Loading...
CONTRACT 6768 Public Works Contract CLOSEDAgreement No. 6768 PUBLIC WORKS CONTRACT BETWEEN THE CITY OF EL SEGUNDO AND WILLIAMS PIPELINE CONTRACTORS, INC. ON -CALL WATER SYSTEMS REPAIR SERVICES PROJECT PROJECT NO.: ENG 23-25 This CONTRACT is entered into this 28`h day of August, 2023, by and between the CITY OF EL SEGUNDO, a general law city and municipal corporation ("the City") and WILLIAMS PIPELINE CONTRACTORS, INC., a California Corporation ("the Contractor"). 1. WORK. A. The Contractor will provide all work required by the Contract Documents (the "Work"). The Contractor agrees to do additional work arising from changes ordered by the City in accordance with the Contract Documents. B. The Contractor and the City agree to abide by the terms and conditions contained in the Contract Documents; C. The Contractor will furnish all of the labor; supplies and materials; equipment; printing; vehicles; transportation; office space and facilities; all tests, testing and analyses; and all matters whatsoever (except as otherwise expressly specified to be furnished by the City) needed to perform and complete the Work and provide the services required of the Contractor by the Contract Documents. D. "Contract Documents" means the Proposal; this Contract; Standard Specifications; Supplementary Conditions; Exhibits; Technical Specifications; List of Drawings; Drawings; Addenda; Notice to Proceed; Change Orders; Notice of Completion; and all other documents identified in the Contract Documents which together form the contract between the City and the Contractor for the Work. The Contract Documents constitute the complete agreement between the City and the Contractor and supersede any previous agreements or understandings. 2. CONTRACT SUM. The City agrees to pay the Contractor a sum not to exceed Fifty Nine Thousand Dullars ($59,000.00) for the Work in the manner set forth in the Contract Documents. 3. TERM. The term of this Contract will commence on September 1, 2023 and will expire on June 30, 2024, unless terminated earlier pursuant to Section 4. 4. TERMINATION. A. City may terminate this Contract at any time with or without cause.. Agreement No. 6768 B. Contractor may terminate this Agreement at anytime with City's mutual consent. Notice will be in writing at least thirty (30) days before the effective termination date. C. Upon receiving a termination notice, Contractor will immediately cease performance under this Agreement unless otherwise provided in the termination notice. Except as otherwise provided in the termination notice, any additional work performed by Contractor after receiving a termination notice will be performed at Contractor's own cost; City will not be obligated to compensate Contractor for such work. D. Should the Agreement be terminated pursuant to this Section, City may procure on its own terms services similar to those terminated. E. By executing this document, Contractor waives any and all claims for damages that might otherwise arise from City's termination under this Section. 5. PREVAILING WAGES. Pursuant to Labor Code § 1720, and as specified in 8 California Code of Regulations § 16000, the Contractor must pay its workers prevailing wages. It is the Contractor's responsibility to interpret and implement any prevailing wage requirements and the Contractor agrees to pay any penalty or civil damages resulting from a violation of the prevailing wage laws. See Section 7-2 of the Standard Specifications. 6. DISPUTES. Disputes arising from this Contract will be determined in accordance with the Contract Documents and Public Contracts Code §§ 10240-10240.13. 7. THIRD PARTY CLAIMS. In accordance with Public Contracts Code § 9201, the City will promptly inform the Contractor regarding third -party claims against the Contractor, but in no event later than ten (10) business days after the City receives such claims. Such notification will be in writing and forwarded in accordance with the "Notice" section of the Contract Documents. As more specifically detailed in the Contract Documents, the Contractor agrees to indemnify and defend the City against any third -party claim. 8. TAXPAYER IDENTIFICATION NUMBER. The Contractor will provide the City with a Taxpayer Identification Number. PERMITS AND LICENSES. Unless otherwise provided, the Contractor, at its sole expense, will obtain and maintain during the term of this Contract, all necessary permits, licenses, and certificates that may be required in connection with the Work. 10. OWNERSHIP OF DOCUMENTS. All documents, data, studies, drawings, maps, models, photographs and reports prepared by the Contractor under the Contract Documents are the City's property. The Contractor may retain copies of said documents and materials as desired, but will deliver all original materials to the City upon the City's written notice. Agreement No. 6768 11. INDEMNIFICATION. The Contractor agrees to indemnify, defend, and hold the City harmless as set forth in the Contract Documents. The requirements as to the types and limits of insurance coverage to be maintained by the Contractor as required by the Contract Documents, and any approval of such insurance by the City, are not intended to and will not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Contractor pursuant to the Contract Documents, including, without limitation, to the provisions concerning indemnification. 12. INDEPENDENT CONTRACTOR. The City and the Contractor agree that the Contractor will act as an independent contractor and will have control of all work and the manner in which is it performed. The Contractor will be free to contract for similar service to be performed for other employers while under contract with the City. The Contractor is not an agent or employee of the City and is not entitled to participate in any pension plan, insurance, bonus or similar benefits the City provides for its employees. Any provision in this Contract that may appear to give the City the right to direct the Contractor as to the details of doing the work or to exercise a measure of control over the work means that the Contractor will follow the direction of the City as to end results of the work only. 13. AUDIT OF RECORDS. The Contractor will maintain full and accurate records with respect to all services and matters covered under this Contract. The City will have free access at all reasonable times to such records, and the right to examine and audit the same and to make transcript therefrom, and to inspect all program data, documents, proceedings and activities. The Contractor will retain such financial and program service records for at least three (3) years after termination or final payment under the Contract Documents. 14. NOTICES. All communications to either party by the other party will be deemed made when received by such party at its respective name and address as follows: The City City of El Segundo -Public Works 350 Main Street El Segundo, CA 90245 Attention: Arianne Bola (310) 524-2364 abola@elsegundo.org The Contractor Williams Pipeline Contractors, Inc. 10200 Sepulveda Blvd. #255 Mission Hills, CA 91345 Attention: Victor Hernandez (805)386-2393 victor~rcwiliiam�i e•c�om Any such written communications by mail will be conclusively deemed to have been received by the addressee three (3) days after deposit thereof in the United States Mail, postage prepaid and properly addressed as noted above. In all other instances, notices will be deemed given at the time of actual delivery. Changes may be made in the names or addresses of persons to whom notices are to be given by giving notice in the manner prescribed in this paragraph. 15. NO THIRD PARTY BENEFICIARY. This Contract and every provision herein is for the exclusive benefit of the Contractor and the City and not for the benefit of any other party. Agreement No. 6768 There will be no incidental or other beneficiaries of any of the Contractor's or the City's obligations under this Contract. 16. INTERPRETATION. This Contract was drafted in, and will be construed in accordance with the laws of the State of California, and exclusive venue for any action involving this Contract will be in Los Angeles County. 17. EFFECT OF CONFLICT. In the event of any conflict, inconsistency, or incongruity between any provision of the Contract Documents, precedence will be as follows: A. This Contract; B. The Standard Specifications; and C. Precedence of documents as determined in the Standard Specifications. 18. SEVERABILITY. If any portion of the Contract Documents are declared by a court of competent jurisdiction to be invalid or unenforceable, then such portion will be deemed modified to the extent necessary in the opinion of the court to render such portion enforceable and, as so modified, such portion and the balance of this Contract will continue in full force and effect. 19. AUTHORITY/MODIFICATION. The Parties represent and warrant that all necessary action has been taken by the Parties to authorize the undersigned to execute this Contract and to engage in the actions described herein. This Contract may be modified by written amendment. The City's city manager, or designee, may execute any such amendment on the City's behalf. 20. ACCEPTANCE OF ELECTRONIC SIGNATURES. The Parties agree that this Contract, agreements ancillary to this Contract, and related documents to be entered into in connection with this Contract will be considered signed when the signature of a party is delivered by electronic (.pdo or facsimile transmission. Such electronic or facsimile signature will be treated in all respects as having the same effect as an original signature. 21. COVENANTS AND CONDITIONS. The parties agree that all of the provisions hereof will be construed as both covenants and conditions, the same as if the words importing such covenants and conditions had been used in each separate paragraph. 22. CAPTIONS. The captions of the paragraphs of this Contract are for convenience of reference only and will not affect the interpretation of this Contract. 23. TIME IS OF ESSENCE. Time is of the essence for each and every provision of the Contract Documents. IN WITNESS WHEREOF the parties hereto have executed this Contract the day and year first hereinabove written. Agreement No. 6768 CITY OF EL SEGUNDO Darrell George, City Manager ATTEST- 1 racy Weaver, City Clerk APPROVED AS TO FORM: MARK D. HEN LEY, City Attorney WILLIAMS PIPELINE CONTRACTORS, INC. Name: Victor H n nde Title: Vice Pr ent ' � N nle"= L�oye Barton -Williams Title: Secretary Taxpayer ID No. S29'!� 2fl_is Contractor State License No.: Contractor City LBusiness ue (� License No.: t `�' 1 V O By: t, w — Joaquin azquez, Deputy City Attorney Insurance Reviewed by: ° V o��� Agreement No. 6768 19f.All I Wel• A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Orange } On August 29, 2023 before me, Susan E. Morales, Notary Public ere insert name and ti a oft e o icer personally appeared Victor Hernandez who proved to me on the basis of satisfactory evidence to be the person* whose name* Won-- subscribed to the within instrument and acknowledged to me that heishe/they executed the same in his!her/their authorized capacity(yes , and that by his herA ei signatureH on the instrument the person*, or the entity upon behalf of which the person(&) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. ISUSAN E. MORALES m WITNESS my hand and official seal. U.. COMM. #2444309 —1 �- NOTARY PUBLIC- CALIFORNIA W ORANGE COUNTY `^* MY COMM. Expires April 14, 2027 Notary Public Signature (Notary Public Seal) ADDITIONAL OPTIONAL INFORMATION DESCRIPTION OF THE ATTACHED DOCUMENT Contract - Project ENG 23-25 (Title or description of attached document) Williams Pipeline Contractors, Inc. (Title or description of attached document continued) Number of Pages Document Date 8/29/23 CAPACITY CLAIMED BY THE SIGNER ❑ Individual (s) 0 Corporate Officer Vice President (Title) ❑ Partner(s) ❑ Attorney -in -Fact ❑ Trustee(s) ❑ Other INSTRUCTIONS FOR COMPLETING THIS FORM This form complies with current California statutes regarding notary wording and, if needed, should be completed and attached to the document. Acknolwedgents from other states may be completed for documents being sent to that state so long as the wording does not require the California notary to violate California notary law. • State and County information must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. • Date of notarization must be the date that the signer(s) personally appeared which must also be the same date the acknowledgment is completed. • The notary public must print his or her name as it appears within his or her commission followed by a comma and then your title (notary public). • Print the name(s) of document signer(s) who personally appear at the time of notarization. • Indicate the correct singular or plural forms by crossing off incorrect forms (i.e. he/she/<hp,;- is /ar@ ) or circling the correct forms. Failure to correctly indicate this information may lead to rejection of document recording. • The notary seal impression must be clear and photographically reproducible. Impression must not cover text or lines. If seal impression smudges, re -seal if a sufficient area permits, otherwise complete a different acknowledgment form. • Signature of the notary public must match the signature on file with the office of the county clerk. Additional information is not required but could help to ensure this acknowledgment is not misused or attached to a different document. Indicate title or type of attached document, number of pages and date. Indicate the capacity claimed by the signer. If the claimed capacity is a corporate officer, indicate the title (i.e. CEO, CFO, Secretary). • Securely attach this document to the signed document with a staple. Agreement No. 6768 CERTIFICATEALL- PURPOSE J OF D ..................... A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of orange } On 0 U Q', ® before me, Beata A. Sensi, Nota Public , (mere Rnsen narne and line of the officer) personally appeared Loye Barton -Williams who proved to me on the basis of satisfactory evidence to be the person(-S) whose name{) is/am subscribed to the within instrument and acknowledged to me that t-re-/she/tom executed the same in ftis/her/#eif authorized capacityfies , and that by iris/herfteir signatures) on the instrument the person(s), or the entity upon behalf of which the personH acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct, BETAA, SENSI WITNESS my hand and official seal. �• « # 940 1 I " NOTARY PUBLIC'- CALIFORNIA 0 U1 AGE COUNTY .� MY COMM, Expires Fabmary 15, 202G Notary,Yublic Signature (Notary Public Seal) ADDITIONAL OPTIONAL INFORMATION DESCRIPTION OF THE ATTACHED DOCUMENT (Title or description of attached document) Williams Pipeline Contractors, Inc. d t (Tille or escription of attached document continue d) Number of Pages Document Date 6?"19_123 CAPACITY CLAIMED BY THE SIGNER ❑ Individual (s) El Corporate Officer Secreta /Treasurer (Title) ❑ Partner(s) ❑ Attorney -in -Fact ❑ Trustee(s) ❑ Other 'f 3 ziR INSTRUCTIONS FOR COMPLETING THIS FORM This form complies with current California statutes regarding notary wording and, if needed, should be completed and attached to the document. Acknolwedgents from other states may be completed for documents being sent to that state so long as the wording does not require the California notary to violate California notary law. • State and County information must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment • Date of notarization must be the date that the signer(s) personally appeared which must also be the same date the acknowledgment is completed, • The notary public must print his or her name as it appears within his or her commission followed by a comma and then your title (notary public), • Print the name(s) of document signer(s) who personally appear at the time of notarization, • Indicate the correct singular or plural forms by crossing off incorrect forms (i,e, he/she/they;- is /are ) or circling the correct forms. Failure to correctly indicate this information may lead to rejection of document recording, • The notary seal impression must be clear and photographically reproducible Impression must not cover text or lines. If seal impression smudges, re -seal if a sufficient area permits, otherwise complete a different acknowledgment form, • Signature of the notary public must match the signature on file with the office of the county clerk Additional information is not required but could help to ensure this acknowledgment is not misused or attached to a different document. Indicate title or type of attached document, number of pages and date, . Indicate the capacity claimed by the signer. If the claimed capacity is a corporate officer, indicate the title (i,e, CEO, CFO, Secretary), • Securely attach this document to the signed document with a staple. Agreement No. 6768 City of El Segundo On -Call Water Systems Maintenance and Repair Services, Project No. ENG 23-25 Company Naine: Williams Pipeline Contractors Inc VZOTor, I Phone #: 805.386.2393 Cell pllove-+: 805.275.906'15 A987784 This work is subject to prevailing wage. The hourly wages to be paid laborers, workers, or mechanics shall not be less than the DIR prevailing wage rates for all hour's work in the satire trade or occupation in Los Angeles County. Prevailing wage rates are available online at L.1 fi %ca.goy'dlsr. _— ­_.�____ .. . ............ . . . . ...... ITEM . ...... ................................................................ DESCRIPTION UNIT HOURLY NO. RATE 1 Project Manager Hour $113.17 2 Foreman/Superintendent Hour $111.07 3 Equipment Operator Hour 1 $110.87 Journeyman Hour $88.59 Laborer or Equivalent Hour $82...9....6...... . .. . . B. EQUIPMENT ........... . ITEM .. . ... DESCRIPTION I ...... UNIT ... ................ . . . . ........ HOURLY NO........ ..... 6 ..... . . . . . ................ ........... . ......... Boom Truck ............ . ............ Hou-r---­­­- $763.65 Service Vehicle (utility body 7 pickup) or Equivalent Hour .71 Backhoe (Case 580E or 8 comparable) Hour $86.86 9 .. . .... . .. . .... Welder .... . ..... Hour ]T160.00 350 Alain SO-eei, El Segundo, CA 90245-3813 (310) 524-2300 Agreement No. 6768 ITEM ................................. . . . ............... . . . . . . ................ . . . DESCRIPTION . .... .......... UNIT . ................ - ....... HOU........................ ..... . RLY NO. . . . . . . ............. ...... ..... . ...... .... RA--.T--E-- 10 . .. . . . ........... . . . . . ........... . ........ Compressor (150 cfm) Hour ......... . ..... . . . $28.53 . .......... 5 yd Dump Truck ------------------- — Hour ------ F $ 93.61 .... . ......... 24-inch Vibratory Smooth Drum . ...... 12 ......... ................ Roller Hour [$ 16.08 . .... The prices proposed for each item listed on the Cost Schedule above will be used for comparative analysis of the proposals. The descriptions set forth below of each of the items are not intended to be exclusive descriptions of work categories and the Contractor shall determine and include in its pricing all materials, labor, and equipment necessary to complete each item as shown and specified. Payment of the items within the Cost Schedule shall be made in the fiscal year (July L 2023 to June 30., 2024) when the work is to be completed. The following is general description of each item. The unit prices for items I to 5 shall include the Proposer's hourly cost for a Project Manager, I tl an on -site Superintendent/Foreman., an Equipment Operator, a Journeyman, and a Laborer., in accordance with the provisions of the California Labor Code, Sections 1779 et. Seq. The unit price shall include all costs required to provide personnel for this work (wages, travel payments, fringe benefits.), apart from overhead and profit. The total amount paid to the Contractor shall be the amount of the unit price multiplied by the actual time that the Contractor's personnel are on the repair work. If one of the Contractor's personnel has a dual role on the repair work, such -as Foreman/Equipment Operator. the unit price for the payment shall be based on the role with the hiaher cost. Any overtime worked will be paid at the standard multiplier based on the unit cost. The unit prices for Items 6 to 12 shall include the Proposer's hourly cost for a Dump Truck (5 lid Bobtail or comparable), a Boom Truck., a Service Vehicle (utility body pickup), a Backhoe (Case 580E or comparable), a Compressor (150 cfm), 24-inch Vibratory Smooth Drum Roller 2nd a Welder. The unit price shall include all costs associated with acquiring and using the necessary equipment for the repair work. The total amount paid to the Contractor shall be the ?mount of the unit price multiplied by the actual time that each piece of equipment is used for the repair work. 350.1fain Street, El Segundo, CA 90245-3813 (310) 524-2300 Agreement No. 6768 DESIGNATION OF SUBCONTRACTORS ON -CALL WATER SYSTEMS MAINTENANCE AND REPAIR SERVICES PROJECTNO.: ENG 23-25 Company Name; . .......... As detailed in Section 2-33.1 (Page 3 of 36) of the City Standard Specifications, Bidder certifies that it has listed below all subcontractors who will perform work in excess of one- half of one percent (0.5%) of the total bid price or certifies that the bidder is fully qualified to yea I)r and tvill ierl"ort-ri that of the woi -k itself Description of Subcontractor's Portion of Name of Contractor Work Estimated Subcontractor Address License No. Subcontracted $ Amount (Number and Street) 5103 Elton Street A987784 Pipe Tec . (City.. Zip Code) .......... . ................. Baldwin Park, CA 91706 --------- Performance Pipeline 5292 Svsteml.Drive 825824 Technologies, Inc. Huntington Beach, CA 92649 ....... 5841 Engineer Drive 774055 Sancon Hunington Beach, CA 92649 . .... .............. . ..... ... Inline Concrete cutting 2420 River Rd Ste 230-823 ____'_j_Q25852 & Coring, Inc. ................................. NorcoCA 92860 , . . . . ........... ......... . . . .......... . ................. . . . . . Concrete Coring _14005 Qpq!]9e - ...nue -A.......ve..... 1081203 Company, Inc. Paramount CA 9072.3 . ............... . . ...... (Make copies, of this page if additional space is needed) t4l-l& 8/24/23 Signature of Bidder Date .350 Afain,.Nlt-eel, El Segundo, C-A 90245-3813 (310) 524-2.300 Agreement No. 6768 REFERENCES Company Name: Williams Pipeline Contractors Inc The following are the names, addresses, and telephone numbers for public agencies for which BIDDER has performed similar work as the prime contractor or rri;.jor subcontractor within the past five (5) years: 1. Project Title: Burbank Water Reclamation Plant (BWRP) Inverted Sanitary Sewer Siphon Emergency Repairs Location: 740 N Lake St, Burbank, CA 91502 City of Burbank 275 E Olive Ave, Burbank, CA 91502 Victor Hernandez 805-275-9069 Victor@williamspipe.com Name, current telephone number, and email of person familiar with project Contract amount: $-?10.2..8,492.26 Date completed: 9/30/2022 Amount of work done by my/our firm under contract $ 2 �O28,492.26 Did vour firm have any financial interest in Project? N# 2. Project Title: ESR - Longwood Avenue (800 Block) Location: 816 S Longwood Ave, Los Angeles, CA 90005 City of Los Angeles 1149 S. Broadway Suite 700 Victor Hernandez 805-275-9069 Victor@williamspipe.com Name., current telephone number, and email of person familiar with project •I a Date completed: 6/4/22 . . . ..... Amount of work done by my/our firm under contract $ 70,414.86 350 Main Sff°eet, El Segundo, CA 90245-3813 (3J0) 524-2300 Agreement No. 6768 3. Project Title: ESR- Mona Blvd(11500 Block) Location: -11561 Mona Blvd, Los Angeles, CA 90059 City of Los Angeles 1149 S. Broadway Suite 700 Name and address of owner Victor Hernandez 805-275-9069 Victor@williamspipe.com Name, current telephone number, and email of person familiar with project I^ - - • I - - Contract arriount: $...85 00 Date completed: 12/23/22 Amount of work done by my/our firm under contract $ 82,373,89 Did your firm have any financial interest in Project? No 4. Project Title: ESR- Morrison Street (15300 Block) Location: 15335 Morrison St, Sherman Oaks, CA 91403 City of Los Angeles 1149 S. Broadway Suite 700 Name and address of owner Victor Hernandez 805-275-9069 Victor@williamspipe.com Name, current telephone number, and email of person familiar with project Type of Work: Sewer Improvement Contract amount- $ 57,000 Date completed: 1/31/23 Amount of work done by my/our firm under contract $_5(�,894.84 .... ..IT_ ITIT ITIT__ 5. Project Title: ESR - Balmer Dr (2000 Block) ........... Location: 2001 Blamer Dr, Los Angeles, CA 90033 City of Los Angeles 1149 S. Broadway Suite 700 Name and address of owner Victor Hernandez 805-275-9069 Victor@williamspipe.com Name, current telephone number, and email of person familiar with project Type of Work: Sewer Improvement 350 .11(fin Sit -eel, 1_71,5egundo, CA 90245-3813 (310) 524-2300 Agreement No. 6768 Contract amounts $ 75,000 ................... -- .... ,-. Date completed: 11/4/22 ........ Amount of work done by my/our firm under contract $61,750 ........ ��Iiave any financial interest in Project? _Ng The following are the names, addresses., and telephone numbers for all brokers and sureties from whom BIDDER intends to procure insurance bonds: Rohm Insurance 26 Plaza Sauare, Suite 200 Orange, CA 90866-1417 (7 516-2960 .................. - . . ii) . . ......................................... North American Specialty Insurance Cornp�!2y..... .. .......... ........... ........ 777 S. Figueroa St., Suite 3700, Los Angeles, CA 90017 (714) 546-5118 -- .... ---- ................. . . - . ..... 350AMin Sireel, El Segundo, C,1 90245-3813 (310) 524-2300 Agreement No. 6768 INSURANCE REQUIREMENTS [MUST BE SUBMITTED WITH PROJECT PROPOSAL] ON -CALL WATER SYSTEMS MAINTENANCE AND REPAIR SERVICES PROJECTNO.: ENG 23-25 To be awarded this contract, the successful bidder must procure and maintain the following types of insurance with coverage limits complying, at a mimmurn, with the limits set forth below: TYN of Ita lrr tncq Urnits Commercial general liability: $2,000,000 Business automobile liability: $1,000,000 lWorkers compensation: Statutory requirement Commercial aeneral liability insurance must meet or exceed the requirements of ISO-CGL Form No. CG 00 01 11 85 or 88. The arnount of insurance set fiertli above must be a combined single limit per occurrence for bodily injury, personal injury, and property damage for the policy coverage. Liability policies must be endorsed to name the City, its officials, and employees as "additional insureds" under said insurance coverage and to state that such insurance will be deemed "primary" such that any other insurance that may be carried by the City will be excess thereto. Such endorsement must be reflected on FSO Form No. CG 20 10 11 85 or 88, or equivalent. Such insurance must be on an "occurrence," not a "claims niade," basis and will not be cancelable or subject to reduction except upon thirty (30) days prior written notice to the City. Insurer will agree in writing to waive all rights of subrogation against the City, its officers, officials, employees and volunteers for losses arising from work performed by Contractor for the City. Automobile coverage must be written on ISO Business Auto Coverage Form CA 00 01 06 92, including symbol I (Any Auto). The Consultant must furnish to the City duly authenticated Certificates of Insurance evidencing maintenance of the insurance required under this Agreement. endorsements as required herein, and such other evidence of insurance or copies of policies as may be reasonably required by the City from time to time. Insurance must be placed with admitted insurers with a current A.M. Best Company Rating equivalent to at least a Rating of "AXIL" Certificate(s) must renect that the insurer will provide thirty (30) day notice of any cancellation of coverage. The Consultant will require its insurer to modifv, such certificates to delete any exculpatory wording stating that failure of the insurer to mail Nvritten notice of cancellation imposes no obligation, and to delete the word "endeavor" with regard to any notice provisions. The City requires California Worker's Compensation Coverage with the associated Waiver. Out-of­ state coverage will not be accepted in lieu of the California coverage, because the work is being performed in the State of California. By signing this form, the bidder certifies that it has read. understands, and will comply with these insurance requirements if it is selected as the City's consultant. Failure to provide this insurance will render the bidder's proposal "nonresponsive." 8/24/23 M_�JA___ Date Bidder's Signature 350 Main Sireel, El Segundo, CA 90245-3813 (310) 524-2300 Agreement No. 6768 SCOPE OF SERVICES 1-0. WATER SYSTEMS MAINTENANCE AND REPAIR SCOPE OF SERVICES: The services requested would be similar to the water system maintenance and repair services provided by the contractor in the normal course of business. All work performed under this contract shall be for potable water facilities owned and operated by the City of El Segundo. The Contractor must respond to emergency sites within 45 minutes. I-L The Services are to be provided on an "as needed and when requested" basis and include, but not be limited to, the following City needs: a. Repairs or replacement of water main lines, service laterals, gate valves, air relief valves, fire hydrants., meters., meter boxes, etc. b. Potholing of existing utilities c. Trenching and subgrade preparations d. Surface restoration e. Disposal of removals f. Traffic Control g. NPDES Compliance h. ewatering of excavations i. Installation of concrete thrust blocks j. Testing k. Disinfection 1. Final Flushing m. Bacteriological Tests n. Disposal of Test Water o. Site remediation and cleaning p. Estimating and providing written quotes regarding repairs or installations to the Project Manager 1-2. The above is not intended as an exhaustive list. The scope of work will be determined on an as requested basis. It is expected that the successful contractor will be able to make good repairs any portion of the City facilities' water systems on as -needed basis. 1-3. The service company's principal business shall be the installation, repair, service, inspection and testing of water systems. 1-4, The service company shall own and operate a fully licensed independent or fully, licensed franchised company, and shall be fully experienced to service, repair., inspect and test all of the water systems installed in the City. 2-0, Working Days Regular working hours shall be Monday to Friday, 7:00am to 4:00pm. Compensation 2D at the hourly rate will begin when work commences on site. 350.1fain Sit -eel, El Segundo, CA 90245-3813 (310) 524-2300 Agreement No. 6768 3.0. Contract Term The to of this contract will be from September 1, 2023 to June 30, 2024. Prices shall remain firm for the first twelve months period of the contract. 4.0. Contractor and City Business Licenses No bid will be accepted from a Contractor who has not been licensed in accordance with the provisions of the State Business and Professions Code. For these projects, the acceptable license class is "A". The Contractor and his Sub -Contractors will be required to possess the correct license for their project classifications, as well as a valid Department of Industrial Relations (DIR) registration, valid Business License from the City of El Segundo, and insurance as required per the construction agreement. 5.0, Subcontractors The services of Sub -contractors will comply with all terms and conditions required of the Conti -actor. 350 Main Slyeel, ElSegundo, CA 90245-3813 (310) 524-2300 Agreement No. 6768 This page is part of your document - DO NOT DISCARD II III III III II'I IIII I IIII � IIII III III II III II I Recorded/Filed in Official Records Recorder's Office, Los Angeles County, California 09/08/23 AT 10:16AM FEES: TAXES: OTHER: SB2: PAID. Inllll II IIIIIII II II I911III hull III IIIIIII II IIII�I III II I II III �IIIII III IIIII II II III LEADSHEET 1111111111111111111111111111111111111111111111111111111 202309081900003 00023755626 �idmidinuimmiiiu 014264997 SEQ: 01 DAR - Counter (Upfront Scan) IIPoIIIi1lYll11111111111111111111111111111111111 IIIIIAlI11IlYIItlIIIIYIUIIIIIIV111111111111Y1 THIS FORM IS NOT TO BE DUPLICATED Pages: 0011 49.00 0.00 0.00 75.00 U24.00 E662432 R(,'0 F',l 7) { \j G R l (J J E S 1 E ["), B Y Agreement No. 6768 WHEN RECORDED MAT IV NAME L#J;%jil%VIftj Cs^*rs6c.*dr&, J:dtc. MAILING 44X,,ESS 10, ,L130 Scjp%jjvejLv4 olvA., Sv;Vt 2,S5 p%-%jvl e lk dj%S4S Pe- r rre r SPACE ABOVE I HO L lIII UQERVEJD FOR RECORDEITS USE Mum, Agreement No. 6768 FAITHFUL PERFORMANCE BOND ON -CALL WATER SYSTEMS REPAIR SERVICES PROJECT PROJECT NO.: ENG 23-25 Bond No. 2340730 Bond Fee: $807.00 Williams Pipeline Contractors Inc. ("PRINCIPAL") and Swiss Re Corporate Solutions America Insurance Corporation , a corporation incorporated under the laws of the State of Missouri and licensed by the State of California to execute bonds and undertakings as sole surety, as surety ("SURETY"), are held and firmly bound unto the CITY OF EL SEGUNDO ("CITY") in the sum of Fitly Nine Thousand, Dollars ($ 9, 00.. 0), lawful money of the United States, which may be increased or decreased by a rider hereto executed in the same manner as this bond, for the payment of which sum PRINCIPAL and SURETY bind themselves, their successors, and assigns, jointly and severally, by this instrument. PRINCIPAL or SURETY will apply this bond for the faithful performance of any and all of the conditions and stipulations set forth in this bond, SPECIFICATIONS NO. ENG 23-25, and the public works contract executed with such Specifications. In the case of any default in the performance of the conditions and stipulations of this undertaking, it is agreed that PRINCIPAL or SURETY will apply the bond or any portion thereof, to the satisfaction of any damages, reclamation, assessments, penalties, or deficiencies arising by reason of such default. BOND CONDITIONS 1. PRINCIPAL will construct the public improvements identified in SPECIFICATIONS NO. ENG 23-25, a copy of which is on file with CITY's Engineering Division ("Public Project"). Such performance will be in accordance with CITY's plans and profiles (CITY DRAWING FILE NO. ENG 23-25) which are made a part of this bond when said plans and profiles are approved by the City Council and filed with CITY's Engineering Division. CITY has estimated the required amount of the bond as shown above. 2. PRINCIPAL's work on the Public Project will be done in accordance with CITY's plans and specifications and with any permit issued by CITY. Should PRINCIPAL fail to complete all required work within the time allowed, CITY may, at its sole discretion, cause all required work to be done and the parties executing the bond will be firmly bound for the payment of all necessary costs therefor. 3. PRINCIPAL will guarantee its work against any defective work, labor, or materials on the Public Project for a period of one (1) year following the Public Project's completion and acceptance by CITY. I-E-1 Agreement No. 6768 4. This bond is conditioned upon and guarantees due compliance with all applicable law including, without limitation, the El Segundo Municipal Code ("ESMC"). 5. SURETY, for value received, agrees that no changes, extensions of time, alteration or modification of SPECIFICATIONS NO. ENG 23-25 or of the obligation to be performed will in any way affect its obligation on this bond, and it waives notice of any such change, extension of time, alteration or modification of the contract documents or of the obligation to be performed. 6. This bond consists of this instrument; the plans and specifications identified above; and the following two (2) attached exhibits all of which are incorporated herein by reference: A. A certified copy of the appointment, power of attorney, bylaws or other instrument entitling or authorizing the persons executing this bond to do so; & A certificate issued by the county clerk for the county in which SURETY's representative is located conforming with California Code of Civil Procedure § 995.640 and stating that SURETY's certificate of authority has not been surrendered, revoked, cancelled, annulled, or suspended, or in the event that it has, that renewed authority has been granted; and 7. Should PRINCIPAL perform its obligations within the time allowed, PRINCIPAL's obligation will be void upon the acceptance of the performance by CITY; otherwise this obligation will remain in full force and effect. [SIGNATURES ON FOLLOWING PAGE] I-E-2 Agreement No. 6768 SIGNED AND SEALED this 29th day of August 2023 Williams Pipeline Contractors, Inc. Swiss Re Corporate Solutions America Insurance Corporation PRINCIPAL's *' Vice President, SURETY's I UT` Attorney -in -Fact, Victor Hernandez Cheryl L. Thomas P` LW1111 L..'s SECRETARY, Loye Barton -Williams SURETY's SECRETARY PRINCIPAL's MAILING ADDRESS: SURETY's MAILING ADDRESS: 10200 Sepulveda Blvd., Suite 255 777 S. Figueroa St., Suite 3700 Mission Hills, CA 91345 Los Angeles, CA 90017 NOTE: (1) ALL signatures must be acknowledged by a notary public. Return one (1) original to City Clerk's Office. (2) Bond shall be effective for one (1) year after acceptance of the job. I-E-3 Agreement No. 6768 ALL- PURPOSE -1 CERTIFICATE OF ACKNOWLEDGMEN11 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Orange } On Oug.29,20J3 before me, Beata A. Sensi, Nota Public (Here insert name and title of the officer) personally appeared Loye Barton -Williams tl who proved to me on the basis of satisfactory evidence to be the persons) whose name(&) is/afe subscribed to the within instrument and acknowledged to me that he/she/" executed the same in ftisiher/thek authorized capacity{tesj, and that by iris/her r signatureH on the instrument the personal, or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. EATAA. SNI WITNESS my hand and official seal. COMM,9�01 NOTARY PUBLIC- CA.IFC RNIA 0 UWJ v ORANGE COUNTY ruary _x. my CCt�V�.lttp+res Fet�arery't5a 2Ci26', NotarqOubiic Signature (Notary Public Seal) ADDITIONAL OPTIONAL INFORMATION DESCRIPTION OF THE ATTACHED DOCUMENT 16 OnC1 (Title or description of attached document) Williams Pipeline Contractors, Inc. Tdle or descri Lion of attached document ed continu.........................m Number of Pages Document Date .' CAPACITY CLAIMED BY THE SIGNER ❑ Individual (s) 0 Corporate Officer Secretery/Treasurer (Title) ❑ Partner(s) ❑ Attorney -in -Fact ❑ Trustee(s) ❑ Other INSTRUCTIONS FOR COMPLETING THIS FORM This form complies with current California statutes regarding notary wording and, if needed, should be completed and attached to the document. Acknolwedgents from other states may be completed for documents being sent to that state so long as the wording does not require the California