CONTRACT 1474 OtherAGREEMENT FOR SUBDIVISION IMPROVEMENTS 1 St THIS AGREEMENT is made and entered into this/day Of March , 1976, by and between the CITY OF EL SEGUNDO , a municipal corporation, hereinafter referred to as "City," and SEPULVEDA PROPERTIES, INC., a California corporation, hereinafter referred to as "Owner -Developer," both of whom understand as follows: RECITALS: Owner -Developer has applied to the Director of Planning for approval of a parcel map (hereinafter called "Map") entitled "Parcel Map No. 6257" (Division of Land No. 5-75) being a subdivision of a portion of the southwest quarter of Section 7, Township 3 South, Range 14 West, in the Rancho Sausal Redondo, in the City of El Segundo, County of Los Angeles, State of California, as per map re- corded in Book 1, Pages 507 and 508 of Patents, in the Office of the County Recorder of said County. Owner -Developer has requested that the Map be approved, and that the construction of the following im- provements be delayed until development of each lot to whic earlier the same are appurtenant or at such/ ' time as deemed necessary: " by the Director of Public Works of the City of El Segundo: 1 4-5- FEB 2 6 19; 6 (a) 5' sidewalk and appurtenances along the southerly boundary of Lot 3 and the northerly boundary of Lot 1; (b) 12' street widening, including asphalt paving and concrete curbs, gutters and appurtenances, along the south side of Grand Avenue, between Continental Boulevard and Owner -Developer's east boundary line and appurtenances. Such improvements are hereinafter called "Subdivision'Im- provements." The land encompassed by the Map is hereinafter called "subdivision." Owner -Developer has filed the Map with the Direc- tor of Planning; on January 8, 1976 such Map was approved. pursuant to the "El Segundo Municipal Code" and the Sub- division Map Act of the State of California; by its Resolu- tion No. 880, the El Segundo Planning Commission granted a delay in the construction of the Subdivision Improvements until the development of each lot or at such time deemed necessary by the Director of Public Works of the City of El Segundo. NOW, THEREFORE, for and in consideration of the approval of the Map, and the grant of the aforesaid delay, and in order to insure satisfactory performance by the owner -Developer of Owner -Developer's obligations under the "El Segundo Municipal Code" and the Subdivision Map Act.of EM FEB 2 6 19,6 the State of California, the parties hereto agree as follows: 1. Performance of Work. Owner -Developer will do and perform, or cause to be done and performed, at owner -Developer's own expense, in a good and workmanlike manner, and furnish all required materials, all under the direction and to the satisfaction of the City Engineer of City, all of the following work and improvements within (and/or without) the subdivision, to wit: (a) Grading: Grading shall be completed as shown on a grading and street construction plan approved by the City Engineer. (b) Streets and Sidewalks: Streets and sidewalks shall be constructed in accordance with Plans approved by the City Engineer. and Owner -Developer shall also do all work and furnish all materials necessary in the opinion of the City Engineer, and on his order, to complete the improvements in accordance with the plans and specifications on file as hereinbefore specified, or with any changes required or ordered by.said Engineer, which in his opinion are necessary or required to complete the work'. Construction of the subdivision improve- ments shall not be required until the development of each lot or at such time deemed necessary by the El Segundo City Staff. 2. Improvements Guaranteed. Owner -Developer shall guarantee such improvements for a period of one year following the completion by owner - Developer and acceptance by City against any defective work or labor done, or defective materials furnished, in the performance of this Subdivision Improvement Agreement by Owner -Developer. 3. Work; Places and Grades to be Fixed by Engineer. All of said work is to be done at the places, of the materials, in the manner, and at the grades, all as shown upon plans and specifications therefor, to be approved by City Engineer and to the satisfaction of said City Engineer. 4D -3- FEB 2 6 1976 4. Work; Notification of Commencement; Time of Completion. At least fifteen calendar days prior to the com- mencement of work hereunder, owner -Developer shall notify City Engineer in writing of the date fixed by Owner -Develop- er for commencement thereof, so that City Engineer shall be able to provide services of inspection. City hereby fixes the time for the completion of said work to be at the time of development of each parcel or within sixty days after written demand from the City Engineer, whichever occurs first, provided that the City Engineer certifies in such written demand that in his opinion the construction of the subdivision improvements is necessary. 