notified if obtaining permits is requested « All agreements must be made in writing. Contractors are required by law to be licensed and regulated by the Contractors State License Board. Any question concerning a contractor may be referred to the registrar of the board, whose address is: CSLB, 3132 Bradshaw Rd. P. O. Box 26000, Sacramento, CA 95826. Right to cancel: You, the buyer, may cancel this transaction at any time prior to midnight of the third business day after the date of this transaction. Proposal is valid for 30 days. Absent gross negligence or willful misconduct, the maximum amount for which Bino Construction can be held responsible is limited to the actual cost of the work performed. Owner agrees and understands by signing, that Bino Construction will not be responsible for any costs and /or damages which exceed the value of the contract. No action related to this contract shall be commenced by Bino Construction or owner after two years. • To the fullest extent permitted by law the owner and their agents shall indemnify, protect, defend and hold harmless Bino Construction from and against all claims, damages, losses and expenses brought by residents or guests stemming from work performed under this estimate so long as BINO Construction is not adjudged negligent by a court of competent jurisdiction, or the owner or property manager has previously approved the completion of work in accordance with the contract documents. • Terms of payment —A 40% down payment is due upon signing. Payment in full is due upon completion. A_finance charge of 2.0% per month applies. for any amount due. cc ept ijcc 1 ^,ST11D 12201 The undersigned hereby authorizes you to furnish all material and labor required to complete the work mentioned in the above proposal. The undersigned agrees to pay the amount stated in said proposal upon presentation of billing. Dated day of Acceptor's Printed Name Acceptor's Signature 2015 Page 4 of 4 Agreement No. 4987 EXHIBIT C CITY OF EL SEGUNDO PUBLIC WORKS DEPARTMENT STANDARD SPECIFICATIONS 0 -0 STANDARD SPECIFICATIONS 0 -1 GENERAL Except as modified by these Standard Specifications, the provisions of the latest edition of the "Standard Specifications for Public Works Construction" ( "Greenbook ") and its supplements prepared and promulgated by the Southern California Chapters of the American Public Works Association and the Associated General Contractors of America, constitute the Standard Specifications for this project. 0 -2 NUMBERING OF SECTIONS The numbering contained within the Standard Specifications of the Contract Documents is intended to correspond with Greenbook numbering. 1 -2 DEFINITIONS The following subsection is added to Subsection 1 -2 of the Greenbook. 1 -2.1 ADDITIONAL DEFINITIONS Acceptance — The date on which the City Council accepts the Work as complete. Architect, Design Engineers, Soils Engineer, Structural Engineers - Advisors employed by the City. Compensable Delay -- a delay entitling the Contractor to an adjustment of the Contract Sum and an adjustment of the Contract Time in accordance with this Agreement. Due Notice - A written notification, given in due time, of a proposed action where such notification is required by the contract to be given a specified interval of time (usually 48 hours or two working days) before the commencement of the contemplated action. Notification may be from Engineer to Contractor . or from Contractor to Engineer. KHB20151022 Page 1 of 36 Agreement No. 4987 Engineer - The City Engineer, or designee, as defined in the Greenbook. Unless otherwise provided, all correspondence and decisions made relative to the contract will be by the City Engineer or his designated representative. PCC — California Public Contract Code. Prompt - The briefest interval of time required for a considered reply, including time required for approval of a governing body. Public Works Director — The City's Public Works Director, or designee. ❑ (Check if applicable) State Standard Specifications - State of California Standard Specifications, dated July 1992, Business and Transportation Agency, Department of Transportation Working Days - A working day is defined as any day, except Saturdays, Sundays, legal holidays and days when work is suspended by the Engineer, as provided in Subsection 6 -3 and days determined to be non - working in accordance with Subsection 6 -7, "Time of Completion." 1 -3 ABBREVIATIONS The following Subsection is added to Subsection 1 -3 of the Greenbook. 1 -3.1 The following abbreviations are added to Subsection 1 -3 of the Greenbook: AAN American Association of Nurserymen AGC Associated General Contractors of America AISC American Institute of Steel Construction APWA American Public Works Association ASME American Society of Mechanical Engineers IEEE Institute of Electric and Electronic Engineers NEC National Electric Code Green Book The most current edition of the Standard Specification for Public Works Construction, and subsequent supplements prepared by Public Works Standards, Inc. WATCH Work Area Traffic Control Handbook SPPWC Standard Plans for Public Works Construction by the American Public Works Association SSPWC Standard Specifications for Public Works Construction by the American Public Works Association ASA American Standard Association CITY City of El Segundo SECTION 2 — SCOPE AND CONTROL OF WORK KHB20151022 Page 2 of 36 Agreement No. 4987 The following subsections 2 -1.1 and 2 -1.2 are added to the Greenbook. 2 -1.1 ACCESS TO PROJECT SITE Not later than the date designated in the City Notice to Proceed, the City will provide access to the real property and facilities upon which the Work is to be performed, including access to real property and facilities designated in the Contract Documents for the Contractor's use. 2 -1.2 OWNERSHIP AND USE OF CONTRACT DOCUMENTS. The Contract Documents and all copies furnished to or provided by the Contractor are the City's property and may not be used on other work. 2 -3 SUBCONTRACTS Subsection 2 -3 Subcontractors of Greenbook is deleted in its entirety and replaced with the following subsection. 2 -3.1 GENERAL Except as provided in PCC §§ 4100 et. seq., each bidder will file with its bid the name and location of the place of business of each subcontractor who will perform work or labor or render service to the prime contractor in or about the construction of the work or improvement, or a subcontractor licensed by the State of California who, under subcontract to the prime contractor, specifically fabricates and installs a portion of the work or improvement according to detailed drawings contained in the plans and specifications, in an amount in excess of one -half of one percent of the prime contractor's total bid. Only one subcontractor will be listed for each portion of the work, which portion will be defined in the bid. In each instance, the nature and extent of the work to be sublet will be described. The failure of the Contractor to specify a subcontractor, or the listing of more than one subcontractor for the same portion of the work, constitutes an agreement by the Contractor that it is fully qualified to perform that portion itself and that it will perform that portion itself. The Contractor must have the City Council's written consent to substitute a subcontractor other than that designated in the original bid, to permit any subcontract to be assigned or transferred, or to allow a subcontract to be performed by other than the original subcontractor. Subcontracting of work for which no subcontractor was designated in the original bid, and which is more than one -half of one percent of the work, will be allowed only in cases of public emergency or necessity, and then only after a finding reduced to writing as a public record of the City Council setting forth the facts constituting the emergency or necessity. KHB20151022 Page 3 of 36 Agreement No. 4987 Violation of any of the above provisions will be considered a breach of the Contract, and the City may terminate the Contractor's control over the Work, cancel the contract, or assess the Contractor a penalty of not more than ten percent of the subcontract involved. All persons engaged in the work, including subcontractors and their employees will be considered as employees of the Contractor. The Contractor will be solely responsible for and have control over construction means, methods, techniques, sequences, procedures, and the coordination of all portions of the Work. The City will deal directly with, and make all payments to, the prime Contractor. When subcontracted work is not being prosecuted in a satisfactory manner, the Contractor will be notified to take corrective action. The Engineer may report the facts to the City Council. If the City Council so orders, and on receipt by the Contractor of written instructions from the Engineer, the subcontractor will be removed immediately from the Work. That subcontractor will not again be employed on the Work. If licensure or proper licensure is controverted, then proof of licensure pursuant to this section must be made by production of a verified certificate of licensure from the Contractors' State License Board which establishes that the individual or entity bringing the action was duly licensed in the proper classification of contractors at all times during the performance of any act or contract covered by the action. Nothing in this subdivision requires any person or entity controverting licensure or proper licensure to produce a verified certificate. When licensure or proper licensure is controverted, the burden of proof to establish licensure or proper licensure is on the licensee. 2 -3.2 ADDITIONAL RESPONSIBILITY Add the following to Subsection 2 -3.2 Additional Responsibility: The Contractor will submit experience statements for each subcontractor who will perform contract work that amounts to more than ten percent (10 %) of the Work. 2 -4 CONTRACT BONDS The following paragraph is added to Subsection 2-4 of the Greenbook. The Faithful Performance Bond and the Labor and Materials Bond must be paid and in effect for one year after the acceptance of the job by the City in accordance with the guarantee required by Subsection 6 -8.1. KHB20151022 Page 4 of 36 Agreement No. 4987 2 -5 PLANS AND SPECIFICATIONS Subsection 2 -5.1 of the Greenbook is replaced by the following subsection. 