Loading...
CONTRACT 3492 Other CLOSEDContract Number: 3492 mpan RESIDENTIAL SOUND INSULATION PROGRAM CONTRACT BETWEEN THE CITY OF EL SEGUNDO AND S &L SPECIALTY CONTRACTING, INC. This CONTRACT is entered into this 21St day of June, 2005, by and between the CITY OF EL SEGUNDO, a general law city and municipal corporation ( "the City ") and S &L Specialty Contracting, Inc. ( "the Contractor "). 1. WORK. A. The Contractor will provide all work required by the Contract Documents (the "Work "). The Contractor agrees to do additional work arising from changes ordered by the City in accordance with the Contract Documents. B. The Contractor and the City agree to abide by the terms and conditions contained in the Contract Documents; C. The Contractor will furnish all of the labor; supplies and materials; equipment; printing; vehicles; transportation; office space and facilities; all tests, testing and analyses; and all matters whatsoever (except as otherwise expressly specified to be furnished by the City) needed to perform and complete the Work and provide the services required of the Contractor by the Contract Documents. D. "Contract Documents" means the Notice Inviting Bids; Instructions to Bidders; Supplementary Instructions to Bidders; Proposal; this Contract; Standard Specifications; Supplementary Conditions; Exhibits; Technical Specifications; List of Drawings; Drawings; Addenda; Notice to Proceed; Change Orders; Notice of Completion; and all other documents identified in the Contract Documents which together form the contract between the City and the Contractor for the Work. The Contract Documents constitute the complete agreement between the City and the Contractor and supersede any previous agreements or understandings. 2. CONTRACT SUM. The City agrees to pay the Contractor a sum not to exceed One million, one hundred fifteen thousand dollars and zero cents ($1,115,000.00) for the Work in the manner set forth in the Contract Documents. The City may adjust this amount as set forth in the Contract Documents. 3. TIME FOR PERFORMANCE. A. The Contractor will fully complete the Work within one hundred and forty (140) calendar days (the "Contract Time. ") RSI Program Contract (6/21/2005) Contract Number: 3492 B. The Contract Time will commence when the City issues a notice to proceed. The Contract Documents will supersede any conflicting provisions included on the notice to proceed issued pursuant to this Contract. C. The Contractor shall not perform any Work until: i. The Contractor furnishes proof of insurance as required by the Contract Documents; and ii. The City gives the Contractor a written, signed, and numbered purchase order and notice to proceed. D. By signing this Contract, the Contractor represents to the City that the Contract Time is reasonable for completion of the Work and that the Contractor will complete the Work within the Contract Time. E. Should the Contractor begin the Work before receiving written authorization to proceed, any such Work is at the Contractor's own cost and risk. 4. DISPUTES. Disputes arising from this contract will be determined in accordance with the Contract Documents and Public Contracts Code §§ 10240 - 10240.13. 5. TAXPAYER IDENTIFICATION NUMBER. The Contractor will provide the City with a Taxpayer Identification Number. 6. PERMITS AND LICENSES. Unless otherwise provided, the Contractor, at its sole expense, will obtain and maintain during the Contract Time, all necessary permits, licenses, and certificates that may be required in connection with the Work. 7. OWNERSHIP OF DOCUMENTS. All documents, data, studies, drawings, maps, models, photographs and reports prepared by the Contractor under the Contract Documents are the City's property. The Contractor may retain copies of said documents and materials as desired, but will deliver all original materials to the City upon the City's written notice. 8. INDEMNIFICATION. The Contractor agrees to indemnify and hold the City harmless as set forth in the Contract Documents. The requirements as to the types and limits of insurance coverage to be maintained by the Contractor as required by the Contract Documents, and any approval of such insurance by the City, are not intended to and will not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Contractor pursuant to the Contract Documents, including, without limitation, to the provisions concerning indemnification. 9. INDEPENDENT CONTRACTOR. The City and the Contractor agree that the Contractor will act as an independent contractor and will have control of all work and the manner in which is it performed. The Contractor will be free to contract for similar service to be performed for other employers while under contract with the City. The Contractor is not an agent or employee RSI Program Contract (6/21/2005) ,T VV oA f SE`Ut�O Contract Number: 3492 of the City and is not entitled to participate in any pension plan, insurance, bonus or similar benefits the City provides for its employees. Any provision in this Contract that may appear to give the City the right to direct the Contractor as to the details of doing the work or to exercise a measure of control over the work means that the Contractor will follow the direction of the City as to end results of the work only. 10. AUDIT OF RECORDS. The Contractor will maintain full and accurate records with respect to all services and matters covered under this Contract. The City will have free access at all reasonable times to such records, and the right to examine and audit the same and to make transcript therefrom, and to inspect all program data, documents, proceedings and activities. The Contractor will retain such financial and program service records for at least three (3) years after termination or final payment under the Contract Documents. 11. NOTICES. All communications to either party by the other party will be deemed made when received by such party at its respective name and address as follows: The City The Contractor James S. O'Neill James W. Leana City of El Segundo S &L Specialty Contacting, Inc. City Hall 472 South Salina Street 350 Main Street Suite 400 El Segundo, CA 90245 Syracuse, NY 13202 Any such written communications by mail will be conclusively deemed to have been received by the addressee three (3) days after deposit thereof in the United States Mail, postage prepaid and properly addressed as noted above. In all other instances, notices will be deemed given at the time of actual delivery. Changes may be made in the names or addresses of persons to who notices are to be given by giving notice in the manner prescribed in this paragraph. 12. NO THIRD PARTY BENEFICIARY. This Contract and every provision herein are for the exclusive benefit of the Contractor and the City and not for the benefit of any other party. There will be no incidental or other beneficiaries of any of the Contractor's or the City's obligations under this Contract. 13. INTERPRETATION. This Contract was drafted in, and will be construed in accordance with the laws of the State of California, and exclusive venue for any action involving this Contract will be in Los Angeles County. 14. EFFECT OF CONFLICT. In the event of any conflict, inconsistency, or incongruity between any provision of the Contract Documents, precedence will be as follows: A. This Contract; B. Precedence of documents as determined in the Standard Specifications. RSI Program Contract (6/21/2005) Y O, v Contract Number: 3492 15. SEVERABILITY. If any portion of the Contract Documents are declared by a court of competent jurisdiction to be invalid or unenforceable, then such portion will be deemed modified to the extent necessary in the opinion of the court to render such portion enforceable and, as so modified, such portion and the balance of this Contract will continue in full force and effect. 16. AUTHORITY/MODIFICATION. The Parties represent and warrant that all necessary action has been taken by the Parties to authorize the undersigned to execute this Contract and to engage in the actions described herein. This Contract may be modified by written amendment. The City's city manager, or designee, may execute any such amendment on the City's behalf. 17. ACCEPTANCE OF FACSIMILE SIGNATURES. The Parties agree that this Contract, agreements ancillary to this Contract, and related documents to be entered into in connection with this Contract will be considered signed when the signature of a party is delivered by facsimile transmission. Such facsimile signature will be treated in all respects as having the same effect as an original signature. 18. COVENANTS AND CONDITIONS. The parties agree that all of the provisions hereof will be construed as both covenants and conditions, the same as if the words importing such covenants and conditions had been used in each separate paragraph. 19. CAPTIONS. The captions of the paragraphs of this Contract are for convenience of reference only and will not affect the interpretation of this Contract. 20. TIME IS OF ESSENCE. Time is of the essence for each and every provision of the Contract Documents. 