Loading...
CONTRACT 5747 Public Works Contract CLOSEDit Agreement No. 5747 PUBLIC WORKS CONTRACT BETWEEN THE CITY OF EL SEGUNDO AND RUIZ CONCRETE & PAVING, INC. DBA RUIZ ENGINEERING PW 19-10: McCarthy Court Street Improvements Project This CONTRACT is entered into this 07 day of August, 2019, by and between the CITY OF EL SEGUNDO, a general law city and municipal corporation ("the City") and RUIZ CONCRETE & PAVING, INC. DBA RUIZ ENGINEERING, a California Corporation ("the Contractor"). 1. WORK. A. The Contractor agrees to perform the work listed in the SCOPE OF SERVICES, "Exhibit A", a copy of which is attached and incorporated herein by this reference. The Contractor agrees to do additional work arising from changes ordered by the City in accordance with the Contract Documents. B. The Contractor and the City agree to abide by the terms and conditions contained in the Contract Documents; C. The Contractor will furnish all of the labor; supplies and materials; equipment; printing; vehicles; transportation; office space and facilities; all tests, testing and analyses; and all matters whatsoever (except as otherwise expressly specified to be furnished by the City) needed to perform and complete the Work and provide the services required of the Contractor by the Contract Documents. D, "Contract Documents" means the Notice Inviting Bids; Instructions to Bidders; Supplementary Instructions to Bidders; Proposal; this Contract; Standard Specifications; Supplementary Conditions; Exhibits; Technical Specifications; List of Drawings; Drawings; Addenda; Notice to Proceed; Change Orders; Notice of Completion; and all other documents identified in the Contract Documents which together form the contract between the City and the Contractor for the Work. The Contract Documents constitute the complete agreement between the City and the Contractor and supersede any previous agreements or understandings. CONTRACT SUM. The City agrees to pay the Contractor a sum not to exceed ONE HUNDRED FIFTY -NINE -'?THOUSAND NINE HUNDRED SEVENTEEN DOLLARS AND FIVE CENTS ($159,917.05) which includes the original bid amount of $139,058.05 as well as a 15% contingency amount, which may or may not be used, of $20,859.00 for the Work in the manner set forth in the Cbntract Documents. The City may adjust this amount as set forth in the Contract Documents. Agreement No. 5747 3. TERM. The term of this Contract will commence on September 1, 2019 and will expire on August 31, 2020, unless terminated earlier pursuant to Section 4. 4. TERMINATION. A. City may terminate this Contract at any time with or without cause. B. Contractor may terminate this Agreement at any time with City's mutual consent. Notice will be in writing at least thirty (30) days before the effective termination date. C. Upon receiving a termination notice, Contractor will immediately cease performance under this Agreement unless otherwise provided in the termination notice. Except as otherwise provided in the termination notice, any additional work performed by Contractor after receiving a termination notice will be performed at Contractor's own cost; City will not be obligated to compensate Contractor for such work. D. Should the Agreement be terminated pursuant to this Section, City may procure on its own terms services similar to those terminated. E. By executing this document, Contractor waives any and all claims for damages that might otherwise arise from City's termination under this Section. 5„ PREVAILING WAGES. Pursuant to Labor Code § 1720, and as specified in 8 California Code of Regulations § 16000, the Contractor must pay its workers prevailing wages. It is the Contractor's responsibility to interpret and implement any prevailing wage requirements and the Contractor agrees to pay any penalty or civil damages resulting from a violation of the prevailing wage laws. See Section 7-2 of the Standard Specifications. 6. DISPUTES. Disputes arising from this Contract will be determined in accordance with the Contract Documents and Public Contracts Code §§ 10240-10240.13. 7. THIRD PARTY CLAIMS. In accordance with Public Contracts Code § 9201, the City will promptly inform the Contractor regarding third -party claims against the Contractor, but in no event later than ten (10) business days after the City receives such claims. Such notification will be in writing and forwarded in accordance with the "Notice" section of the Contract Documents. As more specifically detailed in the Contract Documents, the Contractor agrees to indemnify and defend the City against any third -party claim. 8. TAXPAYER IDENTIFICATION NUMBER. The Contractor will provide the City with a Taxpayer Identification Number. 9. PERMITS AND LICENSES. Unless otherwise provided, the Contractor, at its sole expense, will obtain and maintain during the term of this Contract, all necessary permits, Agreement No. 5747 3. TERM. The term of this Contract will commence on September 1, 2019 and will expire on August 31, 2020, unless terminated earlier pursuant to Section 4. 4. TERMINATION. A. City may terminate this Contract at any time with or without cause. B. Contractor may terminate this Agreement at any time with City's mutual consent. Notice will be in writing at least thirty (30) days before the effective termination date. C. Upon receiving a termination notice, Contractor will immediately cease performance under this Agreement unless otherwise provided in the termination notice. Except as otherwise provided in the termination notice, any additional work performed by Contractor after receiving a termination notice will be performed at Contractor's own cost; City will not be obligated to compensate Contractor for such work. D. Should the Agreement be terminated pursuant to this Section, City may procure on its own terms services similar to those terminated. E. By executing this document, Contractor waives any and all claims for damages that might otherwise arise from City's termination under this Section. 5. PREVAILING WAGES. Pursuant to Labor Code § 1720, and as specified in 8 California Code of Regulations § 16000, the Contractor must pay its workers prevailing wages. It is the Contractor's responsibility to interpret and implement any prevailing wage requirements and the Contractor agrees to pay any penalty or civil damages resulting from a violation of the prevailing wage laws. See Section 7-2 of the Standard Specifications. 6. DISPUTES. Disputes arising from this Contract will be determined in accordance with the Contract Documents and Public Contracts Code §§ 10240-10240.13. 7. THIRD PARTY CLAIMS. In accordance with Public Contracts Code § 9201, the City will promptly inform the Contractor regarding third -party claims against the Contractor, but in no event later than ten (10) business days after the City receives such claims. Such notification will be in writing and forwarded in accordance with the "Notice" section of the Contract Documents. As more specifically detailed in the Contract Documents, the Contractor agrees to indemnify and defend the City against any third -party claim. 8. TAXPAYER IDENTIFICATION NUMBER. The Contractor will provide the City with a Taxpayer Identification Number. 9. PERMITS AND LICENSES. Unless otherwise provided, the Contractor, at its sole expense, will obtain and maintain during the term of this Contract, all necessary permits, Agreement No. 5747 licenses, and certificates that may be required in connection with the Work. 10. OWNERSHIP OF DOCUMENTS. All documents, data, studies, drawings, maps, models, photographs and reports prepared by the Contractor under the Contract Documents are the City's property. The Contractor may retain copies of said documents and materials as desired, but will deliver all original materials to the City upon the City's written notice. 11. INDEMNIFICATION. The Contractor agrees to indemnify, defend, and hold the City harmless as set forth in the Contract Documents. The requirements as to the types and limits of insurance coverage to be maintained by the Contractor as required by the Contract Documents, and any approval of such insurance by the City, are not intended to and will not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Contractor pursuant to the Contract Documents, including, without limitation, to the provisions concerning indemnification. 12. INDEPENDENT CONTRACTOR. The City and the Contractor agree that the Contractor will act as an independent contractor and will have control of all work and the manner in which is it performed. The Contractor will be free to contract for similar service to be performed for other employers while under contract with the City. The Contractor is not an agent or employee of the City and is not entitled to participate in any pension plan, insurance, bonus or similar benefits the City provides for its employees. Any provision in this Contract that may appear to give the City the right to direct the Contractor as to the details of doing the work or to exercise a measure of control over the work means that the Contractor will follow the direction of the City as to end results of the work only. 13. AUDIT OF RECORDS. The Contractor will maintain full and accurate records with respect to all services and matters covered under this Contract. The City will have free access at all reasonable times to such records, and the right to examine and audit the same and to make transcript therefrom, and to inspect all program data, documents, proceedings and activities. The Contractor will retain such financial and program service records for at least three (3) years after termination or final payment under the Contract Documents. 14. NOTICES. All communications to either party by the other party will be deemed made when received by such party at its respective name and address as follows: The Citv City of El Segundo -Public Works 350 Main Street El Segundo, CA 90245 Attention: Lifan Xu, City Engineer (310) 524-2368 Agreement No. 5747 The Contractor Ruiz Concrete & Paving, Inc. DBA Ruiz Engineering 1344 Temple Ave. Long Beach, CA 90804 Attention: Aldo B. Ruiz, Jr., President (562) 439-3070 Any such written communications by mail will be conclusively deemed to have been received by the addressee three (3) days after deposit thereof in the United States Mail, postage prepaid and properly addressed as noted above. In all other instances, notices will be deemed given at the time of actual delivery. Changes may be made in the names or addresses of persons to whom notices are to be given by giving notice in the manner prescribed in this paragraph. 15. NO THIRD PARTY BENEFICIARY. This Contract and every provision herein is for the exclusive benefit of the Contractor and the City and not for the benefit of any other party. There will be no incidental or other beneficiaries of any of the Contractor's or the City's obligations under this Contract. 16. INTERPRETATION. This Contract was drafted in, and will be construed in accordance with the laws of the State of California, and exclusive venue for any action involving this Contract will be in Los Angeles County. 17. EFFECT OF CONFLICT. In the event of any conflict, inconsistency, or incongruity between any provision of the Contract Documents, precedence will be as follows: A. This Contract; B. The Standard Specifications; and C. Precedence of documents as determined in the Standard Specifications. 18. SEVERABILITY. If any portion of the Contract Documents are declared by a court of competent jurisdiction to be invalid or unenforceable, then such portion will be deemed modified to the extent necessary in the opinion of the court to render such portion enforceable and, as so modified, such portion and the balance of this Contract will continue in full force and effect. 19. AUTHORITY/MODIFICATION. The Parties represent and warrant that all necessary action has been taken by the Parties to authorize the undersigned to execute this Contract and to engage in the actions described herein. This Contract may be modified by written amendment. The City's city manager, or designee, may execute any such amendment on the City's behalf. 20. ACCEPTANCE OF ELECTRONIC SIGNATURES. The Parties agree that this Contract, agreements ancillary to this Contract, and related documents to be entered into in connection with this Contract will be considered signed when the signature of a party is delivered by Agreement No. 5747 electronic (.pdf) or facsimile transmission. Such electronic or facsimile signature will be treated in all respects as having the same effect as an original signature. 21. COVENANTS AND CONDITIONS. The parties agree that all of the provisions hereof will be construed as both covenants and conditions, the same as if the words importing such covenants and conditions had been used in each separate paragraph. 22. CAPTIONS. The captions of the paragraphs of this Contract are for convenience of reference only and will not affect the interpretation of this Contract. 23. TIME IS OF ESSENCE. Time is of the essence for each and every provision of the Contract Documents. IN WITNESS WHEREOF the parties hereto have executed this Contract the day and year first hereinabove written. C OF ELSEG N. O cott Mimick, City Manager RUIZ CONCRETE & PAVING, INC. F : fiil�il Taxpayer ID No. SS --14132"01 ATTEST: Contractor State License No.: 966395 Tracy Wea er, City Clerk Contractor City Business License No.: `i l G `i C,_ APPVED AS TO FORM: '* Mark . .Hensley, City Attorney Insurance Reviewed by: t/ , lo -,2,3-19 Agreement No. 5747 CALIFORNIA ALL- PURPOSE CERTIFICATE OF ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of L-0` } On 2 before me, tt- rr�ltc, °tNarrr fln8ePY f4aPftl4 and YYYa abn Ile 17 IGV3F personally appeared AlAcs t who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. MIGUEL ANG WITNESS my hand and official seal. ./21SOUNTY NOTARY NNN T • LOS ANGELES Comm. JUNE . 2020 Publi ggnattt're (Notary Public Seal) ADDITIONAL OPTIONAL INFORMATION INSTRUCTIONS FOR COMPLETING THIS FORM 1°leas fcrr'rra carrrphes swath carr -rens regarrciling notary svordling and, DESCRIPTION OF THE ATTACHED DOCUMENT if rrarerrlcel, ;slrrarrlc! be <°n'rrap,lereal and attacheiii to the a oc°arrr ellit. ,,1ckrrovv1edglinvws °fi°cam othervotes may be arraralrl'etv«'1lllll documents being sent to thew ttaaie so long as the svm-dlira„g aloe.s mart require alae C'arl'tdrormar notary to viointe C;kaltforllnaa rgowily Imv. (Title or description of attached document) • State and County information must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. .......... • Date of notarization must be the date that the signer(s) personally appeared which (Title or description of attached document continued) must also be the same date the acknowledgment is completed. • The notary public must print his or her name as it appears within his or her Number of Pages Document Date commission followed by a comma and then your title (notary public). • Print the name(s) of document signer(s) who personally appear at the time of notarization. CAPACITY CLAIMED BY THE SIGNER • Indicate the correct singular or plural forms by crossing off incorrect forms (i.e. he/she/they— is /are ) or circling the correct forms. Failure to correctly indicate this ❑ Individual (s) information may lead to rejection of document recording. ❑ Corporate Officer • The notary seal impression must be clear and photographically reproducible. Inroprc,ssion must not cover text or fines. Il” seal fin'pression smudges, re -tical if a (Title) sufficient area permits, otherwise complete za differew acknowledgment form. • Signature of the notary public must match the signature on file with the office of El Partner(s) the county clerk. ❑ Attorney -in -Fact 4t Additional information is not required but could help to ensure this ❑ Trustee(s) acknowledgment is not misused or attached to a different document. Other ' Indicate title or type of attached document, number of pages and date. r-1Otherthe capacity claimed by the signer. If the claimed capacity is a corporate officer, indicate the title (i.e. CEO, CFO, Secretary). 2015 Version www. Notar'yC lasses.roin 800-373-9865 • Securely attach this document to the signed document with a staple. m mill muuuu i Im Agreement No. 5747 PROPOSAL FOR THE McCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 Date A&vk-^ 20-a Company Name:- —h ► - .w' f U' 1` TO THE CITY OF EL SEGUNDO: In accordance with the City of El Segundo's Notice Inviting Sealed Bids, the undersigned BIDDER hereby proposes to furnish all materials, equipment, tools, labor, and incidentals required for the above stated project as set forth in the Plans, Specifications, and contract documents therefor, and to perform all work in the manner and time prescribed therein. BIDDER declares that this proposal is based upon careful examination of the work site, Plans, Specifications, Instructions to Bidders, and all other contract documents. Submittal of this bid shall be considered evidence that the BIDDER has satisfied himself regarding the contract documents, access and any other field conditions which may effect bid prices. If this proposal is accepted for award, BIDDER agrees to enter into a contract with the City of El Segundo at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to the City of El Segundo of the proposal guarantee accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids, and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE CITY OF EL SEGUNDO RESERVES THE RIGHT TO INCREASE OR DECREASE THE AMOUNT OF ANY QUANTITY SHOWN AND TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all apparent expenses, taxes, royalties, and fees. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. If awarded the Contract, the undersigned further agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within ten working days after the date of the City of El Segundo's notice of award of contract to the BIDDER, including sending by U.S. Mail a Public Works Contract for signature by the Awardee, the proceeds of the security accompanying this bid shall become the property of the City of El Segundo and this bid and the acceptance hereof may, at the City of El Segundo's option, be considered null and void. I -C-1 Agreement No. 5747 EO JAL EMPLOYMENT OPPORTUNITY COMPLIANCE BIDDER certifies that in all previous contracts or subcontracts, all reports which may have been due under the requirements of any agency, State, or Federal equal employment opportunity orders have been satisfactorily filed, and that no such reports are currently outstanding. AFFIRMATIVE .ACTION CERTIFICATION BIDDER certifies that affirmative action has been taken to seek out and consider minority business enterprises for those portions of the work to be subcontracted, and that such affirmative actions have been fully documented, that said documentation is open to inspection, and that said affirmative action will remain in effect for the life of any contract awarded hereunder. Furthermore, BIDDER certifies that affirmative action will be taken to meet all equal employment opportunity requirements of the contract documents. NONCOI.,LUSION AFFIDAVIT BIDDER declares that the only persons or parties interested in this proposal as principals are those named herein; that no officer, agent, or employee of the City of El Segundo is personally interested, directly or indirectly, in this proposal; that this proposal is made without connection to any other individual, firm, or corporation making a bid for the same work and that this proposal is in all respects fair and without collusion or fraud. I -C-2 Agreement No. 5747 100 ....... ....... «� »IM'C6111100ATIC Nall - June 20, 2019 ADDENDUM NO. 1 to THE CONTRACT DOCUMENTS, SPECIFICATIONS AND PLANS for McCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 ATTENTION BIDDERS: The following additions, modifications, and clarifications to the specifications shall be included in, and become a part of, any contract which may be executed for the above project in the City of El Segundo: 1. The bid due date and time are still Tuesday, June 25, at 11:00 am 2. Please see this project's attached Supplement to Addendum 1 for contractor questions, the City's responses to them, and additional information provided during the job walk. As evidence that the BIDDER has read this Addendum, same in the space provided below and submit thisA I Failure to provide cli acknowle ent shall r do subject to rejccti Signature:' the BIDDER must acknowledge endum with the Bid Proposal. the bid as non-responsive and Date:' /A vq Print Company Name: , �..✓�c° ," ., °el��i Page 1 of 1 350 Main Street, El Segundo, CA 90245-3895 (310) 524-2300 Fax (310) 640-0489 Agreement No. 5747 BID SCHEDULE McCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 Company Name: �Z ► ��N f ti t�, t Item Unit No. Description Price Total QTY Unit M ($) BASE BID ITEMS Mobilization/Demobilization 1 including traffic control (not to 1 LS IG 9S0 ' exceed 5% maximum of Total Bid) 2 Remove ex. curb and replace with 731 LF C q f %4.1 curb and 18" -wide gutter 3 Remove and replace 4" -thick 1,312 SF ° sidewalk 4 Remove and replace 6" -thick driveway approach 884 SF 5 Install asphalt slot paving, 3' -wide 2,193 SF Y 6 Completely remove existing tree 8 EA y Lf �' includin�mp and tree roots ALTERNATIVE BID ITEMS (Determined by the City on an as -needed basis) 7 Remove hardscape and replace with SF 920 compacted soil � . ��� 0s,, 8 Remove and replace ex. curb only LF I 50 TOTAL BID ITEMS 1 THROUGH 8 TOTAL BID ITEMS WRITTEN IN WORDS:. 4 ... _� All work shall be per these specifications and attachments. Prevailing wage rates apply. The City of El Segundo reserves the right to reject any or all bids, to waive any irregularity, and to take all bids under advisement for a period of ninety (90) calendar days. I -C-3 Agreement No. 5747 BIDDER'S INFORMATION Company Name: kLL ' ��eCk�U, BIDDER certifies that the following information is true and correct: Form of Legal Entity (i.e., individual, partnership, corporation, etc.) If corporation, State of Incorporation (i^e., California) t Business ' �. ()';A' _ ' (L - Address / 'Sc/ g Au IJ Telephone No, k� Facsimile No. (�)"i.7) State Contractor's License No. and Class DIR# Original Date Issued, to —g LL Expiration Date ���� The following arc the names, /itles, email addresses, and phone num ers of all individuals, firm members, partners, joint venturers, and/or corporate officers having principal interest in this proposal: .................... VC The date of any voluntary or involuntary bankruptcy judgments against any principal having an interest in this proposal is as follows: All current and prior DBA's, aliases, and/or fictitious business names for any principal having an interest in this proposal are as follows: I -C-4 Agreement No. 5747 BIDDER'S INFORMATION (CONTINUED) Company Name:4c(r ! "(" ' 4,1 Bidder shall list the name of the person who attended the mandatory pre-bid job walk: a Name: _A PL,;f' Title:�'d I -C-5 Agreement No. 5747 IN WITNESS WHEREOF, BIDDER executes and submits this proposal with the names, titles, hands, and seals of all a forenamed principals this `i day of _j Uwip , 20j-?. BIDDER C ULr Subscribed and sworn to this n,'( day of '�ZAA . 20_a: NOTARY PUBLIC I -C-6 PROPOSAL GUARANTEE BID BOND McCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECTNO.', PW 1040 KNOW ALL MEN BY THESE PRESENTS tha4 Ruiz Concrete& Pavinq, Inc. ,asBIDDER,.and American! Contractors $ndemnitv_Com anyy as: SURETY, are held anal ad firmly bound unto the City of El Segundo, in the penal sum, of DOLLARS ($,Iqv J, which is ten (10%) percent of the total amount bid by BIDDER'to the City of El Segundo for the, above stated projecfi; for 4he payment of which sum. BIDDER and SURETY agree -to be bound, jointly.and severally, firmly by these presents, * Ten Percent of the Total Amount of the Bid THE CONDITIONS Of THIS OBLIGATION ARE SUCH that, whereas BIDDER i§. about to submit abid. to the City of El Segundo for the abovd stated: project, if said bid is rejected; or if said, bid is 2accepted and a, contract is awarded and entered into by BIDDER in the mannermd time specified',. then this obligation shall be null and void, otherwise it shall remain in, full force and -effect in favor of"the City of El Segundo. .IN WITNESS WHEREOF the parties horeto have set their names, titles, hands,:and seals this 25th.day ofJurue 2019 BIDDER* Ruiz Con94 a �Pavin 1�jnc./ Loma Beach, CA 90804 (562) 439-307 . ............... 4 SURETY* American Contractors, Indemnity Comoanv 801 S. Flaueroa St.. Suite 7J)q1qs Angeles, CA 900 Pietro M4cc1che._6tgffj1v-in-Fact 3455 0rqAayjW&BLv1L_#2DD_Ql9nda12. CA 22g1.(2Z3J 6�$, 7- ' 4 Subscribed and sworn to this 25th day of J'une .2C19 NOTARY MLIC.............. *Provide BIDDER/SURETY:name, title, address and telephone number and *.e name, tit e, address and telephone number for Authorized representative. I -C-7 Agreement No. 5747 CALIFORNIA ALL- PURPOSE CERTIFICATE OF ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of LrII� } A~� (Hae � n name an ss�r tv � On `.'-k, l tc before me 1 � e otta4 personally appeared6 . who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. MIGUEL ANGEL RUI WITNESS my hand and official seal. NOTARY o< L1tt1 G ANGELES COUNTY lO�ry JUNE , 2020 ` Public S. nature (Notary Public Seal) ADDITIONAL OPTIONAL INFORMATION INSTRUCTIONS FOR COMPLETING THIS FORM This form complies ivith current California statutes regarding notary hording and, DESCRIPTION OF THE ATTACHED DOCUMENT ifneeded, should be completed and attached to the document Acknowledgments fu•om other states may be completed for documents being sent to that state so long as the wording does not require the California notary to violate California notary law, • State and Count information must be the State and County where the document (Title or description of attached document) y ty = signer(s) personally appeared before the notary public for acknowledgment. ---•-• ••---. • Date of notarization must be the date that the signer(s) personally appeared which (Title or description of attached document continued) must also be the same date the acknowledgment is completed. • The notary public must print his or her name as it appears within his or her f Number of Pages Document Date commission followed by a comma and then your title (notary public). • Print the name(s) of document signer(s) who personally appear at the time of notarization. CAPACITY CLAIMED BY THE SIGNER • Indicate the correct singular or plural forms by crossing off incorrect forms (i.e. late/she/they— is /are ) or circling the correct forms. Failure to correctly indicate this ❑ Individual (s) information may lead to rejection of document recording. ❑ Corporate Officer • The notary seal impression must be clear and photographically reproducible. Impression must not cover text or lines. If seal impression smudges, re -seal if a (Title) sufficient area permits, otherwise complete a different acknowledgment form. El Partner(s) • Signature of the notary public must match the signature on file with the office of the county clerk. ❑ Attorney -in -Fact Additional information is not required but could help to ensure this ❑ Trustee(s) acknowledgment is not misused or attached to a different document. Other Indicate title or type of attached document, number of pages and date. ❑ Indicate the capacity claimed by the signer. If the claimed capacity is a corporate officer, indicate the title (i.e. CEO, CFO, Secretary). 2015 Version www.NotaryClasses.com 800-873-,9865 • Securely attach this document to the signed document with a staple f 1 e ��.��u w ��.���� a un„„ , �� ,. ,��,,,,, u�yyw, rnia .,�,� ����. „u, uu nm,,, m. .,, ni.m,�m ui,nu io,i uewu n�o��„ au '.we �„ ... ... ... ....... Agreement No. 5747 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Los Angeles On JUN 0 1 before me, Date personally appeared Pietro Micciche Angel Nunez, Notary Public Here Insert Name and Title of the Officer Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the personm whose namew is/XM subscribed to the within instrument and acknowledged to me that h%0(q(X executed the same in his/jQ)Kpftk authorized capacity(*A), and that by his/it oKsignature(o) on the instrument the person(o, or the entity upon behalf of which the persono) acted, executed the instrument. certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my h n official seal. Signature _ T ✓' Signature of Notary Public Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Corporate Officer — Title(s): !171 Partner — I- Limi d El General El Individual , Attorney in Fact I_j Trustee D Guardian or Conservator ❑ Other: Signer Is Representing: Signer's Name: Corporate Officer — Title(s): El Partner — F Limited ❑ General EJ Individual ❑ Attorney in Fact ❑ Trustee C Guardian or Conservator E-1 Other: Signer Is Representing: 02014 National Notary Association • www.NationaiNotary.org • 1 -800 -US NOTARY (1-800-876-6827) Item #5907 Agreement No. 5747 TOK10MARINE R, it It, POWER OF ATTORNEY AMERICAN CONTRACTORS, INDEMNITY COMPANY TEXAS BONDING COMPANY UNITED STATES SURETY COMPANY U.S. SPECIALTY INSURANCE COMPANY KNOW ALL MEN BY THESE PRESENTS., That American Contractors Indemnity Company, a California corporation, Texas Bonding Company, an assumed name of American Contractors Indemnity Company, United States Surety Company, a Maryland corporation and U.S. Specialty Insurance Company, a Texas corporation (collectively, the "Companies"), do by these presents make, constitute and appoint: Patricia Zenizo, Pietro Micciche, Angel Nunez or Elsa Escobar of Gilendale, California its true and lawful Attorney(s)-in-fact, each In their separate capacity if more than one is named above, with full power and authority hereby conferred in its name, place and stead, to execute, acknowledge and deliver any and all bonds, recognizances, undertakings or other instruments or contracts of suretyship to include riders, amendments, and consents of surety, providing the bond penalty does, not exceed *****Five Million"'" Dollars (' ***$5,000,000.O'0*** ), This Power of Attorney shall expire without further action on April 231d, 2022. This Power of Attorney is granted under and by authority of the following resolutions adopted by the Boards of Directors of the Companies: Be it Resolved, that the President, any Vim -President, any Assistant Vice -President, any Secretary or any Assistant Secretary shatl be and Is hereby vested with full power and authority to appoint any one or more suitable persons as Attorney(s)-in-Fact to represent and act for and on behalf of the Company subject to the following provisions,. Attomey-in-Fact may be given full power and authority for and in the name of and on behalf of the Company, to execute, acknowledge and deliver, any and all bonds, recognizances, contracts, agreements or indemnity and other conditional or obligatory undertakings, including any and all consents for the release of retained percentages and/or final estimates on engineering and construction contracts, and any and all notices and documents canceling or terminating the Company's liability thereunder, and any such instruments so executed by any such Attorney -in -Fact shall be binding upon the Company as if signed by the President and sealed and effected by the Corporate Secretary. Be it Resolved, that the signature of any authorized officer and seal of the Company heretofore or hereafter affixed to any power of attorney or any certificate relating thereto by facsimile, and any power of attorney or certificate bearing facsimile signature or facsimile seal shall be valid and binding upon the Company with respect to any bond or undertaking to which it is attached. IN WITNESS WHEREOF, The Companies have caused this instrument to be signed and their corporate seals to be hereto affixed, this 1 11 day of June, 2018. AMERICAN CONTRACTORS INDEMNITY COMPANY !'TEXAS BONDING COMPANY UNITED STATy§&,SURETY,,ZOMPANY Q�.ftr§,PECIA,LTY,,,IN$,URANCE COMPANY 0 k 0 PoA, %N 011491P40, State of California % By: County of Los Angeles 0,Daniel P. Aguilar, Vice President A Notary Public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, , accuracy, or validdy of that document On this 1 1,1 day of June, 2018, before me, Sonia O. Carrejo, a notary public, personally appeared Daniel P. Aguilar, Vice President of American Contractors Indemnity Company, Texas Bonding Company, United States Surety Company and U,S. Specialty Insurance Company who proved to me on the basis of Satisfactory evidence to be the person whose name is subscribed to the within instrument and acknowledged to me that he executed the same in his authorized capacity, and that by, his signature on the instrument the person, or the entity upon behalf ofwhich 'the person acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. a a A a ter. ft. - WITNESS my hand and official seal. , I P. IdAt, (i• Signature _17A, (seal) rypnAp 13, 102a 444 1, Kio Lo, Assistant Secretary VAmerican Contractors Indemnity Company, Texas Bonding Company, United States Surety Company and U.S. Specialty Insurance Company, do hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney, executed by said Companies, which is still in full force and effect: furthermore, the resolutions of the Boards of Directors, set out in the Power of Attorney are in full force and effect. In Witness Whereof, I have hereunto set my hand and affixed the seals of said Companies at Los Angeles, California this 25,41 day of ,IVa X Corporate Seals Bond No. i A Kio Lo, As2bSecretary Agency No. 3057 HCCSMANPOA05/2019 fo:�ir rriu:',ine: information 1. 3. Agreement No. 5747 CONTRACTOR'S LICENSE DECLARATION (Business and Professions Code Section 7028.15) BIDDER'S Contractor's License Number is: i l 3 vs Class No.: The expiration date of BIDDER'S Contractor License is: , 20 A-. BIDDER acknowledges that Section 7028.15(e) of the Business and Professions Code provides as follows: "A licensed contractor shall not submit a bid to a public agency unless his or her contractor's license number appears clearly on the bid, the license expiration date is stated, and the bid contains a statement that representations herein are made under penalty of perjury. Any bid not containing this information, or a bid containing information which is subsequently proven false, shall be considered non-responsive and shall be rejected by the public agency." The undersigned declares, under penalty of perjury, that the representations made by the undersigned in this bid proposal are true and correct. Executed on Jvn -, .20A at Typed Name MM Title Company Name (insert City and State where Declaration signed). I -C-8 Agreement No. 5747 NON -COLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ) ss. County of Les Atj, .AU ' , being first duly sworn, deposes and say that he or she isOf auok'2 Co,'t:�r""k the party making the foregoing bid that the bid is not made in the interest of, or on behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the BIDDER has not directly or indirectly induced or solicited any other BIDDER to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any BIDDER or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the BIDDER has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price of the BIDDER or any other BIDDER, or to fix any overhead, profit, or cost element of the bid price, or of that of any other BIDDER, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay, any fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. Signa re, Typed Name Title I -C-9 Name of Bidder/Company Name Dat. Agreement No. 5747 WORKER'S COMPENSATION CERTIFICATION Section 1861 OF THE LABOR CODE (Workers' Compensation) Pursuant to Section 1861 of the Labor Code, the BIDDER, in submitting his/her PROPOSAL, shall sign the following certification: "I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers' compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the erlormanc the wo of this contract." Signature of Bidder: Title: Business Name: Business Address: Telephone Number: Dated this 9�C M (�a-)�,R -"5 0-1 c5 day ofp, .20 I -C-10 Agreement No. 5747 DESIGNATION OF SUBCONTRACTORS McCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 Company Name: ► ��r°.