2 -5.1 GENERAL The Contractor will maintain the following at the Work site: 1. One as -built copy of the Plans and Specifications, in good order and marked to record current changes and selections made during construction. As -built plans must be submitted to the City representative for approval before the City pays a final retention amount. 2. The current accepted Contract Schedule. 3, Shop Drawings, Product Data, and Samples. 4. Approved permits from other agencies, including Cal -OSHA permits for trench shoring. 5. All other required submittals. KHB20151022 The Plans, Specifications, and other Contract Documents will govern the Work. The Contract Documents are intended to be complementary and cooperative and to describe and provide for a complete project. Anything in the Specifications and not on the Plans, or on the Plans and not in the Specifications, will be as though shown or mentioned in both. Payment for any items on the plans for which there is no specific bid item will be included in the various items of work or in any item to which it is appurtenant. If the Contractor performs any work which it knows or should know involves an error, inconsistency, or omission without notifying and obtaining written consent from the Engineer, the Contractor will be responsible for the resulting losses, including, without limitation, the costs of correcting defective work. Page 5 of 36 Agreement No. 4987 2 -5.2 PRECEDENCE OF CONTRACT DOCUMENTS The following paragraph is added to subsection 2 -5.2 of the Greenbook: As the figured dimensions shown on the plans and in the specifications of the Contract may not in every case agree with scaled dimensions, the figured dimensions will be followed in preference to the scaled dimensions, and plans to a large scale will be followed in preference to the plans to a small scale. Should it appear that the work to be done, or any of the matters relative thereto, are not sufficiently detailed or explained in the Contract, the Contractor will apply to the Engineer for such further explanations as may be necessary, and will conform thereto as part of the Contract so far as may be consistent with the terms thereof. Any items shown on drawings and not mentioned in the specifications will be of like effect as if shown or mentioned in both. 2 -5.5 ACCURACY OF PLANS AND SPECIFICATIONS Although it is believed that much of the information pertaining to conditions and existing utilities that may affect the cost of the Work will be shown on the Plans or indicated in the Specifications, the City does not warrant the completeness or accuracy of such information. The Contractor will carefully study and compare each of the Contract Documents with the others and with information furnished by the City and will promptly report in writing to the Engineer any errors, inconsistencies, or omissions in the Contract Documents or inconsistencies with applicable law observed by the Contractor. The Contractor will take field measurements, verify field conditions, perform soil investigations, and carefully compare with the Contract Documents such field measurements, conditions, and other information known to the Contractor before commencing the Work. Errors, inconsistencies, or omissions discovered at any time will be promptly reported in writing to the Engineer. 2 -8 RIGHT -OF -WAY The following subsection is added to Subsection 2 -8 of the Greenbook. 2 -8.1 ADDITIONAL WORK AREAS AND FACILITIES When the Contractor arranges for additional temporary work areas and facilities, the Contractor will provide the City with proof that the additional work areas or facilities have been left in a condition satisfactory to the owner(s) of said work areas or facilities before acceptance of the work. 2 -9 SURVEYING KHB20151022 Page 6 of 36 Agreement No. 4987 Subsection 2 -9.3, Survey Service, is deleted in its entirety and replaced by the following subsection: 2 -9.3 SURVEY SERVICE 2 -9.3.1 CONSTRUCTION SURVEYING The Contractor will provide for all construction surveying required to layout, monitor and complete the work. The surveying will be performed by a Land Surveyor or Civil Engineer authorized to practice land surveying by the State of California. The Project Benchmark is shown on the plans. The Contractor will establish all necessary control lines based on the plans and record information on file with the County of Los Angeles Surveyor and the Engineer. It is the responsibility of the Contractor to protect the survey control as shown on the plans. If the survey control is destroyed or disturbed during construction, the Contractor will provide for resetting them and file appropriate documents with the County of Los Angeles at the direction of the Engineer. Computations, survey notes, and other data used to accomplish the work will be neat, legible and accurate. Copies of all computations, survey notes, and other data (electronic format may be required) will be furnished to the Engineer before beginning work that requires their use. 2 -9.3.2 MEASUREMENT AND PAYMENT Construction Survey — Unless a separate bid item is provided, payment will be considered included in the other items of the bid and no additional payment will be made therefore. 3 -3.2.2 BASIS FOR ESTABLISHING COSTS Subsection 3- 3.2.2.3, Tool and Equipment Rental is modified where the second and third paragraphs are replaced with "Regardless of ownership, the rates to be used in determining the equipment usage costs will not exceed those listed for the same or similar equipment in the California State Department of Transportation publication of Labor Surcharge and Equipment Rates effective for the period of usage." 3 -3.2.3 MARKUP Subsection 3- 3.2.3, Mark Up, is deleted in its entirety and replaced by the following subsection: KHB20151022 Page 7 of 36 Agreement No. 4987 (a) Work by Contractor. The following percentages will be added to the Contractor's costs and will constitute the markup for all overhead and profits. 1) Labor ............ ............................... 20 2) Materials ......... .............................15 3) Equipment Rental.--,. . - ...... -- . 15 4) Other Items and Expenditures .....15 To the sum of the costs and markups provided for in this subsection, 1 percent will be added as compensation for bonding. No other formula, e.g., the Eichleay or other method, may be used to calculate daily damages for office overhead, profit, or other purported loss. (b) Work by Subcontractors. When all or any part of the extra work is performed by a Subcontractor, the markup established in 3- 3.2.3(a) will be applied to the Subcontractor's actual cost of such work. A markup of 10 percent on the first $5,000 of the subcontracted portion of the extra work and a markup of 5 percent on work added in excess of $5,000 of the subcontracted portion of the extra work may be added by the Contractor. (c) In the event that City becomes liable to Contractor for compensable delays, City agrees to pay Contractor the daily Contractor Delay Damages set forth in the Bid Form or Contractor's actual daily delay damages, whichever is less, for each day of Compensable Delay as provided for by these Contract Documents. 3 -3.3 DAILY REPORTS BY CONTRACTOR Add the following paragraph to subsection 3 -3.3, Daily Reports by Contractor: If disagreement continues regarding extra work, the Contractor may seek compensation in accordance with the Claims procedure. Daily Reports required by this subsection must be made part of the Claim as supporting data for the Claim. 3 -4 CHANGED CONDITIONS Subsection 3-4, Changed Conditions, is deleted in its entirety and replaced with the following subsection: If the Contractor encounters concealed or unknown conditions that differ materially from those anticipated or expected ( "changed conditions "), the Contractor will immediately notify the Engineer in writing of such changed KHB20151022 Page 8 of 36 Agreement No. 4987 conditions (upon discovery and before disturbing such changed conditions), as provided in Subsection 6 -11, so that the Engineer can determine if such conditions require design details that differ from those design details shown in the Contract Documents. Notwithstanding the time period set forth in Subsection 6 -11.3, the Contractor is liable to the City for any extra costs incurred as a result of the Contractor's failure to promptly give such notice. Changed conditions include, without limitation, the following: Subsurface or latent physical conditions differing materially from those represented in the Contract Documents; 2. Unknown physical conditions of an unusual nature differing materially from those ordinarily encountered and generally recognized as inherent in work of the character being performed; and 3. Material differing from what is represented in the Contract which the Contractor believes may be hazardous waste as defined in California Health & Safety Code § 25117 that is required to be removed to a Class I, II, or III disposal site in accordance with applicable law. The Engineer will promptly investigate conditions that appear to be changed conditions. The Engineer's decision, and any dispute regarding that decision, will be made in accordance with Section 6 -11 except that the Engineer will render a decision promptly. Any information provided pursuant to INFORMATION AVAILABLE TO BIDDERS is subject to the following provisions: 1. The information is made available for the Bidders' convenience and is not a part of the Contract. 2,, The City has not determined the accuracy or completeness of such information and all such information is made available to Bidders without any representation or warranty by the City whatsoever as to its accuracy, completeness, or relevancy. 3. Bidders will independently evaluate such information for their use and will be solely responsible for use or interpretation of such information. Any such use or interpretation will not be the basis of any claim against the City. 3 -5 DISPUTED WORK Subsection 3 -5 is deleted in its entirety and replaced by the following subsection. KHB20151022 Page 9 of 36 Agreement No. 4987 If the Contractor and the City do not reach agreement on disputed work, the City may direct the Contractor to proceed with the work. Any payment for the disputed work will be determined pursuant to the claims procedures in these Standard Specifications. Although not to be construed as proceeding under extra work provisions, the Contractor will keep and furnish records of disputed work as required by the Contract Documents. 