5. Repairs and Replacements. When constructing the dellolar d subdivision improve- ments, Owner -Developer shall replace, or have replaced, or repair, or have repaired, as the case may be, all pipes shown on the map which have been destroyed or damaged, and Owner - Developer shall replace or have replaced, repair, or have re- paired, as the case may be, or pay to the owner, the entire cost of replacement or repairs, of any and all property damaged or destroyed by reason of any work done hereunder, whether such property be owned by the United States or any agency thereof, or the State of California, or any agency or political subdivision thereof, or by the City or by any pub- lic or private corporation, or by any person whomsoever, or by any combination of such owners. Any such repair or replace- ment shall be to the satisfaction, and subject to the ap- proval, of the City Engineer. 6. Location of Utility Lines - Utility Easement. Utility lines, if any, including but not limited to electric, communications, and cable television shall be placed underground. 7. Permits; Com Hance with Law. Owner -Developer shall, at Owner -Developer's ex- pense, obtain all necessary permits and licenses for the con struction of the deinved subdivision improvements, give all necessary notices and pay all fees and taxes required by law.rti 8. Superintendence by Owner -Developer. Owner -Developer shall give personal superintendence t, to the work on the del subdivision improvements, or have a competent foreman or superintendent satisfactory to the City Engineer on the work at all times during progresIs-,,\with authority to act for Owner -Developer. 7- -4- FEB 2 6 1976 9. 'Inspection by City. Owner -Developer shall at all times maintain proper facilities, and provide safe access for inspection by City, to all parts of the work, and to the shops wherein the work is in preparation. 10. Improvement Security for Improvement of Uerlayed Sub division improvements. Concurrently with the execution hereof, Owner - Developer shall furnish improvement security as required by Section 66499 of the Government Code of the State of Cali- fornia and Chapter 19.04 of the El Segundo Municipal Code in the amount of $12,000.00. ll.Hold-Harmless Aareement. Owner -Developer hereby agrees to, and shall, hold City its elective and appointive boards, commissions, offi- cers, agents and employees, harmless from any liability for damage or claims for damage for personal injury, including death, as well as from claims for property damage which may arise from Owner -Developer's or owner -Developer's contrac- tors', subcontractors', agents' or employees' operations under this agreement, whether such operations be by Owner - Developer or by any of Owner -Developer's contractors, sub- contractors, or by any one or more persons directly or indirectly employed by, or acting as agent for, Owner - Developer or any of Owner -Developer's contractors or subcon- tractors. Owner -Developer agrees to, and shall, defend City and its elective and appointive boards, commissions, offi- cers, agents and employees from any suits or actions at law or in equity for damages caused, or alleged to have been caused, by reason of any of the aforesaid operations; provided as follows: (a) That City does not, and shall not, waive any rights against owner -Developer which it may have by reason of the aforesaid hold -harmless agreement, be - .cause of the acceptance by City, or the deposit with City by Owner -Developer of any of the insurance poli- cies described in paragraph 13 hereof. (b) That the aforesaid hold -harmless agreements by owner -Developer shall apply to all damages and * claims for damages of every kind suffered, or alleged to have been suffered, by reason of any of the afore- said operations referred to in this paragraph, regard- less of whether or not City has prepared, supplied, or approved of, plans and/or specifications for the sub- division, or regardless of whether or not such insur- ance policies shall have been determined to be ap- plicable to any of such damages or claims for damages. -5- FEB 26 -9-6 12. Owner -Developer's Insurance. Owner -Developer shall not commence work under this agreement until Owner -Developer shall have obtained all insurance required under this paragraph and such insurance shall have been approved by City Attorney as to form, amount and carrier, nor shall Owner -Developer allow any contractor or subcontractor to commence work on his contract or subcon- tract until all similar insurance required of the contractor or subcontractor shall have been so obtained and approved. All requirements herein provided shall appear either in the body of the insurance policies or as endorsements and shall specifically bind the insurance carrier. (a) Worker's Compensation Insurance: Owner -De- veloper shall maintain, during the life of this agree- ment, Worker's Compensation Insurance for all Owner - Developers' employees employed at the site of improve- ment, and in case