notary to violate California notary law. • State and County information must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. • Date of notarization must be the date that the signer(s) personally appeared which must also be the same date the acknowledgment is completed, • The notary public must print his or her name as it appears within his or her commission followed by a comma and then your title (notary public). • Print the name(s) of document signer(s) who personally appear at the time of notarization, • Indicate the correct singular or plural forms by crossing off incorrect forms (i e. he/she/they, is /are ) or circling the correct forms, Failure to correctly indicate this information may lead to rejection of document recording • The notary seal impression must be clear and photographically reproducible. Impression must not cover text or lines, If seal impression smudges, re -seal if a sufficient area permits, otherwise complete a different acknowledgment form • Signature of the notary public must match the signature on file with the office of the county clerk.. Additional information is not required but could help to ensure this acknowledgment is not misused or attached to a different document Indicate title or type of attached document, number of pages and date, Indicate the capacity claimed by the signer If the claimed capacity is a corporate officer, indicate the title (i e CEO, CFO, Secretary), • Securely attach this document to the signed document with a staple. Agreement No. 6768 ALL- PURPOSE CERTIFICATE OF ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. ------------------ State of California County of Orange } On August 29, 2023 before me, Susan E. Morales, Nota Public ere insert name and title or [ e o cer personally appeared Victor Hernandez F who proved to me on the basis of satisfactory evidence to be the person* whose names) ishffe subscribed to the within instrument and acknowledged to me that hefsheAhey executed the same in hisiher/their authorized capacity0es), and that by hisiheFAhei signatures) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. SUSAN E. MORALES m WITNESS my hand and official seal. U COMM. #2444309 -1 a r ° NOTARY PUBLIC- CALIFORNIA n W ORANGE COUNTY —� MY COMM. Expires April 14, 2027 Notary Public Signature (Notary Public Seal) ADDITIONAL OPTIONAL INFORMATION DESCRIPTION OF THE ATTACHED DOCUMENT Bond #2340730 (Titre or description of attached document) Williams Pipeline Contractors, Inc. �._. ......... (ritie or description of attached document continued) Number of Pages Document Date 8/29/23 CAPACITY CLAIMED BY THE SIGNER ❑ Individual (s) 0 Corporate Officer Vice President (Title) ❑ Partner(s) ❑ Attorney -in -Fact ❑ Trustee(s) ❑ Other INSTRUCTIONS FOR COMPLETING THIS FORM This form complies with current California statutes regarding notary wording and, if needed, should be completed and attached to the document. Acknolwedgenis from other states may be completed for documents being sent to that state so long as the wording does not require the California notary to violate California notary law. • State and County information must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. • Date of notarization must be the date that the signer(s) personally appeared which must also be the same date the acknowledgment is completed. • The notary public must print his or her name as it appears within his or her commission followed by a comma and then your title (notary public). • Print the name(s) of document signer(s) who personally appear at the time of notarization. • Indicate the correct singular or plural forms by crossing off incorrect forms (i.e. he/she/they,— is /are ) or circling the correct forms. Failure to correctly indicate this information may lead to rejection of document recording. • The notary seal impression must be clear and photographically reproducible. Impression must not cover text or lines. If seat impression smudges, re -seal if a sufficient area permits, otherwise complete a different acknowledgment form. • Signature of the notary public must match the signature on file with the office of the county clerk. Additional information is not required but could help to ensure this acknowledgment is not misused or attached to a different document. Indicate title or type of attached document, number of pages and date. Indicate the capacity claimed by the signer, If the claimed capacity is a corporate officer, indicate the title (i,e.. CEO, CFO, Secretary). • Securely attach this document to the signed document with a staple Agreement No. 6768 ALL- PURPOSE *%'.%OERTIFICATE OF ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Oran On August 29, 2023 before me, Susan E. Morales, Notary,Public ere Ise naMo aneOT Me e IVW personally appeared Cheryl L. Thomas p who proved to me on the basis of satisfactory evidence to be the person{-e) whose name{ is/we subscribed to the within instrument and acknowledged to me that he/she/tom executed the same in his/her/their authorized capacityfies), and that by iris/herr#-eO signature* on the instrument the person*, or the entity upon behalf of which the personW acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. c SUSAN E. MORALES m WITNESS my hand and official seal, U ", : COMM. #2444309 —{ F— -v NOTARY PUBLIC- CALIFORNIA n LU ORANGE COUNT Ji MY COMM. Expires April 14, 2027 60 TV A r� 'P d-) m it l Notary Public Signature (Notary Public Seal) ADDITIONAL OPTIONAL INFORMATION DESCRIPTION OF THE ATTACHED DOCUMENT Bond #2340730 (Tide or description of attached document) Swiss Re Corporate Solutions America Ins. Corp. (fide or description of attached document continued) Number of Pages Document Date 8/29/23 CAPACITY CLAIMED BY THE SIGNER ❑ Individual (s) ❑ Corporate Officer (Title) ❑ Partner(s) Z Attorney -in -Fact ❑ Trustee(s) ❑ Other INSTRUCTIONS FOR COMPLETING THIS FORM This form complies with current California statutes regarding notary wording and, if needed, should be completed and attached to the document. Acknohvedgents from other states may be completed for documents being sent to that state so long as the wording does not require the California notary to violate California notary law, • State and County information must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. • Date of notarization must be the date that the signer(s) personally appeared which must also be the same date the acknowledgment is completed. • The notary public must print his or her name as it appears within his or her commission followed by a comma and then your title (notary public). • Print the name(s) of document signer(s) who personally appear at the time of notarization. Indicate the correct singular or plural forms by crossing off incorrect forms (i.e. he/she/they-- is /are ) or circling the correct forms. Failure to correctly indicate this information may lead to rejection of document recording. The notary seal impression must be clear and photographically reproducible. Impression must not cover text or lines. If seal impression smudges, re -seal if a sufficient area permits, otherwise complete a different acknowledgment form. Signature of the notary public must match the signature on file with the office of the county clerk. Additional information is not required but could help to ensure this acknowledgment is not misused or attached to a different document. Indicate title or type of attached document, number of pages and date. Indicate the capacity claimed by the signer. If the claimed capacity is a corporate officer, indicate the title (i.e. CEO, CFO, Secretary). • Securely attach this document to the signed document with a staple. Agreement No. 6768 Swiss Re Corporate Solutions America Insurance Corporation Electronic Corporate Seal Please read through the below Usage Guidelines for our Electronic Corporate Seal: 1) This Electronic Corporate Seal has been provided for convenience. Swiss Re Corso cannot provide assurance that specific obligees will, or will not, accept an Electronic Corporate Seal. The preferred method remains a physically affixed seal. The Electronic Corporate Seal is used at the discretion of your Agency or Brokerage, and Swiss Re Corso disclaims any liability if the use of the Electronic Corporate Seal results in any instrument being rejected or challenged, 2) The Electronic Corporate Seal can only be used for electronically affixing a seal to a surety bond, or related instrument, that has been authorized by Swiss Re Corso and is being executed on behalf of Swiss Re Corso by your Agency or Brokerage pursuant to a valid Power of Attorney; 3) Your Agency or Brokerage may not transfer an Electronic Corporate Seal to any other entity or person without the written consent of Swiss Re Corso; 4) Swiss Re Corso may revoke permission to use the Electronic Corporate Seal at any given time; and 5) Any use of the Electronic Corporate Seal outside of the above described guidelines is not authorized Agreement No. 6768 SWISS RE CORPORATE SOLUTIONS SWISS RE CORPORATE SOLUTIONS AMERICA INSURANCE CORPORATION ("SRCSAIC") SWISS RE CORPORATE SOLUTIONS PREMIER INSURANCE CORPORATION ("SRCSPIC") WESTPORT INSURANCE CORPORATION ("WIC') GENERAL POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS, THAT SRCSAIC, a corporation duly organized and existing under laws of the State of Missouri, and having its principal office in the City of Kansas City, Missouri, and SRCSPIC, a corporation organized and existing under the laws of the State of Missouri and having its principal office in the City of Kansas City, Missouri, and WIC, organized under the laws of the State of Missouri, and having its principal office in the City of Kansas City. Missouri, each does hereby make, constitute and appoint: TODD M. ROHM, CATHY S. KENNEDY, BEATA A. SENSI, CHERYL L. THOMAS, and SHANE WOLF JOINTLY OR SEVERALLY Its true and lawful Attomey(s)-in-Fact, to make, execute, seal and deliver, for and on its behalf and as its act and deed, bonds or other writings obligatory in the nature of a bond on behalf of each of said Companies, as surety, on contracts of suretyship as are or may be required or permitted by law, regulation, contract or otherwise, provided that no bond or undertaking or contract or suretyship executed under this authority shall exceed the amount of: FIFTY MILLION ($50,000,000.00) DOLLARS This Power of Attorney is granted and is signed by facsimile under and by the authority of the following Resolutions adopted by the Boards of Directors of both SRCSAIC and SRCSPIC at meetings duly called and held on the 18th of November 2021 and WIC by written consent of its Executive Committee dated July 18, 2011. "RESOLVED, that any two of the President, any Managing Director, any Senior Vice President, any Vice President, the Secretary or any Assistant Secretary be, and each or any of them hereby is, authorized to execute a Power of Attorney qualifying the attorney named in the given Power of Attorney to execute on behalf of the Corporation bonds, undertakings and all contracts of surety, and that each or any of them hereby is authorized to attest to the execution of any such Power of Attorney and to attach therein the seal of the Corporation; and it is FURTHER RESOLVED, that the signature of such officers and the seal of the Corporation may be affixed to any such Power of Attorney or to any certificate relating thereto by facsimile, and any such Power of Attorney or certificate bearing such facsimile signatures or facsimile seal shall be bindine ution the Corporation when so affixed and in the future with reeard to anv bond, undertaking or contract of surety to which it is attached." P' &� tsoq f;"'M w ° l Iiy .�. — T n m Erik Janssens, Senior V IC & Senior or5RC5A1C &Senior Vice President n �, C'a of SRCSPIC &Senior Vice President of WIC ieb 1973 � x r, fig ° ? ol yy s trV W 3,.•` By -,..« aryl Gerald Jagrowski, Vice President of SRCSAIC & Vice President of SRCSPIC --too � � � &. Vice Prew'0demti of W1 C IN WITNESS WHEREOF, SRCSAIC, SRCSPIC, and WIC have caused their official seals to be hereunto affixed, and these presents to be signed by their authorized officers this 10 day of NOVEMBER 20 22 Swiss Re Corporate Solutions America Insurance Corporation State of Illinois Swiss Re Corporate Solutions Premier Insurance Corporation County of Cook, Westport Insurance Corporation On this 10 day of,.. NOVEMBER . 20 22 , before me, a Notary Public personally appeared Erik fans gl1s , Senior Vice President of SRCSAIC and Senior Vice President of SRCSPIC and Senior Vice President of WIC and t crald Jagrowski , Vice President of SRCSAIC and Vice President of SPCSPIC and Vice President of WIC, personally known to me, who being by me duly sworn, acknowledged that they signed the above Power of Attorney as officers of and acknowledged said instrument to be the voluntary act and deed of their respective companies. OFF10 nt. CHAt"NA14t{I 1= ,l fir.& the duly elected Se . ............... . —...... foregoing is a true and correct copy of a Power of Attorney given by said SRCSAIC and SRCSPIC and WIC, which is still in full force and effect. IN WITNESS WHEREOF, I have set my hand and affixed the seals of the Companies this 29th day of AUGUST 2023 Jeffrey Goldberg, Senior Vice President & Assistant Secretary of SRCSAIC and SRCSPIC and WIC Agreement No. 6768 No. 3208-6 STATE OF CALIFORNIA DEPARTMENT "ARTMENT OF INSURANCE C1" I'll W.11011', Amended Certificate of Authority THIS IS TO CERTIFY that, pursuant to the Insurance Code of the State of California, Swiss Re Corporate Solutions America Insurance Corporation of Missouri, organized under the laws of Missouri, subject to its Articles of Incorporation or other fundamental organizational documents, is hereby authorized to transact within this State, subject to all provisions of this Certificate, the following classes of insurance: Fire, Marine, Surety, Disability, Plate Glass, Liability, Workers' Compensation, Boiler and Machinery, Burglary, Sprinkler, Automobile and Aircraft as such classes are now or may hereafter be defined in the Insurance Laws of the State of California. THIS CERTIFICATE is expressly conditioned upon the holder hereof now and hereafter being in full compliance with all, and not in violation of arty, of the applicable laws and lawful requirements made under authority of the laws of the State of California as long as such laws or requirements are in effect and applicable, and as such laws and requirements now are, or may hereafter be changed or amended. IN WITNESS WHEREOF, effective as of the 7" day of June, 2022, I have set my hand and caused my official seal to be affixed this 7' day of June, 2022 Ricardo Lara Insurance Commissioner By Valerie J. Sarfaty for Catalina Hayes -Bautista Insurance Chief Deputy NOTICE: Qualification with the Secretary of State must be accomplished as required by the Cal ifomia Corporations Code promptly after issuance of this Certificate of Authority, Failure to do so will be a violation of Insurance Code section 701 and will be grounds for revoking this Certificate of Authority pursuant to the covenants made in the application therefor and the conditions contained herein. Agreement No. 6768 This is a true and certified copy of the record U it bears the seal, imprinted in purple ink, of the Registrar-Recorder/County Clerk - c . Agreement No. 6768 This page is part of your document - DO NOT DISCARD 20230599089 Recorded/Filed in Official Records Recorder's Office, Los Angeles County, California 09/08/23 AT 10:16AM Pages: 0011 FEES: 49.00 TAXES: 0.00 OTHER: 0.00 SB2: 75.00 PAID: 124.00 I II IIVI II IIIIII I� IIIIIII AI IIIIII I III IIIIIII II II IIV III YIII� II II III III IIIIIII II II II LEADSHEET 1111111111111111111111111111111111111111 1 202309081900003 00023756626 IAIflVllllllllll@IIIIYVII� 014264997 SEQ: 02 DAR Counter (Upfront Scan) IIIIIIII�IIINNIIIIIVflIAIIIIW191�I111�Y1 - THIS FORM IS NOT TO BE DUPLICATED IIIIIIIII��IIIIIIIIIkIIN11111111�I�IIIIAIIIIII� - 1LI;rB,�,, RECORDEDWHEN R MAILINGAIDDRESS 10ZOD m isiow w11t, CA 913y3 Agreement No. 6768 I � V i 9�l �,i UVE TI lire;, ,_ USE 4ov%A _.._ ... _ _......._ _ . ... Agreement No. 6768 LABOR AND MATERIALS BOND ON -CALL WATER SYSTEMS REPAIR SERVICES PROJECT PROJECT NO.: ENG 23-25 Bond No. 2340730 Bond Fee: Premium included with the Performance Bond Williams Pipeline Conti -actors, Inc. as principal ("PRINCIPAL") and Swiss Re Corporate Solutions America Insurance Corporation a corporation incorporated under the laws of the State of Missouri and licensed by the State of California to execute bonds and undertakings as sole surety, as surety ("SURETY"), are held and firmly bound unto the CITY OF EL SEGUNDO ("CITY") in the sum of Fift Nine "I'housand. Dollars ($5 ,000.O ), lawful money of the United States, which may be increased or decreased by a rider hereto executed in the same manner as this bond, for the payment of which sum PRINCIPAL and SURETY bind themselves, their successors, and assigns, jointly and severally, by this instrument. This bond is conditioned upon and guarantees payment by PRINCIPAL to contractors, subcontractors, and persons renting equipment; payment by PRINCIPAL and all PRINCIPAL'S subcontractors for all materials, provisions, provender, or other supplies, and equipment used in, upon, for or about the performance of the work contemplated in ON -CALL WATER SYSTEMS REPAIR SERVICES PROJECT, SPECIFICATIONS NO. ENG 23-25 ("Public Project"), the public works contract executed for such Public Project, and for all work or labor of any kind performed for the Public Project. In the case of any default in the performance of the conditions and stipulations of this undertaking, it is agreed that PRINCIPAL or SURETY will apply the bond or any portion thereof, to the satisfaction of any damages, reclamation, assessments, penalties, or deficiencies arising by reason of such default. BOND CONDITIONS 1. PRINCIPAL will construct the public improvements identified in SPECIFICATIONS NO. ENG 23-25, and the public works contract executed for such Specifications, copies of which is on file with CITY's Engineering Division ("Public Project"). Such performance will be in accordance with CITY's plans and profiles (CITY DRAWING FILE NO. ENG 23-25), which are made a part of this bond when said plans and profiles are approved by the City Council and filed with CITY's Engineering Division. 2. PRINCIPAL will pay all contractors, subcontractors, and persons renting equipment. 3. PRINCIPAL will pay for all materials and other supplies, for equipment used in, on, for or about the performance of the Public Project, and will pay for all work and labor I-F-1 Agreement No. 6768 thereon. 4. This bond is conditioned upon and guarantees due compliance with all applicable law including, without limitation, the El Segundo Municipal Code ("ESMC"). 5. SURETY, for value received, agrees that no changes, extensions of time, alteration or modification of SPECIFICATIONS NO. ENG 23-25, or of the obligation to be performed will in any way affect its obligation on this bond, and it waives notice of any such change, extension of time, alteration or modification of the contract documents or of the obligation to be performed. 