4 -1.3 INSPECTION REQUIREMENTS Subsection 4 -1.3, Inspection Requirements, is deleted in its entirety and replaced by the following subsections. 4 -1.3.1 GENERAL Unless otherwise specified, inspection at the source of production for such materials and fabricated items as bituminous paving mixtures, structural concrete, fabricated metal products, cast metal products, welding, reinforced and unreinforced concrete pipe, application of protective coatings, and similar shop and plant operations is not required. A certificate of compliance, signed by an authorized officer of the producer, certifying compliance with the contract documents will be submitted for all of the following materials: steel pipe, sizes less than 18 inches; vitrified clay pipe; asbestos cement pipe; cast iron pipe; reinforced concrete pipe; non - reinforced concrete pipe; and PVC sewer and water pipe; subject to sampling and testing by City. Standard items of equipment, such as electric motors, conveyors, plumbing fittings and fixtures, lumber, plywood, and so on, are subject to inspection at the job site. All other equipment items will be inspected and tested in accordance with the contract documents. The City does not provide full time inspection. The Contractor will provide 24 -hour minimum notice for each inspection required by the work unless other arrangements have been agreed upon, in writing, with the City Engineer. Any inspection required outside of normal working hours and days, including holidays, will be at the Contractor's cost at rates established by the City. 4 -1.6 TRADE NAMES OR EQUALS Whenever any material, product, equipment, or service is specified by brand, trade, or proprietary name, the item so specified will be deemed to be followed by the words "or equal." For the City's consideration of a proposed "equal" item, the Bidder must submit, KHB20151022 Page 10 of 36 Agreement No. 4987 a minimum of ten (10) calendar days before the date of the bid opening, documentation of the particulars of the proposed "equal item." At a minimum, the submitted documentation will include: • Written request with explanation of why the product should be considered as an equal product. • Material specifications. • Technical specifications. • Test data. • Samples. • Comparison chart of key specifications of the "equal" item against similar specifications of the specified item. Work locations and reference telephone numbers of at least three (3) locations where the proposed "equal" item has been recently installed under similar conditions. Warranty data. The Bidder will be notified by the Engineer whether or not the proposed "equal" product is acceptable to the City five (5) calendar days before the date of the bid opening. Failure to submit all required documentation and /or submittal of incomplete documents may result in the City's rejection of the proposed "equal" product without further consideration. 5 -2 PROTECTION The following subsection is added to Subsection 5 -2 of the Greenbook.. 5 -2.1 INCORRECT LOCATION OF UTILITIES If the Contractor, while performing the Work, discovers utility facilities not identified correctly or not shown in the contract plans or specifications by the City, the Contractor will immediately notify the City and utility owner in writing. 5-4 RELOCATION The following subsection is added to Subsection 5-4 of the Greenbook. 5 -4.1 RESPONSIBILITY OF UTILITY REMOVAL OR RELOCATION The City will be responsible to arrange for the removal, repair, or relocation of existing utilities located within the project limits if such utilities are not correctly identified in the contract plans or specifications by the City. The City will have the sole discretion to perform repairs or relocation work or permit the Contractor to do such repairs or relocation. 5 -5 DELAYS KHB20151022 Page 11 of 36 Agreement No. 4987 The following paragraphs are added to Subsection 5 -5 of the Greenbook. Actual loss, as used in this Subsection, will be understood to include no items of expense other than idle time of equipment and necessary payments for idle time of workers, cost of extra moving of equipment, and cost of longer hauls. Compensation for idle time of equipment and idle time of workers will be determined by Subsection 5 -5.1 and no markup will be added in either case for overhead and profit. The cost of extra moving of equipment and the cost of longer hauls will be paid for as extra work. The following subsection is added to Subsection 5 -5 of the Greenbook. 5 -5.1 CALCULATING IDLE TIME Equipment idle time will calculated in accordance with Subsection 3 -3.2.2 and based upon the actual normal working time during which the delay condition exists, but in no case will exceed 8 hours in any one day. The days for which compensation will be paid will be the calendar days, excluding Saturdays, Sundays and legal holidays, during the existence of the delay. Worker idle time will be calculated in accordance with Subsection 3- 3.2.2. 6 -1 CONSTRUCTION SCHEDULE AND COMMENCEMENT OF WORK Section 6 -1, Construction Schedule and Commencement of Work, is deleted in its entirety and replaced by the following subsections. I re- Construction Meetin A After contract award, the City will arrange for a pre- construction meeting to discuss the construction of the project. City will invite utility agencies and the contractor will arrange for all of its sub - contractors to attend the meeting. 6 -1.1 CONTRACT SCHEDULE After notification of award and before starting any work, the Contractor will submit a Contract Schedule to the Engineer for review, as required by these Specifications within fifteen (15) calendar days of award. 6 -1.2 CONTENT OF CONTRACT SCHEDULE The Contract Schedule, and any updated Contract Schedule, will meet the following requirements: KHB20151022 Schedules must be suitable for monitoring progress of the Work. Page 12 of 36 Agreement No. 4987 Z Schedules must provide necessary data about the time for the Engineer's decisions. 3, Schedules must be sufficiently detailed to demonstrate adequate planning for the Work. 4. Schedules must represent a practical plan to complete the Work within the Contract Time. 5. Schedules must show the critical path method for completing the Work. The Engineer's review of the form and general content of the Contract Schedule and any updated Contract Schedules is only for the purpose of determining if the listed requirements are satisfied, nothing more. 6 -1.3 EFFECT OF CONTRACT SCHEDULE The Contract Schedule, and any updated Contract Schedules, will represent a practical plan to complete the Work within the Contract Time. Extension of any schedule beyond the Contract Time will not be acceptable. Schedules showing the Work completed in less than the Contract may be acceptable if judged by the Engineer to be practical. Acceptance of such a schedule by the Engineer will not change the Contract Time. The Contract Time, not the Contract Schedule, will control in determining liquidated damages payable by the Contractor and in determining any delay. If a schedule showing the Work completed in less than the Contract Time is accepted, the Contractor will not be entitled to extensions of the Contract Time for Excusable Delays or Compensable Delays or to adjustments of the Contract Sum for Compensable Delays until such delays extend the completion of the Work beyond the expiration of the Contract Time. The Contractor will plan, develop, supervise, control, and coordinate the performance of the Work so that its progress and the sequence and timing of Work activities conform to the current accepted Contract Schedule. The Contractor will continuously obtain from Subcontractors information and data about the planning for and progress of the Work and the delivery of equipment, will coordinate and integrate such information and data into updated Contract Schedules, and will monitor the progress of the Work and the delivery of equipment. The Contractor will act as the expeditor of potential and actual delays, interruptions, hindrances, or disruptions for its own forces and those forces of Subcontractors. The Contractor will cooperate with the Engineer in developing the Contract Schedule and updated Contract Schedules. The Engineer's review and comments about any schedule or scheduling data will not relieve the Contractor from its sole responsibility to plan for, perform, and complete the Work within the Contract Time. Review and comments about any schedule will not transfer responsibility for any schedule to the Engineer or the City nor imply their agreement with (1) any assumption upon which such KHB20151022 Page 13 of 36 Agreement No. 4987 schedule is based or (2) any matter underlying or contained in such schedule. The Engineer's failure to discover errors or omissions in schedules that have been reviewed, or to inform the Contractor that the Contractor, Subcontractors, or others are behind schedule, or to direct or enforce procedures for complying with the Contract Schedule will not relieve the Contractor from its sole responsibility to perform and complete the Work within the Contract Time and will not be a cause for an adjustment of the Contract Time or the Contract Sum. The Contractor will perform the Work in accordance with the currently accepted Contract Schedule. 6 -1.4 COMMENCEMENT OF CONTRACT TIME The Contract Time will commence when the City issues a Notice to Proceed. The Work will start on the date specified in the Notice to Proceed and within a maximum of fifteen (15) calendar days after the date of the Notice to Proceed, and be diligently prosecuted to completion with the time provided in the Specifications. 6 -4 DEFAULT BY CONTRACTOR The language in subsection 6 -4 is deleted in its entirety and replaced with the following subsections. 6 -4.1 GENERAL Should the Contractor fail to begin delivery of material and equipment, to commence the Work within the time specified, to maintain the rate of delivery of material, to execute the Work in the manner and at such locations as specified, or fail to maintain the Work schedule (as determined by the current accepted Contract Schedule) which will ensure the City's interest, or if the Contractor is not carrying out the intent of the Contract, the City may serve written notice upon the Contractor and the Surety on its Faithful Performance Bond demanding satisfactory compliance with the Contract. 