21. COMMUNITY DEVELOPMENT BLOCK GRANT REQUIREMENT This is a federally assisted construction contract and Federal labor standards, including Davis - Bacon requirements, will be enforced. If Federal and State wage rates are applicable, then the higher of the two will prevail. [Signatures on next page] RSI Program Contract (6/21/2005) Contract Number: 3492 IN WITNESS WHERE OF the parties hereto have executed this contract the day and year first hereinabove written. CITY OF EL SEGUNDO: A general law city and municipal corporation By: CIO e tewart � City Manager ATTEST: By: Cindy Wrtesen City Clerk APPROVED MARK D. H: By: g 1 Berger, Assistant City Attoi RSI Program Contract (6/21/2005) CONTRACTOR: S &I Taxpayer ID Number Contractor State License Number Contractor City Business License Number 14- 1825100 796968 23197 THE AMERICAN INSTITUTE OF ARCHITECTS '�1 {n dui Bond #104528615 AIA Document A312 Performance Bond 3492 • • L Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. CONTRACTOR (Name and Address): S & L Specialty Contracting Inc. 472 So. Salina, St., Suite 400 Syracuse, NY 13202 OWNER (Name and Address): City of El Segundo City Hall 350 Main Street El Segundo, CA 90245 SURETY (Name and Principal Place of Business): Travelers Casualty and Surety Company of America 499 Thornall Street Edison, NJ 08837 CONSTRUCTION CONTRACT Date: June 21, 2005 Amount: $1,115,000.00 Description (Name and Location): Residential Sound Insulation Program - Group 6 Contract #3492 BOND Date (Not earlier than Construction Contract Date): July 25, 2005 Amount: $1,115,000.00 Modifications to this Bond: None ❑ See Page 3 CONTRAC RINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) S & L Speci Contractin , INC. Travelers Casualty and Surety Company of America Signature: Name and Titl (Any additional es res appear 4n page 3) Signatur ;kt44 Name and Title: Richard H. Hunt, Attorney -in -Fact (FOR INFORMATION ONLY - Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or R. H. Hunt & Associates, Inc. other party): 15 Meridian Road Eatontown, NJ 07724 Tel: 732 - 578 -9408 AIA DOCUMENT A312 • PERFORMANCE BOND AND PAYMENT BOND • DECEMBER 1984 ED. • AIA THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A312 -1984 1 THIRD PRINTING • MARCH 1987 1 The Contractor and the Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except to participate in conferences as provided in Subparagraph 3.1. 3 If there is no Owner Default, the Surety's obligation under this Bond shall arise after: 3.1 The Owner has notified the Contractor and the Surety at its address described in Paragraph 10 below that the Owner is considering declaring a Contractor Default and has requested and attempted to arrange a conference with the Contractor and the Surety to be held not later than fifteen days after receipt of such notice to discuss methods of performing the Construction Contract. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; and 3.2 The Owner has declared a Contractor Default and formally terminated the Contractor's right to complete the contract. Such Contractor Default shall not be declared earlier than twenty days after the Contractor and the Surety have received notice as provided in Subparagraph 3.1; and 3.3 The Owner has agreed to pay the Balance of the Contract Price to the Surety in accordance with the terms of the Construction Contract or to a contractor selected to perform the Construction Contract in accordance with the terms of the contract with the Owner. 4 When the Owner has satisfied the conditions of Paragraph 3, the Surety shall promptly and at the Surety's expense take one of the following actions: 4.1 Arrange for the Contractor, with consent of the Owner, to perform and complete the Construction Contract; or 4.2 Undertake to perform and complete the Construction Contract itself, through its agents or through independent contractors; or 4.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and the contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Paragraph 6 in excess of the Balance of the Contract Price incurred by the Owner resulting from the Contractor's default; or 4.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: 1 After investigation, determine the amount for which it may be liablat4tlg 2vngr nd;NM soon as practicable after the amount' iW determined, tender payment therefor to the Owner; or .2 Deny liability in whole or in part and notify the Owner citing reasons therefor. 5 If the Surety does not proceed as provided in Paragraph 4 with reasonable promptness, the Surety shall be deemed to be in default on this Bond fifteen days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the surety proceeds as provided in Subparagraph 4.4, and the Owner refuses the payment tendered or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. 6 After the Owner has terminated the Contractor's right to complete the Construction Contract, and if the Surety elects to act under Subparagraph 4.1, 4.2, or 4.3 above, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. To the limit of the amount of this Bond, but subject to commitment by the Owner of the Balance of the Contract Price to mitigation of costs and damages on the Construction Contract, the Surety is obligated without duplication for: 6.1 The responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; 6.2 Additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Paragraph 4; and 6.3 Liquidated damages, or if not liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non- performance of the Contractor. 7 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators or successors. 8 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. 9 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. AIA DOCUMENT A312 • PERFORMANCE BOND AND PAYMENT BOND • DE CEMBER 1984 ED. • AIA THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A312 -1984 2 THIRD PRINTING • MARCH 1987 10 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the signature page. 11 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory bond and not as a common law bond. 12 DEFINITIONS 12.1 Balance of the Contract Price: The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: 3492 • • �J by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. 12.2 Construction Contract: The agreement betwen the Owner and the Contractor identified on the signature page, including all Contract Documents and changes thereto. 12.3 Contractor Default: Failure of the Contractor, which has neither been remedied nor waived, to perform or otherwise to comply with the terms of the Construction Contract. 12.4 Owner Default: Failure of the Owner, which has neither been remedied nor waived, to pay the Contractor as required by the Construction Contract or to perform and complete or comply with the other terms thereof. (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Name and Title: Address: Signature: Name and Title: Address: AIA DOCUMENT A312 • PERFORMANCE BOND AND PAYMENT BOND • DECEMBER 1984 ED. • AIA THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A312 -1984 THIRD PRINTING • MARCH 1987 THE AMERICAN INSTITUTE OF ARCHITECTS 34 9 2 ' Bond # 104528615 AIA Document A312 Payment Bond Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. CONTRACTOR (Name and Address): S & L Specialty Contracting, Inc. 472 So. Salina St., Suite 400 Syracuse, NY 13202 OWNER (Name and Address): City of El Segundo City Hall 350 Main Street El Segundo, CA 90245 CONSTRUCTION CONTRACT Date: June 21, 2005 Amount: $1,115,000.00 Description (Name and Location): SURETY (Name and Principal Place of Business): Travelers Casualty and Surety Company of America 499 Thornall Street Edison, NJ 08837 Residential Sound Insulation Program — Group 6 Contract #3492 BOND Date (Not earlier than Construction Contract Date): July 25, 2005 Amount: $1,115,000.00 Modifications to this Bond: CONTRACTOR AS PRINCIPAL Company: (Corporate Seal) S & L Speci y Co actPu, Inc. Signature: Name and (Any additional on page 6) ✓ None SURETY ❑ See Page 6 Company: (Corporate Seal) Travelers Casualty and Surety Company of America Signaturee. I1 �L�a�►r y� �� ZC7'uf Name and Title: Richard H. Hunt, Attorney -in -Fact (FOR INFORMATION ONLY- Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or R.H. Hunt & Associates, Inc. other party): 15 Meridian Road Eatontown, NJ 07724 Tel: 732 - 578 -9408 AIA DOCUMENT A312 - PERFORMANCE BOND AND PAYMENT BOND - DECEMBER 1984 ED. - AIA THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A312 -1984 4 THIRD PRINTING - MARCH 1987 1 The Contractor and the Surety, jointly and severally, bind successors and assigns to the Owner to pay for labor, themselves, their heirs, executors, administrators, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference. 2 With respect to the Owner, this obligation shall be null and void if the Contractor: 2.1 Promptly makes payment, directly or indirectly, for all sums due Claimants, and 2.2 Defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity whose claim, demand, lien or suit is for the payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, provided the Owner has promptly notified the Contractor and the Surety (at the address described in Paragraph 12) of any claims, demands, liens or suits and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety, and provided there is no Owner Default. 