any work is sublet, Owner -Developer shall require any contractor or subcontractor similarly to provide Worker's Compensation Insurance for all contractors' or subcontractors' employees, unless such employees are covered by the protection afforded by Owner -Developer. In case any class of employees en- gaged in work under this agreement at the site of the .project is not protected under any Worker's Compensa- tion law, Owner -Developer shall provide, and shall cause each contractor and subcontractor to provide, adequate insurance for the protection of employees not otherwise protected. Owner -Developer hereby indemnifies City for any damage resulting to it from failure of either Owner - Developer or any contractor or subcontractor to take out or maintain such insurance. (b) Liability Insurance: Owner -Developer shall furnish the City a policy or certificate of comprehen- sive general and liability insurance in which the City is the named insured or is named as an additional in- sured with the Owner -Developer. Notwithstanding any inconsistent statement in the policy or any subsequent endorsement attached thereto, the City shall be the insured or named as an additional insured covering all operations of the Owner -Developer, whether liability is attributable to the Owner -Developer or the City. The Owner -Developer may file with the City a satisfactory "blanket coverage" policy of insurance. The policy shall insure the City, its officers, and employees while acting within the scope of their duties, against all claims arising out of or in connection with the work. The policy shall provide the following minimum limits• ii�,�N -6- FEB 2 6 1976 Bodily Injury ............ $300,000 each occurrence Property Damage .......... $100,000 each occurrence $300,000 Aggregate operations $300,000 Aggregate products & completed operations $300,000 Aggregate contractual $300,000 Aggregate protective In.the event that any of the aforesaid insurance Policies provided for in this paragraph 142:insures any entity, person, board or commission other than those mentioned in this paragraph, such policy shall contain a standard form of cross -liability endorsement, in- suring on such policy city, its elective and appointive boards, commissions, officers, agents and employees, Subdivider and any contractor or subcontractor per- forming work covered by this agreement. 13. 'Evidence of Insurance. Owner -Developer shall furnish City prior to com- mencement of work on the subdivision improvements, with satisfactory evidence of the insurance required, and evi- dence that each carrier is required to give City at least thirty days' notice by registered mail, of the cancellation, expiration or reduction in coverage of any policy during the effective period of this agreement. 14. Title to Improvements. Title to, and ownership of, dg*,ayed subdivision improvements constructed hereunder by Owner -Developer shall vest absolutely in City, upon completion and acceptance of such improvements by City. t5 15. Repair or ReconstructionofDefective Work. If, within a period of one year after final accep- tance of the - work performed under this agreement, any struc- ture or part of any structure furnished and/or installed or constructed, or caused to be installed or constructed by Owner -Developer, or Any of the work done under this agree- ment, fails to fulfill any of the requirements of this agreement, or the specifications referred to herein, Owner - Developer shall without delay and without any cost to city, repair or replace or reconstruct any defective or otherwise unsatisfactory part or parts of the work or structure. Should Owner -Developer fail to act promptly or in accordance with this requirement, or should the exigencies of the case require repairs or replacements to be made before Owner - Developer can be notified, City may, at its option, make the necessary repairs or replacements or perform the neces- sary work and Owner -Developer shall pay to City the,,"' tual cost of such repairs plus fifteen percent. �a) I I -7- FEB 26 1916 16. Owner -Developer not Agent of City. Neither Owner -Developer nor any of the Owner - Developer's agents or contractors are or shall be considered to be agents of City in connection with the performance of Owner -Developer's obligations under this agreement. 17. Notice of Breach and Default. If Owner -Developer refuses or fails to obtain prosecution of the work, or any severable part thereof, with such diligence as will insure its completion within the time specified, or any extensions thereof, or fails to obtain completion of said work within such time, or if Owner - Developer should be adjudged a bankrupt, or Owner -Developer should make a general assignment for the benefit of Owner - Developer's creditors, or if a receiver should be appointed in the event of Owner -Developer's insolvency, or if Owner - Developer, or any of Owner -Developer's contractors, sub- contractors, agents or employees, should violate any of the provisions of this agreement, City Engineer or City Council may serve written notice upon Owner -Developer and Owner - Developer's surety of breach of this agreement, or of any portion thereof, and default of Owner -Developer. 