6-4.2 TERMINATION OF CONTRACTOR'S CONTROL OVER THE WORK The City may terminate the Contractor's control over the Work without liability for damages when, in the City's opinion, the Contractor is not complying in good faith, has become insolvent, or has assigned or subcontracted any part of the Work without the City's consent. Should such termination occur, the Contractor will be paid the actual amount due based on Contract Unit Prices or lump sums bid and the quantity and quality of the Work completed at the time of termination, less damages caused to the City by the Contractor's action or inaction. KHB20151022 Page 14 of 36 Agreement No. 4987 In the event of such termination of control, the City may do any one, or combination of, the following: 1. Serve written notice upon the Surety on its Faithful Performance Bond demanding satisfactory compliance with the Contract. In such event the Surety will, within 5 days, assume control and perform the Work as successor to the Contractor; 2. The City may perform the Work itself and deduct the cost thereof from any payment due to the Contractor; 3, The City may replace the Contractor with a different contractor to complete the work and deduct the cost thereof from any payment due to the Contractor. Nothing herein will waive, or serve as a limitation upon, any additional remedy the City may have under these Contract Documents or applicable law. 6-4.3 SURETY'S ASSUMPTION OF CONTROL Should the Surety assume any part of the Work, it will take the Contractor's place in all respects for that part, and will be paid by the City for all work performed by it in accordance with the Contract. If the Surety assumes the entire Contract, all money due the Contractor at the time of its default will be payable to the Surety as the Work progresses, subject to the terms of the Contract. If the Surety does not assume control and perform the Work within 5 days after receiving notice of cancellation, or fails to continue to comply, the City may exclude the Surety from the premises. The City may then take possession of all material and equipment and complete the Work by City's forces, by letting the unfinished work to another contractor, or by a combination of such methods. In any event, the cost of completing the Work will be charged against the Contractor and its Surety and may be deducted from any money due or becoming due from the City. If the sums due under the Contract are insufficient for completion, the Contractor or Surety will pay to the City within 5 days of completion, all costs in excess of the sums due. The provisions of this subsection will be in addition to all other rights and remedies available to the City under applicable law. 6 -6 DELAYS AND EXTENSIONS OF TIME Subsection 6 -6 is deleted in its entirety and replaced with the following subsections. 6 -6.1 GENERAL KHB20151022 Page 15 of 36 Agreement No. 4987 If delays are caused by unforeseen events beyond the control of the Contractor, such delays will entitle the Contractor to an extension of time as provided herein, but the Contractor will not be entitled to damages or additional payment due to such delays except as otherwise provided herein. Excusable delay may include: war, earthquakes exceeding 3.5 on the Richter Scale, government regulation, labor disputes outside the contemplation of the parties, strikes outside the contemplation of the parties, fires, floods, changes to the Work as identified herein, or other specific events that may be further described in the Specifications. Delays to the project caused by labor disputes or strikes involving trades not directly related to the project, or involving trades not affecting the project as a whole will not warrant an extension of time. The City will not grant an extension of time for a delay by the Contractor's inability to obtain materials unless the Contractor furnishes to the Engineer documentary proof. The proof must be provided in a timely manner in accordance with the sequence of the Contractor's operations and accepted construction schedule. Should delays be caused by events other than those included herein, the Engineer may, but is not required to, deem an extension of time to be in the City's best interests. 6 -6.2 EXTENSIONS OF TIME If granted, extensions of time will be based upon the effect of delays to the critical path of the Work as determined by the current accepted Contract Schedule. Delays to minor portions of the Work that do not affect the critical path will not be eligible for extensions of time. 6 -6.3 PAYMENT FOR DELAYS TO CONTRACTOR Any payment for compensable delay will be based upon actual costs as set forth in Subsection 5 -5 excluding, without limitation, what damages, if any, the Contractor may have reasonably avoided. The Contractor understands that this is the sole basis for recovering delay damages and explicitly waives any right to calculate daily damages for office overhead, profit, or other purported loss, using different formulas including, without limitation, the Eichleay Formula. 6 -6.4 WRITTEN NOTICE AND REPORT If the Contractor desires payment for a delay or an extension of time, it will give the Engineer written notice of such request not later than the time limit set forth in the Proposal for submitting a claim after the event or occurrence giving rise KHB20151022 Page 16 of 36 Agreement No. 4987 to a delay claim. Failure to submit a written request within such amount of time will result in the Contractor waiving its delay claim. Any claim for payment or an extension of time must be in the form required by the "Claims" sections of these Specifications. In no event will the City grant the Contractor an extension of time if the delay is within the Contract Time as identified by the Contract Documents. 6 -7.2 WORK DAYS AND WORKING HOURS City Hall is open from Monday thru Thursday 7am -6pm. It is closed every Friday and the following holidays: New Year's Day - Thursday, January 1, 2015 Martin Luther King, Jr. Day- Monday, January 19, 2015 President's Day - Monday, February 16, 2015 Memorial Day - Monday, May 25, 2015 Independence Day - Saturday, July 4, 2015 Labor Day - Monday, September 7, 2015 Veterans' Day - Wednesday, November 11, 2015 Thanksgiving - Thursday, November 26, 2015 Christmas Eve - Thursday, December 24, 2015 Christmas - Friday, December 25, 2015 New Year's Eve - Thursday, December 31, 2015 Working on Fridays when City Hall is closed is acceptable. If the Contractor, however, requests an inspection a day when City Hall is closed, then the Contractor will have to reimburse the City for the costs of inspection. The Contractor must request such an inspection at least 48 hours in advance. City inspections during hours when City Hall is closed are subject to inspection overtime fees to be paid for by the Contractor. Friday work that does not require inspection can be done without an inspection fee and must be discussed with City staff before its occurrence. If the Contractor does construction on a Friday or a day when City Hall is closed, that day is counted as a project working day. On workdays, Contractor's activities will be confined to the hours between 7:00 a.m. and 4:00 p.m. Please see Section 6 -7.5 below for weekend and holiday work restrictions. 6 -7.4 NIGHT WORK The following paragraph is added to Section 6 -7 of the Greenbook: The City will not permit Work between the hours of 4 p.m. and 7 a.m. of the KHB20151022 Page 17 of 36 Agreement No. 4987 following day unless specifically provided for in the bid documents or unless the Contractor receives prior written approval. 6 -7.5 WEEKEND AND HOLIDAY WORK The Engineer may, but is not required to, allow the Contractor to work on Saturdays, Sundays and City Holidays. 6 -8 COMPLETION AND ACCEPTANCE Subsection 6 -8 of the Greenbook is deleted in its entirety and replaced by the following: The Work will be inspected by the Engineer for acceptance upon the Engineer receiving the Contractor's written assertion that the Work is complete. If, in the Engineer's judgment, the Work is complete and is ready for acceptance, the Engineer will accept the Work on behalf of the City in the manner prescribed by the City. The Engineer will recommend approval of the Notice of Completion to the City Council. This will be the date when the Contractor is relieved from responsibility to protect the Work. All work will be guaranteed by the Contractor against defective workmanship and materials furnished by the Contractor for a period of 1 year from the date the Work was completed. The Contractor will replace or repair any such defective work in a manner satisfactory to the Engineer, after notice to do so from the Engineer, and within the time specified in the notice. If the Contractor fails to make such replacement or repairs within the time specified in the notice, the City may perform this work and the Contractor's sureties will be liable for the cost thereof. 6 -8.1 GENERAL GUARANTY The Contractor will remedy any defects in the work and pay for any damage to other work resulting therefrom, which will appear within a period of one year from the date of final acceptance of the work unless a longer period is specified. The owner will give notice of observed defects with reasonable promptness. 6 -9 LIQUIDATED DAMAGES Subsection 6 -9, Liquidated Damages, of the Greenbook is deleted in its entirety and replaced by the following subsections. 6 -9.1 FAILURE TO COMPLETE WORK ON TIME If all the work called for under the contract is not completed before or upon the KHB20151022 Page 18 of 36 Agreement No. 4987 expiration of the Contract Time, the City will sustain damage. Since it is and will be impracticable to determine the actual damage which the City will sustain in the event of and by reason of such delay, it is therefore agreed that the Contractor will pay to the City the sum specified in the Proposal for each and every calendar day beyond the time prescribed to complete the work not as a penalty, but as a predetermined liquidated damage. The Contractor agrees to pay such liquidated damages as are herein provided, and in case the same are not paid, agrees that the City may deduct the amount thereof from any money due or that may become due to the Contractor under the contract. Unless otherwise specified, liquidated damages will be $250 per calendar day. 6 -11 DISPUTES AND CLAIMS; PROCEDURE 6 -11.1 GENERAL Consistent with PCC § 10240.6, "Claim" means a written demand or assertion by the Contractor that seeks an adjustment or interpretation of the terms of the Contract Documents, payment of money, extension of time, or other relief with respect to the Contract Documents, including a determination of disputes or matters in question between the City and the Contractor arising out of or related to the Contract Documents or the performance of the Work, and claims alleging an unforeseen condition or an act, error, or omission by the City, the Engineer, their agents or employees. "Claim" does not mean, and the Claims procedures herein do not apply, to the following: 1. Claims respecting penalties for forfeitures prescribed by statute or regulations, which a government agency is specifically authorized to administer, settle, or determine. 