3 With respect to Claimants, this obligation shall be null and void if the Contractor promptly makes payment, directly or indirectly, for all sums due. 4. The Surety shall have no obligation to Claimants under this Bond until: 6 When the Claimant has satisfied tFie conditieme" Paragraph 4, the Surety shall promp(y4n&at`the Surety's 6 - expense take the following actions: 6.1 Send an answer to the Claimant, with a copy to the Owner, within 45 days after receipt of the claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed. 6.2 Pay or arrange for payment of any undisputed amounts. 7 The Surety's total obligation shall not exceed the amount of this Bond, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. 8 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any Construction Performance Bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and the Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. 4.1 Claimants who are employed by or have a direct 9 The Surety shall not be liable to the Owner, Claimants or contract with the Contractor have given notice to the others for obligations of the Contractor that are unrelated to Surety (at the address described in Paragraph 12) and the Construction Contract. The Owner shall not be liable for sent a copy, or notice thereof, to the Owner, stating payment of any costs or expenses of any Claimant under that a claim is being made under this Bond and, with this Bond, and shall have under this Bond no obligations to substantial accuracy, the amount of the claim. make payments to, give notices on behalf of, or otherwise have obligations to Claimants under this Bond. 4.2 Claimants who do not have a direct contract with the Contractor: .1 Have furnished written notice to the Contractor and sent a copy, or notice thereof, to the Owner, within 90 days after having last performed labor or last furnished materials or equipment included in the claim stating, with substantial accuracy, the amount of the claim and the name of the party to whom the materials were furnished or supplied or for whom the labor was done or performed; and .2 Have either received a rejection in whole or in part from the Contractor, or not received within 30 days of furnishing the above notice any communication from the Contractor by which the Contractor has indicated the claim will be paid directly or indirectly; and .3 Not having been paid within the above 30 days, have sent a written notice to the Surety (at the address described in Paragraph 12) and sent a copy, or notice thereof, to the Owner, stating that a claim is being made under this Bond and enclosing a copy of the previous written notice furnished to the Contractor. 5 If a notice required by Paragraph 4 is given by the Owner to the Contractor or to the Surety, that is sufficient compliance. 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. 11 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the location in which the work or part of the work is located or after the expiration of one year from the date (1) on which the Claimant gave the notice required by Subparagraph 4.1 or Clause 4.2.3, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the signature page. Actual receipt of notice by Surety, the Owner or the Contractor, however accomplished, shall be sufficient compliance as of the date received at the address shown on the signature page. 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirements shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. The intent is that this AIA DOCUMENT A312 • PERFORMANCE BOND AND PAYMENT BOND • DECEMBER 1984 ED. • AIA THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A312 -1984 5 THIRD PRINTING • MARCH 1987 Bond shall be construed as a statutory bond and not as a common law bond. 14 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor shall promptly furnish a copy of this Bond or shall permit a copy to be made. 15 DEFINITIONS 15.1 Claimant: An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Contract. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: 3492 in the Construction Contract, architectural 'and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. 15.2 Construction Contract: The agreement between the Owner and the Contractor identified on the signature page, including all Contract Documents and changes thereto. 15.3 Owner Default: Failure of the Owner, which has neither been remedied nor waived, to pay the Contractor as required by the Construction Contract or to perform and complete or comply with the other terms thereof. (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Name and Title: Address: Signature: Name and Title: Address: AIA DOCUMENT A312 • PERFORMANCE BOND AND PAYMENT BOND • DECEMBER 1984 ED. • AIA THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A312 -1984 6 THIRD PRINTING • MARCH 1987 TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA 34 9 2 TRAVELERS CASUALTY AND SURETY COMPANY FARMINGTON CASUALTY COMPANY Hartford, Connecticut 06183 -9062 POWER OF ATTORNEY AND CERTIFICATE OF AUTHORITY OF ATTORNEY(S) -IN-FACT KNOW ALL PERSONS BY THESE PRESENTS, THAT TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY, corporations duly organized under the laws of the State of Connecticut, and having their principal offices in the City of Hartford, County of Hartford, State of Connecticut, (hereinafter the "Companies ") hath made, constituted and appointed, and do by these presents make, constitute and appoint: Richard H. Hunt, of Eatontown, New Jersey, their true and lawful Attorney(s) -in -Fact, with full power and authority hereby conferred to sign, execute and acknowledge, at any place within the United States, the following instrument(s): by his /her sole signature and act, any and all bonds, recognizances, contracts of indemnity, and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking and any and all consents incident thereto and to bind the Companies, thereby as fully and to the same extent as if the same were signed by the duly authorized officers of the Companies, and all the acts of said Attorney(s) -in -Fact, pursuant to the authority herein given, are hereby ratified and confirmed. This appointment is made under and by authority of the following Standing Resolutions of said Companies, which Resolutions are now in full force and effect: VOTED: That the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint Attorneys -in -Fact and Agents to act for and on behalf of the company and may give such appointee such authority as his or her certificate of authority may prescribe to sign with the Company's name and seal with the Company's seal bonds, recognizances, contracts of indemnity, and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking, and any of said officers or the Board of Directors at any time may remove any such appointee and revoke the power given him or her. VOTED: That the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President may delegate all or any part of the foregoing authority to one or more officers or employees of this Company, provided that each such delegation is in writing and a copy thereof is filed in the office of the Secretary. VOTED: That any bond, recognizance, contract of indemnity, or writing obligatory in the nature of a bond, recognizance, or conditional undertaking shall be valid and binding upon the Company when (a) signed by the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary and duly attested and sealed with the Company's seal by a Secretary or Assistant Secretary, or (b) duly executed (under seal, if required) by one or more Attorneys -in -Fact and Agents pursuant to the power prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority. This Power of Attorney and Certificate of Authority is signed and sealed by facsimile (mechanical or printed) under and by authority of the following Standing Resolution voted by the Boards of Directors of TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY, which Resolution is now in full force and effect: VOTED: That the signature of each of the following officers: President, any Executive Vice President, any Senior Vice President, any Vice President, any Assistant Vice President, any Secretary, any Assistant Secretary, and the seal of the Company may be affixed by facsimile to any power of attorney or to any certificate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attorneys -in -Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof, and any such power of attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding upon the Company in the future with respect to any bond or undertaking to which it is attached. (11 -00 Standard) -`4 TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA HARTFORD, CONNECTICUT 06183 FINANCIAL STATEMENT AS OF DECEMBER 31, 2004 CAPITAL STOCK $6,000,000 CASH & INVESTED CASH $ 2,721,251 UNEARNED PREMIUMS $ 517,322,210 BONDS 2,103,575,828 LOSSES 542,595,315 STOCK 11,873,755 LOSS ADJUSTMENT EXPENSES 97,587,047 OTHER INVESTED ASSETS - COMMISSIONS 19,228,115 INVESTMENT INCOME DUE AND ACCRUED 24,085,845 TAXES, LICENSES AND FEES 10,738,457 PREMIUM BALANCES 139,148,258 OTHER EXPENSES 18,724,529 REINSURANCE RECOVERABLE 