18. Cost of Engineering and Inspection. Owner -Developer shall pay to City the actual cost to City for all engineering,inspection, and other service furnished by City in connection with the subdivision improvements. 19.' Breach of Agreement; Performance by Surety or City. In the event of any such notice, Owner -Developer's surety shall have the duty to take over and complete the work and the improvement herein specified; provided, how- ever, that if the surety, within ten working days after the serving upon it of such notice of breach, does not give City written notice of its intention to take over the performance of the contract, and does not commence performance thereof within ten days after notice to City of such election, City may take over the work and prosecute the same to completion, by contract or by any other method City may deem advisable, for the account and at the expense of Owner -Developer and Owner -Developer's surety shall be liable to City for any excess cost or damages occasioned City thereby; and, in such event, City, without liability for so doing, may take pos- session of, and utilize in completing the work, such ma- terials, appliances, plant and other property belonging to Owner -Developer as may be on the site of the work and — necessary therefor. FEB 20 1976 20. Notices. All notices herein required shall be in writing, and delivered in person or sent by registered mail, postage prepaid. Notices required to be given to City shall be addressed as follows: City Engineer, City of El Segundo, City Hall 350 Main Street, El Segundo, California 90245. Notices required to be given to Owner -Developer shall be addressed as follows: Sepulveda Properties, Inc., 2251 E. El Segundo Boulevard, El Segundo, California 90245. Notices required to be given to the surety of Owner -Developer shall be addressed as follows: -L-111tank B, liati—&-Co. 3200 Wilshire 131vd., Los Angeles. —Ca. 0 Provided that any party or the surety may change such address by notice in writing to the other party and thereafter notices shall be addressed and transmitted to the new address. IN WITNESS WHEREOF, the Parties have caused this instrument to be executed on this 1st day of March ATTEST: , 1976. CITY,OF EL SEGUNDO, CALIFORNIA n J By - aMayor I (CITY) City Clerk (SEAL) Approved as to form: City Attorney SEPULVEDA PROPERTIES, INC., California Corporation -9- INSURANCE COMPANY OF NORTH AMERICA, PH ILADELPHIA,PENNSYLVANIA BOND FOR FAITHFUL PERFORMANCE Bond No. M 968841 Premium: $180.00 Whereas, the City Council of the City of El Segundo, State of California, and Sepulveda Properties, Inc. (hereinafter designated as "principal") have entered into an agreement whereby principal agrees to install and complete certain designated public improvements, which said agreement, dated 1976, and identified as project "Parcel Map No. 6257" (Division of Land No. 5-75) being a subdivision of a portion of the southwest quarter of Section 7, Township 3 South, Range 14 West, in the Rancho Sausal Redondo, in the City of El Segundo, County of Los Angeles, State of California, as per map recorded in Book 1, Pages 507 and 508 of Patents, in the Office of the County Recorder of said County, is hereby referred to and made a part hereof; and Whereas, Said principal is required under the terms of said agreement to furnish a bond for the faithful performance of said agreement. Now, therefore, we, the principal and the INSURANCE COMPANY OF NORTH AMERICA, as surety, are held and firmly bound unto the City of E1 Segundo , (hereinafter called "obligee"), in the penal sum of TWELVE THOUSAND AND N0/100 DOLLARS ($12,000.00) lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, successors, executors and administrators, jointly and severally, firmly by these presents. The condition of this obligation is such that if the above bounded principal, his or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and provisions in the said agreement and any alteration thereof made as therein provided, on his or their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the obligee, its officers, agents and employees, as therein stipulated, then this obligation shall become null and void; otherwise it shall be and remain in full force and effect. As a part of the obligation secured hereby and in addition to the face amount specified therefor, there shall be included costs and reasonable expenses and fees, including reasonable attorney's fees, incurred by the obligee in successfully enforcing such obligation, all to be taxed as costs and included in any judgment rendered. The surety hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the agreement or to the work to be performed thereunder or the specifications accompanying the same shall in anywise affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the agreement or to the work or to the specifications. In witness whereof, this instrument has been duly executed by the principal and surety above named, on March 1, 1976. By tothers, Secretary ,+gym, C �CtrTT FB-139A PRINTED IN U.S.A. A'0"R'f)�M SEPUL)2 A PROPERTIES, INC. By: B.