�;Mr . As detailed in Section 2-3.1 (Page II -B-3) of the City Standard Specifications, Bidder certifies that it has listed below all subcontractors who will perform work in excess of one-half of one percent (0.5%) of the total bid price or certifies that the bidder is fully qualified to perform and will perform that portion of the work itself. I Subcontractor's Contractor Description of Name of Subcontractor �i License No., & Portion of DIR Work Estimated Address Registration No. Subcontracted $ Amount . .. --- _ Street........ ........ _........................ . (Number and ) (CSLB #) (City, Zip Code) ' (DI R #) (Make copies of this page if additional space is needed) Signature of Bidder _ Date I -C-11 Agreement No. 5747 REFERENCES Company Name: r"'`+ The following are the names, addresses, and telephone numbers for public agencies for which BIDDER has performed similar work as the prime contractor or major subcontractor within the past five (5) years: y1. Project Title: � W. ,�w ��„ S � �,.�u� � A " Location: Name and address of owner Name and current telephone number of person familiar with project � t Type of Work: C Contract amount: Date completed: Olt x:31 °..0,t Amount of work done by my/our firm under contract $ 10 1( Orr) Did your firm have any financial interest in Project? 2. Project Title: Il — are Location: r"<c�, LZ C qt kc�'Jp .`4 - 160 6:'Va r c' •;�•.I=.'��r C"OL 2il Name and address of owner Name and current telephone number of person familiar with p p project Type of Work: "`s, Contract amount: $ Ulcl — Date completed: C Amount of work done by my/our firm under contract $ °_ " .3 -K-7 Did your firm have any financial interest in Project? ' cu--- I -C-12 Agreement No. 5747 3. Project Title: Location: Name and address of owner Name and cI �v�r telephone number of personfamiliar with project Type of Work:ACIP, Act LA Contract amount: Date completed:. Amount of work done by my/our firm under contract Did your firm have any financial interest in Project? Y 0' 4. Project Title: Location: Name and address of owner Name and current telephone number of person familiar with project: Type of Work: Contract amount: $ Date completed: Amount of work done by my/our firm under contract $ Did your firm have any financial interest in Project? I -C-13 Agreement No. 5747 5. Project Title: Location: Name and address of owner Name and current telephone number of person familiar with project: Type of Work: Contract amount: $ Date completed: Amount of work done by my/our firm under contract $ Did your firm have any financial interest in Project? Bidder may attach additional reference pages if necessary. The following are the names, addresses, and telephone numbers for all brokers and sureties from whom BIDDER intends to procure insurance bonds: ................. I -C-14 Agreement No. 5747 BIDDER'S STATEMENT OF PAST CONTRACT DISQUALIFICATIONS McCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 Company Name: _. C'tIT�°�. Please state all instances of being disqualified, removed, or otherwise prevented from bidding on, or completing, a federal, state, or local government project due to a violation of a law or safety regulation. 1. Have you ever been disqualified from any government contract? Yes ❑ No 2. If yes, explain the circumstances: 3. Are you registered in accordance with Labor Code § 1725.5 [Note: failure to register requires the City to reject your bid as nonresponsive]? Yes No ❑ r 13i� great -1 Name (Please Print) I -C-15 Agreement No. 5747 INSURANCE REQUIREMENTS [MUST BE SUBMITTED WITH PROJECT PROPOSAL] McCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 Company Name: w(a- run To be awarded this contract, the successful bidder must procure and maintain the following types of insurance with coverage limits complying, at a minimum, with the limits set forth below: Type of hisurance Limits Commercial general liability: $2,000,000 Business automobile liability: $1,000,000 Workers compensation: Statutory requirement Commercial general liability insurance must meet or exceed the requirements of ISO -CGL Form No. CG 00 01 11 85 or 88. The amount of insurance set forth above must be a combined single limit per occurrence for bodily injury, personal injury, and property damage for the policy coverage. Liability policies must be endorsed to name the City, its officials, and employees as "additional insureds" under said insurance coverage and to state that such insurance will be deemed "primary" such that any other insurance that may be carried by the City will be excess thereto. Such endorsement must be reflected on ISO Form No. CG 20 10 11 85 or 88, or equivalent. Such insurance must be on an "occurrence," not a "claims made," basis and will not be cancelable or subject to reduction except upon thirty (30) days prior written notice to the City. Insurer will agree in writing to waive all rights of subrogation against the City, its officers, officials, employees and volunteers for losses arising from work performed by Contractor for the City. Automobile coverage must be written on ISO Business Auto Coverage Form CA 00 01 06 92, including symbol 1 (Any Auto). The Consultant must furnish to the City duly authenticated Certificates of Insurance evidencing maintenance of the insurance required under this Agreement, endorsements as required herein, and such other evidence of insurance or copies of policies as may be reasonably required by the City from time to time. Insurance must be placed with admitted insurers with a current A.M. Best Company Rating equivalent to at least a Rating of "A:VII." Certificate(s) must reflect that the insurer will provide thirty (30) day notice of any cancellation of coverage. The Consultant will require its insurer to modify such certificates to delete any exculpatory wording stating that failure of the insurer to mail written notice of cancellation imposes no obligation, and to delete the word "endeavor" with regard to any notice provisions. The City requires Cali fomia Worker's Compensation Coverage with the associated Waiver. Out-of-state coverage will not be accepted in lieu of the California coverage, because the work is being performed in the State of California. By signing this form, the bidder certifies that it has read, understands, and will comply with these insurance requirements if it is selected as the City's consultant.;lFailuireprovide this insurance will render the bidder's proposal "nonresponsive." Date Biddeir I -C-16 Agreement No. 5747 FAITHFUL PERFORMANCE BOND MCCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 Bond No. 1001096871 Bond Fee: $2,879.00 Premium Based on Final Contract Amount ("PRINCIPAL") Ruiz Concrete & Paving, Inc, and Amerio Contractors Indemnity Company , a corporation incorporated under the laws of the State of Caldorni,a and licensed by the State of California to execute bonds and undertakings as sole surety, as surety ("SURETY"), are held and firmly bound unto the CITY OF EL SEGUNDO ("CITY") in the sum of One Hundred Fifty-nine Thousand Nine Hundred Seventeen And 05/100 ($159,917.05) lawful moncy of the United States, which may be hmcreased or decreased by a rider hereto executed in the same manner as this bond, for the payment of which stun PRINCIPAL and SURETY bind themselves, their successors, and assigns, jointly and severally, by this instrument. PRINCIPAL or SURETY will apply this bond for the faithful performance of any and all of the conditions and stipulations set forth in this bond, SPECIFICATIONS NO. PW 19-10, and the Public Works Contract executed with such Specifications_ In the case of any default in the performance of the conditions and stipulations of this undertaking, it is agreed that PRINCIPAL or SURETY will apply the bond or any portion thereof, to the satisfaction of any damages, reclamation, assessments, penalties, or deficiencies arising by reason of such default. BOND CONDITIONS 1. PRINCIPAL will construct the public improvements identified in SPECIFICATIONS NO. PW 19-10, a copy of which is on file with CITY's Engineering Division ("Public Project"), Such performance will be in accordance with CITY's plans and profiles which are made a part of this bond when said plans and profiles are approved by the City Council and filed with CITY's Engineering Division. CITY has estimated the required amount of the bond as shown above. 2. PRINCIPAL's work on the Public Project will be done in accordance with CITY's plans and specifications and with any permit issued by CITY. Should PRINCIPAL fail to complete all required work within the time allowed, CITY may, at its sole discretion, cause all required work to be done and the parties executing the bond will be firmly bound for the payment of all accessary costs therefor. 3. PRINCIPAL will guarantee its work against any defective work, labor, or materials on the Public Project for a period of one (1) year following the Public Project's I -E_ I Agreement No. 5747 completion and acceptance by CITY. 4. This bond is conditioned upon and guarantees due compliance with all applicable law including, without limitation, the El Segundo Municipal Code ("ESMC"). 5. SURETY, for value received, agrees that no changes, extensions of time, alteration or modification of SPECIFICATIONS NO. PW 19-10 or of the obligation to be performed will in any way affect its obligation on this bond, and it waives notice of any such change, extension of time, alteration or modification of the Contract documents or of the obligation to be performed. 6. This bond consists of this instrument; the plans and specifications identified above; and the following two (2) attached exhibits all of which are incorporated herein by reference: A. A certified copy of the appointment, power of attorney, bylaws or other instrument entitling or authorizing the persons executing this bond to do so; B. A certificate issued by the county clerk for the county in which SURETY's representative is loeated conforming with California Code of Civil Procedure § 995.640 and stating that SURETY's certificate of authority has not been surrendered, revoked, cancelled, annulled, or suspended, or in the event that it has, that renewed authority has been granted; and 7. Should PRINCIPAL perform its obligations within the time allowed, PRINCIPAL's obligation will be void upon the acceptance of the performance by CITY; otherwise this obligation will remain in full force and effect. [SIGNATURES ON FOLLOWING PAGE] I -E-1. Agreement No. 5747 •�wTr^wwr+w'mW>.a., :.o <.w.�a+."'.�q-r. ..:w,-,me<,y. ,. aR:7�a+..*....,�rr-v�ar�,;.--�.*sa+�, ,,.,..�, ����.�,�.,..,.., ���, �.., �M;,� i� rwgtl', a ��m+^+Ym"00."""'p .w � � ��.w�M,,, w�, �ar,nua� �u��MiM! b� � �/oPPo� SIGNED AND S ED ,4 PRINCIPAL's PR EA 1J), Al� "—,SL=, pR PRINCIPAL' yof t r2O 9 . ro Preslj Pietro Micciche, �ittorn y -In -fact SURETY's 6 PRINCIPAL's NWLLNG ADDRESS: SURETY's MAILING ADDRESS: Ruiz Concrete & Paving, Inc. American Contractors Indemnity Company 1344 Temple Avenue 01 Fl u" � Cl Long 13each, Cairfomia 90804 los i�nge as, ornia �� ? N NOTE: (1) Aj,,LAWwtuoes must be adwowledW W a notary Public. Return one (1) origiml to City Cleric's Office. (2) Bond shall be effective for one (1) year after accepuutoe of the job. I-13-3 Certificate pumuent to 996.640(s) Code of Civil Pmeeidure DEAN C. Of �AState of Cain County Clerk of the County LOGAN in and for said County IO HEREBY CERTIFY THAT has a certificate of authorbtb as an admitted surety issued by the California insurance Commissioner autnonzing the insurer to transact surety insurance in the State of California and tnbj oased on the records shown in the Department of Insurances weosrta rnat dutnomy nas not oxen surrendered, revoaeo, canceled, annulled, or susperldeo to Testimatly Whersot, I ri tt"rtW nand and affixed the seal of said County on ! l COUNTY CLERK Deputy County Clerk Agreement No. 5747 Agreement No. 5747 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Los Angeles On _„_AUG 16 2019 before me, Date personally appeared Pietro Micciche Angel Nunez, Notary Public Here Insert Name and Title of the Officer Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the persono whose namew iSW6 subscribed to the within instrument and acknowledged to me that he% ()tWX executed the same in his/)QRDftk authorized capacity(1A), and that by his/IfWM)KtKsignature(0 on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. e WITNESS my Signature Place Notary Sea/ Above Signature of Notary Public OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Corporate Officer — Title(s): Partner —D Limd El General I—! Individual °gym, Attorney in Fact I_:? Trustee L7 Guardian or Conservator El Other: Signer Is Representing: Signer's Name: 0 Corporate Officer — Title(s): 0 Partner — Cil Limited D General ED Individual ❑ Attorney in Fact 0 Trustee 0 Guardian or Conservator Other: Signer Is Representing: 02014 National Notary Association - www.NationalNotary.org - 1 -800 -US NOTARY (1-800-876-6827) Item #5907 Agreement No. 5747 CALIFORNIA ALL- PURPOSE CERT"IFICA"TE OF ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of . L , At ;?Q } On �an M before me, („J � � �cc d sar name an cMe dY (ha d Calli personally appeared A1" who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. NAICaUEL ANGEL RUIZ WITNESS my hand and official seal. "y : m s (*'Conn. LOS ANGELES COUNTY JUNE 3,2020 ry Public Si r (Notary Public Seal) ADDITIONAL OPTIONAL INFORMATION INSTRUCTIONS FOR COMPLETING THIS FORM This form complies with current California statutes regarding notary wording and, DESCRIPTION OF THE ATTACHED DOCUMENT ifneeded, should be completed and attached to the document. Acknowledgments from other states may be completed for documents being sent to that state so long as the wording does not require the California notary to violate California notary law. (Title or description of attached document) • State and County information must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. • Date of notarization must be the date that the signer(s) personally appeared which (Title or description of attached document continued) must also be the same date the acknowledgment is completed. • The notary public must print his or her name as it appears within his or her Number of Pages Document Date commission followed by a comma and then your title (notary public). • Print the name(s) of document signer(s) who personally appear at the time of notarization. CAPACITY CLAIMED BY THE SIGNER • Indicate the correct singular or plural forms by crossing off incorrect forms (i.e. he/she/dhey— is /are ) or circling the correct forms. Failure to correctly indicate this ❑ Individual (s) information may lead to rejection of document recording. ❑ Corporate Officer • The notary seal impression must be clear and photographically reproducible. Impression must not cover text or lines. If seal impression smudges, re -seal if a (Title) sufficient area permits, otherwise complete a different acknowledgment form. ElPartner(s) • Signature of the notary public must match the signature on file with the office of the county clerk. ❑ Attorney -in -Fact le Additional information is not required but could help to ensure this ❑ Trustee(s) acknowledgment is not misused or attached to a different document. Other Indicate title or type of attached document, number of pages and date. ❑ •• Indicate the capacity claimed by the signer. If the claimed capacity is a corporate officer, indicate the title (i.e. CEO, CFO, Secretary). 