48,827,434 CURRENT FEDERAL AND FOREIGN INCOME TAXES 43,827,236 CURRENT FEDERAL INCOME TAX RECOVERABLE - PAYABLE FOR SECURITIES NET DEFERRED TAX ASSET 37,424,124 PAYABLE TO PARENT, SUBSIDIARIES 6 AFFILIATES 35,395,260 RECEIVABLE FOR SECURITIES 300,000 OTHER ACCRUED EXPENSES AND LIABILITIES 139,342 8.53 RECEIVABLE FROM PARENT, SUBSIDIARIES & AFFILIATES - TOTAL LIABILITIES —$1,424,761,023 OTHER ASSETS (72,723,020) CAPITAL STOCK S 6,000.000 PAID IN SURPLUS 303,297,402 OTHER SURPLUS 561,175,050 TOTAL SURPLUS TO POLICYHOLDERS $ 870,472,452 TOTAL ASSETS 32,295 233,475 TOTAL LIABILITIES & SURPLUS $2,295,233,475 STATE OF CONNECTICUT COUNTY OF HARTFORD )SS. CITY OF HARTFORD LAWRENCE A. SIUTA, BEING DULY SWORN, SAYS THAT HE IS CHIEF FINANCIAL OFFICER - BOND, OF THE TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, AND THAT TO THE BEST OF HIS KNOWLEDGE AND BELIEF, THE FOREGOING IS A TRUE AND CORRECT STATEMENT OF THE FINANCIAL CONDITION OF SAID COMPANY AS OF THE 31st DAY OF DECEMBER, 2004. SUBSCRIBED AND SWORN TO BEFORE ME THIS 24TH DAY OF MARCH, 2005 �y c. TE r,, , "h.ONN:Crticll �� A CHIEF FINANCIAL OFFICER - BOND '0(\ck,�;, C �intalr`�- NOTARY PUBLIC ' MY COWSSION EXPIRES JUNE 30, 2066 34 92 SQRETY DISCLOSMIM STAT1RSvtENT MM ^a'RTIFICAnQN (for use when surety(its) have a eenifrcatt !i muU Sn N.J.S. ,44.143 Secretary of the Treasury in accordance with 31 U.S.C. section 9303) Travelers Casualty and Surety Company, Travelers Iddemnity Company, Standard Fire Insurance Company, Travelers Casualty and Surety Company of Illinois, Travelers Casualty and Surety Company of America, Farmington Casualty Company, suretp(ies) on the attached bond, hereby certifies(y) the following: 1) The surety(ies) meets (meet) the applicable capital and surplus requirements of R. S.17 :17-6 or R.S.17 :17.7 as of the surety's moat Current annual Ming with the New Jersey Department of Ins=nce. 2) The capital and surplus, as dotcMuned in 30e0rd"04 with the applicable laws of this State, of the turety(ies) participating in the issuance of the attached bond is (arc) in the following amounts u of the calendar year ended December 31, 2002 (moat recent calendar year which capital and Surplus amounts are available), which amounts have been certified on a Consolidated Certification by ,KPMG Peat Marwick LLP, Mart/ord, Cmnedicur and art included in the Annual Statement on flit with the New Jersey Department of Insurance, 20 West State Street CN -32S, Trenton, New Jersey 086250323. srrev cam"eu Traveleae Uw m ly carp" 510,0001000 cYM19 $3,96),726,203 Travelsn Qwa* wad awety compm,y $23,000,000 $2472,746,429 surA&M pin saau..e.a C°,^P,,,,Y Trvelan Cawahy end SWM CoaWMY atAeraiaa ss,000,000 $6,000,000 $741,632.010 $707,744,210 TftV*laa Caauahy and surd' Compeey of Illinois Banta „Ca 46* $6,000,000 5332,323,060 0' $6.000,000 f173,49S,143 3) With respect to each surety participating in the issuance of the attached bond that has received from the U.S. Secretary of the Treasury, a certificate of authority pursuant to 31 U,S.C, Section 9305, the underwriting limitation established there on July 1, 2003 (mast recent calendar year available) is AS tollowS. -Iwo ca"ta"v Tnvolan kWUM4 CORMY '$$avatars Caawtty am8urety Canp+"Y Stun W Fire Insurance company Tlrayslas Casualty and Lw* Campuy or America F.r v Company Illinois 4) The aatount of the bond to which the statement and certification is attach S357,961,000 3169,132,000 $74,165,000 570,774,000 $33,23,000 $17,349,000 ed is S / //,S L -i-4L ._ 5) If, by virtue of one or more contracts of reinsurtlnee, the amount of the bond indicated under Item 4 above exceeds the total underwriting limitation of all Sureties on the bond as set forth in Item 3 above, then for each such contact of reinsurance; A) The name and address of each such reimutr under that contract and the amount of the reinsurer's participation in the contact is as follows; and; Ra Addrarr ATOP b) Each Surety that is party to such contract of reinsurance car les that each reinaurer listed tinder Item 5(a) satisfies the credit for reinsurance requirtment established under P.L.1993, 0.143(C.17:31B•1 et Seq.) and any applicable regulations in effect as of the date on which the bond to which this statement and certification is attached shell have been filed with the appropriate public agency. 0=10 rE I. Kari K Johanson, As Attorney -in -Fact for Travelers Casualty and Surety Company, A corporation domiciled in Connecticut, DO HEREBY CERTIFY that, to the best of my knowledge, the foregoing statements made are true, ACKNOWLEDGE that, if any of those Statements made by me are false, this bore! is VOIDABLE. (Si nature of ce ng Agont/offic er) Date: Q k Z l Zt3d Koh M. Johanson (Print name of certifying agenttofficer)� Asdatant SecrelM (Title of certifying agent/officer) TO 'd Sb:Clt 0007 T9 ZS �12W RTTF7FA77C', :x12 4 TR�?�,iE_tRS Fax : 7,24949118 Feb i6 �'': ! 1 i2 : 0 STATE OF CALZFORN A DEPARTMENT OF INSURANCE SAN FRANCISCO Amended Certificate of Authority F'. -'C. 3492. N2 65 -16 TWS Is TO Caftan, That, pursuant to the Insurance Code of the State of California, Travelers Casualty and Surety Company of America . • , of Hartford, Connecticut , organized under the laws of Connecticut , subject to its Articles of Incorporation or other ft$ndamentd organizational documents, is hereby authorized to transact within this State, subject to all provisions of thW Cert*ate, the following classes of insurance: Fire, Marine, Surety, Disability, Plate Glass, Liability, Workers' CompenSation, Common Carrier Liability, $oiler and Machinery, 9urglary, Credit, Sprinkler, Team and. Vehicle, Automobile, Aircraft, and Miscellaneous as such classes are now or may hereafter be defined in the Insurance Yaws of the State of California. Tits t;sataxtCAT$ is expressly conditioned Upon the holder hereof now and hereafter being in full compliance with all, and not in violation of any, of the applicable lawn and lawful requiremetnt# made under authority of the laws of the State of Cali f vrnia as long as such laws or requirements are in efe,t and applicable, and as such laws and'requirements now are, or may hereafter be changed or at"anded. Ix WrrN%ss Ww=or, e$Qctit)e as of the........1 t,.............day 1,912—, 1 have hereunto act my hand and caused my official Seal to be affixed day o f 19ai.. By Ef of State must be iwooa+ 4hed st requited�4Y l�itD� promptly tdtw b aanoe of this CettiBoste of Authority. Failure to do so ws1! be a vioLeioo of Ins. and w111 bc'swwds tot revoldNIS this Grtl0vate of Authority pueru"t to tl+e covensnts made is therefor and the coodkioos contained herein. r Code :. 701 u Owl Q5/30/2005 22:59 3154718807 S &L WICKER BIIIDERS'S PROPOSAL AND STATEMENT CITY OF EL SEGUNDO, LOS ANGELES COUNTY, CALIFORNIA Project Number RSI 05-07 "Residential Sound insulation Program -- Group 6" PROPOSAL To the Mayor and City Council City of El Segundo 350 Main St. El Segundo. CA 90243 PAGE 01/05 3492. The undersigned declares that he /she has carefully examined the location of the proposed work and has otherwise satisfied himself/herself as to the nature and location of the work. and is full informed as to all conditions and matters which can in any way affect the work or cost thereof, that he!she has examined the Contract Documents, and has read the accompanying "BIDDING INSTRUMONS" and hereby agrees to provide the following. To furnish all labor. materials. equipment, transportation. and services and to do all the work required for the "Residential Sound insulation Program - Group 6" in strict conformity with the Contract Documents and at the following lump sum price, to Wit: ID Address Description Cost Property Subtotal 6.01 770 vv. Imperial Ave. 403 RSI Improvements I $ •°'° $ �S `-" 6.0' 770 W. imperial A%-c. #07 RSJ Improvements I SAS- '°" S A ISI=. 6.0 , 770 W. Im erial Ave. 031 RSI Improvements S 6.04 770 W. Imperial Ave. k43 RSI Improvements 1 $ ';z mg7o I $ 2s 'M 6.05 77U W. Imperial Ave. #5� RSI Improvements $ z4 ism $ 2 `° 6.06 '10 W Imperial Ave. 002 ,RSI Im rovements I $ V%X '° $ V.I. 10M-Q 0.67 212 E. Imperial Ave. C RSJ Improvements Tint windows and Doors B 8 C l: pgrade door A from EP 19 t() [;P7 S z tmo SJSD. . $ 6.08 926 E. lm eriaf Ave. #0l RSr Im rovcments ' S $ k 6.09 926 E. lm erial Ave. #02 RSI Improvements 1 S °°i S VA KMD °O 6.10 926 E. Imperial Ave. M03 RSI Improvements Provide ne "• window at Window #4 S \55�Oit I $�I Is 5 "XS°° 6.1 1 926 E. imperial Ave. #04 RSI Improvements $ - m-.Tzm °' $ t M 6.12 976 E. Imperial Ave. #05 i RSI Improvements I $ �� $ V ; Z. -0 6.13 936 E. Imperial Ave. #06 RSI Im rovements $ 1 5'23,`200-5 I Addendum #I 05/30/2005 22:59 3154718807 S &L WICKER PAGE 02/05 3492 . 6.14 1103 E. Acacia Ave. 903 Cedar St. 907 Cedar St. 911 Cedar St. ; 941 Dune St. RSI Im rovements RSI Imp RSI Improvements RSI Improvements RSI Improvements $ $ .�, $ fSA $ °4 S `� $ $ AMC $ "14 CW00 $1►. 