(G Cole,'President INSURANCE COMPANY, - F NORTH AMERICA . t By: r C. G. Gass ,Attorney -in -Fact Q A INSURANCE COMPANY OF NORTH AMERICA,PHILADELPHIA, PENNSYLVANIA "The Prc ' .:r e :..- ='. ;Or this BOND FOR LABOR AND MATERIAL Bond is incinc.ecl in ti_ra shown on the Fcric_m .nce Bond. Bond No. M 968841 Whereas, the City Council of the City of El Segundo, State of California, and Sepulveda Properties, Inc. (hereinafter designated as "principal") have entered into an agreement whereby principal agrees to install and complete certain designated public improvements, which said agreement, dated , 1976, and identified as project, "Parcel Map No. 6257" (Division of Land No. 5-75) being a subdivision of a portion of the southwest quarter of section 7, Township 3 South, Range 14 West, in the Rancho Sausal Redondo, in the City of E1 Segundo, County of Los Angeles, State of California, as per map recorded in Book 1, Pages 507 and 508 of Patents, in the Office of the County Recorder of said County, is hereby referred to and made a part hereof; and Whereas, Under the terms of said agreement, principal is required before entering the performance of the work, to file a good and sufficient payment bond with the City of E1 Segundo to secure the claims to which reference is made in Title 15 (commencing with Section.3082) of Part 4 of Division 3 of the Civil Code of the State of California. Now, therefore, said principal and the undersigned as corporate surety, are held firmly bound unto the City of E1 Segundo and all contractors, subcontractors, laborers, materialmen and other persons employed in the performance of the aforesaid agreement and referred to in the aforesaid Code of Civil Procedure in the sum of TWELVE THOUSAND AND NO/100 DOLLARS ($12,000.00), for materials furnished or labor thereon of any kind, or for amounts due under the Unemployment Insurance Act with respect to such work or labor, that said surety will pay the same in an amount not exceeding the amount hereinabove set forth, and also in case suit is brought upon this bond, will pay, in addition to the face amount thereof, costs and reasonable expenses and fees, including reasonable attorney's fees, incurred by the city in successfully enforcing such obligation to be awarded and fixed by the court, and to be taxed as costs and to be included in the judgment therein rendered. It is hereby expressly stipulated and agreed that this bond shall inure to the benefit of any and all persons, companies and corporations entitled to file claims under Title 15 (commencing with Section 3082) of Part 4 of Division 3 of the Civil Code, so as to give a right of action to them or their assigns in any suit brought upon this bond. Should the condition of this bond be fully performed, then this obligation shall become null and void, otherwise it shall be and remain in full force and effect. The surety hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of said agreement or the specifications accompanying the same shall in any manner affect its obligations on this bond, and it does hereby waive notice of any such change, extension, alteration or addition. In witness whereof, this instrument has been duly executed by the principal and surety above named, on March 1, 1976. By: / J./M. Stothers, Secretary CITY Arro"IN APPROVED AS TO FOW C ��i� FB-139A PRINTED IN U.S.A. SEPULE'A PROPERTIES, INC. �BColePresident INSURANCE, COMPANY OF NORTH AMERICA C. G. a. r , Attorney -in -Fact r e 1 , °', o' 'Eiii INSU.RANt;E COMPANY OF N0I11-H AMERICA Rn,atu all men bp kppreze N: That, the INSURANCE COMPANY OF NORTH AMERICA, a corporation of the Commonviealthof Peansyl,�anlsa Having its principal office in the City of Philadelphia, Pennsylvania, pursuant to' the ftrllowing J�res6luticini which was adopted by the :Board of Directors of the said Company on June 9, 1903„ to With. "RESOLVED, pursuanh to Articles 3.6 and 5.'1 of the By 1 as, that the following Rules shall goverh the execution for the Company of bonds, vemKg rlaances, cka�nta acts and other writings in the, nature thereof; (1) "Such writings shall be signed by the President, a Vice President, an tNsslstaht Vice President, a Residem Vice President or an Attorney -in -Fact. (2) "Unless signed by an s,uult twrltia'ogs shall have the seal of the Carmpany affixed thereto, duly attested by the Secretary, 4in Assistant Secretary or a Resident Assistant Secretary. When such "writings are 4igned by an Attorney -in -Fact, he shall either Orr an iutirra�ss4m of the Company's seal or use Sonare other generally accepted method of irralara¢ing use of a. seal (as by orritrnjz tlha