2015 Version wuvvw.NoiaiyClassps.com 800-873 9865 • Securely attach this document to the signed document with a staple. II HTq,It �!q,MARINE IC Agreement No. 5747 POWER OF ATTORNEY AMERICAN CONTRACTORS INDEMNITY COMPANY TEXAS BONDING COMPANY UNITED STATES SURETY COMPANY U.S. SPECIALTY INSURANCE COMPANY KNOW ALL MEN BY THESE PRESENTS: That American Contractors Indemnity Company, a California corporation, Texas Bonding Company, an assumed name of American Contractors Indemnity Company, United States Surety Company, a Maryland corporation and U.S. Specialty Insurance Company, a Texas corporation (collectively, the "Companies"), do by these presents make, constitute and appoint: Patricia Zenizo, Pietro Micciche:, Angel Nunez or Elsa Escobar of Glendale, California Its true and lawful Attorney(s)-in-fact, each in their separate capacity if more than one is named above, with full power and authority hereby conferred in its name, place and stead, to execute, acknowledge and deliver any and all bonds, recognizances, undertakings or other instruments or contracts of suretyship to Include riders, amendments, and consents of surety, providing the bond penalty does not exceed "'Five Million""' Dollars f `$5,000,000-00' ). This Power of Attorney shall expire without further action on April 231d, 2022. This Power of Attorney is granted under and by authority of the following resolutions adopted by the Boards of Directors of the Companies: Be it Resolved, that the President, any Vice -President, any Assistant Vice -President, any Secretary or any Assistant Secretary shall be and is hereby vested with full power and authority to appoint any one or more suitable persons as Attorney(s)-in-Fact to represent and act for and on behalf of the Company subject to the following provisions: Attorney -in -Fact may be given full power and authority for and in the name of and on behalf of the Company, to execute, acknowledge and deliver, any and all bonds, recognizances, contracts, agreements or indemnity and other conditional or obligatory undertakings, including any and all consents for the release of retained percentages and/or final estimates on engineering and construction contracts, and any and all notices and documents canceling or terminafing the Company's liability thereunder, and any such Instruments so executed by any such Attorney -in -Fact shall be binding upon the Company as if signed by the President and sealed and effected by the Corporate Secretary, Be it Resolved, that the signature of any authorized officer and seat of the Company heretofore or hereafter affixed to any power of attorney or any certificate relating thereto by facsimile, and any power of attorney or certificate bearing facsimile signature or facsimile seal shall be valid and binding upon the Company with respect to any bond or undertaking to which it is attached. IN WITNESS WHEREOF, The Companies have caused this instrument to be signed and their corporate seals to be hereto affixed, this 111 day of June, 2018. AMERICAN CONTRACTORS INDEMNITY COMPANY TEXAS BONDING COMPANY' UNITED STA,�,T,�SSURETY,404 4,�IN!, .IPANY JUapd,, FEC 14,� UIRANCE COMPANY 4ZO CA State of California ot w County of Los Angeles By: Daniel P, Aguilar, Vice President A Notary Public or other officer completing this certificate, verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that, document I On this 111 day of June, 2018, before me, Sonia O. Carrejo, a notary public, personally appeared Daniel P. Aguilar, Vice President of American Contractors Indemnity Company, Texas Bonding Company, United States Surety Company and U.S. Specialty Insurance Company who proved to me on the basis of satisfactory evidence to be the person whose name is subscribed to the within instrument and acknowledged to me that he executed the same in his authorized capacity, and that by his signature on the instrument the person, or the entity upon behalf of which the person acted, executed the instrument, I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct, WITNESS my hand and official seal, RMIAO.CARREJO thA Notary Pubtic - calftmtd 111,111 -1 Los Amjf¢q% ta�rdy Signature (seal) #Aytomm. bor 41 Apr 1), �0 2 2 1, Kio Lo, Assistant Secretary American Contractors Indemnity Company, Texas Bonding Company, United States Surety Company and U.S. Specialty Insurance Company, do, hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney, executed by said Companies, which is still in full force and effect, furthermore, the resolutions of the Boards of Directors, set out in the Power of Attorney are in full force and effect. IIn Witness Whereof, I have hereuntoset my hand and affixed the seals of said Companies at Los Angeles, California this I bAk day of, A uOus + Corporate Seals Ao.:.Jvo,'% Bond No. 100 10 C1 6,S7 F0 kw" A It �,4,ry„nl Klo Lo, A Agency No. 3057 ssi&secretary HCCSMANPOA05/2019 ni(;re((:(formaton Agreement No. 5747 LABOR AND MATERIALS BOND MCCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 Bond No. 1001096871 Bond Fee: Included in Performance Bond Ruiz Concrete & Paving, Inc. gas principal ("PRINCIPAL") and American Contractors Indemnity Company a corporation incorporated under the laws of the State of Ca&mia and licensed by the State of California to execute bonds and undertakings as sole surety, as surety ("SURETY"), are held and firmly bound unto the CITY OF EL SEGUNDO ("CITY") in the sum of One Hundred Fifty-nine Thousand Nine Hundred Seventeen And 05/100 ($159,917.05) lawful money of the United States, which may be increased or decreased by a rider hereto executed in the same manner as this bond, for the payment of which sum PRINCIPAL: and SURETY bind themselves, their successors, and assigns, Jointly and severally, by this instrument. This bond is conditioned upon and guarantees payment by PRINCIPAL to Contractors, Subcontractors, and persons renting eyuiptnent; payment by PRINCIPAL and all PRINCIPAL'S Subcontractors for all materials. provisions, provender, or other supplies, and equipment used in, upon, for or about the performance of the work contemplated in FY 18/19 SLURRY SEAL PROJECT, SPECIFICATIONS NO. PW 19-10 ("Public Project"), the Public Works Contract executed for such Public Project, and for all work or labor of any kind performed for the Public Project. In the case of any default in the performance of the conditions and stipulations of this undertaking, it is agreed that PRINCIPAL or SURETY will apply the bond or any portion thereof, to the satisfaction of any damages. reclamation, assessments, penalties, or deficiencies arising by mason of such default - BOND CONDITIONS 1. PRINCIPAL will construct the public improvements identified in SPECIFICATIONS NO. PW 19-10, and the Public Works Contract executed for such Specifications, copies of which is on file with CITY's Fi*necring Division ("Public Project'). Such performance will be in accordance with CITY's plans and profiles which are made a pure of this bond when said plans and profiles are approved by the City Council and filed with CITY's Engineering Division_ equipment PRINCIPAL will pay all Contractors, Subcontractors, and persons renting I -F- I Agreement No. 5747 3. PRINCIPAL will pay for all materials and other supplies, for equipment used in, on, for or about the performance of the Public Project, and will pay for all work and labor thereon. 4. This bond is conditioned upon and guarantees due compliance with all applicAhle law including, without limitation, the E1 Segundo Municipal Code ("SSMC"). 5. SURETY, for value received, agrees that no changes, extensions of time, alteration or modification of SPECIFICATIONS NO. PW 19-10, or of the obligation to be performed will in any way affect its obligation on this bond, and it waives notice of any such change, extension of time, alteration or modification of the Contract documents or of the obligation to be performed. 6. This bond consists of this instrument; the plans and specifications identified above; and the following TWO (2) attached exhibits all of which are incorporated herein by reference: A. A certified copy of the appointment, power of attorney, bylaws or other instrument entitling or authorizing the persons executing this bond to do so; and & A certificate issued by the county clerk for the county in which SURETY's representative is located conforming with California Code ofCivil Procedure 995.640 and stating that SURETY's certificate of authority has not been surrendered, revoked, cancelled, annulled, or suspended, or in the event that it has, that renewed authority has been granted. 7. Should PRINCIPAL perform its obligations within the time allowed, PRINCIPAL's obligation will be void upon the acceptance of the performance. by CITY; otherwise this obligation will remain in full force and effect. (SIGNATURES ON FOLLOWING PAGE] I -F-2 SIGNED AND S Al, `:D. thi PRINCIPAL'S PRESIDEN PRINCIPAL's-91!"1 r'FI`` - day of August Agreement No. 5747 2 9 /--� e -1-11C_-_-1> r " ° '1°ietro ll icckhe, Attomey-lig-Fact SURETY'r. PRINCIPAL's MAILING ADDRESS: SURETY's MAILING ADDRESS: Ruiz oncrele & PwAnq„ Inc, AmeriQm Car�aa9r 4er ty Cqm—snY 1344 TetnDle Avenue A AS. ngeles, � t. Suite 700 1.o Beach, a1itornra 908134 a ilomiiFW61 " NOTE- (1) ALL signatures must be acknowledged by a notary public. Return one ( I) original to City Clerk's Office. (2) Bond shall be effective for one (1) year after acceptance of the job. 1-F-3 Agreement No. 5747 CALIFORNIA ALL-PURPOSE ACKNOWLEDGEMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California } County of Los Angeles ) On A UG 16 20 l 19 before me, Angel Nunez, Notary Public Date Here insert Name and Title of the Officer personally appeared Pietro Micciche Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the personN whose name0o is/X06 subscribed to the within instrument and acknowledged to me that heNNq&M, executed the same in his/)Q)KAtMk authorized capacity(M), and that by histo signature(aj on the instrument the person(g), or the entity upon behalf of which the person) acted, executed the instrument. certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature , Signature of tary P Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: E-1 Corporate Officer — Title(s): El Partner — I.:... Liml d ❑ General 0Individual I ,� Attorney in Fact 1 J Trustee [D Guardian or Conservator C! Other: Signer Is Representing: Signer's Name: C 1 Corporate Officer — Title(s): El Partner — I..] Limited ❑ General F:::1 Individual 0 Attorney in Fact ❑ Trustee ❑ Guardian or Conservator 1:= :l Other: Signer Is Representing: 02014 National Notary Association • www.NationaiNotary.org • 1 -800 -US NOTARY (1-800-876-6827) Item #5907 U Agreement No. 5747 4 CALIFORNIA ALL- PURPOSE CERTIFICATE OF ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California } County of Lt } On 9 before me, g ere irtsor name area tuode at a(ra x tlto rt personally a ,A---1 p Y eared p p .... #c, I� who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. I It 19 -L rl!W L I UI WITNESS my hand and official seal. w �tM IIOTARYINlN LOS ANGELES COUNTY Comm. Exp, JUNE 3, 2020" ?4<blic Signature (Notary Public Seal) ADDITIONAL OPTIONAL INFORMATION INSTRUCTIONS FOR COMPLETING THIS FORM This form complies with current California stamtes regarding notary wording and, DESCRIPTION OF THE ATTACHED DOCUMENT if rpe`+ r'rdi shouhl be coinpleted and attac•1' ed to the Arai mesa Acknowledgmesits from other states maybe completed, far documents being .sent to that stater so long �I as the wording does not require the California notary to violate California notary - law. (Title or description of attached document) • State and County information must be the State and County where the document signer(s) personally appeared before the notary public for acknowledgment. mm • Date of notarization must be the date that the signer(s) personally appeared which (Title or description of attached document continued) must also be the same date the acknowledgment is completed. • The notary public must print his or her name as it appears within his or her Number of Pages Document Date commission followed by a comma and then your title (notary public). • Print the name(s) of document signer(s) who personally appear at the time of notarization. CAPACITY CLAIMED BY THE SIGNER • Indicate the correct singular or plural forms by crossing off incorrect forms (i.e. he/she/Eke);- is /are ) or circling the correct forms. Failure to correctly indicate this ❑ Individual (s) information may lead to rejection of document recording. ❑ Corporate Officer • The notary seal impression must be clear and photographically reproducible. Impression must not cover text or lines. If seal impression smudges, re -seal if a (Title) sufficient area permits, otherwise complete a different acknowledgment form. El Partner(s) • Signature of the notary public must match the signature on file with the office of the county clerk. ❑ Attorney -in -Fact Additional information is not required but could help to ensure this ❑ Trustee(s)acknowledgment is not misused or attached to a different document. -I Other Indicate title or type of attached document, number of pages and date. ❑ Indicate the capacity claimed by the signer. If the claimed capacity is a corporate officer, indicate the title (i.e. CEO, CFO, Secretary). 2015 Version t avvw.Not.aryCltxsses. ca m 800-873-9865 • Securely attach this document to the signed document with a staple. 1 a, Agreement No. 5747 M TO 10 MARL NE POWER OF ATTORNEY AMERICAN CONTRACTORS INDEMNITY COMPANY TEXAS BONDING COMPANY UNITED STATES S'U'RETY COMPANY U.S. SPECIALTY INSURANCE COMPANY KNOW ALL MEN BY THESE PRESENTS: That American Contractors Indemnity Company, a California corporation, Texas Bonding Company, an assumed name of American Contractors Indemnity Company, United States Surety Company, a Maryland corporation and U.S. Specialty Insurance Company, a Texas corporation (collectively, the "Companies"), do by these presents make, constitute and appoint. Patricia Zenizo, Pietro Micciche, Angel Nunez or Elsa Escobar of Glendale, California its true and lawful Attorney(s)-in-fact,' each in their separate capacity if more than one is named above, with full power and authority hereby conferred in its name, place and stead, to execute, acknowledge and deliver any and all bonds, recognizances, undertakings or other instruments or contracts of suretyship to include riders, amendments, and consents of surety, providing the bond penalty Power Attorney shall expire without further action on April Million`** ,Dollars Five M �� �Ut7130g.1)1�+�� Y p. p " ��'�, 2I12�'. This Power of Attorney is granted under and by authority of the following resolutions adopted by the Boards of Directors of the Companies: Be it Resolved, that the President, any Vice -President, any Assistant Vice -President, any Secretary or any Assistant Secretary shall be and is hereby vested with full power and authority to appoint any one or more suitable persons as Attorney(s)-in-Fact to repr'esen't and act for and on behalf of the Company subject to the following provisions: Attorney -in -Fact may be given full power and authority for and in the name of and on behalf of the Company, to execute, acknowledge and deliver„ any and all bonds, reco,gnizances, contracts, agreements or indemnity and other conditional or obligatory undertakings, including any and all consents for the release of retained percentages and/or final estimates on engineering and construction contracts, and any and all notices and documents canceling or terminating the Company's liability thereunder, and any such instruments so executed by any such Attorney -Mn -Fact shall be binding upon the Company as if signed by the President and sealed and effected by the Corporate Secretary. Be it Resolved, that the 'signature of any authorized' officer and seal of the Company heretofore or hereafter affixed to any power of attorney or any certificate relating thereto by facsimile, and any power of attorney or certificate bearing facsimile signature' or facsimile seal shall be valid and binding upon the Company with respect to any bond or undertaking to which it is attached. IN WITNESS WHEREOF, The Companies have caused this instrument to be signed and their corporate seals to be hereto affixed, this 1s' day of June, 2018. AMERICAN CONTRACTORS INDEMNITY COMPANY 'TEXAS BONDING COMPANY � - ; � �CO,' P IJ tit, tIRAN COMPANY UNITED S SURETY fjJJPANYS + ECIA W n California " ,, s a sC �,�� fir, 1. l� :P—nno ®�1i F r✓ M ,fix w^� .. 4 te Coaunt of of Los Angeles » r t°;{1Y.,T „, WN, By. Y 9 r Daniel P. Aguilar, Vice President i A (Votary Public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document On this 11' day of June, 2018, before me, Sonia O. Carrejo, a notary public, personally appeared Daniel P. Aguilar, "dice President of American Contractors Indemnity Company, Texas Bonding Company, United States Surety Company and US. Specialty Insurance Company who proved to me on the basis of satisfactory evidence to be the person whose name is subscribed to the within instrument and acknowledged to me that he executed the same in his authorized capacity, and that by his signature on the instrument the person, or the entity upon behalf of which the person acted, executed the instrument. I certify under PENALTY OF PERJURY' under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal.« r+c UO.CARA MsdA" ` laAyCamsm. lyaaN,�,�edswl„uvwnitY 't LperwnM,est"z Y �ig7� n Signature ' (seal) a�w r>x��'as„saa I, Kio Lo, Assistant Secretary American Contractors Indemnity Company, Texas Bonding Company, United States Surety Company and U.S. Specialty Insurance Company, do hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney, executed by said Companies, which is still in full force and effect; furthermore, the resolutions of the Boards of Directors, set out in the Power of Attorney are in full force and effect. In Witness Whereof„ I ave hereunto set my hand and affixed the seals of said Companies at Los Angeles, California this P b 4ln day of _7_0 1.1._.... m6Wq ren% ' 0.A a� ��u ^'000+in�rvnur �� ni d r r Corporate SealsIle, esus. as. sats ?'"r^'-�..,, ��# 3p aw d, Bond No. 10 1 N n � ' � l t ...,�....