6.15 6.16 6.17 6.18 Upgrade doors A & 13 from EP 15 to EP 17 6.19 6.20 845 Eucal tus Dr. 861 Eucalyptus Dr. RSI Imp rovements RSI Improvements $ $`oO $ � $ ANKMF 7 Provide new window at Window 01 (with nlles) $ ��� 6.21 862 Eucalyptus Dr. RSI improvements $ �' At� co $ �J. = Provide new window at Window 420 Provide new window at Window #21 and #22 Provide new window at Window #23 $ z� 6.2' 917 1 {illcrest St. RSl improvements $ "Z "" $'3 td'"O 6.2: 906 Loma Vista St. RS1 mp rovements $ I& $ Z .4M Upgrade door B from EP 15 and S L I to EP 17 $ Air Conditioning URgride $°"' 6,24 915 Loma Vista St. RSI Im rdvements $ '�°� � MrA $ trz 6.2; 912 Lomita St. ' RSI lm rovements $ $ ":J CCU— 6.26 935" Main St. #304 1 RSI Improvements $ M ILQ0°" $ '°° '6.27 6.28 6.29 618 %'. Ma le Ave. 912 McCarthy Ct, 709 Redwood Ave. : RSI Improvements 1 RSI Improvements I RSl Improvements $ "j3 '°' $ 4° $ '°° $ "?s' °b $' 'C 0►°° $ MP 6.30 9:7 Sheldon St. 1 RSI Improvements 6.31 944 Sheldon St. RSI lm rovcments 6.: _' 116 W. Sycamore Ave. RS1 Improvements $ t'i1OCtw $ sZ t CSCD• 6.3 1 2310 W. Sycamore Avc. ' RSI improvements Air Conditionin Uegrade $ '�A tcwcu s, $ $ 500 6. 14 641 W. Sycamore Ave. RSI Improvements R10 Virginia St. RSl Improvements, $ "� CxD`a $ 3'.a �° 6.36 901 Virginia-S)- i RSI lm rovements t:pgmde door A from i EP 15 to EP 17 with sidelites and grilles $ $ � 637 941 Virginia St. RSI Im rovements $ C "4 $ -Sk" '- 6.38 941 V., Virginia St. RSI Improvements Upgrade door A from EP 19 to EP7 $ � $ �'.� $ .23 "2005 2' Addendum #I . t 05/30/2005 22:59 3154718807 S &L WICKER PAGE 03/05 3492 . . 4 �Total Bid (`Contract Sum) (words) (figures) In case of discrepancy between the words and figures. the words must prevail. unTirF- RrnnFRS WILL NOT BE RELEASED DUE TO ERRORS AND ILLEGIBLE BIDS MUST BE DISQUALIFIED NOTICE: Total Bid (Contract Sum) must equal the total of Schedule of Values. If the Total Bid does not equal the total of the Schedule of Values, it is grounds for rejection of the Bid. Furthermore, inconsistencies between the Schedule of Values and the Plans for each Dwelling are grounds for rejection of the Bid This bid is based upon completing•the'work as set in the Construction Schedule published in the Contract Documents. If awarded the contract for the Work, the undersigned hereby agrees to sign the contract and furnish the necessary bonds not more than ten (10) calendar days after Notice to Proceed date. Enclosed is a Bidder's Bond, certified check or cashier's check, which is not less than ten percent (101/0). as a guarantee that the undersigned will enter into the contract if awarded to the undersigned. The undersigned further agrees that in case of default in executing the required contract with necessary bonds and insurance, within the time limits above specified. said bonds or check and money, payable therein must be fortified to and become the property of the City of El Segundo. State of California. tW !�9 e�4��Cu., Name of Firm: Address: Telephone Number: Contractor's License Number: Type of License: Licens�-Expiration Date: r Type bt' Entity: ❑ Sole Proprietorship D Partncrship�Corporation ❑ Other 5-23-2005 3 • Addendum 01 I declare under penalty of perjury that the foregoing is true and correct. Contractor Representative: Um,o,6 Vi • � Title: Signature: Dated this Z-� day of ,3492.,;: If Corporation, please attach evidence of authority to sign. 5 ,2 ; ,2005 Addendum #I 3492 , '~ ACKNOWLEDGEMENT OF RECEIPT OF ADDENDA Bidder acknowledges receipt of the following addenda, has become familiar with their contents, and has accounted for all such changes in the Bidder's Proposal and Statement. The Bidder must attach copies of transmittal letters and facsimile cover sheets for each identified addendum. Addendum ?dumber Addendum Number Signature: Da VOLUME 1 Date: 2-7— ?`0s Date: Date: Date: Date: Date: VOLUME 2 Date: Date: )5. 5232005 ti Addendum #1 Addendum Number Addendum Number Addendum Number 3 Addendum Number .Addendum Number Addendum Number Addendum ?dumber Addendum Number Signature: Da VOLUME 1 Date: 2-7— ?`0s Date: Date: Date: Date: Date: VOLUME 2 Date: Date: )5. 5232005 ti Addendum #1 05/31/2005 09:07 3154718807 S &L WICKER 3 PALE 2 01 / 01 • , WRITTEN CONSENT OF THE BOARD OF DIRECTORS S &L SPECIALTY CONTRACTING, 23, 2004 �Nrx, INC. OMMUS RESOLUTION Resolved, that James W. LeQDR� President of S &L Specialty Contracting, Inc. is authorized and empowered to execute any documents in his discretion on behalf of S &L Specialty Contracting, Inc. IN WITNESS WHEREOF, the foregoing resolutions is hereby consented to and approved as of the date first written above. This Consent may be executed in any number of counterparts, each of which shall be deemed an original and all of which together, shall constitute one instrument. L Specialty Contracting, Inc. J Ves . Leana P S &L Specialty Contracting, Inc. 05/30/2005 22:59 3154718807 S &L WICKER DESIGNATION OF HATERIAL SUPPLIERS AND SU$CONTRA.CTORS 3492. PAGE 04/05 ' In compliance with the Subletting and Subcontracting Fair Practices Act (Chapter 2, commencing at Section 4100,,Division 5, Title I of the Government Code of the State of California) and any amendments thereof each bidder must set forth below: (a) the name and location of the place of business of each subcontractor who will perform work or labor or render service to the prime contractor in or about the construction of the wort: or improvement to be performed under this contract in an amount in excess of one -half of one percent (0.5 %) of the prime contractor's total bid, and (b) the portion of the work which will be done by each subcontractor under this act and their license number. The prime contractor must list only one subcontractor for each such portion as is defined by the. prime contractor in this bid. If a prime contractor fails to specify a subcontractor or if a prime contractor specifies more than one subcontractor for the same portion of work to be performed under the contract in excess of one -half of one percent (0.5 %) of the prime contractor's total bid, the Contractor must be deemed to have agreed that he /she is fully qualified and will perform that portion themselves. No prime contractor whose. bid is accepted must (a) substitute any subcontractor, (b) permit any subcontract to be voluntarily assigned or transferred or allow it to be periormed by anyone other than the original subcontractor listed in the original bid, or subcontract am portion of the work in excess of one -half of one percent (0.5 %) of the prime contractor's total bid as to which the original bid did not designate a subcontractor. except as authorized in the Subletting! and Subcontracting, Fair Practices Act. Subletting or subcontracting of any portion of the work in excess of one -half of one percent (0.5 %) of the prime contractor's total bid as to which no subcontractor was designated in the original hid must only be permitted in cases of public emergency or necessity, and then onk after a finding reduced to writing as a public record of the •City awarding this cantrtct setting forth the facts constituting the emergency or necessity. MATERIAL SL'PPLIFRS j .2 "'200 5 6'' Addendum 91 Name of Supplier Supplier Address Supplier Phone Number Aluminum Windows �2���r \'fit �'"k•2c�c1��e IJAIto.,.�.t�, ya¢\e...Ck VN44S- I �in�l Vt•indows i�Qm..� -�-�. I I Acoustical A'ood Doors � �C���a�� Y"� 2.S A �^�, \�•�l� -e� Cam- ckorozz Ik,�3C7 85%5 A \Vood Doors I Sccandarr. (Storm) Doors j .2 "'200 5 6'' Addendum 91 05/30/2005 22:59 3154718807 FV4 S &L WICKER 3492. PAGE 05/05° ` Sliding Glass Doors cZ �ha� License Number a�b• Business Location Secondary Sliding Glass �p�c`�Q"°c+•.�`�'�' .Doers i Fireplace Dampers i Fireplace Glass Doors i HVAC Equipment \t Pt C,`h.�.a= ��. 4 �+.Vti�� �5�at'� Casa�c `� • SUBCONTRACTORS W'S Work Activih• Name of Address & City of Subcontractor Subcontractor's License Number Percentage of Bid Total Business Location v C,`h.�.a= ��. 4 �+.Vti�� �5�at'� Casa�c `� • � I I I I � 5'23'2005 � I I i I i 7• Addendum #1 , 3492 �- REFERENCES Please list similar projects on which you were the general contractor. This information must be included with your bid, and will be used by the City in assessing your capabilities and qualifications for performing the work. You are hereby advised that this project is complex and requires an experienced contractor. Your bid will be considered non - responsive if the information you provide is untrue or is insufficient to allow the Cite to adequately assess your capabilities and qualifications. Please copy this sheet if you need more space. Eyhpf� 2 M 4 Project Name Agency Contact Person Description of Project Proiect Name Agency Contact Person Description of Project Project Name Agency Contact Person Description of Project Project Name Agency Contact Person Description of Project Project No._ Dollar Value Tel. No. Project No._ Dollar Value Tel. No. Project No._ Dollar Value Tel. No. Project No._ Dollar Value Tel. No. Bidder's Initials '20 0 ; 8' Addendum 41 S &L Specialty Contracting, Inc. Statement of Experience Projects Completed and/or Substantially Complete May 2005 S &L Specialty Contracting, Inc., has participated in and completed sound insulation treatments in approximately 1,100 homes for many different programs across the country. S &L can provide full services including all architectural treatments including doors, windows, interior trim details, insulation, HVAC, and electrical upgrades. The staff