word "Seal" or the letter- 'l..S.", after his signature). (3) "Resident Vice Presidents, Resident Assistant Secretaries and Attorneys in Fact may he appointed by the President ar any Vice President, with with such limits on their authority to bind the Company as the appointing officer may see fit to impose. (4) "Such Resident.Offlcei,s And Attorw,yas-in-Fact shall have uvthori'ty to Act as afinesa4l, whether w, not the President, the Secretary, or both, be absent or intapaoitated;.and shedl also Ihaveaautnorit,y to "wtifv or verify copies of this Resolu- tion, the By -Laws- of the Company, and ally affidavit Or record of the Caunpaany necessary to the dischirpe of their duties. (5) "Any such writing executed in acenrdwice with these Rules shall be as binding kilion the Company in any case as though signed by the President and attested by the Secretary." does hereby nominate, constitute and appoint DONALD E. RAPP and C. G. GRASSO, both of the City of Los Angeles, State of California its true and lawful agent and attorney -in-fact, to make, execute, seal and deliver for and on its behalf, and as its act and deed any and all bonds and undertakings in its business of guaranteeing the fidelity of persons holding places of public or private trust, and in the performance of contracts other than insurance policies, and executing and guaranteeing bonds or other undertakings, required or permitted in all actions or proceedings or by law required or permitted. All such bonds and undertakings as aforesaid to be signed for the Company and the Seal of the Company attached thereto by either one of the said Donald E. Rapp or C. G. Grasso, individually. And the execution of such bonds or undertakings in pursuance of these presents, shall be as binding upon said Company, as fully and amply, to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the Company at its office in Philadelphia, Com- monwealth of Pennsylvania, in their own proper persons. IN WITNESS WHEREOF, the said ._____ ..__ .-„_..C,__DANIEL._.DR= _..... ..... ., Vice -President, has hereunto subscribed his name and affixed the corporate seal of the said INSURANCE COMPANY OF NORTH AMERICA this. ..................... 26,th.. day of ....... .... ......... ........._...August.......,. .19.74-.... INSURANCEANY ORTH AMERICA ✓ _ (�_ �y _71(SEAL) by _ _.. _ Vice -President STATE OF PENNSYLVANIAss. COUNTY OF PHILADELPHIA On this 241h, _day of August , A. D. 19 74 _ , before the subscriber, a Notary Public of the Commonwealth of Pennsylvania, in and for the County of Philadelphia, duly commissioned and qualified, came DANTEL DRAKXK Vice -President of the INSURANCE COMPANY OF NORTH AbII': UCA to 7ne personally known to be the individual and officer described in, and who executed the preceding instrument, and he aclanowledged the execution of the same, and, being by me duly sworn„ deposeth and saith, that he is the officer of the Company afoa'esaid, and that the seal affixed to the preceding instrument is the corporate seal of said Company, and the .said corporate seal And his signature as officer were duly affixed and subscribed to the said instru- ment by the authority and direction of the said corporation, and that Resolution, adapted by the Board of Directors of said Company, referred to in the 1;Ireceding instrument, is now in force. IN TESTIMONY WHEREOF, I have hereunto set nay hand and affixed my official seal at the City of Philadelphia, the day and year first above written. otary P rcra�T.t.-�-r-• --. P xp res November 28, 1977 e ssistant Secretary of INSURANCE COMPANY OF NORTH AMERICA, do hereby certify that F TORNEY, of which the foregoing is a full, true and correct copy, is Hull force and effect. I ha e ereunto subscribed my name as Assiatalat Secretary, and afit, crate seal of y ix orpo _....day of ._,..::... M arch ssistant Se retary SB-IB �'•�"-�"� AI„N- IN U s w FEB 26 1976 20. Notices., All notices herein required shall be in writing, and delivered in person or sent by registered mail, postage prepaid. Notices required to be given to City shall be addressed as follows: City Engineer, City of El Segundo, City Hall 350 Main Street, El Segundo, California 90245. Notices required to be given to Owner -Developer shall be addressed as follows: Sepulveda Properties, Inc., 2251 E. El Segundo Boulevard, El Segundo, California 90245. Notices required to be given to the surety of Owner -Developer shall be addressed as follows: —Frank 11. JjjjjL&CQ. 3200 Witshire Blvd.. Los ArTg-e—h-si. —cn- A Provided that any party or the he surety may change such address by notice in writing to the other party and thereafter notices shall be addressed and transmitted to the new address. IN WITNESS WHEREOF, the Parties have caused this instrument to be executed on this 1st day of March 1976. ATTEST: CITY OF EL SEGUNDO, CALIFORNIA By ) 110— L-ALL Mayor P IE (CITY) City Clerk (SEAL) Approved as to form: , C City Attorney SEPULVEDA PROPERTIES, INC., California Corporation -9-