� w rR.dl'`r o.,. ,,,, e+ n� ruin nuin 'tl n M @o Agency No. 3057 m A w+„ �� �a,l,C' yd' v1 f ICIo Lo, Assl Se'oretary HCCSMANPOA05/2019 visit tri i c.comisurety for more information Agreement No. 5747 1 It CONTRACT DOCUMENTS PLANS & SPECIFICATIONS FOR McCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 PUBLIC WORKS DEPARTMENT ENGINEERING DIVISION 350 MAIN STREET EL SEGUNDO, CA 90245 310-524-2300 http://www.elsegundo.org/depts/works/bids rfps.asp http://www.elsegundo.org/depts/works/proj ect_request_contact_form.asp MANDATORY PRE-BID MEETING MONDAY, JUNE 17, 2019 AT 10 AM IN CITY HALL COUNCIL CHAMBERS 350 MAIN STREET EL SEGUNDO, CA 90245 BADS DUE TUESDAY, JUNE 25, 2019 AT 11:00 AM Agreement No. 5747 BIDS WILL BE RECEIVED UP TO THE HOUR OF 11:00 A.M. TUESDAY, JUNE 25, 2019 IN THE OFFICE OF THE CITY CLERK CITY HALL 350 MAIN STREET EL SEGUNDO, CALIFORNIA 90245 AT WHICH TIME THEY WILL BE PUBLICLY OPENED Agreement No. 5747 SPECIAL INSTRUCTIONS TO CONTRACTORS Contractors are required to review section 7-3 of the STANDARD SPECIFICATIONS, pages II -B-25 thru II -B-26 "LIABILITY INSURANCE". ONLY CONTRACTORS ABLE TO OBTAIN AND FURNISH THE REQUIRED COVERAGE AND ENDORSEMENT "ISO" FORMS SHOULD CONSIDER SUBMITTING A BID PACKAGE. The Contractor will be required to apply and obtain an Encroachment Permit from the City Public Works Department as well as any applicable Building/Safety Permit from the City Building Planning and Building Safety Department. The permits will be issued on a "no -fee" basis. The Contractor shall be responsible for calling the Building Safety Division for inspections. All noted deficiencies shall be corrected by the contractor. The project will not be accepted as complete until the contractor obtains a final sign -off from the Department of Planning and Building Safety. Agreement No. 5747 TABLE OF CONTENTS SECTION I — LEGAL A. NOTICE INVITING SEALED BIDS B. BIDDING INSTRUCTIONS I. DEFINITION 2. BIDDER'S REPRESENTATIONS 3. BIDDING DOCUMENTS 4. INTERPRETATION OR CORRECTION OF BIDDING DOCUMENTS 5. PRODUCT SUBSTITUTIONS 6. SUBCONTRACTORS 7. ADDENDA 8. PRE-BID CONFERENCE 9. FORM AND STYLE OF BIDS 10. BID SECURITY 11. MODIFICATION OR WITHDRAWAL OF BID 12. OPENING OF BIDS 13. REJECTION OF BIDS 14. AWARD C. PROPOSAL 1. PROPOSAL, FIRST PAGE 2. BID SCHEDULES a. BASE BID 3. BIDDER'S INFORMATION 4. BIDDER AND NOTARIAL ACKNOWLEDGEMENT 5. PROPOSAL GUARANTEE BID BOND 6. CONTRACTOR'S LICENSE DECLARATION 7. NON -COLLUSION AFFIDAVIT 8. WORKER'S COMPENSATION CERTIFICATION 9. DESIGNATION OF SUBCONTRACTORS 10. REFERENCES 11. BIDDER'S STATEMENT OF PAST DISQUALIFICATIONS 11. INSURANCE REQUIREMENTS D. CITY OF EL SEGUNDO PUBLIC WORKS CONTRACT E. FAITHFUL PERFORMANCE BOND PAGE I -A-1 TO A-3 I -B-1 TO B-8 I -B-1 I -B-1 I -B-2 I -B-2 I -B-3 I -B-3 I -B-3 I -B-3 I -B-4 I -B-5 I -B-6 I -B-6 I -B-6 I -B-6 I -C-1 TO C-17 I -C-1 I -C-3 I -C-3 I -C-4 I -C-6 I -C-7 I -C-8 I -C-9 I -C-10 I -C-11 I -C-12 I -C-15 I -C-16 I -D-1 TO D-5 I -E-1 TO E-3 F. MATERIAL AND LABOR BOND I -F-1 TO F-3 SECTION II - GENERAL REQUIREMENTS A. GENERAL SPECIFICATIONS 1. REGISTRATION OF CONTRACTORS 2. INSURANCE AND CITY BUSINESS LICENSE 3. EMERGENCY INFORMATION 4. FURNISHING OF WATER 5. CALIFORNIA - OCCUPATIONAL SAFETY AND HEALTH ADMINISTRATION 6. SOUND CONTROL 7. AIR POLLUTION CONTROL 8. WORKER UNIFORMS B. STANDARD SPECIFICATIONS Agreement No. 5747 PAGE II -A -I TO A-2 II -A-1 II -A-1 II -A-1 II -A-1 II -A-1 II -A-2 II -A-2 II -A-2 II -B-1 TO B-34 0-1 STANDARD SPECIFICATIONS 0-2 NUMBERING OF SECTIONS 0-3 MODIFICATIONS 1-2 DEFINITIONS 1-2.1 ADDITIONAL DEFINITIONS 1-3 ABBREVIATIONS 2-0 SCOPE AND CONTROL OF WORK 2-1.1 ACCESS TO PROJECT SITE 2-1.2 OWNERSHIP AND USE OF CONTRACT DOCUMENTS 2-3 SUBCONTRACTS 2-3.1 GENERAL 2-3.2 ADDITIONAL RESPONSIBILITY 2-4 CONTRACT BONDS 2-5 PLANS AND SPECIFICATIONS 2-5.1 GENERAL 2-5.2 PRECEDENCE OF CONTRACT DOCUMENTS 2-5.5 ACCURACY OF PLANS AND SPECIFICATIONS 2-8 RIGHT-OF-WAY 2-8.1 ADDITIONAL WORK AREAS AND FACILITIES 2-9 SURVEYING 2-9.3 SURVEY SERVICE 2-9.3.1 CONSTRUCTION SURVEYING 2-9.3.2 MEASUREMENT AND PAYMENT 3-3.2.2 BASIS FOR ESTABLISHING COSTS 3-3.2.3 MARK UP it II -B-3 II -B-3 II -B-4 II -B-4 II -B-5 II -B-5 II -13-5 II -B-6 I1 -B-6 II -B-6 II -B-6 II -B-6 II -B-6 II -B-7 II -B-7 II -B-7 Agreement No. 5747 SECTION II — GENERAL REQUIREMENTS (Continued) 3-3.3 DAILY REPORTS BY CONTRACTOR 3-4 CHANGED CONDITIONS 3-5 DISPUTED WORK 4-1.3 INSPECTION REQUIREMENTS 4-1.3.1 GENERAL 4-1.3.2 INSPECTION OF MATERIALS NOT PRODUCED LOCALLY 4-1.6 TRADE NAMES OR EQUALS 5-2 PROTECTION 5-2.1 INCORRECT LOCATION OF UTILITIES 5-4 RELOCATION 5-4.1 RESPONSIBILITY OF UTILITY REMOVAL OR RELOCATION 5-5 DELAYS 5-5.1 CALCULATING IDLE TIME 6-1 CONSTRUCTION SCHEDULE AND COMMENCEMENT OF WORK 6-1.1 CONTRACT SCHEDULE 6-1.2 CONTENT OF CONTRACT SCHEDULE 6-1.3 EFFECT OF CONTRACT SCHEDULE 6-1.4 COMMENCEMENT OF CONTRACT TIME 6-4 DEFAULT BY CONTRACTOR 6-4.1 GENERAL 6-4.2 TERMINATION OF CONTRACTOR'S CONTROL OVER THE WORK 6-4.3 SURETY'S ASSUMPTION OF CONTROL 6-6 DELAYS AND EXTENSIONS OF TIME 6-6.1 GENERAL 6-6.2 EXTENSION OF TIME 6-6.3 PAYMENT FOR DELAYS TO CONTRACTOR 6-6.4 WRITTEN NOTICE AND REPORT 6-7.2 WORK DAYS AND WORKING HOURS 6-7.4 NIGHT WORK 6-7.5 WEEKEND AND HOLIDAY WORK 6-8 COMPLETION AND ACCEPTANCE 6-8.1 GENERAL GUARANTY 6-9 LIQUIDATED DAMAGES 6-9.1 FAILURE TO COMPLETE WORK ON TIME 6-11 DISPUTES AND CLAIMS; PROCEDURE 6-11.1 GENERAL 6-11.2 FORM PAGE II -B-8 II -B-8 II -B-9 II -B-9 II -B-9 II -B-10 II -B-12 II -B-12 II -B-13 II -B-14 II -B-14 II -B-14 II -B-14 Agreement No. 5747 SECTION II — GENERAL REQUIREMENTS (Continued) 6-11.3 CLAIMS SUBMITTED TO ENGINEER 6-11.4 CLAIMS IS PREREQUISITE TO OTHER REMEDY 6-11.5 DECISION ON CLAIMS 6-11.6 APPEAL OF ENGINEER'S DECISION 6-11.7 MEDIATION 6-11.8 ARBITRATION 6-11.9 WHEN ARBITRATION DECISION BECOMES BINDING 6-11.10APPEAL TO SUPERIOR COURT; WAIVER OF JURY TRIAL 7-2 LABOR 7-2.3 PREVAILING WAGES 7-2.4 RECORD OF WAGES PAID; INSPECTION 7-3 LIABILITY INSURANCE 7-3.1 GENERAL 7-3.2 INDEMNIFICATION AND DEFENSE 7-5 PERMITS 7-8.1 CLEAN UP AND DUST CONTROL 7-8.1.1 GENERAL 7-8.1.2 WATERING 7-8.6 WATER POLLUTION CONTROL 7-9 PROTECTION AND RESTORATION OF EXISTING IMPROVEMENTS 7-10 PUBLIC CONVENIENCE AND SAFETY 7-10.1 TRAFFIC AND ACCESS 7-10.2 STREET CLOSURES, DETOURS, BARRICADES 7-10.5 PROTECTION OF THE PUBLIC 7-15 HAZARDOUS MATERIAL 9-2 LUMP SUM WORK 9-3.2 PARTIAL AND FINAL PAYMENTS 9.3.3 DELIVERED MATERIALS 100-1 TERMINATION OF AGENCY LIABILITY iv PAGE II -B-20 II -B-21 II -B-21 II -B-21 II -B-22 II -B-22 II -B-22 II -B-22 II -B-23 II -B-23 II -B-24 II -B-24 II -B-24 II -B-27 II -B-28 II -B-28 II -B-28 II -B-28 II -B-28 II -B-29 II -B-30 II -B-30 II -B-30 II -B-31 II -B-31 II -B-32 II -B-33 II -B-34 II -B-34 Agreement No. 5747 SECTION III — SPECIAL PROVISIONS PAGE 1-0 GENERAL SCOPE, TIME FOR COMPLETION v AND LOCATION OF WORK III -A -I 2-0. NOTIFICATIONS III -A-2 3-0. STANDARDS III -A-3 4-0. EXAMINATION OF JOB SITE III -A-3 5-0. INSPECTION III -A-3 6-0. USE OF PRIVATE PROPERTY III -A-3 7-0. STORAGE OF MATERIALS AND EQUIPMENT III -A-4 8-0. CENTERLINE TIES III -A-4 9-0. QUALITY ASSURANCE III -A-4 SECTION IV — MEASUREMENT AND PAYMENT PAGE 1-0. GENERAL IV -A -I 2-0. BID ITEMS IV -A-1 3-0. PAYMENT OF ANY CHANGE ORDERS IV -A-3 4-0. PROGRESS PAYMENT IV -A-4 SECTION V — TECHNICAL SPECIFICATIONS PAGE 1-0. MOBILIZATION V -A -I 24 NOTIFICATION V -A-2 34 TRASH PICKUP, STREET SWEEPING, AND V -A-2 MAIL DELIVERIES 4-0. STORM DRAIN PROTECTION V -A-3 5-0. EXCAVATION V -A-3 6-0. REMOVAL OF EXISTING CONCRETE V -A-3 7-0. REPLACEMENT OF DAMAGE TO EXISTING V -A-4 FACILITIES 8-0, REPLACE CURB ONLY OR REPLACE V -A-4 CURB AND GUTTER 9-0. REPLACE SIDEWALK V -A-5 10-0. REPLACE DRIVEWAY APPROACH V -A-5 11-0. REPLACE ADA RAMPS V -A-6 12-0. WASHING OF CONCRETE TRANSIT MIXERS V -A-7 13-0. CUT TREE ROOTS V -A-7 14-0. ASPHALT SLOT PAVING V -A-7 15-0. SURFACE RESTORATION V -A-8 16-0. STRIPING V -A-8 17-0. TRAFFIC CONTROL V -A-8 v Agreement No. 5747 SECTION VI - APPENDICES 1. CITY MAP 2. TYPICAL NO PARKING SIGN — EL SEGUNDO STANDARD ST -18 3. STREET SWEEPING SCHEDULE 4. TRASH HAULING SCHEDULE 5. CENTERLINE TIE INFORMATION 6. PROJECT PLANS vi Agreement No. 5747 NOTICE INVITING SEALED BIDS FOR THE McCARTHY COURT STREET IMPROVEMENTS PROJECT IN THE CITY OF EL SEGUNDO PROJECT NO.: PW 19-10 The City of El Segundo is accepting sealed bids in the City Clerk's office, 350 Main Street, El Segundo, California 90245, until 11:00 a.m. on: TUESDAY, JUNE 25, 2019 at which time they will be publicly opened. Bids will not be accepted after that time. As described in the Bidding Documents, the bids are for a public works project ("Project") which consists of removal of problem trees, removal of curb and replacement with curb and gutter, removal and replacement of sidewalk, driveway approaches, and asphalt pavement as shown on the plans on file with the City's Public Works Department. Work on the Project must be performed in strict conformity with Specifications No. PW 19-10 as adopted by the El Segundo City Council on April 16, 2019 which is filed with the Public Works Department. Contractors bidding the project shall provide a minimum of five municipal references for building same or similar projects (in terms of scope, size, type, magnitude and complexity) for municipalities or entities of similar size and structure, as the prime contractor or major subcontractor in the past five (5) years. Bidders shall include City references, etc. to demonstrate qualification. Copies of the Plans, Specifications, Contract Documents and Engineer's estimate are available from the Engineering Division of the Public Works Department, City of El Segundo, 350 Main Street, El Segundo, California, 90245. Plans And Specifications are alternately available electronically via http://www.elsegundo.org/depts/works/project_request_contact form.asp A MANDATORY pre-bid meeting is scheduled for Monday, June 17, 2019, at 10:00 AM at the Council Chambers room of City hall at 350 Main St., El Segundo, CA 90245 and then proceeding to the project site. Failure to attend the mandatory meeting will disqualify your bid. All questions regarding the project are due to http://www.elsegundo.org/depts/works/project_request_contact_form.asp by Tuesday, June 18, 2019, at 4:00 pm. The terms and conditions for bidding on the Project are described in the attached Bidding Instructions. This project requires payment of State prevailing rates of wages for Los Angeles County. The contractor must post copies of the prevailing schedule at each job site. Copies of these rates of wages are available from the State of California Department of Industrial Relations Prevailing I -A-1 Agreement No. 5747 Wage Unit, Telephone No. (415) 703-4774. The website for this agency is currently located at www.dir.ca.gov. Note that the Project is subject to compliance monitoring and enforcement by California Department of Industrial Relations. Pursuant to California law, the City must find bids failing to comply with all applicable Labor Code requirements including, without limitation, Labor Code §§ 1725.5 and 1771.4 to be nonresponsive. The contractor to whom the contract is awarded must assist in locating, qualifying, hiring and increasing the skills of minority group employees and applicants for employment, as set forth in Executive Order 11246 and 11375. Any contract entered into pursuant to this notice will incorporate the provisions of the State Labor Code. Compliance with the prevailing rates of wages and apprenticeship employment standards established by the State Director of Industrial Relations will be required. Affirmative action to ensure against discrimination in employment practices on the basis of race, color, national origin, ancestry, sex, or religion will also be required. The City of El Segundo hereby affirmatively ensures that minority business enterprises will be afforded full opportunity to submit bids in response to this notice and will not be discriminated against on the basis of race, color, national origin, ancestry, sex, or religion in any consideration leading to the award of contract. Five percent (5%) will be deducted from each progress payment and retained by the City. The remainder less the amount of all previous payments will be paid to the Contractor. Pursuant to Public Contracts Code ("PCC") § 22300, the Contractor may substitute securities for retention monies held by the City or request that the City place such monies into an escrow account. The Contractor is notified, pursuant to PCC § 22300, any such election will be at the Contractor own expense and will include costs incurred by the City to accommodate the Contractor's request. In entering into a Public Works contract, or a subcontract, to supply goods, services, or materials pursuant to a public works contract, the Contractor, or Sub -Contractor, offers and agrees to assign to the awarding body all rights, title and interest in, and to, all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Section 15) or under the Cartwright Act (Chapter 2 [commencing with Section 16700] of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of goods, services, or materials pursuant to the public works contract or the subcontract. This assignment shall be made and become effective at the time the awarding body tenders final payment to the Contractor, without further acknowledgment by the parties. Bids must be prepared on the approved Proposal forms in conformance with the Instructions to Bidders and submitted to the City Clerk, 350 Main Street, City of El Segundo, in a sealed envelope plainly marked on the outside: NEW Agreement No. 5747 McCARTHY COURT STREET IMPROVEMENTS PROJECT "SEALED BIDS FOR PROJECT NO.: PW 19-10 IN THE CITY OF EL SEGUNDO DO NOT OPEN WITH REGULAR MAIL" The bid must be accompanied by a bid bond, made payable to the City of El Segundo for an amount no less than ten percent (10%) of the amount bid for the base contract. No bid will be accepted from a Contractor who has not been licensed in accordance with the provisions of the State Business and Professions Code. For these projects, those acceptable classes of license shall be "A" or "C-12". The successful Contractor and his Sub -Contractors will be required to possess the correct license for their project classifications, and valid City Business Licenses from the City of El Segundo. The City of El Segundo reserves the right to reject any or all bids, to waive any irregularity, and to take all bids under advisement for a period of ninety (90) calendar days. Any contract entered into pursuant to this notice shall become effective or enforceable against the City of El Segundo only when the formal written contract has been duly executed by the appropriate officer(s) of the City of El Segundo. DATED this day of 2019. CITY OF EL SEGUNDO, CALIFORNIA Tracy Weaver, City Clerk I -A-3 Agreement No. 5747 BIDDING INSTRUCTIONS 1. DEFINITIONS. Unless provided otherwise, the definitions in the Greenbook, Special Conditions, or other Contract Documents are applicable to all Bidding Documents. 1.1 "Addenda" means written or graphic instruments issued by the City before the Bid Deadline that modify or interpret the Bidding Documents by additions, deletions, clarifications, or corrections. 1.2 "Alternate" means a proposed change in the Work, as described in the Bidding Documents which, if accepted, may result in a change to either the Contract Sum or the Contract Time, or both. 1.3 "Bid Deadline" means the date and time designated in the Notice for Bids as the last date and time for receipt of Bids, as may be revised by Addenda. 1.4 "Bidder" means a person or firm that submits a Bid. 1.5 "Bidding Documents" means the construction documents prepared and issued for bidding purposes including all Addenda. 1.6 "Lump Sum Base Bid" means the sum stated in the Bid for which Bidder offers to perform the Work described in the Bidding Documents, but not including unit price items or Alternates. 1.7 "Unit Price" means an amount stated in the Bid for which Bidder offers to perform the Unit Price Work for a fixed price per unit of measurement. 2. BIDDER'S REPRESENTATIONS. By making its Bid, Bidder represents that: 2.1 Bidder read, understood, and made the Bid pursuant to the requirements in the Bidding Documents. 2.2 Bidder visited the Project site and is familiar with the conditions under which the Work will be performed and the local conditions as related to the Contract Documents. 2.3 The Bid is based upon the materials, equipment, and systems required by the Bidding Documents. 2.4 Bidder and all Subcontractors, regardless of tier, have the appropriate current licenses issued by the State of California Contractor's State License Board for the Work to be performed. If Bidder is a joint venture, the Bidder will have a joint venture license appropriate for the performance of the work, and each member of the joint venture will likewise have the appropriate license. Business and Professions Code § § 7000-7191 establish licensing requirements for contractors. If a Bidder, that is a specialty contractor, submits a Bid involving 3 or more specialized building trades, the work of which is more than incidental and supplemental to the performance of the Work for which Bidder holds a specialty contractor license, Bidder must also hold either (1) a specialty contractor "C" license in each such trade, (2) a General Engineering contractor "A" license, or (3) a General Building contractor "B" license. This requirement is applicable whether or not Bidder lists a Subcontractor for each such trade. 2.5 If licensure or proper licensure is controverted, then proof of licensure pursuant to this section must be made by production of a verified certificate of licensure from the I -B-1 Agreement No. 5747 Contractors' State License Board which establishes that the individual or entity bringing the action was duly licensed in the proper classification of contractors at all times during the performance of any act or contract covered by the action. Nothing in this subdivision requires any person or entity controverting licensure or proper licensure to produce a verified certificate. When licensure or proper licensure is controverted, the burden of proof to establish licensure or proper licensure is on the licensee. 2.6 Bidder has the expertise and financial capacity to perform and complete all obligations under the Bidding Documents. 2.7 The person executing the Bid Form is duly authorized and empowered to execute the Bid Form on Bidder's behalf. 