at S &L is dedicated to providing a high quality installation that meets or exceeds customer expectations while completing the work on schedule. Below is a summary of projects that were completed or are on- going. San Diego International Airport "QUIETER HOME" Program Period: June 2002 to Present Value: In excess of $8 million Self Performed Portion: 70% of work PROJECT VALUE COMPLETED Phase 1D -4 $1,380,000.00 In Progress 5/2005 Phase 1D -2 $2,087,651.00 11/2004 Phase 1C -2 $1,370,000.00 5/2004 Phase 1C -4 $1,506,000.00 3/2004 Phase 1C -3 $1,233,730.00 1/2004 Phase 1C -1 $2,243,377.00 1/2004 Phase 113-1 $4,645,069.00 10/2002 To date S & L Specialty Contracting, Inc. has completed approximately 170 homes in the San Diego, California program. Contact Information: C &S Engineers, Inc. Attn: Mr. Brian Lahr 2020 Camino Del Rio North Suite 200 San Diego, CA 92108 (619) 296 -9373 3492 . * � 7 Detroit, Michigan Wayne County Airport Authority Residential Sound Insulation Program Period: May 2003 to Present Value: $2 million Self Performed Portion: 50% of work PROJECT VALUE COMPLETED Phase F -04 $1,750,000.00 Phase C -04 $1,736,000.00 Phase F -03 $1,731,000.00 Phase F -02 $1,992,965.00 Phase G -02 $1,030,000.00 Phase E -02 $1,326,005.00 Phase A -02 $660,792.00 Contact Information: C &S Engineers, Inc. Attn: Doug Clark 37229 Huron River Road New Boston, MI 48164 (734) 753 -5993 Cleveland Hopkins International Airport Residential Sound Insulation Program Period: September 2000 — January 2004 Value: $5.5 million Self Performed Portion: 80% of Work ongoing 1/2005 9/2004 6/2004 4/2004 1/2004 10/2003 PROJECT VALUE COMPLETED D -02 General Construction $1,036,350.00 1/2004 I -02 HVAC & Electrical $423,675.00 9/2003 H -02 HVAC & Electrical $394,235.00 9/2003 F -02 HVAC & Electrical $324,347.00 7/2003 A -02 HVAC & Electrical $516,258.00 7/2003 B -01 General Construction $1,066,899.00 5/2003 C -01 HVAC & Electrical $591,501.00 2/2003 A -01 HVAC & Electrical $1,015,944.00 1/2003 A -01 General Construction $ 627,055.00 10/2002 To date S & L Specialty Contracting, Inc. has completed approximately 430 homes in the Cleveland, Ohio program. 3492. Contact Information: C &S Engineers, Inc. Attn: Mr. Ed Regan 20445 Emerald Parkway Suite 100 Cleveland, OH 44135 (216) 619 -5449 Tulsa International Airport Acoustical Abatement Program Period: November 2001 to Present Total Value: In excess of $6 million Self Performed Portion: 50% of Work PROJECT VALUE COMPLETED Group 8A $1,100,000.00 8/2004 Group 5A $970,000.00 1/2004 Group 3C $683,826.00 7/2003 Group 3A $672,024.00 2/2003 Group 1C $686,946.00 7/2002 Group IA $886,971.00 7/2002 To date S & L Specialty Contracting, Inc. has completed approximately 175 homes in the Tulsa, Oklahoma program. Contact information: White Construction Company Attn: Mr. Charles White 560 North Memorial Drive Tulsa, OK 74115 (918) 836 -1766 Columbus Regional Airport Residential Sound Insulation Program Period: June 2003 to Present Value: $1.5 million Self Performed Portion: 60% of work PROJECT VALUE COMPLETED Phase VII $1,500,000.00 5/2004 Phase IX $1,996,000.00 In progress 5/2005 3492 . Additional houses added as project progresses Contact Information: Jones Payne Group Attn: Jim Kubat 321 Summer Street Boston, MA 02210 (617) 790 -3747 San Diego Housing Commission Mira Mesa/Kitchen Bath Upgrades Period: Value: Self Performed Portion: PROJECT VALUE COMPLETED Mira Mesa Kitchen/Bath Upgrade $277,791.00 11/2004 Contact Information: San Diego Housing Commission 9550 Ridgehaven Court San Diego, CA 92123 Attn: (619) Festival Hall Noise Mitigation PROJECT VALUE COMPLETED Festival Hall Noise Mitigation $341,245.00 12/2004 Contact Information: City of Santa Ana 20 Civic Center Drive M -22 Santa Ana, CA 92702 Attn: Tyrone Chesanek 714- 647 -5045 Casa Nueva Apartments PROJECT VALUE COMPLETED Casa Nueva Apartment Renovations Contact Information: South Bay Community Services 1124 Bay Boulevard, Suite D Chula Vista, CA 91910 Attn: Roger Dinsmore 760 - 436 -6891 $508,962.00 Barton Elementary School HVAC Upgrade 3492 . ••a In Progress 5/2005 PROJECT VALUE COMPLETED Barton Elementary School $496,652.000 1/2005 Longbeach Unified School District HVAC Upgrade Contact Information: Long Beach Unified School District 2425 Webster Ave Long Beach, CA 90810 Attn: David Sorlie 562 - 997 -7512 In Addition to the projects listed S & L Specialty Contracting Inc has also performed Work for Sound Insulation Programs in Cincinnati, OH, Toledo, OH and Phoenix, AZ. Along with the Sound insulation experience we bring to the table a wide array of management capabilities. These include private and public commercial projects telecommunication and highway construction projects, and residential renovation and new construction. These projects are reflected in the individual resumes of our management staff. 3492 . « ., THE AMERICAN INSTITUTE OF ARCHITECTS i IUOY AIA Document A310 Bid Bond KNOW ALL MEN BY THESE PRESENTS, that we S & L Specialty Contracting, Inc. 472 South Salina St., Suite 400, Syracuse, NY 13202 as Principal, hereinafter called the Principal, and Travelers Casualty and Surety Company of America a corporation duly organized under the laws of the State of Connecticut as Surety, hereinafter called the Surety, are held and firmly bound unto City of El Segundo, 350 Main Street, El Segundo, CA 90245 as Obligee, hereinafter called the Obligee, in the sum of Ten Percent of Amount Bid for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid for Residential Sound Insulation Program — Group 6 NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a Contract with the Obligee in accordance with the terms of such bid, and give such bond or bonds as may be specified in the bidding or Contract Documents with good and sufficient surety for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the Work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. Signed and sealed this 25th day of May, 2005. 6 S pecialt ra ting, Inc. rinci a) (meal) (Witness) (Title) Trav®r, asualty and Surety Company of America (Surety) (Seal) (Witness) Richard H. Hunt, torney -in -F t _ (Title) AIA DOCUMENT A310 • BID BOND • AIA ® • FEBRUARY 1970 ED • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 N.Y. AVE., N.W., WASHINGTON, D.C. 20006 i' TRAVELERS CASUALTY & SURETY COMPANY OF AMERICA Hartford, Connecticut 06156 CERTIFICATE OF SURETY TRAVELERS CASUALTY & SURETY COMPANY OF AMERICA, a corporation organized and existing under the laws of the State of Connecticut and duly authorized to do business in the State of Michigan, as Surety, will provide to S & L Specialty Contracting, Inc. as Principal, the bond(s) in such sum and form as is required by the advertisement or specifications for Residential Sound Insulation Program — Group 6 and in conjunction with bid or proposal dated the 31 st day May of 2005, submitted by the said Principal, in the amount of Ten Percent of Amount Bid (10 %) . to City of El Segundo ,as Obligee, should the said bid or proposal be accepted and contract awarded to the said Principal. This Certificate of Surety is issued in accordance with N.J.S.A 40A:1 1 -22. Signed and sealed this 25th day of May, 2005. TRAVELERS CASUALTY & SURETY COMPANY OF AMERICA Richard H. Hunt, Attorney -in -Fact 3492 NON - COLLUSION AFFIDAVIT The undersigned, being first duly sworn, deposes and says that he or she is authorized to represent the party ("Bidder") making the foregoing bid; that the Bidder has not directly or indirectly entered into any agreement, participated in any collusion, or otherwise taken anv action in restraint of free competitive bidding in connection with such contract: that the bid is genuine and not collusion or sham: that the bidder has not directly or indirectly induced or solicited any other bidder to put a false or sham bid, or that anyone must refrain from bidding: that the bidder has not in any manner, directly or indirectly, sought by agreement. communication, or conference with anyone to fix the bid price of the bidder or any other bidder. or to fix any overhead, profit, or cost element of the bid price or of that of anv other bidder, or to secure any advantage against the public body a,.%arding the contract of anyone interested in the proposed contract; that all statements contained are true. and. further, that the bidder has not, directly or indirectly, submitted its bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto. or paid. and will not pay, any fee to any corporation. partnership, compan% association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. I declare under penalty of perjury that the foregoing is true and correct. Name of Firm: Address: Telephone Number: Contractor Representative Subscribed and S%%( Signattr 181 6 - )--10 °f 7 0 NotarN Public in and for the County of Nom► State of Cam. ,My Commission Expires 11 '3'o(P MAUREEN A. WICKER [Notarial Seal] Notary Public, State of New York NO: 01 W 18075382 Qualified in Onondaga County Commisssion Expires June 3, 20Av, ', 3 -,0p; 16 Addendum #I 34 9 2 ' • s � BIDDER'S STATEMENT ON PREVIOUS CONTRACTS SUBJECT TO EEO CLAUSE The Bidder has participated ED has not participated in a previous contract subject to the equal o unity clause prescribed by Executive Order 11246, as amended, of September 24. 