6. This bond consists of this instrument; the plans and specifications identified above; and the following TWO (2) attached exhibits all of which are incorporated herein by reference: A. A certified copy of the appointment, power of attorney, bylaws or other instrument entitling or authorizing the persons executing this bond to do so; and B. A certificate issued by the county clerk for the county in which SURETY's representative is located conforming with California Code of Civil Procedure § 995.640 and stating that SURETY's certificate of authority has not been surrendered, revoked, cancelled, annulled, or suspended, or in the event that it has, that renewed authority has been granted. 7. Should PRINCIPAL perform its obligations within the time allowed, PRINCIPAL's obligation will be void upon the acceptance of the performance by CITY; otherwise this obligation will remain in full force and effect. [SIGNATURES ON FOLLOWING PAGE] I-F-2 Agreement No. 6768 SIGNED AND SEALED this 29th day of August 1 20 23 Williams Pipeline Contractors, Inc. Swiss Re Corporate Solutions America Insurance Corporation PRIN&AL's MT" MY Vice President, S1 Rl " Y's n � Attorney -in -Fact, Victor Hernandez Cheryl L. Thomas AL's SECRETARY, Loye Barton -Williams SURETY'S SECRETARY PRINCIPAL's MAILING ADDRESS: 10200 Sepulveda Blvd., Suite 255 Mission Hills, CA 91345 SURETY's MAILING ADDRESS: 777 S. Figueroa St., Suite 3700 Los Angeles, CA 90017 NOTE: (1) ALL signatures must be acknowledged by a notary public. Return one (1) original to City Clerk's Office. (2) Bond shall be effective for one (1) year after acceptance of the job I-F-3 Agreement No. 6768 ALL- PU�RPOSiE A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Oran On t • 0 3 before me, Beata A. Sensi„ Notary Public , (Here insert name and fitle of the officer) personally appeared Loye Barton -Williams b who proved to me on the basis of satisfactory evidence to be the personfsj whose name() is/afe subscribed to the within instrument and acknowledged to me that f-ma/she/they executed the same in his/her/their authorized capacity{fesj, and that by ifis/herf#beir signatureH on the instrument the personH, or the entity upon behalf of which the person(a) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. ATAA. SE N 1. WITNESS my hand and official seal. COMM, #2394012 NOTARY PUBLIC— CALIFORNIA n„ W' ORANGE COUNTY .a MY . " COMM. Expires February t5, �ti�tf Notaqt45ublic ignat re (Notary Public Seal) ADDITIONAL OPTIONAL INFORMATION DESCRIPTION OF THE ATTACHED DOCUMENT Aonl (Title or description of attached document) Williams Pipeline Contractors, Inc. (Title or description of attached document continued) Number of Pages Document Date CAPACITY CLAIMED BY THE SIGNER ❑ Individual (s) 0 Corporate Officer Secrets /Treasurer (Title) - ❑ Partner(s) ❑ Attorney -in -Fact ❑ Trustee(s) ❑ Other INSTRUCTIONS FOR COMPLETING THIS FORM This form complies with current California statutes regarding notary wording and, if needed, should be completed and attached to the document. Acknolwedgents from other states may be completed for documents being sent to that state so long as the wording does not require the California notary to violate California notary law. • State and County information must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. • Date of notarization must be the date that the signer(s) personally appeared which must also be the same date the acknowledgment is completed • The notary public must print his or her name as it appears within his or her commission followed by a comma and then your title (notary public), • Print the name(s) of document signer(s) who personally appear at the time of notarization • Indicate the correct singular or plural forms by crossing off incorrect forms (i e.. he/she/they—, is /are ) or circling the correct forms. Failure to correctly indicate this information may lead to rejection of document recording. • The notary seal impression must be clear and photographically reproducible Impression must not cover text or lines, If seal impression smudges, re -seal if a sufficient area permits, otherwise complete a different acknowledgment form • Signature of the notary public must match the signature on file with the office of the county clerk. Additional information is not required but could help to ensure this acknowledgment is not misused or attached to a different document Indicate title or type of attached document, number of pages and date. Indicate the capacity claimed by the signer If the claimed capacity is a corporate officer, indicate the title (i.e. CEO, CFO, Secretary). • Securely attach this document to the signed document with a staple. Agreement No. 6768 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Orange } On August 29, 2023 before me, Susan E. Morales, Notary Public ere insert name ana title oft e o icer personally appeared Victor Hernandez R who proved to me on the basis of satisfactory evidence to be the persons} whose names) isfafe subscribed to the within instrument and acknowledged to me that hefshefthey executed the same in hisiheiftheii authorized capacity0es), and that by hisiheFAhei signature* on the instrument the personal, or the entity upon behalf of which the person( acted, executed the instrument. certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. SUSAN E. MORALES M () =r COMM. #2444309 —1 NOTARY PUBLIC- CALIFORNIA 0 W ORANGE COUNTY MY COMM. Expires April 14, 2027 Notary Public Signature (Notary Public seal) ADDITIONAL OPTIONAL INFORMATION DESCRIPTION OF THE ATTACHED DOCUMENT Bond #2340730 (Title or description of attached document) Williams Pipeline Contractors, Inc. (Title or description of attached document continued) Number of Pages Document Date 8/29/23 CAPACITY CLAIMED BY THE SIGNER ❑ Individual (s) 0 Corporate Officer Vice President (Title) ❑ Partner(s) ❑ Attorney -in -Fact ❑ Trustee(s) ❑ Other INSTRUCTIONS FOR COMPLETING THIS FORM This form complies with current California statutes regarding notary wording and, if needed, should be completed and attached to the document. Acknolwedgenis from other states may be completed for documents being sent to that state so long as the wording does not require the California notary to violate California notary law. • State and County information must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. • Date of notarization must be the date that the signer(s) personally appeared which must also be the same date the acknowledgment is completed. • The notary public must print his or her name as it appears within his or her commission followed by a comma and then your title (notary public). • Print the name(s) of document signer(s) who personally appear at the time of notarization. • Indicate the correct singular or plural forms by crossing off incorrect forms (i.e. lie/she/they, is /are ) or circling the correct forms. Failure to correctly indicate this information may lead to rejection of document recording. • The notary seal impression must be clear and photographically reproducible. Impression must not cover text or lines. If seal impression smudges, re -seal if a sufficient area permits, otherwise complete a different acknowledgment form. • Signature of the notary public must match the signature on file with the office of the county clerk. Additional information is not required but could help to ensure this acknowledgment is not misused or attached to a different document. Indicate title or type of attached document, number of pages and date. Indicate the capacity claimed by the signer. If the claimed capacity is a corporate officer, indicate the title (i.e. CEO, CFO, Secretary). • Securely attach this document to the signed document with a staple. Agreement No. 6768 ALL- PURPOSE CERTIFICATE OF ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Orange On August 29, 2023 before me, Susan E. Morales, Nota Public eio miarsert name wan° Re 31 fne o a rt personally appeared Cheryl L. Thomas who proved to me on the basis of satisfactory evidence to be the person fe) whose name{sj ish" subscribed to the within instrument and acknowledged to me that hee/she/#+teyR executed the same in bi-s/her/the# authorized capacityfie*, and that by i-is/herf hei signature(s) on the instrument the personal, or the entity upon behalf of which the persons) acted, executed the instrument. certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Notary Public Signature (Notary Public Seal) ADDITIONAL OPTIONAL INFORMATION DESCRIPTION OF THE ATTACHED DOCUMENT Bond #2340730 (Title or description of attached document) Swiss Re Corporate Solutions America Ins. Corp. (Title or description of attached document continued) Number of Pages Document Date 8129123 CAPACITY CLAIMED BY THE SIGNER ❑ Individual (s) ❑ Corporate Officer (Title) ❑ Partner(s) E Attorney -in -Fact. n Trustee(s) ❑ Other SUSAN E. MORALES nl COMM, #2444309 —I 0 NOTARY PUBLIC- CALIFORNIA n W ORANGE COUNTY MY COMM. Expires April 14, 2027 INSTRUCTIONS FOR COMPLETING THIS FORM This form complies with current California statutes regarding notary wording and, if needed, should be completed and attached to the document. Acknohaedgents j•om other states may be completed for documents being sent to that state so long as the wording does not require the California notary to violate California notary law. • State and County information must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. • Date of notarization must be the date that the signer(s) personally appeared which must also be the same date the acknowledgment is completed. • The notary public must print his or her name as it appears within his or her commission followed by a comma and then your title (notary public). • Print the name(s) of document signer(s) who personally appear at the time of notarization. • Indicate the correct singular or plural forms by crossing off incorrect forms (i.e. he/she/they,— is /are ) or circling the correct forms. Failure to correctly indicate this information may lead to rejection of document recording. • The notary seal impression must be clear and photographically reproducible. Impression must not cover text or lines. If seal impression smudges, re -seal if a sufficient area permits, otherwise complete a different acknowledgment form. • Signature of the notary public must match the signature on file with the office of the county clerk. Additional information is not required but could help to ensure this acknowledgment is not misused or attached to a different document, Indicate title or type of attached document, number of pages and date. Indicate the capacity claimed by the signer. If the claimed capacity is a corporate officer, indicate the title (i.e. CEO, CFO, Secretary). • Securely attach this document to the signed document with a staple, Agreement No. 6768 Swiss Re Corporate Solutions America Insurance Corporation Electronic Corporate Seal Please read through the below Usage Guidelines for our Electronic Corporate Seal: 1) This Electronic Corporate Seal has been provided for convenience. Swiss Re Corso cannot provide assurance that specific obligees will, or will not, accept an Electronic Corporate Seal. The preferred method remains a physically affixed seal. The Electronic Corporate Seal is used at the discretion of your Agency or Brokerage, and Swiss Re Corso disclaims any liability if the use of the Electronic Corporate Seal results in any instrument being rejected or challenged; 2) The Electronic Corporate Seal can only be used for electronically affixing a seal to a surety bond, or related instrument, that has been authorized by Swiss Re Corso and is being executed on behalf of Swiss Re Corso by your Agency or Brokerage pursuant to a valid Power of Attorney, 3) Your Agency or Brokerage may not transfer an Electronic Corporate Seal to any other entity or person without the written consent of Swiss Re Corso, 4) Swiss Re Corso may revoke permission to use the Electronic Corporate Seal at any given time and 5) Any use of the Electronic Corporate Seal outside of the above described guidelines is not authorized Agreement No. 6768 SWISS RE CORPORATE SOLUTIONS SWISS RE CORPORATE SOLUTIONS AMERICA INSURANCE CORPORATION ("SRCSAIC") SWISS RE CORPORATE SOLUTIONS PREMIER INSURANCE CORPORATION ("SRCSPIC") WESTPORT INSURANCE CORPORATION ("WIC") GENERAL POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS, THAT SRCSAIC, a corporation duly organized and existing under laws of the State of Missouri, and having its principal office in the City of Kansas City, Missouri, and SRCSPIC, a corporation organized and existing under the laws of the State of Missouri and having its principal office in the City of Kansas City, Missouri, and WIC, organized under the laws of the State of Missouri, and having its principal office in the City of Kansas City, Missouri, each does hereby make, constitute and appoint: TODD M. ROHM, CATHY S. KENNEDY, BEATA A. SENSI, CHERYL L. THOMAS, and SHANE WOLF JOINTLY OR SEVERALLY Its true and lawful Attomey(s)-in-Fact, to make, execute, seal and deliver, for and on its behalf and as its act and deed, bonds or other writings obligatory in the nature of a bond on behalf of each of said Companies, as surety, on contracts of suretyship as are or may be required or permitted by law, regulation, contract or otherwise, provided that no bond or undertaking or contract or suretyship executed under this authority shall exceed the amount of: FIFTY MILLION ($50,000,000.00) DOLLARS This Power of Attorney is granted and is signed by facsimile under and by the authority of the following Resolutions adopted by the Boards of Directors of both SRCSAIC and SRCSPIC at meetings duly called and held on the 18th of November 2021 and WIC by written consent of its Executive Committee dated July 18, 2011. "RESOLVED, that any two of the President, any Managing Director, any Senior Vice President, any Vice President, the Secretary or any Assistant Secretary be, and each or any of them hereby is, authorized to execute a Power of Attorney qualifying the attorney named in the given Power of Attorney to execute on behalf of the Corporation bonds, undertakings and all contracts of surety, and that each or any of them hereby is authorized to attest to the execution of any such Power of Attorney and to attach therein the seal of the Corporation; and it is FURTHER RESOLVED, that the signature of such officers and the seal of the Corporation may be affixed to any such Power of Attorney or to any certificate relating thereto by facsimile, and any such Power of Attorney or certificate bearing such facsimile signatures or facsimile seal shall be bindine tenon the Corporation when sea affixed and in the future with reeard to anv bond, undertaking or contract of surety to which it is attached." ysa5 rkaf "vraatp C s' t & P 0 F� S E A L . �� �°��� S E A L . 1973 J"P '�Is's 1j , P. T frN'NNMX,M1W y,,,,, y �k:Hk. Janssens, Senior Vice President of SRCSAIC & Senior Vice President ofSRCSPIC & Senior ^Viicce''Preesident of WIC X,U By " U Gerald Jagrmski, Vice President of SRCSAIC & Vice President orsRCSPIC & Vice President of WIC IN WITNESS WHEREOF, SRCSAIC, SRCSPIC, and WIC have caused their official seals to be hereunto affixed, and these presents to be signed by their authorized officers this 10 day of NOVEMBER 20 22 Swiss Re Corporate Solutions America Insurance Corporation State of Illinois. Swiss Re Corporate Solutions Premier Insurance Corporation County of Cook, ss Westport Insurance Corporation On this 10 day of _wwwwwNOVEMBER 20 22 , before me, a Notary Public personally appeared balk J anssens, , Senior Vice President of SRCSAIC and Senior Vice President of SRCSPIC and Senior Vice President of WIC and tia r p(c'I la �«, yski , Vice President of SRCSAIC and Vice President of SPCSPIC and Vice President of WIC, personally known to me, who being by me duly sworn, acknowledged that they signed the above Power of Attorney as officers of and acknowledged said instrument to be the voluntary act and deed of their respective companies. NISCO MtfarMPt�' I, Jllra y,,aLtlti)a the duly elected Senior Vice President and Assistant Secretor of SRCSAIC and SRCSPIC and WIC, do hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney given by said SRCSAIC and SRCSPIC and WIC, which is still in full force and effect, IN WITNESS WHEREOF, I have set my hand and affixed the seals of the Companies this 29th day of AUGUST 20 23 Jeffrey Goldberg, Senior Vice President & Assistant Secretary of SRCSAIC and SRCSPIC and WIC Agreement No. 6768 No. 3208-6 STATE OF CALIFORNIA DEPARTMENT' TMENT' F INSURANCE OAKLAND Amended Certificate of Authority THIS IS TO CERTIFY that, pursuant to the Insurance Code of the State of California, Swiss Re Corporate Solutions America Insurance Corporation of Missouri, organized under the laws of Missouri, subject to its Articles of Incorporation or other fundamental organizational documents, is hereby authorized to transact within this Stale, subject to all provisions of this Certificate, the following classes of insurance: Fire, Marine, Surety, Disability, Plate Glass, Liability, Workers' Compensation, Boiler and Machinery, Burglary, Sprinkler, Automobile and Aircraft as such classes are now or may hereafter be defined in the Insurance Laws of the State of California. THIS CERTIFICATE is expressly conditioned upon the holder hereof now and hereafter being in full compliance with all, and not in violation of any, of the applicable laws and lawful requirements made under authority of the laws of the State of California as long as such laws or requirements are in effect and applicable, and as such laws and requirements now are, or may hereafter be changed or amended. IN WITNESS WHEREOF, effective as of the 7rh day of June, 2022, I have set my hand and caused my official seal to be affixed this 7"' day of June, 2022. Ricardo Lara Insurance Commissioner ZML�W_1'44j By Valerie J. Sarfaty for Catalina Hayes -Bautista Insurance Chief Deputy NOTICE: Qualification with the Secretary of State must be accomplished as required by the California Corporations Code promptly after issuance of this Certificate of Authority, Failure to do so will be a violation of Insurance Code section 701 and will be grounds for revoking this Certificate of Authority pursuant to the covenants made in the application therefor and the conditions contained herein. Agreement No. 6768 This is a true and certified copy of the record If it bears the seal, imprinted in purple ink, of the Registrar-Recorder/County Clerk t � t REGI -RI~ I I �11 ch.... LOS ANGEM COUNTY. CAUFORNIA Agreement No. 6768 0-0 STANDARD SPECIFICATIONS 0-1 GENERAL Except as modified by these Standard Specifications, the provisions of the latest edition of the "Standard Specifications for Public Works Construction" ("Greenbook") and its supplements prepared and promulgated by the Southern California Chapters of the American Public Works Association and the Associated General Contractors of America, constitute the Standard Specifications for this project. 0-2 NUMBERING OF SECTIONS The numbering contained within the Standard Specifications of the Contract Documents is intended to correspond with Greenbook numbering. 1-2 DEFINITIONS The following subsection is added to Subsection 1-2 of the Greenbook. 