2.8 Bidder is aware of and, if awarded the Contract, will comply with Applicable Code Requirements in its performance of the Work. 2.9 The Bidder has paid the City's business license fee(s) 2.10 The Bidder, per SB 854 requirements for public projects, has registered with and paid their annual fee to the California State Department of Industrial Relations. Information about SB 854 and its requirements can be found at this link: http://www.dir.ca.gov/Public-Works/SB854.html 3. BIDDING DOCUMENTS 3.1 Bidders may obtain complete sets of the Bidding Documents from the City's Public Works Department for the sum stated in the Notice for Bids. 3.2 Bidders will use a complete set of Bidding Documents in preparing Bids. 3.3 The City makes copies of the Bidding Documents available, on the above terms, for the sole purpose of obtaining Bids for the Work and does not confer a license or grant permission for any other use of the Bidding Documents. 4. INTERPRETATION OR CORRECTION OF BIDDING DOCUMENTS. 4.1 Before submitting its Bid, Bidder will carefully study and compare the various documents comprising the Bidding Documents and compare them with any other work being bid concurrently or presently under construction which relates to the Work for which the Bid is submitted; will examine the Project site, the conditions under which the Work is to be performed, and the local conditions; and will at once report to the City's Representative errors, inconsistencies, or ambiguities discovered. 4.2 Requests for clarification or interpretation of the Bidding Documents will be addressed to the City's Representative. 4.2.1 The release of the bid package begins a quiet period for potential Bidders participating in this project. The City of El Segundo realizes it is critical to provide Bidders with a vehicle to ask questions so that quality responses can be prepared. Questions must be submitted in writing to project managers via the City website: littt)://www.els P-utido.or /det)ts/works/i)roiect recuiesC contact fbrtn.asp. Responses to all questions will be provided in writing to all Bidders in accordance with the schedule below. We will not identify companies or individuals that pose questions. Potential bidders must not call City of El Agreement No. 5747 Segundo employees to discuss potential projects or ask questions regarding the bid. Questions Due by 4:00 pin, June 18, 2019 Questions Answered by June 24, 2019 4.3 Clarifications, interpretations, corrections, and changes to the Bidding Documents will be made by Addenda. Clarifications, interpretations, corrections, and changes to the Bidding Documents made in any other manner will not be binding and Bidders must not rely upon them. PRODUCT SUBSTITUTIONS. No substitutions will be considered before award of Contract. Substitutions will only be considered after award of the Contract and as provided for in the Contract Documents. 6. SUBCONTRACTORS. 6.1 Each Bidder will list in the Bid Form all first-tier Subcontractors that will perform work, labor or render such services. The Bid Form contains spaces for the following information when listing Subcontractors: (1) Work Activity; (2) name of Subcontractor; (3) city of Subcontractor's business location. Failure to list any of these items on the Bid Form will result in the City treating the Bid as if no Subcontractor was listed for the Work and that Bidder represents to the City that it is fully qualified to perform that portion of the Work and will perform do so. 6.2 Subcontractors listed in the Bid Form will only be substituted after the Bid Deadline with the City's written consent in accordance with California law. 7. ADDENDA. 7.1 Addenda will be in writing and issued only by the City. Addenda will be mailed or delivered to all who are known by the City to have received a complete set of Bidding Documents and who have provided a street address for receipt of Addenda. 7.2 Copies of Addenda will be made available for inspection at the City's Public Works Department. 7.3 The City will issue Addenda so that they are received by prospective Bidders not later than three (3) business days before the Bid Deadline. Addenda that withdraw the request for Bids or postpone the Bid Deadline may be issued anytime before the Bid Deadline. 7.4 Each Bidder is responsible for ensuring that it has received all issued Addenda before issuing a Bid. 8. PRE-BID CONFERENCE. Bidder will attend a Pre -Bid Conference where the City will discuss the Bidding Documents, answer questions, accept comments, and conduct a Project site visit. The City requires all Pre -Bid Conference attendees to arrive for the meeting on time and to sign an attendance list which is used to determine if Bidders meet this requirement. Any Bidder not attending the Pre -Bid Conference in its entirety will be deemed to have not complied with the requirements of the Bidding Documents and its Bid will be RM Agreement No. 5747 rejected. 9. FORM AND STYLE OF BIDS 9.1 Bids will be submitted on the Bid Form included with the Bidding Documents. Bids not submitted on the City's Bid Form will be rejected. 9.2 All blanks on the Bid Form will be filled in legibly in ink or by typewriter. 9.3 Bidder's failure to submit a price for any Alternate or unit price will result in the Bid being considered as nonresponsive. If Alternates are called for and no change in the Lump Sum Base Bid is required, enter "No Change." 9.4 Each Bidder must fill out the `Bidders Statement of Past Contract Disqualifications" form stating any and all instances of contract disqualifications due to a violation of a law or safety regulation. The Bidder must explain the circumstances of each disqualification. The City may reject the bid based on such information. 9.5 Bidder will make no stipulations on the Bid Form nor qualify the Bid in any manner. 9.6 The Bids will be based upon full completion of all the Work as shown on the plans and specifications. It is expressly understood that the plans are drawn with as much accuracy as is possible in advance, but should errors, omissions or discrepancies exist in the plans which show conditions that vary from those encountered in construction, the Bidder (if awarded the Contract) specifically agrees to construct a completed work ready for the use and in the manner which is intended. In the event of increasing or decreasing of work, the total amount of work actually done or materials or equipment furnished must be paid for according to the unit or lump sum price established for such work under the contract, wherever such unit or lump sum price has been established. In the event no prices are named in the contract to cover such changes or alterations, the cost of such changes must be covered as extra work. 9.7 The Bid Form will be signed by a person or persons legally authorized to bind Bidder to a contract. Bidder's Representative will sign and date the Declaration included in the Bid Form. Failure to sign and date the declaration will cause the Bid to be rejected. 9.8 Bids must be submitted in writing on the Proposal forms provided by the City of El Segundo. One (1) set of these Proposal forms is inserted loose herein for use by the bidders. Bidders are required to submit one (1) original set of the proposal forms. All information requested therein must be clearly and legibly set forth in the manner and form indicated. 9.9 Bidders must satisfy themselves by personal examination of the work site, Plans, Specifications, and other contract documents, and by any other means as they may believe necessary, as to the actual physical conditions, requirements and difficulties under which the work must be performed. No bidder shall at any time after submissions of a proposal make any claim or assertion that there was any misunderstanding or lack of information regarding the nature or amount of work necessary for the satisfactory completion of the job. Any errors, omissions, or discrepancies found in the Plans, Specifications, or other contract documents shall be called to the attention of the City of El Segundo and clarified prior to the submission of proposals. I -B-4 Agreement No. 5747 10. BID SECURITY 10.1 Each Bid will be accompanied by Bid Security, in the amount of 10% of the Lump Sum Base Bid as security for Bidder's obligation to enter into a Contract with the City on the terms stated in the Bid Form and to furnish all items required by the Bidding Documents. Bid Security will be a Bid Bond on the form provided by the City or a certified check made payable to "City of El Segundo." When a Bond is used for Bid Security, failure to use the City's Bid Bond form will result in the rejection of the Bid. 10.2 If the apparent lowest responsible Bidder fails to sign the Agreement and furnish all items required by the Bidding Documents within the time limits specified in these Instructions to Bidders, the City will disqualify such Bidder and select the next apparent lowest responsible Bidder until all bids have been exhausted or the City may reject all bids. In such an event, the disqualified Bidder will be liable for and forfeit to the City the amount of the difference, not to exceed the amount of the Bid Security, between the amount of the disqualified Bid and the larger amount for which the City procures the Work. 10.3 If a Bid Bond is submitted and an attorney-in-fact executes the Bid Bond on behalf of the surety, a notarized and current copy of the power of attorney will be affixed to the Bid Bond. The surety issuing the Bid Bond will be listed in the latest published State of California, Department of Insurance list of, "Insurers Admitted to Transact Surety Insurance in This State." 10.4 The City will retain Bid Security until the occurrence of one of the following: 10.4.1 All items required by the Bidding Documents have been furnished and the Agreement has been signed by the successful Bidder and the City. 10.4.2 The specified time has elapsed during which Bids may be withdrawn. 10.4.3 All Bids have been rejected. 10.5 The Bid Form, Bid Security, and all other documents required to be submitted with the Bid must be enclosed in a sealed opaque envelope. The envelope must be addressed to the City Clerk. The envelope must be identified with the Bidder's name and address, and identify the Project for which the Bid is submitted, as follows: "SEALED BIDS FOR PW 19-10: McCARTHY COURT STREET IMPROVEMENTS PROJECT. DO NOT OPEN WITH REGULAR MAIL." Proposals may be mailed or delivered by messenger. 10.6 Bids will be deposited at the designated location on or before the Bid Deadline. A Bid received after the Bid Deadline will be returned to Bidder unopened. 10.7 Bidder will assume full responsibility for timely delivery at the location designated for receipt of Bids. 10.8 Oral, telephonic, facsimile, or telegraphic Bids are invalid and will not be accepted. 10.9 All proposals must be submitted, filed, made, and executed in accordance with State and Federal laws related to bids for contracts of this nature whether the same is expressly referred to herein or not. Any bidder submitting a proposal shall by such action thereby agree to each and all of the terms, conditions, provisions, and requirements set forth, contemplated, and referred to in the Plans, Specifications, and other contract documents, and to full compliance therewith. Agreement No. 5747 11. MODIFICATION OR WITHDRAWAL OF BID. 11.11 Before the Bid Deadline, a submitted Bid may be modified or withdrawn. Notice of such action will be given to the City in writing and signed by the Bidder's authorized representative. A change so made will be so worded as not to reveal the amount of the original Bid. 11.12 A withdrawn Bid may be resubmitted up to the Bid Deadline, provided that it then fully complies with the Bidding Requirements. 11.13 Bid Security will be in an amount sufficient for the Bid as modified or resubmitted. 11.14 Bids may not be modified, withdrawn, or canceled within sixty (60) days after the Bid Deadline unless otherwise provided in Supplementary Instructions to Bidders. 11.15 Proposals may not be withdrawn after said Bid Deadline without forfeiture of the proposal guarantee. 11.16 The withdrawal of a proposal will not prejudice the right of the bidder to submit a new proposal, providing there is time to do so. 11.17 No mention shall be made in the proposal of Sales Tax, Use Tax, City Business License, or any other tax, as all amounts bid will be deemed and held to include any such taxes, which may be applicable. 11.18 No mention shall be made in the proposal of the cost of bonds as all amounts bid will be deemed and held to include any such costs, which may be applicable. 12. OPENING OF BIDS. Bids submitted in the manner required by these instructions and are received on or before the Bid Deadline will be opened publicly. 13. REJECTION OF BIDS. 13.1 The City will have the right to reject all Bids. 13.2 The City will have the right to reject any Bid not accompanied by the required Bid Security or any other item required by the Bidding Documents, or a Bid which is in any other way materially incomplete or irregular. 13.2.1 Unrequested/unauthorized conditions, limitations, or provisions attached to a proposal will render it irregular and may cause its rejection. The completed proposal forms shall be without interlineations, alterations, or erasures. Alternative proposals will not be considered unless specifically requested. No oral, telegraphic, or telephonic proposal, modification, or withdrawal will be considered. 13.3 In the event that any bidder acting as a prime contractor has an interest in more than one proposal, all such proposals will be rejected, and the bidder will be disqualified. This restriction does not apply to subcontractors or suppliers who may submit quotations to more than one bidder, and while doing so, may also submit a formal proposal as a prime contractor. No proposal will be accepted from a bidder who has not been licensed in accordance with the provisions of the State Business and Professions Code. RM Agreement No. 5747 14. AWARD 14.1 The City may retain all bids for a period of sixty (90) days for examination and comparison, and to delete any portion of the work from the contract. 14.2 The City will have the right to waive nonmaterial irregularities in a Bid and to accept the lowest responsive Bid as determined by The City. 14.3 The City will have the right to accept Alternates in any order or combination, unless otherwise specifically provided in the Bidding Documents. 14.4 The City will determine the low Bidder on the basis of the sum of the Lump Sum Base Bid plus all unit prices multiplied by their respective estimated quantities as stated in the Bid Form, if any, plus the Contractor Delay Damages multiplied by the "multiplier" as stated in the Bid Form, plus the amounts of all accepted Alternates. 14.4.1 Inclusion of Contractor Delay Damages within the Bid Form is solely for the purpose of determining the low bidder and establishing the City's maximum daily liability as a result of City delays to Contractor, if any, and City has no obligation to pay any daily Contractor Delay Damages except as provided for in these Contract Documents for Compensable Delays. In the event that City becomes liable to Contractor for compensable delays, City agrees to pay Contractor the daily Contractor Delay Damages set forth in the Proposal Form or Contractor's actual daily delay damages, whichever is less, for each day of Compensable Delay as provided for by these Contract Documents. 14.5 The City will select the apparent lowest responsive and responsible Bidder and notify such Bidder within thirty (30) days (unless number of days is modified in Supplementary Instructions to Bidders) after the Bid Deadline or reject all bids. Within ten (10) days after receiving the City's notice that Bidder was selected as the apparent lowest responsible Bidder, Bidder will submit to the City all of the following items: 14.5.1 One original of the Agreement signed by Bidder. 14.5.2 One original of the Payment Bond. 14.5.3 One original of the Performance Bond. 14.5.4 Certificates of Insurance on form provided by the City. 14.5.5 Names of all Subcontractors, with their addresses, telephone number, facsimile number, trade on Bidders' company stationery. Evidence, as required by the City, of the reliability and responsibility of the proposed Subcontractors such as statements of experience, statements of financial condition, and references. 14.5.6 Preliminary Contract Schedule. 14.5.7 Selection of Retention Options and Escrow Agreement for Deposit of Securities in Lieu of Retention and Deposit of Retention. If not submitted, the City will withhold retention, 14.5.8 Cost Breakdown. 14.6 Before award of the Contract, the City will notify Bidder in writing, if the City objects to a Subcontractor proposed by Bidder, in which case Bidder will propose a substitute acceptable to the City. Failure of the City to object to a proposed Subcontractor before award will not preclude the City from requiring replacement of any Subcontractor based upon information received subsequent to award, information which cannot be property evaluated before award due to time I -B-7 Agreement No. 5747 constraints, or information relating to a failure to comply with the requirements of the Contract. 14.7 If Bidder submits the original signed Agreements and all other items within ten (10) days after receiving the City's notification, and all such items comply with the requirements of the Bidding Documents, the City will award the Contract to Bidder by signing the Agreement and returning a signed copy of the Agreement to Bidder. 