1965. The Bidder has submitted ❑ has not submitted all compliance reports in connection with any suc contract due under the applicable filing requirements; and that representations indicating submission of required compliance reports signed by proposed subcontractors will be obtained prior to award of subcontracts. If the Bidder has participated in a previous contract subject to the equal opportunity clause and has not submitted compliance reports due under applicable filing requirements, the Bidder must submit a compliance report on Standard Form 100, "Employee Information Report EE04I prior to award of the contract. Note: Failure to complete the blanks may be grounds for rejecting the bid. I declare under penalty of pedun• that the foregoing is true and correct. Name of Firth: 7z- S- S ctr 9-t, q-06 Address: tQQ Telephone lumber: �! �'T� O l �� Contractor Representati\•e: T�,OM-e_-s 1- yea -i(l aJ Title: �R e-`-� Signature: Da )5. 5,232005 11 Addendum #1 3492. ' e • i CERTIFICATION OF NON - SEGREGATED FACILITIES (Contractors / Subcontractors) (A certificate of Non - segregated Facilities must be submitted prior to award of a contract or subcontract exceeding $10,000 which is not exempt from the provisions of Equal Opportunity Clauses) The Federally assisted construction contractor certifies that it does not maintain or provide for its employees any segregated facilities at any of its establishments, and that it does not permit its employees to perform their services at any location, under its control, where segregated facilities are maintained. The Federally assisted construction contractor certifies further that it will not maintain or provide for its employees any segregated facilities at any of its establishments, and that it will not permit any of its employees to perform their services at any location, under its control. where segregated facilities are maintained. The Federally assisted construction contractor agrees that a breach of this certification is a violation of the Equal Opportunity clause in this contract. As used in this certification, the term "segregated facilities" means an), waiting room. Mork areas. rest rooms and washrooms, restaurants and other eating areas, time clocks, locker rooms and other storage or dressing areas, parking lots, drinking fountains, recreation or entertainment areas. transportation, and housing facilities provided for employees which are segregated b% explicit directive or are in fact segregated on the basis of race, color, religion, sex or national origin. because of habit, local custom, or any other reason The Federally assisted construction contractor agrees that (except where it has obtained identical certifications from proposed subcontractors for specific time periods) it will obtain identical certifications from proposed subcontractors prior -to the award of subcontracts exceeding $10,000 which are not exempt from the provisions of the Equal Opportunity clause, and that it will retain such certification in its files. Certification - The information above is true and complete to the best of my knowledge and belief. Narne of Firm: S+1,.. / uP_— 4-7 2 4? SCL t n ke L1 Cb Address: r t° Telephone Number: Contractor Representative: V Ct wet, Q-x-)GZ . T' e. Sicnature i Dated this a� of ,'005. Note: The penalty for making fals atements in offers 4srescribed in 18 L.S.C. 1001. 2005 12 Addendum #I 3492 . BIDDER'S ASSURANCE OF COMPLIANCE WITH TITLE 49 CFR PART 26 RELATING TO DISADVANTAGED BUSINESS ENTERPRISE PARTICIPATION The bidder hereby gives assurance pursuant to the requirements of Title 49 CFR part 26 that bidder has made a reasonable effort to meet goals for Disadvantaged Business Enterprise participation specified for the contract for which this proposal is submitted and that the bidder, if the contract is awarded to bidder, will have a DBE participation of three percent (3 %) of the amount of this bid. Bidder further gives assurance that bidder will submit the documentation required by said Regulations and the Contract Documents, including the Listing of Disadvantaged Business Enterprises with which the bidder will subcontract if the contract is awarded and if bidder is unable to meet the contract goals for DBE participation, of the steps bidder has taken to obtain DBE participation. Name of Firm: JT Address: / �1 Telephone Number: Contractor Representative: Signature: 5'232005 13 Addendum # 1 3492 `. f -Si SUSPENSION AND DEBARMENT REQUIREMENTS FOR ALL CONTRACTS OVER $25,000 (49 CFR PART 29) The bidder /offeror certifies, by submission of this proposal or acceptance of this contract, that neither it nor its principals is presently-debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any. Federal department or agency. It further agrees by submitting this proposal that it will include this clause without modification in all lower tier transactions, solicitations, proposals. contracts, and subcontracts. Where the bidder /offerer /contractor or any lower tier participant is unable to certify to this statement, it must attach an explanation to this solicitation/proposal. Tele Contractor Signature: F ,_ 3 200; 14 Addendum 41 3492 . • . 4. TRADE RESTRICTION CLAUSES TO BE INCLUDED IN ALL SOLICITATIONS CONTRACTS AND SUBCONTRACTS The contractor or subcontractor, by submission of an offer and/or execution of contract, certifies that it: A. is not owned or controlled by one or more citizens or nationals of a foreign country included in the list of countries that discriminate against U.S. firms published by the Office of the United States Trade Representative (USTR); B. has not knowingly entered.into any contract or subcontract for this project with a person that is a citizen or a national of a foreign country on said list, or is owned or controlled directly or indirectly by one or more citizens or nationals of a foreign country on said list; C. has not procured any product nor subcontracted for the supply of any product for use on the project that is produced in a foreign country on said list. Unless the restrictions of this clause are waived by the Secretary of Transportation in accordance with 49 CFR 30.17, no contract must be awarded to a contractor or subcontractor who is unable to certify to the above. If the contractor knowingly procures or subcontracts for the supply of any product or services of a foreign country on the said list for use on the project, the Federal Aviation Administration may direct, through the Cite, cancellation of the contract at no cost to the government. Further the contractor agrees that, if awarded a contract resulting from this solicitation, it will incorporate this provision for certification without modification in each contract and in all lower tier subcontracts. The contractor may rely on the certification of a prospective subcontractor unless it has knowledge that the certification is erroneous. The contractor must provide immediate written notice to the sponsor if the contractor learns that its certification or that of a subcontractor was erroneous when submitted or has become erroneous by reason of changed circumstances. The subcontractor agrees to provide immediate written notice to the contractor, if at any time it learns that its certification was erroneous by reason of changed circumstances. This certification is a material representation of fact upon which reliance was placed when making the award. If it is later determined that the contractor or subcontractor knowingly rendered an erroneous certification. the Federal Aviation Administration may direct. through the Cite. cancellation of the contract or subcontract for default at no cost to the government. Nothing contained in the foregoing must be construed to require establishment of a system of records in order to render, in good faith, the certification required by this provision. The knowledge and information of a contractor is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings. This certification concerns a matter within the jurisdiction of an agency of the United States of America and the making of a false. fictitious. or fraudulent certification may render the maker subject to prosecution under Title 18, United States Code, Section 1001. 5.'23'2005 15 Addendum 41 Name of Finn: Address: Telephone Number: Contractor Representative: Signature: Dated this 11-14Z) d1v of 5 23 2005 16 3492 . , ; 2005. Addendum #I 349.2•,�'j BUY AMERICAN — STEEL AND MANUFACTURED PRODUCTS FOR CONSTRUCTION CONTRACTS The contractor agrees that only domestic steel and manufactured products will be used by the Contractor, subcontractors, materialmen, and suppliers in the performance of this contract, and defined in A. below. A. The following terms apply to this clause: 1. Steel and manufactured products. As used in this clause, steel and manufactured products include: a.) those products produced in the United States or b.) a manufactured product produced in the United States, if the cost of its components mined, produced or manufactured in the United States exceeds sixty percent (60 %) of the cost of all its components and final assembly has taken place in the United States. ?. Components. As used in this clause, components means those articles, materials, and supplies incorporated directly into steel and manufactured products. ;. Cost of Components. This means the costs for production of the components. exclusive of final assembly labor costs. Name of Firm Address Telephone Number: Contractor Representative Signature: Dated this Ti S+- - e 1✓)& IL 1 5- �al(n 2.. p 13 7-n QM� Ktll� 2005. 