1-2.1 ADDITIONAL DEFINITIONS Acceptance — The date on which the City Council accepts the Work as complete. Architect, Design Engineers, Soils Engineer, Structural Engineers - Advisors employed by the City. Compensable Delay -- a delay entitling the Contractor to an adjustment of the Contract Sum and an adjustment of the Contract Time in accordance with this Agreement. Due Notice - A written notification, given in due time, of a proposed action where such notification is required by the contract to be given a specified interval of time (usually 48 hours or two working days) before the commencement of the contemplated action. Notification may be from Engineer to Contractor or from Contractor to Engineer. KHB20151022 Agreement No. 6768 Engineer - The City Engineer, or designee, as defined in the Greenbook. Unless otherwise provided, all correspondence and decisions made relative to the contract will be by the City Engineer or his designated representative. PCC — California Public Contract Code. Prompt - The briefest interval of time required for a considered reply, including time required for approval of a governing body. Public Works Director — The City's Public Works Director, or designee. ❑ (Check if applicable) State Standard Specifications - State of California Standard Specifications, dated July 1992, Business and Transportation Agency, Department of Transportation Working Days - A working day is defined as any day, except Saturdays, Sundays, legal holidays and days when work is suspended by the Engineer, as provided in Subsection 6-3 and days determined to be non -working in accordance with Subsection 6-7, "Time of Completion." 1-3 ABBREVIATIONS The following Subsection is added to Subsection 1-3 of the Greenbook. 1-3.1 The following abbreviations are added to Subsection 1-3 of the Greenbook: AAN American Association of Nurserymen AGC Associated General Contractors of America AISC American Institute of Steel Construction APWA American Public Works Association ASME American Society of Mechanical Engineers IEEE Institute of Electric and Electronic Engineers NEC National Electric Code Green Book The most current edition of the Standard Specification for Public Works Construction, and subsequent supplements prepared by Public Works Standards, Inc. WATCH Work Area Traffic Control Handbook SPPWC Standard Plans for Public Works Construction by the American Public Works Association SSPWC Standard Specifications for Public Works Construction by the American Public Works Association ASA American Standard Association CITY City of El Segundo KHB20151022 Page 2 of 36 Agreement No. 6768 SECTION 2 — SCOPE AND CONTROL OF WORK The following subsections 2-1.1 and 2-1.2 are added to the Greenbook,. 2-1.1 ACCESS TO PROJECT SITE Not later than the date designated in the City Notice to Proceed, the City will provide access to the real property and facilities upon which the Work is to be performed, including access to real property and facilities designated in the Contract Documents for the Contractor's use. 2-1.2 OWNERSHIP AND USE OF CONTRACT DOCUMENTS, The Contract Documents and all copies furnished to or provided by the Contractor are the City's property and may not be used on other work. 2-3 SUBCONTRACTS Subsection 2-3 Subcontractors of Greenbook is deleted in its entirety and replaced with the following subsection. 2-3.1 GENERAL Except as provided in PCC §§ 4100 et. seq., each bidder will file with its bid the name and location of the place of business of each subcontractor who will perform work or labor or render service to the prime contractor in or about the construction of the work or improvement, or a subcontractor licensed by the State of California who, under subcontract to the prime contractor, specifically fabricates and installs a portion of the work or improvement according to detailed drawings contained in the plans and specifications, in an amount in excess of one-half of one percent of the prime contractor's total bid. Only one subcontractor will be listed for each portion of the work, which portion will be defined in the bid. In each instance, the nature and extent of the work to be sublet will be described. The failure of the Contractor to specify a subcontractor, or the listing of more than one subcontractor for the same portion of the work, constitutes an agreement by the Contractor that it is fully qualified to perform that portion itself and that it will perform that portion itself. The Contractor must have the City Council's written consent to substitute a subcontractor other than that designated in the original bid, to permit any subcontract to be assigned or transferred, or to allow a subcontract to be performed by other than the original subcontractor. Subcontracting of work for which no subcontractor was designated in the original bid, and which is more than one-half of one percent of the work, will be allowed only in cases of public emergency or necessity, and then only after a KHB20151022 'w- Agreement No. 6768 finding reduced to writing as a public record of the City Council setting forth the facts constituting the emergency or necessity. Violation of any of the above provisions will be considered a breach of the Contract, and the City may terminate the Contractor's control over the Work, cancel the contract, or assess the Contractor a penalty of not more than ten percent of the subcontract involved. All persons engaged in the work, including subcontractors and their employees will be considered as employees of the Contractor. The Contractor will be solely responsible for and have control over construction means, methods, techniques, sequences, procedures, and the coordination of all portions of the Work. The City will deal directly with, and make all payments to, the prime Contractor. When subcontracted work is not being prosecuted in a satisfactory manner, the Contractor will be notified to take corrective action. The Engineer may report the facts to the City Council. If the City Council so orders, and on receipt by the Contractor of written instructions from the Engineer, the subcontractor will be removed immediately from the Work. That subcontractor will not again be employed on the Work. If licensure or proper licensure is controverted, then proof of licensure pursuant to this section must be made by production of a verified certificate of licensure from the Contractors' State License Board which establishes that the individual or entity bringing the action was duly licensed in the proper classification of contractors at all times during the performance of any act or contract covered by the action. Nothing in this subdivision requires any person or entity controverting licensure or proper licensure to produce a verified certificate. When licensure or proper licensure is controverted, the burden of proof to establish licensure or proper licensure is on the licensee. 2-3.2 ADDITIONAL RESPONSIBILITY Add the following to Subsection 2-3.2 Additional Responsibility:. The Contractor will submit experience statements for each subcontractor who will perform contract work that amounts to more than ten percent (10%) of the Work. 2-4 CONTRACT BONDS The following paragraph is added to Subsection 2-4 of the Greenbook. The Faithful Performance Bond and the Labor and Materials Bond must be paid and in effect for one year after the acceptance of the job by the City in KHB20151022 Agreement No. 6768 accordance with the guarantee required by Subsection 6-8.1, 2-5 PLANS AND SPECIFICATIONS Subsection 2-5.1 of the Greenbook is replaced by the following subsection. 2-5.1 GENERAL The Contractor will maintain the following at the Work site; One as -built copy of the Plans and Specifications, in good order and marked to record current changes and selections made during construction. As -built plans must be submitted to the City representative for approval before the City pays a final retention amount. 2. The current accepted Contract Schedule. 3. Shop Drawings, Product Data, and Samples.. 4. Approved permits from other agencies, including Cal -OSHA permits for trench shoring. 5. All other required submittals. KHB20151022 The Plans, Specifications, and other Contract Documents will govern the Work. The Contract Documents are intended to be complementary and cooperative and to describe and provide for a complete project. Anything in the Specifications and not on the Plans, or on the Plans and not in the Specifications, will be as though shown or mentioned in both. Payment for any items on the plans for which there is no specific bid item will be included in the various items of work or in any item to which it is appurtenant. If the Contractor performs any work involves an error, inconsistency, o obtaining written consent from the responsible for the resulting losses, costs of correcting defective work. *." r which it knows or should know omission without notifying and Engineer, the Contractor will be including, without limitation, the Agreement No. 6768 2-5.2 PRECEDENCE OF CONTRACT DOCUMENTS The following paragraph is added to subsection 2-5.2 of the Greenbook: As the figured dimensions shown on the plans and in the specifications of the Contract may not in every case agree with scaled dimensions, the figured dimensions will be followed in preference to the scaled dimensions, and plans to a large scale will be followed in preference to the plans to a small scale. Should it appear that the work to be done, or any of the matters relative thereto, are not sufficiently detailed or explained in the Contract, the Contractor will apply to the Engineer for such further explanations as may be necessary, and will conform thereto as part of the Contract so far as may be consistent with the terms thereof. Any items shown on drawings and not mentioned in the specifications will be of like effect as if shown or mentioned in both. 2-5.5 ACCURACY OF PLANS AND SPECIFICATIONS Although it is believed that much of the information pertaining to conditions and existing utilities that may affect the cost of the Work will be shown on the Plans or indicated in the Specifications, the City does not warrant the completeness or accuracy of such information. The Contractor will carefully study and compare each of the Contract Documents with the others and with information furnished by the City and will promptly report in writing to the Engineer any errors, inconsistencies, or omissions in the Contract Documents or inconsistencies with applicable law observed by the Contractor. The Contractor will take field measurements, verify field conditions, perform soil investigations, and carefully compare with the Contract Documents such field measurements, conditions, and other information known to the Contractor before commencing the Work. Errors, inconsistencies, or omissions discovered at any time will be promptly reported in writing to the Engineer. 2-8 RIGHT-OF-WAY The following subsection is added to Subsection 2-8 of the Greenbook. 2-8.1 ADDITIONAL WORK AREAS AND FACILITIES When the Contractor arranges for additional temporary work areas and facilities, the Contractor will provide the City with proof that the additional work areas or facilities have been left in a condition satisfactory to the owner(s) of said work areas or facilities before acceptance of the work. KHB20151022 Agreement No. 6768 2-9 SURVEYING Subsection 2-9.3, Survey Service, is deleted in its entirety and replaced by the following subsection: 2-9.3 SURVEY SERVICE 2-9.3.1 CONSTRUCTION SURVEYING The Contractor will provide for all construction surveying required to layout, monitor and complete the work. The surveying will be performed by a Land Surveyor or Civil Engineer authorized to practice land surveying by the State of California. The Project Benchmark is shown on the plans. The Contractor will establish all necessary control lines based on the plans and record information on file with the County of Los Angeles Surveyor and the Engineer. It is the responsibility of the Contractor to protect the survey control as shown on the plans. If the survey control is destroyed or disturbed during construction, the Contractor will provide for resetting them and file appropriate documents with the County of Los Angeles at the direction of the Engineer. Computations, survey notes, and other data used to accomplish the work will be neat, legible and accurate. Copies of all computations, survey notes, and other data (electronic format may be required) will be furnished to the Engineer before beginning work that requires their use. 2-9.3.2 MEASUREMENT AND PAYMENT Construction Survey — Unless a separate bid item is provided, payment will be considered included in the other items of the bid and no additional payment will be made therefore. 3-3.2.2 BASIS FOR ESTABLISHING COSTS Subsection 3-3.2.2.3, Tool and Equipment Rental is modified where the second and third paragraphs are replaced with "Regardless of ownership, the rates to be used in determining the equipment usage costs will not exceed those listed for the same or similar equipment in the California State Department of Transportation publication of Labor Surcharge and Equipment Rates effective for the period of usage." 3-3.2.3 MARKUP Subsection 3-3.2.3, Mark Up, is deleted in its entirety and replaced by the KHB20151022 Page 7 of 36 Agreement No. 6768 following subsection: (a) Work by Contractor. The following percentages will be added to the Contractor's costs and will constitute the markup for all overhead and profits. 1) Labor ........................................... 20 2) Materials......................................15 3) Equipment Rental .................. _ _ 15 4) Other Items and Expenditures_... 15 To the sum of the costs and markups provided for in this subsection, 1 percent will be added as compensation for bonding. No other formula, e.g., the Eichleay or other method, may be used to calculate daily damages for office overhead, profit, or other purported loss. (b) Work by Subcontractors. When all or any part of the extra work is performed by a Subcontractor, the markup established in 3-3.2.3(a) will be applied to the Subcontractor's actual cost of such work. A markup of 10 percent on the first $5,000 of the subcontracted portion of the extra work and a markup of 5 percent on work added in excess of $5,000 of the subcontracted portion of the extra work may be added by the Contractor. (c) In the event that City becomes liable to Contractor for compensable delays, City agrees to pay Contractor the daily Contractor Delay Damages set forth in the Bid Form or Contractor's actual daily delay damages, whichever is less, for each day of Compensable Delay as provided for by these Contract Documents. 3-3.3 DAILY REPORTS BY CONTRACTOR Add the following paragraph to subsection 3-3.3, Daily Reports by Contractor: If disagreement continues regarding extra work, the Contractor may seek compensation in accordance with the Claims procedure. Daily Reports required by this subsection must be made part of the Claim as supporting data for the Claim. 3-4 CHANGED CONDITIONS Subsection 3-4, Changed Conditions, is deleted in its entirety and replaced with the following subsection: If the Contractor encounters concealed or unknown conditions that differ materially from those anticipated or expected ("changed conditions"), the KHB20151022 Page 8 of 36 Agreement No. 6768 Contractor will immediately notify the Engineer in writing of such changed conditions (upon discovery and before disturbing such changed conditions), as provided in Subsection 6-11, so that the Engineer can determine if such conditions require design details that differ from those design details shown in the Contract Documents. Notwithstanding the time period set forth in Subsection 6-11.3, the Contractor is liable to the City for any extra costs incurred as a result of the Contractor's failure to promptly give such notice. Changed conditions include, without limitation, the following: 1. Subsurface or latent physical conditions differing materially from those represented in the Contract Documents; 2. Unknown physical conditions of an unusual nature differing materially from those ordinarily encountered and generally recognized as inherent in work of the character being performed; and 3. Material differing from what is represented in the Contract which the Contractor believes may be hazardous waste as defined in California Health & Safety Code § 25117 that is required to be removed to a Class I, II, or III disposal site in accordance with applicable law. The Engineer will promptly investigate conditions that appear to be changed conditions. The Engineer's decision, and any dispute regarding that decision, will be made in accordance with Section 6-11 except that the Engineer will render a decision promptly. Any information provided pursuant to INFORMATION AVAILABLE TO BIDDERS is subject to the following provisions: 1. The information is made available for the Bidders' convenience and is not a part of the Contract. 2, The City has not determined the accuracy or completeness of such information and all such information is made available to Bidders without any representation or warranty by the City whatsoever as to its accuracy, completeness, or relevancy. 3. Bidders will independently evaluate such information for their use and will be solely responsible for use or interpretation of such information. Any such use or interpretation will not be the basis of any claim against the City. 3-5 DISPUTED WORK Subsection 3-5 is deleted in its entirety and replaced by the following KHB20151022 Page 9 of 36 Agreement No. 6768 subsection. If the Contractor and the City do not reach agreement on disputed work, the City may direct the Contractor to proceed with the work. Any payment for the disputed work will be determined pursuant to the claims procedures in these Standard Specifications. Although not to be construed as proceeding under extra work provisions, the Contractor will keep and furnish records of disputed work as required by the Contract Documents. 4-1.3 INSPECTION REQUIREMENTS Subsection 4-1.3, Inspection Requirements, is deleted in its entirety and replaced by the following subsections. 4-1.3.1 GENERAL Unless otherwise specified, inspection at the source of production for such materials and fabricated items as bituminous paving mixtures, structural concrete, fabricated metal products, cast metal products, welding, reinforced and unreinforced concrete pipe, application of protective coatings, and similar shop and plant operations is not required. A certificate of compliance, signed by an authorized officer of the producer, certifying compliance with the contract documents will be submitted for all of the following materials: steel pipe, sizes less than 18 inches; vitrified clay pipe; asbestos cement pipe; cast iron pipe; reinforced concrete pipe, non -reinforced concrete pipe; and PVC sewer and water pipe; subject to sampling and testing by City. Standard items of equipment, such as electric motors, conveyors, plumbing fittings and fixtures, lumber, plywood, and so on, are subject to inspection at the job site. All other equipment items will be inspected and tested in accordance with the contract documents. The City does not provide full time inspection. The Contractor will provide 24-hour minimum notice for each inspection required by the work unless other arrangements have been agreed upon, in writing, with the City Engineer. Any inspection required outside of normal working hours and days, including holidays, will be at the Contractor's cost at rates established by the City. 4-1.6 TRADE NAMES OR EQUALS Whenever any material, product, equipment, or service is specified by brand, trade, or proprietary name, the item so specified will be deemed to be followed by the words "or equal." Page 10 of 36 Agreement No. 6768 For the City's consideration of a proposed "equal" item, the Bidder must submit, a minimum of ten (10) calendar days before the date of the bid opening, documentation of the particulars of the proposed "equal item." At a minimum, the submitted documentation will include: Written request with explanation of why the product should be considered as an equal product. Material specifications. Technical specifications. Test data. Samples. Comparison chart of key specifications of the "equal" item against similar specifications of the specified item. Work locations and reference telephone numbers of at least three (3) locations where the proposed "equal" item has been recently installed under similar conditions. Warranty data. The Bidder will be notified by the Engineer whether or not the proposed "equal" product is acceptable to the City five (5) calendar days before the date of the bid opening. Failure to submit all required documentation and/or submittal of incomplete documents may result in the City's rejection of the proposed "equal" product without further consideration. 