2. Claims respecting personal injury, death, reimbursement, or other compensation arising out of or resulting from liability for personal injury or death. 3. Claims respecting a latent defect, breach of warranty, or guarantee to repair. 4. Claims respecting stop notices. If a Claim is subject to the Change Order procedures, the Claim arises upon the issuance of a written final decision denying in whole or in part the Contractor's Change Order Request. If a Claim is not subject to the Change Order Procedures, the Claim arises when the Contractor discovers, or reasonably should discover, the condition or event giving rise to the Claim. 6 -11.2 FORM A Claim must include the following: KHB20151022 Page 19 of 36 1. 2. 3. 4.. 5. a 7 KHB20151022 Agreement No. 4987 A statement that it is a Claim and a request for a decision. A detailed description of the act, error, omission, unforeseen condition, event or other condition giving rise to the Claim. If the Claim is subject to the Change Order procedures, a statement demonstrating that a Change Order Request was timely submitted and denied. A detailed justification for any remedy or relief sought by the Claim, including to the extent applicable, the following: a) If the Claim involves extra work, a detailed cost breakdown claimed. The breakdown must be provided even if the costs claimed have not been incurred when the Claim is submitted. b) To the extent costs have been incurred when the Claim is submitted, the Claim must include actual cost records (including, without limitation, payroll records, material and rental invoices) demonstrating that costs claimed have actually been incurred. c) To the extent costs have not yet been incurred at the time the Claim is submitted, actual cost records must be submitted on a current basis not less than once a week during any periods costs are incurred. A cost record will be considered current if submitted within seven (7) calendar days of the date the cost reflected in the record is incurred. At the Engineer's request, claimed extra costs may be subject to further verification procedures (such as having an inspector verify the performance of alleged extra work on a daily basis). If the Claim involves an error or omission in the Contract Documents: a) An affirmative representation that the error or omission was not discovered before submitting a bid for the Contract; and b) A detailed statement demonstrating that the error or omission reasonably should not have been discovered by the Contractor, its Subcontractors and suppliers, before submitting a bid for the Contract. If the Claim involves an extension of the Contract Time, written documentation demonstrating the Contractor's entitlement to a time extension. If the Claim involves an adjustment of the Contract Sum for delay, written Page 20 of 36 Agreement No. 4987 documentation demonstrating the Contractor's entitlement to such an adjustment. 8. A personal certification from the Contractor that reads as follows: III„ ,, BEING THE (MUST BE AN OFFICER) OF _ _ ® (CONTRACTOR NAME), DECLARE UNDER PENALTY OF PERJURY UNDER CALIFORNIA LAW, AND DO PERSONALLY CERTIFY AND ATTEST THAT I HAVE THOROUGHLY REVIEWED THE ATTACHED CLAIM FOR ADDITIONAL COMPENSATION OR EXTENSION OF TIME, AND KNOW ITS CONTENTS, AND SAID CLAIM IS MADE IN GOOD FAITH; THE SUPPORTING DATA IS TRUTHFUL AND ACCURATE; THAT THE AMOUNT REQUESTED ACCURATELY REFLECTS THE CONTRACT ADJUSTMENT FOR WHICH THE CONTRACTOR BELIEVES CITY IS LIABLE; AND, FURTHER, THAT I AM FAMILIAR WITH CALIFORNIA PENAL CODE § 72 AND CALIFORNIA GOVERNMENT CODE § 12650, ET SEQ., PERTAINING TO FALSE CLAIMS, AND FURTHER KNOW AND UNDERSTAND THAT SUBMITTING OR CERTIFYING A FALSE CLAIM MAY LEAD TO FINES, IMPRISONMENT, AND OTHER SEVERE LEGAL CONSEQUENCES." 6 -11.3 CLAIMS SUBMITTED TO ENGINEER Within thirty (30) calendar days after the circumstances giving rise to a Claim occur, the Contractor will submit its Claim to the Engineer for a decision. Regardless of any Claim submittal, or any dispute regarding a Claim, unless otherwise directed by the Engineer, the Contractor will not cause any delay, cessation, or termination of the Work, but will diligently proceed with the performing the Work in accordance with the Contract Documents. Except as otherwise provided, the City will continue to make payments in accordance with the Contract Documents. 6 -11.4 CLAIM IS PREREQUISITE TO OTHER REMEDY The Contractor certifies that it is familiar with PCC § 10240.2 and understands and agrees that submitting a Claim in accordance with these Specifications is an express condition precedent to the Contractor's right to otherwise pursue a claim whether through alternative dispute resolution or by litigation. Should the Contractor fail to submit a claim in accordance with these Specifications, including the time limits set forth herein, it will waive any right to a remedy, whether in law or equity, it might otherwise have pursuant to the Contract Documents or applicable law. 6 -11.5 DECISION ON CLAIMS KHB20151022 Page 21 of 36 Agreement No. 4987 The Engineer will promptly review Claims submitted by the Contractor in accordance with these Specifications. Should the Engineer require additional supporting evidence to evaluate the claim, the Engineer will request such additional information in writing. Any such requested data will be furnished not later than ten (10) calendar days after the Contractor receives the Engineer's request. The Engineer will render a decision not later than 30 calendar days after either receiving the Claim or the deadline for furnishing additional supporting data, whichever is later. If the Claim amount is more than $50,000, the time period will be extended to 60 days. If the Engineer fails to render a decision within the time period established herein, then the Claim will be deemed denied. The Engineer's decision will be final and binding unless appealed in accordance with these Specifications. The Engineer's decision on a Claim will include a statement substantially as follows: "This is a decision pursuant to the General Specifications of your contract. If you are dissatisfied with the decision, and have complied with the procedural requirements for asserting claims, you may have the right to alternative dispute resolution or litigation. Should you fail to take appropriate action within thirty (30) calendar days of the date of this decision, the decision will become final and binding and not subject to further appeal." 6- 11.6APPEAL OF ENGINEER'S DECISION Should the Contractor dispute the Engineer's decision, then the Contractor must appeal that decision to the City's Public Works Director within thirty (30) calendar days of receiving the Engineer's decision. The Public Works Director will address disputes or claims within thirty (30) calendar days after receiving such request and all necessary supporting data. The Public Works Director's decision on the dispute or claim will be the City's final decision. If the Contractor disputes the Public Works Director's decision, then the Contractor must demand alternative dispute resolution in accordance with this Section and the PCC within thirty (30) calendar days of the City's final decision. 6 -11.7 MEDIATION If the City and the Contractor agree, disputes between the parties may be submitted to non - binding mediation. If the parties cannot agree to an alternative form of mediation, then mediation will be administered by the American KHB20151022 Page 22 of 36 Agreement No. 4987 Arbitration Association ( "AAA ") under its Construction Industry Mediation Rules, unless the use of such rules are waived by mutual stipulation of both parties. The parties may, but are not required to be, represented by counsel in mediation. The requirement for mediation will not alter or modify the time limitations otherwise provided for claims and no conduct or settlement negotiation during mediation will be considered a waiver of the City's right to assert that claim procedures were not followed. 6 -11.8 ARBITRATION If the City and Contractor do not agree to mediation, then a disputes will be submitted to neutral non - binding (except as provided herein) arbitration.. Arbitration will be conducted in accordance with PCC § 10240.3. Any decision rendered by an arbitrator will be consistent with PCC § 10240.8. The exclusive venue for any arbitration will be in Los Angeles County. The expenses and fees of the arbitrators and the administrative fees, if any, will be divided among the parties equally. Each party will pay its own counsel fees, witness fees, and other expenses incurred for its own benefit. 6 -11.9 WHEN ARBITRATION DECISION BECOMES BINDING The decision rendered by the arbitrator will become binding upon the parties unless appealed to the Los Angeles County Superior Court pursuant to PCC § 10240.12 within thirty (30) calendar days of the decision. If subsequent litigation results in an award to the party appealing the arbitration that is less than or equal to that of the arbitration decision, or if the litigation results in a decision in favor of the nonappealing party, then the party appealing the arbitration will pay the nonappealing party's attorney's fees and court costs. 6- 11.10. APPEAL TO SUPERIOR COURT: WAIVER OF JURY TRIAL Should a party timely object to the arbitration decision, it may file a petition with the Los Angeles County Superior Court in accordance with California Code of Civil Procedure ( "CCP ") §§ 1285, et seq. Notwithstanding the limitations set forth in CCP § 1286.2, the court may vacate, correct, or adjust an arbitration award, and enter judgment in accordance with CCP § 1287.4, for any legal or equitable basis including, without limitation, error of law. The court will apply the substantial evidence standard of review when considering the appeal of an objecting party. KHB20151022 Page 23 of 36 Agreement No. 4987 BY EXECUTING THESE CONTRACT DOCUMENTS, THE CONTRACTOR AGREES TO HAVE DISPUTES OR CONTROVERSY CONCERNING THE CONSTRUCTION, INTERPRETATION, PERFORMANCE, OR BREACH OF THESE CONTRACT DOCUMENTS, INCLUDING CLAIMS FOR BREACH OF CONTRACT OR ISSUES OF BAD FAITH DECIDED IN ACCORDANCE WITH THIS SECTION 6 -11. BOTH THE CITY AND THE CONTRACTOR WAIVE THEIR RIGHT TO A JURY TRIAL FOR THESE DISPUTES OR ISSUES. 