52312005 17 Addendum #1 3492. Mandatory Pre -Bid Meeting Monday, May 16,2005,10:30 a.m. City Council Chambers, 350 Main Street, El Segundo, California 90245 Attendees List 1. JOE O A� Pe-Z- l ar Z-3 196 qqlr 2. ?, s�VX0 S i L_ 31 S - S l s - :) CEL` .rl.x. �;K qS I- dot, - o/Y� 4. i� ,q2_ - —2357f - 7. Residential Sound Insulation Program Attendees List Mandator\ Pre -Bid Meeting (5 W05) 6. 7. Residential Sound Insulation Program Attendees List Mandator\ Pre -Bid Meeting (5 W05) Residential Sound Insulation Program Group 6 (RSI 05-07) Plans Holders List City of El Segundo (City Clerk) 2. City of El Se undo (Seimone Juriis) City of El Segundo (File Co v) 4. The Jones Pavne Grou The Jones Pavne Group 6. The Jones Pavne Group- 7. The Jones Pavne Group WN-1e Laboratories Inc. 9. W le Laboratories. Inc. 10. ',/1cGra,.% -Hill Co. 1 1. S &- 1. Specialty Contracting. Inc. 472 South Salina St. Suite 400 Syracuse. NY 13202 (315)178 -9746 phone ( 315) 4 71-8 807 fax 13. H.K.l:lectrical Inc. 17428 Lahev Street Granada Hills. CA 9134-1 ( 818) 831 -8$00 phone ( 818) 832 -9 92 fax 13. Discount Exteriors 17612 Beach Bled. 13B Huntington Beach. CA 92647 (714) 596 -6766 phone ( 714) 596 -6746 fax 3492. Page 1- of 2 5:34 PM 5/20/2005 14. Mil and 40239 Redbud Dr. Oakhurst, CA 93644 (559) 692 -2440 phone (559) 692 -2441 fax 15. Specialty Door Comj2anv Inc. 525 -A Railroad Avenue S. San Francisco. CA 94080 (650) 589 -4888 phone (650) 589 -4288 fax 16. NSA Construction Grou Inc. 19562 Ventura Blvd. #219 Tarzana. CA 91356 (818) 3.15 -1153 phone ( 818) 345 -0590 fax 17. Peerless Products 2403 S. Main Ft. Scott. Kansas 66701 (800) 279 -9999 phone (620) 224-3107 fax 18. Torrance .Aluminum 4901 Morena Bled. Suite = 128 San Diego. CA 92117 ( 619) 247 -9106 phone ( 619) 299 -6292 fax 19. PBC.Inc. 125 Sheldon Street E:I Segundo. California 90245 (3 10) 524 -0580 phone (310) 524 -058.3 fax 20. Zodiac Ileatin g & Air Conditioning. Inc. 14411 Gilmore Street Van Nuys. C,rA 91.101 (8 18) 785 -3699 phone 21. Graham Architectural Products 1551 Mt. Rose Ave. York. PA 17303 (800) 755 -6274 phone 2 3492 Page 2 of 2 5:34 PM 5/20/2005 IF ACORDM CERTIFICATE OF LIABILITY INSURANCE - 0712512605 ` PRODUCER (973)812 -9855 FAX (973)812 -9860 C &H Agency, Inc . PO Box 324 783 North Riverview Drive Totowa, NJ 07512 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. INSURERS AFFORDING COVERAGE NAIC # INSURED S & L Specialty Contracting, Inc. 472 South Salina Street, Suite 400 Syracuse, NY 13202 -2481 INSURERA: American Home Assurance Co. (AIG ) 19380 INSURERB: Arch Insurance Company (Hartan) 11150 INSURER C: INSURER D: EACH OCCURRENCE INSURER E: DAMAGE TO RENTED THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTW ITHSTANDINi ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR DD' TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE POLICY EXPIRATION LIMITS 350 Main Street XdObUKK*MM NK )tXXOJEKIiKXiU*XXXMMXXXXXXXX GENERAL LIABILITY El Segundo, CA 90245 Michael Culnen CARENB EACH OCCURRENCE $ 2,000,00( DAMAGE TO RENTED $ 50,00( X I COMMERCIAL GENERAL LIABILITY GL7047177 03/17/2005 03/17/2006 MED EXP (Any one person) $ CLAIMS MADE n OCCUR PERSONAL & ADV INJURY $ 1,000,00( A GENERAL AGGREGATE $ 4,000,00( GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS - COMP /OP AGG $ 4,000,000 POLICY X JE LOC AUTOMOBILE LIABILITY ANY AUTO CA8261997 03/17/2005 03/17/2006 COMBINED SINGLE LIMIT (Ea accident) $ 1,000,000 X X BODILY INJURY (Per person) $ A ALL OWNED AUTOS SCHEDULED AUTOS HIRED AUTOS NON -OWNED AUTOS X X BODILY INJURY (Per accident) $ X PROPERTY DAMAGE (Per accident) $ GARAGE LIABILITY AUTO ONLY - EA ACCIDENT $ OTHER THAN EA ACC $ ANY AUTO $ H AUTO ONLY: AGG EXCESS /UMBRELLA LIABILITY ULP0005384 -00 03/17/2005 03/17/2006 EACH OCCURRENCE $ 10 000,00 AGGREGATE $ 10,000,000 X OCCUR r__] CLAIMS MADE $ B $ DEDUCTIBLE $ X RETENTION $ 10,00 WORKERS COMPENSATION AND W T E.L. EACH ACCIDENT $ EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? E.L. DISEASE - EA EMPLOYE $ E.L. DISEASE - POLICY LIMIT $ It yes, describe under SPECIAL PROVISIONS below OTHER DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES / EXCLUSIONS ADDED BY ENDORSEMENT / SPECIAL PROVISIONS E: City of E1 Segundo, Residential Sound Insulation Program - GROUP 6 G2010 (11/85) Additional Insured - Owners, Lessees or Contractors (Form B) (attached) *See attached for cancellation clause" #%A\Ir -=1 1 ATIA \1 ACORD 25 (2001/08) © ACORD CORPORATION 1988 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL *)= MAIL City of El Segundo 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, City Hall lf�( KxIXlQD4xdWi1614X116YlYIXiCXX 350 Main Street XdObUKK*MM NK )tXXOJEKIiKXiU*XXXMMXXXXXXXX AUTHORIZED REPRESENTATIVE El Segundo, CA 90245 Michael Culnen CARENB ACORD 25 (2001/08) © ACORD CORPORATION 1988 3492 . City of E1 Segundo Certificate issued to City of E1 Segundo 07/25/2005 C &H Agency,Inc 04/29/2005 * *Should any of the above - described policies be cancelled before the expiration dates thereof, the issuing company will mail within 30 days written notice to the certificate holder. ** 07/25/2005 11:38 3154718807 nine, 1 u, 4VVJ I ; JVrivi . POLICY NUMBER: S &L WICKER PAGE 04/04 NO. 1948 P. 4 3492 • . . COMMERCIAL GENERAL LIABILITY THIS ENDORSEMENT CHANGES THE POLICY, PLEASE READ IT CAREFULLY, ADDITIONAL INSURED - OWNERS, LESSEES OR 'CONTRACTORS - (FORM B) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART. SCHEDULE Name of Person ar Organization; As required by contract, provided contract executed prior to loss City of E1 Segundo (If no entry appears above, Information required to complete this endorsement will be shown In the Declarations as applicable to this endorsement.) WHO IS AN INSURED (Sectlon II) is amended to incl )de as an Insured the person or organization shown in the Schedule, but only with respect to liability arising out o 'your work" for that insured by or for you, CO 20 10 1185 Copyright, Insurance Services Office, Inc,, 1984 Page 1 of 1 13 ocT entire IL Q 2 1.11C111. 1: -7�.�i QTM CERTIFICATE OF - - --- LIABILITY INSURANCE ANY REQUIREMENT, TERM MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, 07/25/05 PRODUCER Allied North America Insurance Brokerage of New York, LLC 390 North Broadway Jericho, NY 11753 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. INSURERS AFFORDING COVERAGE GENERAL LIABILITY INSURED — S & L Specialty Contracting, Inc. 472 South Salina Street, Suite 400 Syracuse, NY 13202 -2481 INSURERA: American Home Assurance Company INSURER B: MED EXP (Any one person) $ -- INSURER C: PERSONAL 8 ADV INJURY $ _ INSURER D: _ INSURER E: PRODUCTS - COMP /OPAGG $ GU V tKAU t5 OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING THE POLICIES OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR ANY REQUIREMENT, TERM MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. 1 TR - POLICY EFFECTIVE POLICY EXPIRATION TYPE OF INSURANCE POLICY NUMBER DATE MM/DD/YY DATE MM/DD/YY LIMITS GENERAL LIABILITY EACH OCCURRENCE $ T ICOMMERCLALGENERALLIABILITY C FIREDAMAGE (Anyone fire) $ CLAIMS MADE L_j OCCUR MED EXP (Any one person) $ -- j— PERSONAL 8 ADV INJURY $ _ GENERAL AGGREGATE $ GEN'L AGGREGATE LIMITAPPLIESPER: PRODUCTS - COMP /OPAGG $ POLICY PRO- LOC AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT $ (Ea accident) ANY AUTO ALL OWNED AUTOS BODILY INJURY $ (Per person) SCHEDULED AUTOS BODILY INJURY HIRED AUTOS $ (Per accident) — r NON -OWNED AUTOS — PROPERTY DAMAGE I $ � — I (Per accident) — AUTO ONLY - EA ACCIDENT $ GARAGE LIABILITY ANY AUTO OTHER THAN EA ACC $ _ $ AUTO ONLY: AGG EXCESS LIABILITY EACH OCCURRENCE $ _ AGGREGATE OCCUR CLAIMS MADE $ $ DEDUCTIBLE - - - -- A RETENTION $ AND WC2 6 7 5 7 8 7 112/01/04112/01/05 WC STATU- OTH- X TORY $ WORKERS COMPENSATION 0 0 0 0 0 0 EMPLOYERS' LIABILITY E.L. EACH ACCIDENT_ $1 , , E.L. DISEASE - EA EMPLOYEE $1 , 00_0 , 000 E.L. DISEASE - POLICY LIMIT $1 0 0 0 0 0 0 OTHER DESCRIPTION OF OPERATIONS /LOCATIONSIVEHICLES/EXCLUSIONS ADDED BY ENDORSEMENT /SPECIAL PROVISIONS City of El Segundo Residential Sound Insulation Program - Group 6. Foregoing per policy form. :L•1EI1=GI City of E1 Segundo City Hall 350 Main Street E1 Segundo, CA 90245 SHOULD ANYOFTHE ABOVE DESCRIBED POLICIES SE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL 30— DAYS WRITTEN NOTICETOTHE CERTIFICATE HOLDERNAMED TOTHE LEFT, BUTFAILURE TODOSOSHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURERJTS AGENTS OR ACORD25- S(7/97)1 of 2 ##S321250/M2y46bi env .___ IMPORTANT If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). DISCLAIMER The Certificate of Insurance on the reverse side of this form does not constitute a contract between the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon. ACORD25- S(7/97)2 of 2 #S321250/M294681