5-2 PROTECTION The following subsection is added to Subsection 5-2 of the Greenbook. 5-2.1 INCORRECT LOCATION OF UTILITIES If the Contractor, while performing the Work, discovers utility facilities not identified correctly or not shown in the contract plans or specifications by the City, the Contractor will immediately notify the City and utility owner in writing. 5-4 RELOCATION The following subsection is added to Subsection 5-4 of the Greenbook. 5-4.1 RESPONSIBILITY OF UTILITY REMOVAL OR RELOCATION The City will be responsible to arrange for the removal, repair, or relocation of existing utilities located within the project limits if such utilities are not correctly identified in the contract plans or specifications by the City. The City will have the sole discretion to perform repairs or relocation work or permit the Contractor to do such repairs or relocation. Agreement No. 6768 5-5 DELAYS The following paragraphs are added to Subsection 5-5 of the Greenbook. Actual loss, as used in this Subsection, will be understood to include no items of expense other than idle time of equipment and necessary payments for idle time of workers, cost of extra moving of equipment, and cost of longer hauls. Compensation for idle time of equipment and idle time of workers will be determined by Subsection 5-5.1 and no markup will be added in either case for overhead and profit. The cost of extra moving of equipment and the cost of longer hauls will be paid for as extra work. The following subsection is added to Subsection 5-5 of the Greenbook. 5-5.1 CALCULATING IDLE TIME Equipment idle time will calculated in accordance with Subsection 3-3.2.2 and based upon the actual normal working time during which the delay condition exists, but in no case will exceed 8 hours in any one day. The days for which compensation will be paid will be the calendar days, excluding Saturdays, Sundays and legal holidays, during the existence of the delay. Worker idle time will be calculated in accordance with Subsection 3-3.2.2. 6-1 CONSTRUCTION SCHEDULE AND COMMENCEMENT OF WORK Section 6-1, Construction Schedule and Commencement of Work, is deleted in its entirety and replaced by the following subsections. After contract award, the City will arrange for a pre -construction meeting to discuss the construction of the project. City will invite utility agencies and the contractor will arrange for all of its sub -contractors to attend the meeting. 6-1.1 CONTRACT SCHEDULE After notification of award and before starting any work, the Contractor will submit a Contract Schedule to the Engineer for review, as required by these Specifications within fifteen (15) calendar days of award. 6-1.2 CONTENT OF CONTRACT SCHEDULE The Contract Schedule, and any updated Contract Schedule, will meet the following requirements: KHB20151022 Page 12 of 36 Agreement No. 6768 1. Schedules must be suitable for monitoring progress of the Work. 2. Schedules must provide necessary data about the time for the Engineer's decisions. 3, Schedules must be sufficiently detailed to demonstrate adequate planning for the Work. 4„ Schedules must represent a practical plan to complete the Work within the Contract Time. 5. Schedules must show the critical path method for completing the Work. The Engineer's review of the form and general content of the Contract Schedule and any updated Contract Schedules is only for the purpose of determining if the listed requirements are satisfied, nothing more. 6-1.3 EFFECT OF CONTRACT SCHEDULE The Contract Schedule, and any updated Contract Schedules, will represent a practical plan to complete the Work within the Contract Time. Extension of any schedule beyond the Contract Time will not be acceptable. Schedules showing the Work completed in less than the Contract may be acceptable if judged by the Engineer to be practical. Acceptance of such a schedule by the Engineer will not change the Contract Time. The Contract Time, not the Contract Schedule, will control in determining liquidated damages payable by the Contractor and in determining any delay. If a schedule showing the Work completed in less than the Contract Time is accepted, the Contractor will not be entitled to extensions of the Contract Time for Excusable Delays or Compensable Delays or to adjustments of the Contract Sum for Compensable Delays until such delays extend the completion of the Work beyond the expiration of the Contract Time. The Contractor will plan, develop, supervise, control, and coordinate the performance of the Work so that its progress and the sequence and timing of Work activities conform to the current accepted Contract Schedule. The Contractor will continuously obtain from Subcontractors information and data about the planning for and progress of the Work and the delivery of equipment, will coordinate and integrate such information and data into updated Contract Schedules, and will monitor the progress of the Work and the delivery of equipment. The Contractor will act as the expeditor of potential and actual delays, interruptions, hindrances, or disruptions for its own forces and those forces of Subcontractors. The Contractor will cooperate with the Engineer in developing the Contract Schedule and updated Contract Schedules. The Engineer's review and comments about any schedule or scheduling data will not relieve the Contractor from its sole responsibility to plan for, perform, and complete the Work within the Contract Time. Review and comments about any schedule will not transfer responsibility for any schedule to the Engineer or KHB20151022 Page 13 of 36 Agreement No. 6768 the City nor imply their agreement with (1) any assumption upon which such schedule is based or (2) any matter underlying or contained in such schedule. The Engineer's failure to discover errors or omissions in schedules that have been reviewed, or to inform the Contractor that the Contractor, Subcontractors, or others are behind schedule, or to direct or enforce procedures for complying with the Contract Schedule will not relieve the Contractor from its sole responsibility to perform and complete the Work within the Contract Time and will not be a cause for an adjustment of the Contract Time or the Contract Sum. The Contractor will perform the Work in accordance with the currently accepted Contract Schedule. 6-1.4 COMMENCEMENT OF CONTRACT TIME The Contract Time will commence when the City issues a Notice to Proceed. The Work will start on the date specified in the Notice to Proceed and within a maximum of fifteen (15) calendar days after the date of the Notice to Proceed, and be diligently prosecuted to completion with the time provided in the Specifications. 6-4 DEFAULT BY CONTRACTOR The language in subsection 6-4 is deleted in its entirety and replaced with the following subsections. 6-4.1 GENERAL Should the Contractor fail to begin delivery of material and equipment, to commence the Work within the time specified, to maintain the rate of delivery of material, to execute the Work in the manner and at such locations as specified, or fail to maintain the Work schedule (as determined by the current accepted Contract Schedule) which will ensure the City's interest, or if the Contractor is not carrying out the intent of the Contract, the City may serve written notice upon the Contractor and the Surety on its Faithful Performance Bond demanding satisfactory compliance with the Contract. 6-4.2 TERMINATION OF CONTRACTOR'S CONTROL OVER THE WORK The City may terminate the Contractor's control over the Work without liability for damages when, in the City's opinion, the Contractor is not complying in good faith, has become insolvent, or has assigned or subcontracted any part of the Work without the City's consent. Should such termination occur, the Contractor will be paid the actual amount due based on Contract Unit Prices or lump sums bid and the quantity and quality of the Work completed at the time of termination, less damages caused to the City by the Contractor's action or KHB20151022 Agreement No. 6768 inaction. In the event of such termination of control, the City may do any one, or combination of, the following: 1. Serve written notice upon the Surety on its Faithful Performance Bond demanding satisfactory compliance with the Contract. In such event the Surety will, within 5 days, assume control and perform the Work as successor to the Contractor, 2. The City may perform the Work itself and deduct the cost thereof from any payment due to the Contractor, 3. The City may replace the Contractor with a different contractor to complete the work and deduct the cost thereof from any payment due to the Contractor. Nothing herein will waive, or serve as a limitation upon, any additional remedy the City may have under these Contract Documents or applicable law. 6-6 DELAYS AND EXTENSIONS OF TIME Subsection 6-6 is deleted in its entirety and replaced with the following subsections. 6-6.1 GENERAL If delays are caused by unforeseen events beyond the control of the Contractor, such delays will entitle the Contractor to an extension of time as provided herein, but the Contractor will not be entitled to damages or additional payment due to such delays except as otherwise provided herein. Excusable delay may include: war, earthquakes exceeding 3.5 on the Richter Scale, government regulation, labor disputes outside the contemplation of the parties, strikes outside the contemplation of the parties, fires, floods, changes to the Work as identified herein, or other specific events that may be further described in the Specifications. Delays to the project caused by labor disputes or strikes involving trades not directly related to the project, or involving trades not affecting the project as a whole will not warrant an extension of time. The City will not grant an extension of time for a delay by the Contractor's inability to obtain materials unless the Contractor furnishes to the Engineer documentary proof. The proof must be provided in a timely manner in accordance with the sequence of the Contractor's operations and accepted construction schedule. Should delays be caused by events other than those included herein, the Page 15 of 36 Agreement No. 6768 Engineer may, but is not required to, deem an extension of time to be in the City's best interests. 6-6.2 EXTENSIONS OF TIME If granted, extensions of time will be based upon the effect of delays to the critical path of the Work as determined by the current accepted Contract Schedule. Delays to minor portions of the Work that do not affect the critical path will not be eligible for extensions of time. 6-6.3 PAYMENT FOR DELAYS TO CONTRACTOR Any payment for compensable delay will be based upon actual costs as set forth in Subsection 5-5 excluding, without limitation, what damages, if any, the Contractor may have reasonably avoided. The Contractor understands that this is the sole basis for recovering delay damages and explicitly waives any right to calculate daily damages for office overhead, profit, or other purported loss, using different formulas including, without limitation, the Eichleay Formula. 6-6.4 WRITTEN NOTICE AND REPORT If the Contractor desires payment for a delay or an extension of time, it will give the Engineer written notice of such request not later than the time limit set forth in the Proposal for submitting a claim after the event or occurrence giving rise to a delay claim. Failure to submit a written request within such amount of time will result in the Contractor waiving its delay claim. Any claim for payment or an extension of time must be in the form required by the "Claims" sections of these Specifications. In no event will the City grant the Contractor an extension of time if the delay is within the Contract Time as identified by the Contract Documents. 59MR1791 4 Page 16 of 36 Agreement No. 6768 6-7.2 WORK DAYS AND WORKING HOURS City Hall is open from Monday thru Friday 7am-4pm. It is closed on the following holidays: New Year's Day Martin Luther King, Jr. Day President's Day Memorial Day Independence Day Labor Day Veterans' Day Thanksgiving Christmas Eve Christmas New Year's Eve City inspections during hours when City Hall is closed are subject to inspection overtime fees to be paid for by the Contractor. If the Contractor does construction on a day when City Hall is closed, that day is counted as a project working day. On workdays, Contractor's activities will be confined to the hours between 7:00 a.m. and 4:00 p.m. Please see Section 6-7.5 below for weekend and holiday work restrictions. 6-7.4 NIGHT WORK The following paragraph is added to Section 6-7 of the Greenbook: The City will not permit Work between the hours of 4 p.m. and 7 a.m. of the following day unless specifically provided for in the bid documents or unless the Contractor receives prior written approval. 6-7.5 WEEKEND AND HOLIDAY WORK The Engineer may, but is not required to, allow the Contractor to work on Saturdays, Sundays and City Holidays. 6-8 COMPLETION AND ACCEPTANCE Subsection 6-8 of the Greenbook is deleted in its entirety and replaced by the following: KHB20151022 Page 17 of 36 Agreement No. 6768 The Work will be inspected by the Engineer for acceptance upon the Engineer receiving the Contractor's written assertion that the Work is complete. If, in the Engineer's judgment, the Work is complete and is ready for acceptance, the Engineer will accept the Work on behalf of the City in the manner prescribed by the City. The Engineer will recommend approval of the Notice of Completion to the City Council. This will be the date when the Contractor is relieved from responsibility to protect the Work. All work will be guaranteed by the Contractor against defective workmanship and materials furnished by the Contractor for a period of 1 year from the date the Work was completed. The Contractor will replace or repair any such defective work in a manner satisfactory to the Engineer, after notice to do so from the Engineer, and within the time specified in the notice. If the Contractor fails to make such replacement or repairs within the time specified in the notice, the City may perform this work and the Contractor's sureties will be liable for the cost thereof. 6-8.1 GENERAL GUARANTY The Contractor will remedy any defects in the work and pay for any damage to other work resulting therefrom, which will appear within a period of one year from the date of final acceptance of the work unless a longer period is specified. The owner will give notice of observed defects with reasonable promptness. 6-9 LIQUIDATED DAMAGES Subsection 6-9, Liquidated Damages, of the Greenbook is deleted in its entirety and replaced by the following subsections. 6-9.1 FAILURE TO COMPLETE WORK ON TIME If all the work called for under the contract is not completed before or upon the expiration of the Contract Time, the City will sustain damage. Since it is and will be impracticable to determine the actual damage which the City will sustain in the event of and by reason of such delay, it is therefore agreed that the Contractor will pay to the City the sum specified in the Proposal for each and every calendar day beyond the time prescribed to complete the work not as a penalty, but as a predetermined liquidated damage. The Contractor agrees to pay such liquidated damages as are herein provided, and in case the same are not paid, agrees that the City may deduct the amount thereof from any money due or that may become due to the Contractor under the contract. Unless otherwise specified, liquidated damages will be $250 per calendar day. 6-11 DISPUTES AND CLAIMS PROCEDURE KHB20151022 Page 18 of 36 Agreement No. 6768 6-11.1 GENERAL Consistent with PCC § 10240.6, "Claim" means a written demand or assertion by the Contractor that seeks an adjustment or interpretation of the terms of the Contract Documents, payment of money, extension of time, or other relief with respect to the Contract Documents, including a determination of disputes or matters in question between the City and the Contractor arising out of or related to the Contract Documents or the performance of the Work, and claims alleging an unforeseen condition or an act, error, or omission by the City, the Engineer, their agents or employees. "Claim" does not mean, and the Claims procedures herein do not apply, to the following: 1. Claims respecting penalties for forfeitures prescribed by statute or regulations, which a government agency is specifically authorized to administer, settle, or determine. 2. Claims respecting personal injury, death, reimbursement, or other compensation arising out of or resulting from liability for personal injury or death. 3. Claims respecting a latent defect, breach of warranty, or guarantee to repair. 4. Claims respecting stop notices. If a Claim is subject to the Change Order procedures, the Claim arises upon the issuance of a written final decision denying in whole or in part the Contractor's Change Order Request. If a Claim is not subject to the Change Order Procedures, the Claim arises when the Contractor discovers, or reasonably should discover, the condition or event giving rise to the Claim. 6-11.2 FORM A Claim must include the following- 1 . A statement that it is a Claim and a request for a decision. 2. A detailed description of the act, error, omission, unforeseen condition, event or other condition giving rise to the Claim. 3. If the Claim is subject to the Change Order procedures, a statement demonstrating that a Change Order Request was timely submitted and denied. 4. A detailed justification for any remedy or relief sought by the Claim, including to the extent applicable, the following: KHB20151022 a) If the Claim involves extra work, a detailed cost breakdown Page 19 of 36 Agreement No. 6768 claimed. The breakdown must be provided even if the costs claimed have not been incurred when the Claim is submitted. ) To the extent costs have been incurred when the Claim is submitted, the Claim must include actual cost records (including, without limitation, payroll records, material and rental invoices) demonstrating that costs claimed have actually been incurred. c) To the extent costs have not yet been incurred at the time the Claim is submitted, actual cost records must be submitted on a current basis not less than once a week during any periods costs are incurred. A cost record will be considered current if submitted within seven (7) calendar days of the date the cost reflected in the record is incurred. At the Engineer's request, claimed extra costs may be subject to further verification procedures (such as having an inspector verify the performance of alleged extra work on a daily basis). 