7 -2 LABOR The following subsections are added to Subsection 7 -2 of the Green Book, 7 -2.3 PREVAILING WAGES The Contractor will post at appropriate conspicuous points at the site of the project a schedule showing determinations of the Director of Industrial Relations of the prevailing rate of per diem wages. It will be the Contractor's responsibility to obtain copies of the prevailing rate of per diem wages. One source that may be used is the California Department of Industrial Relations website which is currently located at www.dir.ca.gov, or by calling the Prevailing Wage Unit at (415) 703 -4774. Attention is directed to Labor Code §§ 1777.5, 1777.6 and 3098 concerning the employment of apprentices by the Contractor or any subcontractor. Labor Code § 1777.5 requires the Contractor or subcontractor employing tradesmen in any apprenticeship occupation to apply to the joint apprenticeship committee nearest the site of the public works project and which administers the apprenticeship program in that trade for a certificate of approval. The certificate will also fix the ratio of apprentices to journeymen that will be used in the performance of the contract. The ratio of apprentices to journeymen in such cases will not be less than one to five except: a) When employment in the area of coverage by the joint apprenticeship committee has exceeded an average of 15 percent in the ninety (90) calendar days before the request for certificate, or b) When the number of apprentices in training in the area exceeds a ratio of one to five, or c) When the trade can show that it is replacing at least 1/30 of its membership through apprenticeship training on an annual basis state -wide or locally, or d) When the Contractor provides evidence that the Contractor employs registered apprentices on all of his contracts on an annual average of KHB20151022 Page 24 of 36 Agreement No. 4987 not less than one apprentice to eight journeymen. The Contractor is required to make contributions to funds established for the administration of apprenticeship programs if the Contractor employs registered apprentices or journeymen in any apprenticeable trade on such contracts and if other contractors on the public works site are making such contributions. The Contractor and any subcontractor will comply with Labor Code §§ 1777.5 and 1777.6 in the employment of apprentices. Information relative to apprenticeship standards, wage schedules and other requirements may be obtained from the Director of Industrial Relations, ex- officio the Administrator of Apprenticeship, San Francisco, California, or from the Division of Apprenticeship Standards and its branch offices. 7 -2.4 RECORD OF WAGES PAID: INSPECTION Every Contractor and subcontractor will keep an accurate certified payroll records showing the name, occupation, and the actual per diem wages paid to each worker employed in connection with the Work. The record will be kept open at all reasonable hours to the inspection of the body awarding the contract and to the Division of Labor Law Enforcement. If requested by the City, the Contractor will provide copies of the records at its cost. 7 -3 LIABILITY INSURANCE Subsection 7 -3, Liability Insurance, of the Greenbook is deleted in its entirety and replaced by the following subsections. 7 -3.1 GENERAL Contractor must procure and maintain for the duration of the contract the following insurance coverages and limits against claims for injuries to persons or damage to property that may arise from or in connection with the performance of the work covered by this agreement by the Contractor, its agents, representatives, employees or subcontractors: COVERAGE PER OCCURRENCE Comprehensive General Liability Business Auto Workers' Compensation ISO FORM COMBINED SINGLE LIMIT CL 00 02 01 85 or 88 $2,000,000 CA 00 01 01 87 $1,000,000 Statutory Contractor will provide endorsements or other proof of coverage for contractual KHB20151022 Page 25 of 36 Agreement No. 4987 liability, Combined single limit per occurrence will include coverage for bodily injury, personal injury, and property damage for each accident. If Commercial General Liability Insurance or other form with a general aggregate limit is used, the policy will be endorsed such that the general aggregate limit will apply separately to this contract and a copy of the endorsement provided to the City. Liability policies will contain, or be endorsed to contain the following provisions: GENERAL LIABILITY AND AUTOMOBILE LIABILITY: The City, its officers, officials, employees, agents, and volunteers will be covered as insureds as respects: liability arising out of activities performed by or on behalf of the Contractor; products and completed operations of the Contractor; premises owned, occupied or used by the Contractor; or automobiles owned, leased, hired or borrowed by the Contractor. The coverage will contain no special limitations on the scope or protection afforded to the City, its officers, officials, employees, agents, or volunteers. The Contractor's insurance coverage will be primary insurance as respects the City, its officers, officials, employees, agents, and volunteers. Any insurance or self- insurance maintained by the City, its officers, officials, employees, agents, and volunteers will be excess of the Contractor's insurance and will not contribute with it. The insurer will agree in writing to waive all rights of subrogation against the City, its officers, officials, employees and volunteers for losses arising from work performed by the Contractor for the City. Any failure to comply with reporting provisions of the policies will not affect coverage provided to the City, its officers, officials, employees, agents and volunteers. The Contractor's insurance will apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. WORKERS' COMPENSATION; The insurer will agree to waive all rights of subrogation against the City, its officers, officials, employees and volunteers for losses arising from work performed by the Contractor for the City. ALL COVERAGES: KHB20151022 Page 26 of 36 Agreement No. 4987 Each insurance policy required by this subsection will be endorsed to state that coverage will not be suspended, voided, cancelled by either party, reduced in coverage or in limits except after thirty (30) calendar days written notice by certified mail, return receipt requested, has been given to: CITY CLERK City of El Segundo 350 Main Street El Segundo, CA 90245 Notwithstanding the foregoing, the endorsement may state that insurance may be cancelled upon ten (10) calendar day notification for non - payment of premium. The Contractor will provide the City with updated proof of insurance should the Contract Time extend beyond the policy expiration date. All liability insurance will be on an occurrence basis. Insurance on a claims made basis will be rejected. Any deductibles or self- insured retentions will be declared to and approved by City. The insurer will provide an endorsement to City eliminating such deductibles or self- insured retentions as respects the City, its officials, employees, agents, and volunteers. Except for Workers Compensation Insurance, Contractor will furnish to City certificates of insurance and endorsements on forms acceptable to the City's City Attorney, duly authenticated, giving evidence of the insurance coverages required in this contract and other evidence of coverage or copies of policies as may be reasonably required by City from time to time. Endorsements must be supplied on ISO Form No. CG 20 10 11 85, or equivalent. Certificate /endorsement for Workers Compensation Insurance will be furnished on State Comp Fund or other industry standard form. Except for worker's compensation insurance, all insurance required herein will be placed with insurers with a Best's Rating of not less than A:VII. Worker's compensation insurance policies will meet the requirements of California law. All subcontractors employed on the work referred to in this contract will meet the insurance requirements set forth for Contractor. Contractor will furnish certificates of insurance and endorsements for each subcontractor at least five days before the subcontractor entering the job site, or Contractor will furnish City an endorsement including all subcontractors as insureds under its policies. Except as provided in Subsection 6 -10, the Contractor will save, keep and hold harmless the City, its officers, officials, employees, agents and volunteers from all damages, costs or expenses in law or equity that may at any time arise or be claimed because of damages to property, or personal injury received by reason of or in the course of performing work, which may be caused by any willful or negligent act or omission by the Contractor or any of the Contractor's O NIM11M Page 27 of 36 Agreement No. 4987 employees, or any subcontractor. The City will not be liable for any accident, loss or damage to the work before its completion and acceptance, except as provided in Subsection 6 -10. The cost of such insurance will be included in the various items of work in the Contractor's bid and no additional compensation for purchasing insurance or additional coverage needed to meet these requirements will be allowed. In the event that any required insurance is reduced in coverage, cancelled for any reason, voided or suspended, Contractor agrees that City may arrange for insurance coverage as specified, and Contractor further agrees that administrative and premium costs may be deducted from payments due to the Contractor. Contractor will not be allowed to work until alternate coverage is arranged. Coverage will not extend to any indemnity coverage for the active negligence of the additional insured if the agreement to indemnify the additional insured would be invalid under Civil Code § 2782(b). 