14.8 If the City consents to the withdrawal of the Bid of the apparent lowest responsible Bidder, or the apparent lowest responsible Bidder fails or refuses to sign the Agreement or submit to the City all of the items required by the Bidding Documents, within ten (10) days after receiving the City's notification, or the City determines that the Bidder is not financially or otherwise qualified to perform the Contract, the City may reject such Bidder's Bid and select the next apparent lowest responsible Bidder, until all bids are exhausted, or reject all Bids. MW -1 Agreement No. 5747 PROPOSAL FOR THE McCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 Date 20_ Company Name: TO THE CITY OF EL SEGUNDO: In accordance with the City of El Segundo's Notice Inviting Sealed Bids, the undersigned BIDDER hereby proposes to furnish all materials, equipment, tools, labor, and incidentals required for the above stated project as set forth in the Plans, Specifications, and contract documents therefor, and to perform all work in the manner and time prescribed therein. BIDDER declares that this proposal is based upon careful examination of the work site, Plans, Specifications, Instructions to Bidders, and all other contract documents. Submittal of this bid shall be considered evidence that the BIDDER has satisfied himself regarding the contract documents, access and any other field conditions which may effect bid prices. If this proposal is accepted for award, BIDDER agrees to enter into a contract with the City of El Segundo at the unit and/or lump sum prices set forth in the following Bid Schedule. BIDDER understands that failure to enter into a contract in the manner and time prescribed will result in forfeiture to the City of El Segundo of the proposal guarantee accompanying this proposal. BIDDER understands that a bid is required for the entire work, that the estimated quantities set forth in the Bid Schedule are solely for the purpose of comparing bids, and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. THE CITY OF EL SEGUNDO RESERVES THE RIGHT TO INCREASE OR DECREASE THE AMOUNT OF ANY QUANTITY SHOWN AND TO DELETE ANY ITEM FROM THE CONTRACT. It is agreed that the unit and/or lump sum prices bid include all apparent expenses, taxes, royalties, and fees. In the case of discrepancies in the amounts bid, unit prices shall govern over extended amounts, and words shall govern over figures. If awarded the Contract, the undersigned further agrees that in the event of the BIDDER'S default in executing the required contract and filing the necessary bonds and insurance certificates within ten working days after the date of the City of El Segundo's notice of award of contract to the BIDDER, including sending by U.S. Mail a Public Works Contract for signature by the Awardee, the proceeds of the security accompanying this bid shall become the property of the City of El Segundo and this bid and the acceptance hereof may, at the City of El Segundo's option, be considered null and void. Agreement No. 5747 EQUAL EMPLOYMENT OPPORTUNITY COMPLIANCE BIDDER certifies that in all previous contracts or subcontracts, all reports which may have been due under the requirements of any agency, State, or Federal equal employment opportunity orders have been satisfactorily filed, and that no such reports are currently outstanding. AFFIRMATIVE ACTION CERTIFICATION BIDDER certifies that affirmative action has been taken to seek out and consider minority business enterprises for those portions of the work to be subcontracted, and that such affirmative actions have been fully documented, that said documentation is open to inspection, and that said affirmative action will remain in effect for the life of any contract awarded hereunder. Furthermore, BIDDER certifies that affirmative action will be taken to meet all equal employment opportunity requirements of the contract documents. NONCOLLUSION AFFIDAVIT BIDDER declares that the only persons or parties interested in this proposal as principals are those named herein; that no officer, agent, or employee of the City of El Segundo is personally interested, directly or indirectly, in this proposal; that this proposal is made without connection to any other individual, firm, or corporation making a bid for the same work and that this proposal is in all respects fair and without collusion or fraud. I -C-2 Agreement No. 5747 BID SCHEDULE McCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 Company Name: Item No. Description Unit Price QTY Unit ($) Total M BASE BID ITEMS Mobilization/Demobilization I including traffic control (not to I LS exceed 5% maximum of Total Bid) 2 Remove ex. curb and replace with 731 LF _._ curb and 18" -wide gutter 3 Remove and replace 4" -thick 1 SF sidewalk ,312 4 Remove and replace 6" -thick 884 SF drivewajroach 5 Install asphalt slot paving, 3' -wide 2,193 SF 6 i Completely remove existing tree 8 EA inckiding_stump and tree roots ALTERNATIVE BID ITEMS (Determined � by the City on an as -needed basis) 7 Remove hardscape and replace with SF 920 compacted soil I L_8 Remove and replace ex. curb only LF 50 TOTAL BID ITEMS I THROUGH 8 ... . . .... . TOTAL BID ITEMS WRITTEN IN WORDS: All work shall be per these specifications and attachments. Prevailing wage rates apply. The City of El Segundo reserves the right to reject any or all bids, to waive any irregularity, and to take all bids under advisement for a period of ninety (90) calendar days. I -C-3 Agreement No. 5747 BIDDER'S INFORMATION Company Name: BIDDER certifies that the following information is true and correct: Form of Legal Entity (i.e., individual, partnership, corporation, etc.) If corporation, State of Incorporation (i.e., California) Business Address Telephone No._ Facsimile No. State Contractor's License No. and Class DIR4 Original Date Issued Expiration Date The following are the names, titles, email addresses, and phone minibers of all individuals, firm members, partners, joint venturers, and/or corporate officers having principal interest in this proposal: The date of any voluntary or involuntary bankruptcy judgments against any principal having an interest in this proposal is as follows: All current and prior RBA's, aliases, and/or fictitious business names for any principal having an interest in this proposal are as follows: I -C-4 BIDDER'S INFORMATION (CONTINUED) Company Name: Agreement No. 5747 Bidder shall list the name of the person who attended the mandatory pre-bid job walk: Name: Title: I -C-5 Agreement No. 5747 IN WITNESS WHEREOF, BIDDER executes and submits this proposal with the names, titles, hands, and seals of all a forenamed principals this _ day of 20 Subscribed and sworn to this day of .20— NOTARY PUBLIC I -C-6 Agreement No. 5747 PROPOSAL GUARANTEE BID BOND McCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 KNOW ALL MEN BY THESE PRESENTS that, , as BIDDER, and , as SURETY, are held and firmly bound unto the City of El Segundo, in the penal sum of DOLLARS ($_), which is ten (10%) percent of the total amount bid by BIDDER to the City of El Segundo for the above stated project, for the payment of which sum, BIDDER and SURETY agree to be bound, jointly and severally, firmly by these presents. THE CONDITIONS OF THIS OBLIGATION ARE SUCH that, whereas BIDDER is about to submit a bid to the City of El Segundo for the above stated project, if said bid is rejected, or if said bid is accepted and a contract is awarded and entered into by BIDDER in the manner and time specified, then this obligation shall be null and void, otherwise it shall remain in full force and effect in favor of the City of El Segundo. IN WITNESS WHEREOF the parties hereto have set their names, titles, hands, and seals this day of 20 I _11_"t1 - SURETY* Subscribed and sworn to this _ day of 20_ ... NOTARY PUBLIC *Provide BIDDER/SURETY name, title, address and telephone number and the name, title, address and telephone number for authorized representative. I -C-7 Agreement No. 5747 CONTRACTOR'S LICENSE DECLARATION (Business and Professions Code Section 7028.15) 1. BIDDER'S Contractor's License Number is: Class No.: 2. The expiration date of BIDDER'S Contractor License is: ,20 3. BIDDER acknowledges that Section 7028.15(e) of the Business and Professions Code provides as follows: "A licensed contractor shall not submit a bid to a public agency unless his or her contractor's license number appears clearly on the bid, the license expiration date is stated, and the bid contains a statement that representations herein are made under penalty of perjury. Any bid not containing this information, or a bid containing information which is subsequently proven false, shall be considered non-responsive and shall be rejected by the public agency." The undersigned declares, under penalty of perjury, that the representations made by the undersigned in this bid proposal are true and correct. Executed on .20 at Signature Typed Name Title Company Name (insert City and State where Declaration signed). I -C-8 Agreement No. 5747 NON -COLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID State of California ) ss. County of , being first duly sworn, deposes and say that he or she is of the party making the foregoing bid that the bid is not made in the interest of, or on behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the BIDDER has not directly or indirectly induced or solicited any other BIDDER to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any BIDDER or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the BIDDER has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price of the BIDDER or any other BIDDER, or to fix any overhead, profit, or cost element of the bid price., or of that of any other BIDDER, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements, contained in the bid are true; and further, that the bidder has not, directly or indirectly. Submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, or paid, and will not pay, any fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. Signature Typed Name Title I -C-9 Name of Bidder/Company Name Date Agreement No. 5747 WORKER'S COMPENSATION CERTIFICATION Section 1861 OF THE LABOR CODE (Workers' Compensation) Pursuant to Section 1861 of the Labor Code, the BIDDER, in submitting his/her PROPOSAL, shall sign the following certification: "I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers' compensation or to undertake self- insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract." Signature of Bidder: Title; Business Name: Business Address: Telephone Number: C---) Dated this day of , 20 1-C-10 Agreement No. 5747 DESIGNATION OF SUBCONTRACTORS McCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 Company Name: As detailed in Section 2-3.1 (Page 11-B-3) of the City Standard Specifications, Bidder certifies that it has listed below all subcontractors who will perform work in excess of one-half of one percent (0.5%) of the total bid price or certifies that the bidder is fully qualified to perform and will perform that portion of the work itself. — — Subcontractor's Contractor Description of License No., & Portion of Name of DIR Work Estimated Subcontractor Address Registration No. Subcontracted $ Amount (Number and Street) (CSLB #) I (City, Zip Code) (DIR #) (Make copies of this page if additional space is needed) Signature of Bidder Date REFERENCES Company Name: Agreement No. 5747 The following are the names, addresses, and telephone numbers for public agencies for which BIDDER has performed similar work as the prime contractor or major subcontractor within the past five (5) years: 1. Project Title: Location: Name and address of owner Name and current telephone number of person familiar with project Type of Work: Contract amount: . ...... Date completed: Amount of work done by my/our firm under contract Did your firm have any financial interest in Project? 2. Project Title: Location: Name and address of owner Name and current telephone number of person familiar with project Type of Work: Contract amount: $ Date completed: Amount of work done by my/our fin -n under contract Did your firm have any financial interest in Project? 1-C-12 Agreement No. 5747 3. Project Title: Location: Name and address of owner Name and current telephone number of person familiar with project Type of Work: Contract amount: $ Date completed: _ Amount of work done by my/our firm under contract $ . ...... . . Did your firm have any financial interest in Project? 4, Project Title: Location: Name and address of owner Name and current telephone number of person familiar with project: Type of Work: Contract amount: ............. — Date completed: Amount of work done by my/our firm under contract Did your firm have any financial interest in Project? I -C- 13 Agreement No. 5747 S. Project Title: Location: Name and address of owner Name and current telephone number of person familiar with project: Type of Work: Contract amount: $ Date completed: Amount of work done by my/our firm under contract $ Did your firm have any financial interest in Project? Bidder may attach additional reference pages if necessary. The following are the names, addresses, and telephone numbers for all brokers and sureties from whom BIDDER intends to procure insurance bonds: I -C- 14 Agreement No. 5747 BIDDER'S STATEMENT OF PAST CONTRACT DISQUALIFICATIONS McCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 Company Name: Please state all instances of being disqualified, removed, or otherwise prevented from bidding on, or completing, a federal, state, or local government project due to a violation of a law or safety regulation. 1. Have you ever been disqualified from any government contract? Yes ❑ No ❑ 2. If yes, explain the circumstances: 3. Are you registered in accordance with Labor Code § 1725.5 [Note: failure to register requires the City to reject your bid as nonresponsive]? Yes ❑ No ❑ Bidder's Signature Name (Please Print) I -C-15 Agreement No. 5747 INSURANCE REQUIREMENTS [Mt.JSTBE SUBMITTED WITH PROJECT PROPOSAL] McCARTH'Y COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 Company Name: To be awarded this contract, the successful bidder must procure and maintain the following types of insurance with coverage limits complying, at a minimum, with the limits set forth below: Iype of Insurance Limits Commercial general liability: $2,000,000 Business automobile liability: $1,000,000 Workers compensation: Statutory requirement Commercial general liability insurance must meet or exceed the requirements of ISO -CGL Form No, CG 00 01 11 85 or 88. The amount of insurance set forth above must be a combined single limit per occurrence for bodily injury, personal injury, and property damage for the policy coverage. [lability policies niList be endorsed to name the City, its officials, and employees as "additional insureds" under said insurance coverage and to state that such insurance will be deemed "primary" such that any other insurance that may be carried by the City will be excess thereto. Stich endorsement must be reflected oil ISO Form No. CG 20 10 1185 or 88, or equivalent. Such insurance must be on an "occurrence," not a "claims made," basis and will not be cancelable or subject to reduction except upon thirty (30) days prior written notice to the City. Insurer will agree in writing to waive all rights of subrogation against the City, its officers, officials, employees and volunteers for losses arising frown work performed by Contractor for the City. Automobile coverage must be written on ISO Business Auto Coverage Form CA 00 01 06 92, including symbol I (Any Auto). The Consultant must furnish to the City duly authenticated Certificates of Insurance evidencing maintenance of the insurance required under this Agreement, endorsements as required herein, and such other evidence of insurance or copies of policies as may be reasonably required by the City fron-i time to tirne. Insurance must be placed with admitted illStIrerS With a Current A,M. Best Company Rating equivalent to at least a Rating of "A:VlUCertificate(s) rnnst reflect that the insurer will provide thirty (30) day notice of any cancellation of coverage. The Consultant will require its insurer to modify such certificates to delete any exculpatory wording stating that failure of the insurer to mail written notice of cancellation imposes no obligation, and to delete the word "endeavor" with regard to any notice provisions. The City requires CalL rnia Worker's Compensation Coverage NNIth the associated Waiver. OLit-of-state (o coverage will not be accepted in lieu of the California coverage, because the work is being perforilled in the State of California. By signing this form, the bidder certifies that it has read, understands, and will comply with these insurance requirements if it is selected as the City's consultant. Failure to provide this insurance will render the bidder's proposal "nonresponsive." Date I -C- 16 Bidder's Signature Agreement No. 5747 END PROPOSAL SECTION I -C-17 Agreement No. 5747 PUBLIC WORKS CONTRACT BETWEEN THE CITY OF EL SEGUNDO AND [CONTRACTOR] McCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 This CONTRACT is entered into this day of 20 by and between the CITY OF EL SEGUNDO, a general law city and municipal corporation ("the City") and , ("the Contractor"). A. The Contractor will provide all work required by the Contract Documents (the "Work"). The Contractor agrees to do additional work arising from changes ordered by the City in accordance with the Contract Documents. B. The Contractor and the City agree to abide by the terms and conditions contained in the Contract Documents; C. The Contractor will furnish all of the labor; supplies and materials; equipment; printing; vehicles; transportation; office space and facilities; all tests, testing and analyses; and all matters whatsoever (except as otherwise expressly specified to be furnished by the City) needed to perform and complete the Work and provide the services required of the Contractor by the Contract Documents. D. "Contract Documents" means the Notice Inviting Bids; Instructions to Bidders; Supplementary Instructions to Bidders; Proposal; this Contract; Standard Specifications; Supplementary Conditions; Exhibits; Technical Specifications; List of Drawings; Drawings; Addenda; Notice to Proceed; Change Orders; Notice of Completion; and all other documents identified in the Contract Documents which together form the contract between the City and the Contractor for the Work. The Contract Documents constitute the complete agreement between the City and the Contractor and supersede any previous agreements or understandings. 