CONTRACT 4500 One Page Service Agreement CLOSED® S1.000.000 per occurrence.
❑ 5_1_Q0.000 - 300.000 per occurrence.
❑ As required by State Statutes. A copy of your current policy must be submitted naming yourself and or your company.
® Wo t rV Compensation Insurance: as required by State Statutes. (Not needed N Self- employed with no employees and
CONTRACTOR signs.statementio this effect)
® Business License; The CONTRACTOR shag agree to have a current City of El Segundo license on file at City Hall or purchase
said license (at no cost tD the City).
❑
Permits Plans must be approved and permit(s) Issued (no fee) by the Planning and Building Safety If appropriate. Call the
Planning Manager ® (310) 5242340 if you have questions.
PLEASE NOTE ALL APPLICABLE INFORMATION USTED ABOVE MUST BE OBTAINED AND ON FLIE PRIOR TO THE ISSUANCE OF A CITY
puRcHASE ORDER BEND SENT TO YOU (VIA FAX OR HARD COPY] BY THE RISK MANAGE MRCHASING AGENT, THUS AUTHORIZING
COMME UMENT OF WORK FOR THE CRY.
Submitted by (Mmolete al blenlcel:
Including covere fo promises, product and completed operations, Ind dent contractoirs ,
n l l ,
personal Injury and contractual obligations Wth combined side limb of coverage of at least 10 0 00 per occurTe
CONTRACTOR Will rtquirs its Insurer to rnodlf� such certificates to delete any exculpatory Wording starting
that failure of the insurer to wail written it 0 lca of cancellation imposes no obligation, and to delete the word
"endeavor" with regard to any notice provisions.
Auto Uabirritr, including owned, non -owned and hired vehicles with at least
® $1,000.000 per occurrence.
❑ $100.000- 300.000 per occurrence.
As required by State Statutes. A copy of your current policy must be submitted naming yourself and or your company.
® Workers' Comoensation Insurance: as required by State Statutes. (Not needed if Self - employed with no employees and
CONTRACTOR signs statementtO this effect)
® Justness license: The CONTRACTOR shall agree to have a current City of M Segundo license on file at City Hall or purchase
said license (at no cost b the City).
❑ Pe tsi' : Plans must be approved and permit(s) issued (no fee) by the Planning and Building Safety if appropriate. Cell the
Planning Manager @ (310) 5242340 ii you have questions.
PLEASE pURCHASEO BEING 3ENT O YOUAW FAX �OR HARD COPY) BY THE RISK MANAOERFURCHASSING AGENT, THUS AUTHORIZING
COWA NCEMENT OF WORK FOR THE CITY.
Submitted 6v wadete d 1211113 l:
4 � �
City Manager, Greg Carpenter
City Cleik 1019113
City of El Segundo
1.GENERALLY. The materials, supplies, or services (collectively,
'Purchasel covered by this services agreement and purchase order
("orderl must be furnished by Seger subject to all the terms and
conditions contained in this order which Seller, in accepting this order,
agrees to be bound by and comply with in all particulars, No other terms
or conditions are binding upon the parties unless subsequently agreed to
in writing. Written acceptance or shipment of all or any portion of the
Purchase covered by this order constitutes unqualified acceptance of all
terms and conditions in this order. The terms of any proposal referred to
in this order are included and made a part of the order only to the extent
it specified the Purchase ordered, the price, and the delivery, and then
only to the extent that such terms are consistent with the terms and
conditions of this order.
2.INSPECTION. The Purchase furnished must be exactly as specified in
this order, free from all defects In Seller's performance, design,
workmanship, and materials, and, except as otherwise provided, is
subject to inspection and test by City at all times and places. If, before
final acceptance, any any Purchase is found to be incomplete, or not as
specified, City may reject it require Seger to correct it without charge, or
require delivery of such Purchase at a reduction in price that is equitable
under the circumstances. If seller is unable or refuses to correct such
items within a time deemed reasonable by City, City may terminate the
order in whole or in part. Seller bears all risks as to rejected Purchases
and, in addition to any costs for which Seller may become liable to City
under other provislons of this order, must reimburse City for all
transportation costs, other related costs incurred, or payments to Seger
In accordance with the terms of this order for unaccepted Purchases.
Notwithstanding City's acceptance of any Purchase, Seller is liable for
latent defects, fraud, or such gross mistakes as constitute fraud.
&CHANGES. City may make changes within the general scope of this
order in drawings and specifications for specially manufactured supplies,
place of delivery, method of shipment or packing of the order by giving
notice to Seller and subsequently confirming such changes in writing. If
such changes affect the cost of or the time required for performance of
this order, an equitable adjustment In the price or delivery or both must
be made. No change by Seller is allowed without City's written approval.
Any claim by Seller for an adjustment under this section must be made
In writing within thirty (30) days from the date of receipt by Seller of
notification of such change unless City waives this condition in writing.
Nothing In this section excuses Seller from proceeding with performance
of the order as changed.
4. TERMINATION. City may terminate this order at any time, either
verbally or in writing, with or without cause. Should termination occur,
City will pay Seller as full performance until such termination the unit or
pro rata order price for the performed and accepted portion of the
Purchase. City may provide written notice of termination for Seller's
default if Seller refuses or fans to comply with this order. If Seller does
not cure such failure within a reasonable time period, or fails to perform
the Purchase within the time specified (or allowed by extension). Seger
will be liable to City for any excess costs incurred by City.