7 -3.2 INDEMNIFICATION AND DEFENSE In addition to the provisions of Subsection 7 -3 of the Greenbook as between the City and Contractor, Contractor will take and assume all responsibility for the work as stated herein or shown on the plans. The Contractor will bear all losses and damages directly or indirectly resulting to it, to the City, its officers, employees, and agents, or to others on account of the performance or character of the work, unforeseen difficulties, accidents, traffic control, job site maintenance, or any other causes whatsoever. The Contractor will assume the defense of and indemnify and save harmless the City of El Segundo, its officers, employees, and agents, from and against any and all claims, losses, damage, expenses and liability of every kind, nature, and description, directly or indirectly arising from the performance of the contract or work, regardless of responsibility for negligence, and from any and all claims, losses, damage, expenses, and liability, howsoever the same may be caused, resulting directly, or indirectly from the nature of the work covered by the contract, regardless of responsibility for negligence, to the fullest extent permitted by law. In accordance with Civil Code § 2782, nothing in this Subsection 7 -3.2 or in Subsection 7 -3 of the Standard Specifications will require defense or indemnification for death, bodily injury, injury to property, or any other loss, damage or expense arising from the sole negligence or willful misconduct of the City, or its agents, servants or independent contractors who are directly responsible to the City, or for defects in design furnished by such persons. Moreover, nothing in this Subsection 7 -3.2 or in Subsection 7 -3 will apply to impose on the Contractor, or to relieve the City from, liability for active KHB20151022 Page 28 of 36 Agreement No. 4987 negligence of the City. The City does not, and will not, waive any rights against the Contractor which it may have by reason of the aforesaid hold harmless agreements because of the acceptance by the City, or deposit with City by Contractor, of any insurance policies described in Subsection 7 -3 of the Special Provisions. This hold harmless agreement by the Contractor will apply to all damages and claims for damages of every kind suffered, or alleged to have been suffered by reasons of any of the aforesaid operations of Contractor, or any subcontractor, regardless of whether or not such insurance policies are determined to be applicable to any of such damages or claims for damages. No act by the City, or its representatives in processing or accepting any plans, in releasing any bond, in inspecting or accepting any work, or of any other nature, will in any respect relieve the Contractor or anyone else from any legal responsibility, obligation or liability he might otherwise have. 7 -5 PERMITS The following paragraph will be added to Subsection 7 -5 of Greenbook: The Contractor will apply for permits required by the City. These permits will be issued on a "no -fee" basis. However, the Contractor must pay for and obtain all other permits from other governmental and utility agencies necessitated by their operations. All bonding fees, (overweight and oversized vehicle permit fees) inspection permit fees or other fees charged or required for such permits must be paid by the Contractor. These costs will be included in the bid item provided. If no bid item is included, costs will be included in the various items of work, and no additional payment will be allowed. 7 -8.1 CLEANUP AND DUST CONTROL Subsection 7 -8.1, Cleanup and Dust Control, of the Greenbook is deleted in its entirety and replaced by the following subsections. 7 -8.1.1 GENERAL On any construction project requiring trenching within public streets and for which total trenching is in excess of 500 feet, the Contractor will be required to sweep the worksite utilizing a pick -up type street sweeper a minimum of once daily. 7 -8.1.2 WATERING KH620151022 Page 29 of 36 Agreement No. 4987 Water for dust control caused by Contractor's operations or the passage of traffic through the work will be applied as necessary or as directed by the Engineer. Water for the above or other purposes may be obtained from any approved source. If the Contractor chooses to use a City fire hydrant upon placing deposits and fees as described in this contract, the Engineer will cause a meter to be installed. All water used from the hydrant will be metered and charged to the Contractor at the prevailing rate plus the current daily meter rental rate. The Contractor will be charged a $15 reconnect fee if the Contractor wishes to move the meter to a different hydrant. Costs of water to be used will be included in the cost of various bid items. 7 -8.6 WATER POLLUTION CONTROL The following requirements are added to establish storm water and urban runoff pollution prevention controls. (a) Storm or construction generated water containing sediment such as, construction waste, soil, slurry from concrete /asphalt concrete saw cutting operations, clean up of concrete transit mixers or other pollutants from construction sites and parking areas will be retained or controlled on site and will not be permitted to enter the storm drain system. (b) Temporary sediment filtering systems such as sandbags, silt fences, or gravel berms will be utilized to trap sediment so that only filtered water enters the City's storm drain system. Proper clean up and disposal of settled sediment and the filtering system will be the responsibility of the Contractor. (c) Discharge of concrete transit mixer wash water on to approved dirt areas (sub -grade area designated for new concrete construction for example) is acceptable. Discharge on to private property, parkway areas, or the street is not permitted. (d) Plastic or other impervious covering will be installed where appropriate to prevent erosion of an otherwise unprotected area, along with any other runoff control devices deemed appropriate by the City. (e) Excavated soil stored on the site will be covered in a manner that minimizes the amount of sediments running into the storm drain system, street or adjoining properties. (f) No washing of construction or other industrial vehicles and equipment will be allowed adjacent to a construction site. During the rainy season (October 15 to April 15), Contractor will keep at the construction site sufficient materials and labor to install temporary sediment filtering systems and other water pollution prevention control measures. These KHB20151022 Page 30 of 36 7 -9 7 -10 7 -10.1 Agreement No. 4987 control measures will be in place and maintained by the Contractor on a daily basis on days when construction is not in progress due to rain. (h) All costs associated with water pollution control will be borne by the Contractor. Any expense incurred by the City to expeditiously respond to storm drain contamination resulting from Contractor's failure to implement water pollution control measures will be charged to the Contractor. PROTECTION AND RESTORATION OF EXISTING IMPROVEMENTS The following requirements are added to Section 7 -9: Where existing traffic striping, pavement markings, and curb markings are damaged or their reflectively reduced by the Contractor's operations, such striping or markings will also be considered as existing improvements and the Contractor will replace such improvements. Relocations, repairs, replacements, or re- establishments will be at least equal to the existing improvements and will match such improvements in finish and dimensions unless otherwise specified. PUBLIC CONVENIENCE AND SAFETY The following requirement is added to Section 7 -10: Unless otherwise specified all traffic control will be performed in accordance with the Work Area Traffic Control Handbook (WATCH) Latest Edition, published by Building News, 3055 Overland Avenue, Los Angeles, CA 90034, telephone 310 - 474 -7771. TRAFFIC AND ACCESS The Contractor will notify the occupants of all affected properties at least 48 hours before any temporary obstruction of access. Vehicular access to property line will be maintained except as required for construction for a reasonable period of time. No overnight closure of any driveway will be allowed except as permitted by the Engineer. At least one (1) twelve (12) foot wide traffic lane will be provided for each direction of travel on all streets at all times except as permitted by the Engineer. The traffic lanes will be maintained on pavement, and will remain unobstructed. All work requiring that a lane be closed or a lane moved right or left will be noticed to the traveling public by use of City approved lighted arrow boards. Clearances from traffic lanes will be five (5) feet to the edge of any excavation KHB20151022 Page 31 of 36 Agreement No. 4987 and two (2) feet to the face of any curb, pole, barricade, delineator, or other vertical obstruction. One four (4) foot wide paved pedestrian walkway will be maintained in the parkway area on each side of all streets. The clearance from the pedestrian walkway to any traffic lane will be five (5) feet. Pedestrians and vehicles will be protected from all excavations, material storage, and /or obstructions by the placement of an adequate number of lighted barricades (minimum two (2)) at each location, one (1) at each end of the obstruction or excavation), which will have flashing lights during darkness. Barricades will be Type I or Type II per Section 7 -3 of the WATCH Manual and lights will be Type A per Section 7 -6 of the "Work Area Traffic Control Handbook" (WATCH). 7 -10.2 STREET CLOSURES DETOURS BARRICADES Street closures will not be allowed except as specifically permitted by the Engineer. The Contractor will prepare any traffic control or detour plans that may be required as directed by the Engineer. Lane transitions will not be sharper than a taper of thirty (30) to one (1). Temporary traffic channelization will be accomplished with barricades or delineators. Temporary striping will not be allowed unless specifically permitted by the Engineer. The Contractor will prepare any plans that may be required for temporary striping to the satisfaction of the Engineer. In no event will temporary striping be allowed on finish pavement surfaces, which are to remain. Where access to driveway or street crossings need to be maintained, minimum 1 1/4 inch thick steel plating will be used to bridge the trench. All steel plating will have temporary asphalt concrete 1:12 minimum sloped ramps to assist vehicles to cross comfortably over the plates and have a non -skid surface. Plates subject to vehicle high traffic speeds and in residential areas will be secured by welding at the discretion of the Engineer. 