5. If the Claim involves an error or omission in the Contract Documents a) An affirmative representation that the error or omission was not discovered before submitting a bid for the Contract; and b) A detailed statement demonstrating that the error or omission reasonably should not have been discovered by the Contractor, its Subcontractors and suppliers, before submitting a bid for the Contract. & If the Claim involves an extension of the Contract Time, written documentation demonstrating the Contractor's entitlement to a time extension. 7. If the Claim involves an adjustment of the Contract Sum for delay, written documentation demonstrating the Contractor's entitlement to such an adjustment. 8. A personal certification from the Contractor that reads as follows: A,1, , BEING THE (MUST BE AN OFFICER) OF (CONTRACTOR NAME), DECLARE UNDER PENALTY OF PERJURY UNDER CALIFORNIA LAW, AND DO PERSONALLY CERTIFY AND ATTEST THAT I HAVE THOROUGHLY REVIEWED THE ATTACHED CLAIM FOR ADDITIONAL COMPENSATION OR EXTENSION OF TIME, AND KNOW ITS CONTENTS, AND SAID CLAIM IS MADE IN GOOD FAITH; THE SUPPORTING DATA IS TRUTHFUL AND ACCURATE; THAT 21:r e Agreement No. 6768 THE AMOUNT REQUESTED ACCURATELY REFLECTS THE CONTRACT ADJUSTMENT FOR WHICH THE CONTRACTOR BELIEVES CITY IS LIABLE; AND, FURTHER, THAT I AM FAMILIAR WITH CALIFORNIA PENAL CODE § 72 AND CALIFORNIA GOVERNMENT CODE § 12650, ET SEQ., PERTAINING TO FALSE CLAIMS, AND FURTHER KNOW AND UNDERSTAND THAT SUBMITTING OR CERTIFYING A FALSE CLAIM MAY LEAD TO FINES, 'IMPRISONMENT, AND OTHER SEVERE LEGAL CONSEQUENCES." 6-11.3CLAIMS SUBMITTED TO ENGINEER Within thirty (30) calendar days after the circumstances giving rise to a Claim occur, the Contractor will submit its Claim to the Engineer for a decision. Regardless of any Claim submittal, or any dispute regarding a Claim, unless otherwise directed by the Engineer, the Contractor will not cause any delay, cessation, or termination of the Work, but will diligently proceed with the performing the Work in accordance with the Contract Documents. Except as otherwise provided, the City will continue to make payments in accordance with the Contract Documents. 6-11 ACLAIM IS PREREQUISITE TO OTHER REMEDY The Contractor certifies that it is familiar with PCC § 10240.2 and understands and agrees that submitting a Claim in accordance with these Specifications is an express condition precedent to the Contractor's right to otherwise pursue a claim whether through alternative dispute resolution or by litigation. Should the Contractor fail to submit a claim in accordance with these Specifications, including the time limits set forth herein, it will waive any right to a remedy, whether in law or equity, it might otherwise have pursuant to the Contract Documents or applicable law. 6-11.5 DECISION ON CLAIMS The Engineer will promptly review Claims submitted by the Contractor in accordance with these Specifications. Should the Engineer require additional supporting evidence to evaluate the claim, the Engineer will request such additional information in writing. Any such requested data will be furnished not later than ten (10) calendar days after the Contractor receives the Engineer's request. The Engineer will render a decision not later than 30 calendar days after either receiving the Claim or the deadline for furnishing additional supporting data, whichever is later. If the Claim amount is more than $50,000, the time period will be extended to 60 days. If the Engineer fails to render a decision within the time period established herein, then the Claim will be deemed denied. The KHB20151022 Page 21 of 36 Agreement No. 6768 Engineer's decision will be final and binding unless appealed in accordance with these Specifications. The Engineer's decision on a Claim will include a statement substantially as follows.. "This is a decision pursuant to the General Specifications of your contract. If you are dissatisfied with the decision, and have complied with the procedural requirements for asserting claims, you may have the right to alternative dispute resolution or litigation. Should you fail to take appropriate action within thirty (30) calendar days of the date of this decision, the decision will become final and binding and not subject to further appeal." 6-11.6APPEAL OF ENGINEER'S DECISION Should the Contractor dispute the Engineer's decision, then the Contractor must appeal that decision to the City's Public Works Director within thirty (30) calendar days of receiving the Engineer's decision. The Public Works Director will address disputes or claims within thirty (30) calendar days after receiving such request and all necessary supporting data. The Public Works Director's decision on the dispute or claim will be the City's final decision. If the Contractor disputes the Public Works Director's decision, then the Contractor must demand alternative dispute resolution in accordance with this Section and the PCC within thirty (30) calendar days of the City's final decision. 6-11.7 MEDIATION If the City and the Contractor agree, disputes between the parties may be submitted to non -binding mediation. If the parties cannot agree to an alternative form of mediation, then mediation will be administered by the American Arbitration Association ("AAA") under its Construction Industry Mediation Rules, unless the use of such rules are waived by mutual stipulation of both parties. The parties may, but are not required to be, represented by counsel in mediation. The requirement for mediation will not alter or modify the time limitations otherwise provided for claims and no conduct or settlement negotiation during mediation will be considered a waiver of the City's right to assert that claim procedures were not followed. 6-11.8 ARBITRATION ..W1 1 Page 22 of 36 Agreement No. 6768 If the City and Contractor do not agree to mediation, then a disputes will be submitted to neutral non -binding (except as provided herein) arbitration. Arbitration will be conducted in accordance with PCC § 10240.3. Any decision rendered by an arbitrator will be consistent with PCC § 10240.8. The exclusive venue for any arbitration will be in Los Angeles County. The expenses and fees of the arbitrators and the administrative fees, if any, will be divided among the parties equally. Each party will pay its own counsel fees, witness fees, and other expenses incurred for its own benefit. 6-11.9 WHEN ARBITRATION DECISION BECOMES BINDING The decision rendered by the arbitrator will become binding upon the parties unless appealed to the Los Angeles County Superior Court pursuant to PCC § 10240.12 within thirty (30) calendar days of the decision. If subsequent litigation results in an award to the party appealing the arbitration that is less than or equal to that of the arbitration decision, or if the litigation results in a decision in favor of the nonappealing party, then the party appealing the arbitration will pay the nonappealing party's attorney's fees and court costs. 6-11.1.0 APPEAL TO SUPERIOR COURT; WAIVER OF JURY TRIAL Should a party timely object to the arbitration decision, it may file a petition with the Los Angeles County Superior Court in accordance with California Code of Civil Procedure ("CCP") §§ 1285, et seq. Notwithstanding the limitations set forth in CCP § 1286.2, the court may vacate, correct, or adjust an arbitration award, and enter judgment in accordance with CCP § 1287.4, for any legal or equitable basis including, without limitation, error of law. The court will apply the substantial evidence standard of review when considering the appeal of an objecting party. BY EXECUTING THESE CONTRACT DOCUMENTS, THE CONTRACTOR AGREES TO HAVE DISPUTES OR CONTROVERSY CONCERNING THE CONSTRUCTION, INTERPRETATION, PERFORMANCE, OR BREACH OF THESE CONTRACT DOCUMENTS, INCLUDING CLAIMS FOR BREACH OF CONTRACT OR ISSUES OF BAD FAITH DECIDED IN ACCORDANCE WITH THIS SECTION 6-11. BOTH THE CITY AND THE CONTRACTOR WAIVE THEIR RIGHT TO A JURY TRIAL FOR THESE DISPUTES OR ISSUES. 7-2 LABOR The following subsections are added to Subsection 7-2 of the Green Book, KHB20151022 Page 23 of 36 Agreement No. 6768 7-2.3 PREVAILING WAGES The Contractor will post at appropriate conspicuous points at the site of the project a schedule showing determinations of the Director of Industrial Relations of the prevailing rate of per diem wages. It will be the Contractor's responsibility to obtain copies of the prevailing rate of per diem wages. One source that may be used is the California Department of Industrial Relations website which is currently located at www.dir.ca.gov, or by calling the Prevailing Wage Unit at (415) 703-4774. Attention is directed to Labor Code §§ 1777.5, 1777.6 and 3098 concerning the employment of apprentices by the Contractor or any subcontractor. Labor Code § 1777.5 requires the Contractor or subcontractor employing tradesmen in any apprenticeship occupation to apply to the joint apprenticeship committee nearest the site of the public works project and which administers the apprenticeship program in that trade for a certificate of approval. The certificate will also fix the ratio of apprentices to journeymen that will be used in the performance of the contract. The ratio of apprentices to journeymen in such cases will not be less than one to five except: a) When employment in the area of coverage by the joint apprenticeship committee has exceeded an average of 15 percent in the ninety (90) calendar days before the request for certificate, or b) When the number of apprentices in training in the area exceeds a ratio of one to five, or c) When the trade can show that it is replacing at least 1/30 of its membership through apprenticeship training on an annual basis state-wide or locally, or d) When the Contractor provides evidence that the Contractor employs registered apprentices on all of his contracts on an annual average of not less than one apprentice to eight journeymen. The Contractor is required to make contributions to funds established for the administration of apprenticeship programs if the Contractor employs registered apprentices or journeymen in any apprenticeable trade on such contracts and if other contractors on the public works site are making such contributions. The Contractor and any subcontractor will comply with Labor Code §§ 1777.5 and 1777.6 in the employment of apprentices. Information relative to apprenticeship standards, wage schedules and other requirements may be obtained from the Director of Industrial Relations, KHB20151022 Agreement No. 6768 ex-officio the Administrator of Apprenticeship, San Francisco, California, or from the Division of Apprenticeship Standards and its branch offices. 7-2.4 RECORD OF WAGES PAID: INSPECTION Every Contractor and subcontractor will keep an accurate certified payroll records showing the name, occupation, and the actual per diem wages paid to each worker employed in connection with the Work. The record will be kept open at all reasonable hours to the inspection of the body awarding the contract and to the Division of Labor Law Enforcement. If requested by the City, the Contractor will provide copies of the records at its cost. 7-3 LIABILITY INSURANCE Subsection 7-3, Liability Insurance, of the Greenbook is deleted in its entirety and replaced by the following subsections. 7-3.1 GENERAL Contractor must procure and maintain for the duration of the contract the following insurance coverages and limits against claims for injuries to persons or damage to property that may arise from or in connection with the performance of the work covered by this agreement by the Contractor, its agents, representatives, employees or subcontractors: COVERAGE PER OCCURRENCE Comprehensive General Liability Business Auto Workers' Compensation ISO FORM COMBINED SINGLE LIMIT CL 00 02 01 85 or 88 $2,000,000 CA 00 01 01 87 $1,000,000 Statutory Contractor will provide endorsements or other proof of coverage for contractual liability. Combined single limit per occurrence will include coverage for bodily injury, personal injury, and property damage for each accident. If Commercial General Liability Insurance or other form with a general aggregate limit is used, the policy will be endorsed such that the general aggregate limit will apply separately to this contract and a copy of the endorsement provided to the City. Liability policies will contain, or be endorsed to contain the following provisions: Page 25 of 36 Agreement No. 6768 GENERAL LIABILITY AND AUTOMOBILE LIABILITY:. The City, its officers, officials, employees, agents, and volunteers will be covered as insureds as respects: liability arising out of activities performed by or on behalf of the Contractor; products and completed operations of the Contractor; premises owned, occupied or used by the Contractor; or automobiles owned, leased, hired or borrowed by the Contractor. The coverage will contain no special limitations on the scope or protection afforded to the City, its officers, officials, employees, agents, or volunteers. The Contractor's insurance coverage will be primary insurance as respects the City, its officers, officials, employees, agents, and volunteers. Any insurance or self-insurance maintained by the City, its officers, officials, employees, agents, and volunteers will be excess of the Contractor's insurance and will not contribute with it. The insurer will agree in writing to waive all rights of subrogation against the City, its officers, officials, employees and volunteers for losses arising from work performed by the Contractor for the City. Any failure to comply with reporting provisions of the policies will not affect coverage provided to the City, its officers, officials, employees, agents and volunteers. The Contractor's insurance will apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. WORKERS' COMPENSATION: The insurer will agree to waive all rights of subrogation against the City, its officers, officials, employees and volunteers for losses arising from work performed by the Contractor for the City. ALL COVERAGES: Each insurance policy required by this subsection will be endorsed to state that coverage will not be suspended, voided, cancelled by either party, reduced in coverage or in limits except after thirty (30) calendar days written notice by certified mail, return receipt requested, has been given to: CITY CLERK City of El Segundo 350 Main Street El Segundo, CA 90245 Notwithstanding the foregoing, the endorsement may state that insurance may KHB20151022 Agreement No. 6768 be cancelled upon ten (10) calendar day notification for non-payment of premium. The Contractor will provide the City with updated proof of insurance should the Contract Time extend beyond the policy expiration date. All liability insurance will be on an occurrence basis. Insurance on a claims made basis will be rejected. Any deductibles or self -insured retentions will be declared to and approved by City. The insurer will provide an endorsement to City eliminating such deductibles or self -insured retentions as respects the City, its officials, employees, agents, and volunteers. Except for Workers Compensation Insurance, Contractor will furnish to City certificates of insurance and endorsements on forms acceptable to the City's City Attorney, duly authenticated, giving evidence of the insurance coverages required in this contract and other evidence of coverage or copies of policies as may be reasonably required by City from time to time. Endorsements must be supplied on ISO Form No. CG 20 10 11 85, or equivalent. Certificate/endorsement for Workers Compensation Insurance will be furnished on State Comp Fund or other industry standard form. Except for worker's compensation insurance, all insurance required herein will be placed with insurers with a Best's Rating of not less than A:VII. Worker's compensation insurance policies will meet the requirements of California law. All subcontractors employed on the work referred to in this contract will meet the insurance requirements set forth for Contractor. Contractor will furnish certificates of insurance and endorsements for each subcontractor at least five days before the subcontractor entering the job site, or Contractor will furnish City an endorsement including all subcontractors as insureds under its policies. Except as provided in Subsection 6-10, the Contractor will save, keep and hold harmless the City, its officers, officials, employees, agents and volunteers from all damages, costs or expenses in law or equity that may at any time arise or be claimed because of damages to property, or personal injury received by reason of or in the course of performing work, which may be caused by any willful or negligent act or omission by the Contractor or any of the Contractor's employees, or any subcontractor. The City will not be liable for any accident, loss or damage to the work before its completion and acceptance, except as provided in Subsection 6-10. The cost of such insurance will be included in the various items of work in the Contractor's bid and no additional compensation for purchasing insurance or additional coverage needed to meet these requirements will be allowed. In the event that any required insurance is reduced in coverage, cancelled for any reason, voided or suspended, Contractor agrees that City may arrange for insurance coverage as specified, and Contractor further agrees that administrative and premium costs may be deducted from payments due to the KHB20151022 Page 27 of 36 Agreement No. 6768 Contractor. Contractor will not be allowed to work until alternate coverage is arranged. Coverage will not extend to any indemnity coverage for the active negligence of the additional insured if the agreement to indemnify the additional insured would be invalid under Civil Code § 2782(b). 