5.TIME EXTENSION. City may extend the time for completion if, in
City's sole determination, Seller was delayed because of causes beyond
Seller's control and without Sellers fault or negligence. In the event
delay was caused by City, Sellers sole remedy Is limited to recovering
money actually and necessarily expended by Seller because of the
delay; there is no right to recover anticipated profrL
&REMEDIES CUMULATIVE. City's rights and remedies under this order
are not exclusive and are in addition to any rights and remedies provided
by law.
7.TITLE. Title to materials and supplies purchased under this order
pass directly from Seller to City upon City's written acceptance following
an actual Inspection and City's opportunity to relecL
Agreement No. 4500
&PAYMENT. City will pay Seller after receiving acceptable invoices for
materials and supplies delivered and accepted or services rendered and
accepted. City will not pay cartage, shipping, packaging or boxing
expenses unless specified in this order. Drafts will not be honored.
%INDEMNIFICATION. Seller agrees to indemnify and hold City
harmless from and against any claim, action, damages, costs (including,
without Ilmmilatton, aftomeys fees), Injuries, or liability, arising out of the
Purchase or the order, or their performance. Should City be named to
any suit, or should any claim be brought against it by suit or otherwise,
whether the same be groundless or not, arising out of the Purchase or
order, or their performance. Seller will defend City (at City's request and
with counsel satisfactory to City) and indemnify City for any judgment
rendered against It or any sums paid out In settlement or otherwise. For
purposes of this section 'City" Includes City's officers, elected officials,
and employees. It is expressly understood and agreed that the
foregoing provisions will survive termination of this order. The
requirements as to the types and limits of insurance coverage to be
maintained by Seller, and any approval of such insurance by City, are
not intended to and will not in any manner limit or qualify the liabilities
and obligations otherwise assumed by Seller pursuant to this order,
including, without limitation, to the provisions concerning indemnification.
10.WARRANTY. Seller agrees that the Purchase is covered by the
most favorable commercial warranties the Seller gives to any customer
for the some or substantially similar supplies or services, or such other
more favorable warranties as is specified in this order. Warranties will
be effective notwithstanding any Inspection or acceptance of the
Purchase by City.
KASSIGNMENT. City may assign this order. Except as to any
payment due under this order, Seger may not assign or subcontract the
order without City's written approval. Should City give consent, it will riot
relieve Seller from any obligations under this order and any transferee or
subcontractor will be considered Seller's agent.
12.INSURANCE. Seger must provide the insurance indicated on the
face sheet of this Services Agreement.
13.PERMITS. Seller must procure all necessary permits and licenses,
and abide by all federal, state, and local laws, for performing this order.
14.I1KIDEPENDENT CONTRACTOR. City and Seger agree that Seller
will act as an Independent contractor and will have control of all work
and the manner in which is it performed, Seller will be free to contract
for similar service to be performed for other employers while under
contract with City. Seller is not an agent or employee of City and Is not
entitled to participate In any pension plan, insurance, bonus or similar
benefits City provides for its employees. Any provision in this order that
may appear to give City the right to direct Seger as to the details of doing
the work or to exercise a measure of control over the work means that
Seller will follow the direction of the City as to end results of the work
only.
15.WAiVER. City's review or acceptance of, or payment for, work
product prepared by Seller under this order will not be construed to
operate as a waiver of any rights City may have-under this Agreement or
of any cause of action arising from Seller's performance. A waiver by
City of any breach of any term, covenant, or condition contained in this
order will not be deemed to be a waiver of any subsequent breach of the
same or any other temp, covenant, or condition contained in this order,
whether of the some or different character.
%INTERPRETATION. This Agreement was drafted in, and will be
construed in accordance with the laws of the State of California, and
exclusive venue for any action involving this agreement will be in Los
Angeles County.
1018113
Party Posies Floral
Floral & Event Planning
Agreement No. 4500
Qq,%ZbA:+ k
Theme The theme this year is "Traditional Classics" Going back in time
were simplicity is classy using the colors of shades of red and gold and lite
accent of green. An assortment of ribbon sizes will be used to complement
all ddcor.
* Ornaments- A spectacular Red & Green Christmas Tree with 10,000 fog
lights that shows the tradition of Christmas. This 21 -22 Ft. tree will be
decorated in large red and gold ornaments, and gift box ornaments and a
touch of green accents.
Rental Price: $2000.00
Total Cost: $2000.00
Service Fee: 200.00
Sub Total $ 2200.00
Total Project: S 2200.00
Deposit to save the date: $1000.00
Balance Due/Date: $1000.00 November 30, 2013
1311 Sartori Ave., CA 90501
Phone: (310) 378-1018 Fax. (310) 320 -3450
Party Posies Floral
Floral & Event Planning
This is To Confirm the Date and Delivery
Event: El Segundo Tree Lighting Ceremony
Date: Tuesday, December 3, 2010 --
Location: 350 Main Street ( Court Yard City Hall)
El Segundo, CA 90245
Contact Person: Meridith Phone: (310) 524 -2880
Time Line
Tuesday, December 3
Wednesday, December 4
Please Confirm:
Contact,, Date
Agreement No. 4500
- Mobile Basket delivery
8:00 am -10:00 am
- Decoration of tree 11:00 am-
5:00pm
- Decoration of tree 8:00am-
5:00pm
- Completion by 6:00am
- If Needed
Anita Pardo, Date
1311 Sartori Ave., CA 90501
Phone; (310) 378 -1018 Fax.• (310) 320 -3450