7 -10.5 PROTECTION OF THE PUBLIC It is part of the service required of the Contractor to make whatever provisions are necessary to protect the public. The Contractor will use foresight and will take such steps and precautions as his operations warrant to protect the public from danger, loss of life or loss of property, which would result from interruption or contamination of public water supply, interruption of other public service, or from the failure of partly completed work or partially removed facilities. Unusual conditions may arise on the Project which will require that immediate and unusual provisions be made to protect the public from danger or loss of life, or KHB20151022 Page 32 of 36 Agreement No. 4987 damage to life and property, due directly or indirectly to prosecution of work under this contract. Whenever, in the opinion of the Engineer, an emergency exists against which the Contractor has not taken sufficient precaution for the public safety, protection of utilities and protection of adjacent structures or property, which may be damaged by the Contractor's operations and when, in the opinion of the Engineer, immediate action will be considered necessary in order to protect the public or property due to the Contractor's operations under this contract, the Engineer will order the Contractor to provide a remedy for the unsafe condition. If the Contractor fails to act on the situation immediately, the Engineer may provide suitable protection to said interests by causing such work to be done and material to be furnished as, in the opinion of the Engineer, may seem reasonable and necessary. The cost and expense of said labor and material, together with the cost and expense of such repairs as are deemed necessary, will be borne by the Contractor. All expenses incurred by the City for emergency repairs will be deducted from the progress payments and the final payment due to the Contractor. Such remedial measures by the City will not relieve the Contractor from full responsibility for public safety, 7 -15 HAZARDOUS MATERIAL The following Subsection will be added to Section 7 of the Greenbook: For any excavation, which extends more than four feet below existing grade, the Contractor will promptly, and before the conditions are disturbed, notify the Engineer, in writing, of 1) any material that the Contractor believes may be hazardous waste, as defined in Health and Safety Code § 25117, which is required to be removed to a Class I, Class II, or Class III disposal site in accordance with provisions of existing law, 2) subsurface or latent physical conditions at the site differing from those indicated, or 3) unknown physical conditions at the site of any unusual nature, different materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract Documents. After receiving notice from the Contractor, the Engineer will promptly investigate any condition identified by the Contractor as being hazardous. The rights and obligations of the City and the Contractor with regard to such conditions (including, without limitation, the procedures for procuring change orders and filing claims) will be specified by the provisions of Subsection 3-4 (Changed Conditions) of the Greenbook. If a dispute arises between the City and the Contractor whether the conditions materially differ, involve hazardous waste, or cause a change in the KHB20151022 Page 33 of 36 Agreement No. 4987 Contractor's cost or time required for performance of the work, the Contractor will not be excused from any scheduled completion date provided for by the contract, but will proceed with all work to be performed under the contract. The Contractor will retain all rights provided by Subsection 3 -5, Disputed Work, of the Greenbook. If the Engineer determines that material called to the Engineer's attention by the Contractor is hazardous waste, or if the Engineer otherwise discovers the existence of hazardous waste, the Contractor will be responsible for removal and disposal of the hazardous waste by qualified personnel and appropriate equipment in the manner required by law as directed by the Engineer, subject to the provisions of Section 3 (Changes in Work) of the Greenbook. 9 -2 LUMP SUM WORK Subsection 9 -2, Lump Sum Work, of the Greenbook is deleted in its entirety and replaced by the following: Items for which quantities are indicated as "Lump Sum," "L.S.," or "Job" will be paid for at the price indicated in the Proposal. Such payment will be full compensation for all costs for labor, equipment, materials and plant necessary to furnish, construct and install the lump sum item of work, complete, in place, and for all necessary appurtenant work, including, but not limited to, all necessary cutting, patching, repair and modification of existing facilities, and clean up of site. Contractor will furnish three copies of a detailed schedule, which breaks down the lump sum work into its component parts and cost for each part, in a form and sufficiently detailed as to satisfy Engineer that it correctly represents a reasonable apportionment of the lump sum. This schedule is subject to approval by Engineer as to both the components into which the lump sum item is broken down, and the proportion of cost attributable to each component. This schedule will be the basis for progress payments for the lump sum work. 9 -3.2 PARTIAL AND FINAL PAYMENTS The text of Subsection 9 -3.2 of the Standard Specifications is deleted and replaced with the following: The closure date for the purpose of making partial progress payments will be the last working day of each month. The Contractor will prepare the partial payment invoice with measurement of the work performed through the closure date and submit it to the CITY for approval. When work is complete, the Contractor will determine the final quantities of the KHB20151022 Page 34 of 36 Agreement No. 4987 work performed and prepare the final progress payment, and submit it to the Engineer for approval. It will take a minimum of thirty -five (35) calendar days from the date of approving the Contractor's invoice to make the payment to the Contractor. However, payments will be withheld pending receipt of any outstanding reports required by the contract documents, or legal release of filed Stop Payment Notices against the Contractor. In addition, the final progress payment will not be released until the Contractor returns the control set of Plans and Specifications showing the as -built conditions. The full five percent (5 %) retention will be deducted from all progress payments. The Contractor will make a payment request for the retained amount, for approval by the City, upon field acceptance of the work by the City Engineer. The City Engineer upon field acceptance and receipt of the final as- built plans and any other reports or documents required to be provided by the Contractor will process a recommendation to the City Council for acceptance of the work. Not less than thirty -five (35) calendar days from the City Council acceptance of the work, the Contractor's final payment will be made provided Stop Payment Notices or other claims have not been filed against the Contractor and /or the City by material suppliers, sub - contractors, other governmental agencies, and private property owners. Until these Stop Payment Notices are released and claims are resolved the stop payment/claim amount will be withheld from the final payment. The Contractor, however, may receive interest on the retention for the length of construction, or receive the retention itself as long as the retention is substituted with escrow holder surety or equal value. At the request and expense of the Contractor, surety equivalent to the retention may be deposited with the State Treasurer, or a State or Federally chartered bank, as the escrow agent, who will pay such surety to the Contractor upon satisfactory completion of the contract. Pursuant to PCC § 22300, the Contractor may substitute securities for retention monies held by the City or request that the City place such monies into an escrow account. The Contractor is notified, pursuant to PCC § 22300, that any such election will be at the Contractor's own expense and will include costs incurred by the City to accommodate the Contractor's request. Progress payment paid by the City as contemplated herein, will be contingent upon the Contractor submitting, in addition to any additional documents, an updated Contract Schedule in the form prescribed by these Contract Documents. Failure of the Contractor to submit an acceptable updated Contract Schedule will result in the City withholding partial payment, without liability to the City, until such an acceptable updated Contract Schedule is submitted. KHB20151022 Page 35 of 36 Agreement No. 4987 Nothing herein will allow the Contractor to suspend or slow progress of the Work. A City Council resolution established a Project Payment Account, encumbered money in the current budget, and assigned that money to the Project Payment Account which is the sole source of funds available for payment of the Contract Sum. Contractor understands and agrees that Contractor will be paid only from this special fund and if for any reason this fund is not sufficient to pay Contractor, Contractor will not be entitled to payment. The availability of money in this fund, and City's ability to draw from this fund, are conditions precedent to City's obligation to make payments to Contractor. 9 -3.3 DELIVERED MATERIALS Materials and equipment delivered or stored, but not incorporated into the work, will not be approved for progress payments. 100 -1 TERMINATION OF AGENCY LIABILITY Before receiving final payment, the Contractor will execute a "Release on Contract" form which will operate as, and will be a release to the City, the City Council, and each member of the City Council and their agencies, from all claims and liability to the Contractor for anything done or furnished for, or relating to, the work or for any act of neglect of the City of any person relating to or affecting the work, except the claim against the City for the remainder, if any there be, of the amounts kept or retained as provided in Subsections 9 -3 of the Standard Specifications and except for any unsettled claims listed on said form which have been filed in compliance with the requirements for making claims. - END OF SECTION - KHB20151022 Page 36 of 36