7-3.2 INDEMNIFICATION AND DEFENSE In addition to the provisions of Subsection 7-3 of the Greenbook as between the City and Contractor, Contractor will take and assume all responsibility for the work as stated herein or shown on the plans. The Contractor will bear all losses and damages directly or indirectly resulting to it, to the City, its officers, employees, and agents, or to others on account of the performance or character of the work, unforeseen difficulties, accidents, traffic control, job site maintenance, or any other causes whatsoever. The Contractor will assume the defense of and indemnify and save harmless the City of El Segundo, its officers, employees, and agents, from and against any and all claims, losses, damage, expenses and liability of every kind, nature, and description, directly or indirectly arising from the performance of the contract or work, regardless of responsibility for negligence, and from any and all claims, losses, damage, expenses, and liability, howsoever the same may be caused, resulting directly, or indirectly from the nature of the work covered by the contract, regardless of responsibility for negligence, to the fullest extent permitted by law. In accordance with Civil Code § 2782, nothing in this Subsection 7-3.2 or in Subsection 7-3 of the Standard Specifications will require defense or indemnification for death, bodily injury, injury to property, or any other loss, damage or expense arising from the sole negligence or willful misconduct of the City, or its agents, servants or independent contractors who are directly responsible to the City, or for defects in design furnished by such persons. Moreover, nothing in this Subsection 7-3.2 or in Subsection 7-3 will apply to impose on the Contractor, or to relieve the City from, liability for active negligence of the City. The City does not, and will not, waive any rights against the Contractor which it may have by reason of the aforesaid hold harmless agreements because of the acceptance by the City, or deposit with City by Contractor, of any insurance policies described in Subsection 7-3 of the Special Provisions. This hold harmless agreement by the Contractor will apply to all damages and claims for damages of every kind suffered, or alleged to have been suffered by reasons of any of the aforesaid operations of Contractor, or any subcontractor, regardless of whether or not such insurance policies are determined to be applicable to any of such damages or claims for damages. KHB20151022 Page 28 of 36 Agreement No. 6768 No act by the City, or its representatives in processing or accepting any plans, in releasing any bond, in inspecting or accepting any work, or of any other nature, will in any respect relieve the Contractor or anyone else from any legal responsibility, obligation or liability he might otherwise have. 7-5 PERMITS The following paragraph will be added to Subsection 7-5 of Greenbook: The Contractor will apply for permits required by the City. These permits will be issued on a "no -fee" basis. However, the Contractor must pay for and obtain all other permits from other governmental and utility agencies necessitated by their operations. All bonding fees, (overweight and oversized vehicle permit fees) inspection permit fees or other fees charged or required for such permits must be paid by the Contractor. These costs will be included in the bid item provided. If no bid item is included, costs will be included in the various items of work, and no additional payment will be allowed. 7-8.1 CLEANUP AND DUST CONTROL Subsection 7-8.1, Cleanup and Dust Control, of the Greenbook is deleted in its entirety and replaced by the following subsections. 7-8.1.1 GENERAL On any construction project requiring trenching within public streets and for which total trenching is in excess of 500 feet, the Contractor will be required to sweep the worksite utilizing a pick-up type street sweeper a minimum of once daily. 7-8.1.2 WATERING Water for dust control caused by Contractor's operations or the passage of traffic through the work will be applied as necessary or as directed by the Engineer. Water for the above or other purposes may be obtained from any approved source. If the Contractor chooses to use a City fire hydrant upon placing deposits and fees as described in this contract, the Engineer will cause a meter to be installed. All water used from the hydrant will be metered and charged to the Contractor at the prevailing rate plus the current daily meter rental rate. The Contractor will be charged a $15 reconnect fee if the Contractor wishes to move the meter to a different hydrant. Costs of water to be used will be included in the cost of various bid items. 7-8.6 WATER POLLUTION CONTROL KHB20151022 Agreement No. 6768 The following requirements are added to establish storm water and urban runoff pollution prevention controls. (a) Storm or construction generated water containing sediment such as, construction waste, soil, slurry from concrete/asphalt concrete saw cutting operations, clean up of concrete transit mixers or other pollutants from construction sites and parking areas will be retained or controlled on site and will not be permitted to enter the storm drain system. (b) Temporary sediment filtering systems such as sandbags, silt fences, or gravel berms will be utilized to trap sediment so that only filtered water enters the City's storm drain system. Proper clean up and disposal of settled sediment and the filtering system will be the responsibility of the Contractor. (c) Discharge of concrete transit mixerwash water on to approved dirt areas (sub -grade area designated for new concrete construction for example) is acceptable. Discharge on to private property, parkway areas, or the street is not permitted. (d) Plastic or other impervious covering will be installed where appropriate to prevent erosion of an otherwise unprotected area, along with any other runoff control devices deemed appropriate by the City. (e) Excavated soil stored on the site will be covered in a manner that minimizes the amount of sediments running into the storm drain system, street or adjoining properties. (f) No washing of construction or other industrial vehicles and equipment will be allowed adjacent to a construction site. During the rainy season (October 15 to April 15), Contractor will keep at the construction site sufficient materials and labor to install temporary sediment filtering systems and other water pollution prevention control measures. These control measures will be in place and maintained by the Contractor on a daily basis on days when construction is not in progress due to rain. (h) All costs associated with water pollution control will be borne by the Contractor. Any expense incurred by the City to expeditiously respond to storm drain contamination resulting from Contractor's failure to implement water pollution control measures will be charged to the Contractor. 7-9 PROTECTION AND RESTORATION OF EXISTING IMPROVEMENTS The following requirements are added to Section 7-9: Page 30 of 36 Agreement No. 6768 Where existing traffic striping, pavement markings, and curb markings are damaged or their reflectively reduced by the Contractor's operations, such striping or markings will also be considered as existing improvements and the Contractor will replace such improvements. Relocations, repairs, replacements, or re -establishments will be at least equal to the existing improvements and will match such improvements in finish and dimensions unless otherwise specified. 7-10 PUBLIC CONVENIENCE AND SAFETY The following requirement is added to Section 7-10: Unless otherwise specified all traffic control will be performed in accordance with the Work Area Traffic Control Handbook (WATCH) Latest Edition, published by Building News, 3055 Overland Avenue, Los Angeles, CA 90034, telephone 310-474-7771. 7-10.1 TRAFFIC AND ACCESS The Contractor will notify the occupants of all affected properties at least 48 hours before any temporary obstruction of access. Vehicular access to property line will be maintained except as required for construction for a reasonable period of time. No overnight closure of any driveway will be allowed except as permitted by the Engineer. At least one (1) twelve (12) foot wide traffic lane will be provided for each direction of travel on all streets at all times except as permitted by the Engineer. The traffic lanes will be maintained on pavement, and will remain unobstructed. All work requiring that a lane be closed or a lane moved right or left will be noticed to the traveling public by use of City approved lighted arrow boards. Clearances from traffic lanes will be five (5) feet to the edge of any excavation and two (2) feet to the face of any curb, pole, barricade, delineator, or other vertical obstruction. One four (4) foot wide paved pedestrian walkway will be maintained in the parkway area on each side of all streets. The clearance from the pedestrian walkway to any traffic lane will be five (5) feet. Pedestrians and vehicles will be protected from all excavations, material storage, and/or obstructions by the placement of an adequate number of lighted barricades (minimum two (2)) at each location, one (1) at each end of the obstruction or excavation), which will have flashing lights during darkness. Barricades will be Type I or Type II per Section 7-3 of the WATCH Manual and lights will be Type A per Section 7-6 of the "Work Area Traffic Control Handbook" (WATCH). KHB20151022 Page 31 of 36 Agreement No. 6768 7-10.2 STREET CLOSURES, DETOURS, BARRICADES Street closures will not be allowed except as specifically permitted by the Engineer. The Contractor will prepare any traffic control or detour plans that may be required as directed by the Engineer. Lane transitions will not be sharper than a taper of thirty (30) to one (1). Temporary traffic channelization will be accomplished with barricades or delineators. Temporary striping will not be allowed unless specifically permitted by the Engineer. The Contractor will prepare any plans that may be required for temporary striping to the satisfaction of the Engineer. In no event will temporary striping be allowed on finish pavement surfaces, which are to remain. Where access to driveway or street crossings need to be maintained, minimum 1 114 inch thick steel plating will be used to bridge the trench. All steel plating will have temporary asphalt concrete 1.12 minimum sloped ramps to assist vehicles to cross comfortably over the plates and have a non-skid surface. Plates subject to vehicle high traffic speeds and in residential areas will be secured by welding at the discretion of the Engineer. 7-10.5 PROTECTION OF THE PUBLI It is part of the service required of the Contractor to make whatever provisions are necessary to protect the public. The Contractor will use foresight and will take such steps and precautions as his operations warrant to protect the public from danger, loss of life or loss of property, which would result from interruption or contamination of public water supply, interruption of other public service, or from the failure of partly completed work or partially removed facilities. Unusual conditions may arise on the Project which will require that immediate and unusual provisions be made to protect the public from danger or loss of life, or damage to life and property, due directly or indirectly to prosecution of work under this contract. Whenever, in the opinion of the Engineer, an emergency exists against which the Contractor has not taken sufficient precaution for the public safety, protection of utilities and protection of adjacent structures or property, which may be damaged by the Contractor's operations and when, in the opinion of the Engineer, immediate action will be considered necessary in order to protect the public or property due to the Contractor's operations under this contract, the Engineer will order the Contractor to provide a remedy for the unsafe condition. If the Contractor fails to act on the situation immediately, the Engineer may provide suitable protection to said interests by causing such work KHB20151022 Page 32 of 36 Agreement No. 6768 to be done and material to be furnished as, in the opinion of the Engineer, may seem reasonable and necessary. The cost and expense of said labor and material, together with the cost and expense of such repairs as are deemed necessary, will be borne by the Contractor. All expenses incurred by the City for emergency repairs will be deducted from the progress payments and the final payment due to the Contractor. Such remedial measures by the City will not relieve the Contractor from full responsibility for public safety. 7-15 HAZARDOUS MATERIAL The following Subsection will be added to Section 7 of the Greenbook: For any excavation, which extends more than four feet below existing grade, the Contractor will promptly, and before the conditions are disturbed, notify the Engineer, in writing, of 1) any material that the Contractor believes may be hazardous waste, as defined in Health and Safety Code § 25117, which is required to be removed to a Class I, Class II, or Class III disposal site in accordance with provisions of existing law, 2) subsurface or latent physical conditions at the site differing from those indicated, or 3) unknown physical conditions at the site of any unusual nature, different materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract Documents. After receiving notice from the Contractor, the Engineer will promptly investigate any condition identified by the Contractor as being hazardous. The rights and obligations of the City and the Contractor with regard to such conditions (including, without limitation, the procedures for procuring change orders and filing claims) will be specified by the provisions of Subsection 3-4 (Changed Conditions) of the Greenbook. If a dispute arises between the City and the Contractor whether the conditions materially differ, involve hazardous waste, or cause a change in the Contractor's cost or time required for performance of the work, the Contractor will not be excused from any scheduled completion date provided for by the contract, but will proceed with all work to be performed under the contract. The Contractor will retain all rights provided by Subsection 3-5, Disputed Work, of the Greenbook. If the Engineer determines that material called to the Engineer's attention by the Contractor is hazardous waste, or if the Engineer otherwise discovers the existence of hazardous waste, the Contractor will be responsible for removal and disposal of the hazardous waste by qualified personnel and appropriate equipment in the manner required by law as directed by the Engineer, subject to the provisions of Section 3 (Changes in Work) of the Greenbook. Page 33 of 36 Agreement No. 6768 9-2 LUMP SUM WORK Subsection 9-2, Lump Sum Work, of the Greenbook is deleted in its entirety and replaced by the following: Items for which quantities are indicated as "Lump Sum," "L.S.," or "Job" will be paid for at the price indicated in the Proposal. Such payment will be full compensation for all costs for labor, equipment, materials and plant necessary to furnish, construct and install the lump sum item of work, complete, in place, and for all necessary appurtenant work, including, but not limited to, all necessary cutting, patching, repair and modification of existing facilities, and clean up of site. Contractor will furnish three copies of a detailed schedule, which breaks down the lump sum work into its component parts and cost for each part, in a form and sufficiently detailed as to satisfy Engineer that it correctly represents a reasonable apportionment of the lump sum. This schedule is subject to approval by Engineer as to both the components into which the lump sum item is broken down, and the proportion of cost attributable to each component. This schedule will be the basis for progress payments for the lump sum work. 9-3.2 PARTIAL AND FINAL PAYMENTS The text of Subsection 9-3.2 of the Standard Specifications is deleted and replaced with the following: The closure date for the purpose of making partial progress payments will be the last working day of each month. The Contractor will prepare the partial payment invoice with measurement of the work performed through the closure date and submit it to the CITY for approval. When work is complete, the Contractor will determine the final quantities of the work performed and prepare the final progress payment, and submit it to the Engineer for approval. It will take a minimum of thirty-five (35) calendar days from the date of approving the Contractor's invoice to make the payment to the Contractor. However, payments will be withheld pending receipt of any outstanding reports required by the contract documents, or legal release of filed Stop Payment Notices against the Contractor. In addition, the final progress payment will not be released until the Contractor returns the control set of Plans and Specifications showing the as -built conditions. The full five percent (5%) retention will be deducted from all progress KHB20151022 Page 34 of 36 Agreement No. 6768 payments. The Contractor will make a payment request for the retained amount, for approval by the City, upon field acceptance of the work by the City Engineer. The City Engineer upon field acceptance and receipt of the final as - built plans and any other reports or documents required to be provided by the Contractor will process a recommendation to the City Council for acceptance of the work. Not less than thirty-five (35) calendar days from the City Council acceptance of the work, the Contractor's final payment will be made provided Stop Payment Notices or other claims have not been filed against the Contractor and/or the City by material suppliers, sub -contractors, other governmental agencies, and private property owners. Until these Stop Payment Notices are released and claims are resolved the stop payment/claim amount will be withheld from the final payment. The Contractor, however, may receive interest on the retention for the length of construction, or receive the retention itself as long as the retention is substituted with escrow holder surety or equal value. At the request and expense of the Contractor, surety equivalent to the retention may be deposited with the State Treasurer, or a State or Federally chartered bank, as the escrow agent, who will pay such surety to the Contractor upon satisfactory completion of the contract. Pursuant to PCC § 22300, the Contractor may substitute securities for retention monies held by the City or request that the City place such monies into an escrow account. The Contractor is notified, pursuant to PCC § 22300, that any such election will be at the Contractor's own expense and will include costs incurred by the City to accommodate the Contractor's request. Progress payment paid by the City as contemplated herein, will be contingent upon the Contractor submitting, in addition to any additional documents, an updated Contract Schedule in the form prescribed by these Contract Documents. Failure of the Contractor to submit an acceptable updated Contract Schedule will result in the City withholding partial payment, without liability to the City, until such an acceptable updated Contract Schedule is submitted. Nothing herein will allow the Contractor to suspend or slow progress of the Work. A City Council resolution established a Project Payment Account, encumbered money in the current budget, and assigned that money to the Project Payment Account which is the sole source of funds available for payment of the Contract Sum. Contractor understands and agrees that Contractor will be paid only from this special fund and if for any reason this fund is not sufficient to pay Contractor, Contractor will not be entitled to payment. The availability of money in this fund, and City's ability to draw from this fund, are conditions precedent to City's obligation to make payments to Contractor. Page 35 of 36 Agreement No. 6768 9-3.3 DELIVERED MATERIALS Materials and equipment delivered or stored, but not incorporated into the work, will not be approved for progress payments. 100-1 TERMINATION OF AGENCY LIABILITY Before receiving final payment, the Contractor will execute a "Release on Contract" form which will operate as, and will be a release to the City, the City Council, and each member of the City Council and their agencies, from all claims and liability to the Contractor for anything done or furnished for, or relating to, the work or for any act of neglect of the City of any person relating to or affecting the work, except the claim against the City for the remainder, if any there be, of the amounts kept or retained as provided in Subsections 9-3 of the Standard Specifications and except for any unsettled claims listed on said form which have been filed in compliance with the requirements for making claims. - END OF SECTION - KHB20151022 Page 36 of 36