2. CONTRACT SUM. The City agrees to pay the Contractor a sum not to exceed Dollars ($ ) for the Work in the manner set forth in the Contract Documents. The City may adjust this amount as set forth in the Contract Documents. 3. TIME FOR PERFORMANCE. I -D-1 Agreement No. 5747 A. The Contractor will fully complete the Work within one hundred twenty (70) working days (the "Contract Time.") B. The Contract Time will commence when the City issues a Notice to Proceed. The Contract Documents will supersede any conflicting provisions included on the notice to proceed issued pursuant to this Contract. C. The Contractor may not perform any Work until: i. The Contractor furnishes proof of insurance as required by the Contract Documents; and ii. The City gives the Contractor a written, signed, and numbered purchase order and notice to proceed. D. By signing this Contract, the Contractor represents to the City that the Contract Time is reasonable for completion of the Work and that the Contractor will complete the Work within the Contract Time. E. Should the Contractor begin the Work before receiving written authorization to proceed, any such Work is at the Contractor's own cost and risk. 4. DISPUTES. Disputes arising from this contract will be determined in accordance with the Contract Documents and Public Contracts Code §§ 10240-10240.13. 5. THIRD PARTY CLAIMS. In accordance with Public Contracts Code § 9201, the City will promptly inform the Contractor regarding third -party claims against the Contractor, but in no event later than ten (I 0) business days after the City receives such claims. Such notification will be in writing and forwarded in accordance with the "Notice" section of the Contract Documents. As more specifically detailed in the Contract Documents, the Contractor agrees to indemnify and defend the City against any third -party claim. 6. TAXPAYER IDENTIFICATION NUMBER. The Contractor will provide the City with a Taxpayer Identification Number. 7. PERMITS AND LICENSES. Unless otherwise provided, the Contractor, at its sole expense, will obtain and maintain during the Contract Time, all necessary permits, licenses, and certificates that may be required in connection with the Work, 8. OWNERSHIP OF DOCUMENTS. All documents, data, studies, drawings, maps, models, photographs and reports prepared by the Contractor under the Contract Documents are the City's property. The Contractor may retain copies of said documents and materials as desired, but will deliver all original inaterials to the City upon the City's written notice. 9. INDEMNIFICATION. The Contractor agrees to indemnify, defend, and hold the City harmless as set forth in the Contract Documents. The requirements as to the types and limits I -D-2 Agreement No. 5747 of insurance coverage to be maintained by the Contractor as required by the Contract Documents, and any approval of such insurance by the City, arc not intended to and will not in any manner limit or qualify the liabilities and obligations otherwise assumed by the Contractor pursuant to the Contract Documents, including, without limitation, to the provisions concerning indemnification. 10. INDEPENDENT CONTRACTOR. The City and the Contractor agree that the Contractor will act as an independent contractor and will have control of all work and the manner in which is it performed. The Contractor will be free to contract for similar service to be performed for other employers while under contract with the CityJ, lie Contractor is not an agent or employee of the City and is not entitled to participate in any pension plan, insurance, bonus or similar benefits the City provides for its employees. Any provision in this Contract that may appear to give the City the right to direct the Contractor as to the details of doing the work or to exercise a measure of control over the work means that the Contractor will follow the direction of the City as to end results of the work only. 11. AUDIT OF RECORDS. The Contractor will maintain full and accurate records with respect to all services and matters covered under this Contract. The City will have free access at all reasonable times to such records, and the right to examine and audit the same and to make transcript therefrom, and to inspect all prograrn data, documents, proceedings and activities. The Contractor will retain such financial and program service records, for at least three (3) years after termination or final payment under the Contract Documents. 12. NOTICES. All communications to either party by the other party will be deemed made when received by such party at its respective name and address as follows: The Citv "I'lie Contractor Lifan Xu City Engineer City of El Segundo 350 Main Street, El Segundo, CA 90245 (310) 524-2368 Any such written conimUllications by mail will be Conclusively deemed to have been received by the addressee three (3) days after deposit thereof in the United States Mail, postage prepaid and properly addressed as noted above. In all other instances, notices will be deemed given at, the time of actual delivery. Changes may be made in the names or addresses of persons to whom notices are to be given by giving notice in the manner prescribed in this paragraph. 13. NO THIRD PARTY BENEFICIARY. This Contract and every provision herein is for the exclusive benefit of the Contractor and the City and not for the benefit of any other party. I -D-3 Agreement No. 5747 There will be no incidental or other beneficiaries of any of the Contractor's or the City's obligations under this Contract. 14. INTERPRETATION. This Contract was drafted in, and will be construed in accordance with the laws of the State of California, and exclusive venue for any action involving this Contract will be in Los Angeles County. 15. EFFECT OF CONFLICT. In the event of any conflict, inconsistency, or incongruity between any provision of the Contract Documents, precedence will be as follows: A. This Contract; B. The Standard Specifications; and C. Precedence of documents as determined in the Standard Specifications. 16. SEVERABILITY. If any portion of the Contract Documents are declared by a court of competent jurisdiction to be invalid or unenforceable, then such portion will be deemed modified to the extent necessary in the opinion of the court to render such portion enforceable and, as so modified, such portion and the balance of this Contract will continue in full force and effect. 17. AUTHORITY/MODIFICATION. The Parties represent and warrant that all necessary action has been taken by the Parties to authorize the undersigned to execute this Contract and to engage in the actions described herein. This Contract may be modified by written amendnient. The City's city manager, or designee, may execute any such anlendnient on (lie City's behalf. 18. ACCEPTANCE OF FACSIMILE SIGNATURES. The Parties agree that this Contract, agreements ancillary to this Contract, and related documents to be entered into in conriectimi with this Contract will be considered signed when the signature of a party is delivered by facsimile transmission. Such facsimile signature will be treated in all respects as having the same effect as an original signature. 19. COVENANTS AND CONDITIONS. The parties agree that all of the provisions hereof wi I I be construed as both covenants and conditions, the same as if the words importing such covenants and conditions had been used in each separate paragraph. 20. CAPTIONS. The captions of the paragraphs of this Contract are for convenience of reference only and will not affect the interpretation of this Contract. 21. TIME IS OF ESSENCE. Time is of the essence for each and every provision of the Contract Documents. IN WITNESS WHEREOF the parties hereto have executed this contract the day and year first hereinabove written. I -D-4 CITY OF EL SEGUNDO Greg Carpenter City Manager ATTEST: Tracy Weaver, City Clerk APPROVED AS TO FORM: MARK D. HENSLEY, City Attorney LO -3 David H. King, Assistant City Attorney Insurance Reviewed by: I -D-5 Agreement No. 5747 Taxpayer ID No. Contractor State License No.: Contractor City Business License No.: Agreement No. 5747 FAITHFUL PERFORMANCE BOND McCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 Bond No. Bond Fee: ("PRINCIPAL") and , a corporation incorporated under the laws of the State of and licensed by the State of California to execute bonds and undertakings as sole surety, as surety ("SURETY"), are held and firmly bound unto the ary OF EL SEGUNDO ("CITY") in the sum of DOLLARS, lawful money of the United States, which may be increased or decreased by a rider hereto executed in the same manner as this bond, for the payment of which sum PRINCIPAL and SURETY bind themselves, their successors, and assigns, jointly and severally, by this instrument. PRINCIPAL or SURETY will apply this bond for the faithful performance of any and all of the conditions and stipulations set forth in this bond, SPECIFICATIONS NO. PW 19-10, and the public works contract executed with such Specifications. In the case of any default in the performance of the conditions and stipulations of this undertaking, it is agreed that PRINCIPAL or WRETN' will apply the bond or arty portion thereof, to the satisfaction of any damages, reclamation, assessments, penalties, or deficiencies arising by reason of such default. BOND CONDITIONS 1. PRINCIPAL will construct the public improvements identified in SPECIFICATIONS NO. PW 19-10, a copy of which is on file with CITY's Engineering Division ("Public Project"). Such performance will be in accordance with CITY's plans and profiles (CITY DRAWING FILE NO. ) which are made, a part of this bond when said plans and profiles are approved by the City Council and filed with CITY's Engineering Division. CITY has estimated the required amount of the bond as shown above. 2. PRINCIPAL's work on the Public Project will be done in accordance with CITY's plans and specifications and with any permit issued by CITY. Should PRINCIPAL fail to complete all required work within the time allowed, CITY may, at its sole discretion, cause all required work to be done and the parties executing the bond will be firmly bound for the payment of all necessary costs therefor. 3. PRINCIPAL will guarantee its work against any defective work, labor, or materials on the Public Project for a period of one (1) year following the Public Project's I -E- I Agreement No. 5747 completion and acceptance by CITY. 4. This bond is conditioned upon and guarantees due compliance with all applicable law including, without limitation, the El Segundo Municipal Code ("ESMC"). 5. SURETY, for value received, agrees that no changes, extensions of time, alteration or modification of SPECIFICATIONS NO, PW 19-10 or of the obligation to be performed will in any way affect its obligation on this bond, and it waives notice of any such change, extension of time, alteration or modification of the contract documents or of the obligation to be performed. 6. This bond consists of this instrument; the plans and specifications identified above; and the following two (2) attached exhibits all of which are incorporated herein by reference: A. A certified copy of the appointment, power of attorney, bylaws or other instrument entitling or authorizing the persons executing this bond to do so; B. A certificate issued by the county clerk for the county in which SURETY's representative is located conforming with California Code of Civil Procedure § 995.640 and stating that SURETY's certificate of authority has not been surrendered, revoked, cancelled, annulled, or suspended, or in the event that it has, that renewed authority has been granted; and 7. Should PRINCIPAL perform its obligations within the time allowed, PRINCIPAL's obligation will be void upon the acceptance of the performance by CITY; otherwise this obligation will remain in full force and effect. [SIGNATURES ON FOLLOWING PAGE] I -E-2 SIGNED AND SEALED this day of PRINCIPAL's PRESIDENT PRINCIPAL's SECRETARY PRINCIPAL's MAILING ADDRESS: Agreement No. 5747 .20 SURETY's PRESIDENT SURETY's SECRETARY SURETY's MAILING ADDRESS: NOTE: (1) ALI., signatures Must be acknowledged by a notary public. Return one (1) original to City Clerk's Office. (2) Bond shall be effective for one (1) year after acceptance of the job. I -E-3 Agreement No. 5747 LABOR AND MATERIALS BOND McCARTHY COURT STREET IMPROVEMENTS PROJECT PROJECT NO.: PW 19-10 Bond No. Bond Fee: . as principal ("PRINCIPAL") and a corporation incorporated under the laws of the State of and licensed by the State of California to execute bonds and undertakings as sole surety, as surety ("SURETY"), are held and firmly bound unto the CITY OF EL SEGUNDO ("CITY") in the sum of DOLLARS, lawful money of the Onited States, which may be increased or decreased by a rider hereto executed in the same manner as this bond, for the payment of which sum PRINCIPAL and SURETY bind themselves, their successors, and assigns, jointly and severally, by this instrument. This bond is conditioned upon and guarantees payment by PRINCIPAL to contractors, subcontractors, and persons renting equipment; payment by PRINCIPAL and all PRINCIPALS subcontractors for all materials, provisions, provender, or other supplies, and equipment used in, upon, for or about the performance of the work contemplated in McCARTHY COURT STREET IMPROVEMENTS PROJECT, SPECIFICATIONS NO. PW 19-10 ("PUblic Project,-), the public works contract executed for such Public Project, and far all work or labor of any kind performed for the Public Project. In the case of any default in the performance of the conditions and stipulations of this undertaking, it is agreed that PRINCIPAL or SURETN'will apply the bond or any portion thereof, to the satisfaction of any damages, reclamation, assessments,, penalties, or deficiencies arising by reason of such default. BOND CONDITIONS 1. PRINCIPAL will construct the public improvements identified in SPECIFICATIONS NO, PW 19-10, and the public works contract executed for such Specifications, copies of'which is on file with CITY's Engineering Division (*'Public project"). Such performance will be in accordance with CITY's plans, and profiles. which are made a part of this bond when said plans and profiles are approved by the City Council and Filed with CITY's Engineering Division. 2. PRINCIPAL will pay all contractors, subcontractors, and persons renting equipment. 3. PRINCIPAL will pay for all materials and other supplies, for equipment used in, on, for or about the performance of the Public Project, and will pay for all work and labor I -F- I Agreement No. 5747 thereon. 4. This bond is conditioned upon and guarantees due compliance with all applicable law including, without limitation, the El Segundo Municipal Code ("ESMC"). 5. suiu-,Ty'. for value received, agrees that no changes, extensions of tinle, alteration or modification of SPECIFICATIONS NO. PW 19-10, or of the obligation to be performed will in any way affect its obligation on this bond, and it waives notice of any such change, extension of time, alteration or modification of the contract docurnents or of the obligation to be performed. 6. This bond consists of this instrument; the plans and specifications identified above; and the following TWO (2) attached exhibits all of which are incorporated herein by reference: A. A certified copy of the appointment, power of attorney, bylaws or other instrument entitling or authorizing the persons executing this bond to do so; and B. A certificate isst,ied by the county cled< for the county in which SLJRETY's representative is located conforming with California Code of Civil Procedure § 995.6,40 and stating that StJRETY's certificate of authority has not been surrendered, revoked, cancelled, annulled, or suspended, or in the event that it has, that renewed authority has been granted. 7. Should PRINCIPAL perform its obligations within the time allowed, PRINCIPAL's obligation will be void upon the acceptance of the performance by CITY; otherwise this obligation will remain in full force and effect. [SIGNATURES ON FOLLOWING PAGE] I -F-2 SIGNED AND SEALED this day of PRINCIPAL's PRESIDENT PRINCIPAL's SECRETARY PRINCIPAL's MAILING ADDRESS: Agreement No. 5747 Im SURETY's PRESIDENT SURETY's SECRETARY SURETY's MAILING ADDRESS: NOTE: (1) ALL, signatures must be acknowledged by a notary public. Return one (1) original to City Clerk's Office. (2) Bond shall be effective for one (1) year after acceptance of the job, I -F-3 Agreement No. 5747 SECTION 11- GENERAL REOUTRE MENTS CITY OF EL SEGUNDO PUBLIC WORKS DEPARTMENT GENERAL SPECIFICATIONS 1. REGISTRATION OF CONTRACTORS No bid will be accepted from a Contractor who has not been licensed in accordance with the provisions of the laws of the State of California relating to licensing of contractors, for the type of work to be performed under this Contract. 2. INSURANCE AND ci"ry BUSINESS LICENSE Contractor and Sub -Contractors will obtain appropriate insurance and a City Business License before execution of the construction contract. 3. EMERGENCY INFORMATION The names, addresses and telephone numbers of the CONTRACTOR and subcontractors, or their representatives, will be filed with the City Engineer and the City Police Department BEFORE PERFORMING WORK. 4. FURNISHING OF WATER Water necessary for the prosecution of the work as herein specified will be furnished by the City in the following manner: The CONTRACTOR will deposit with the City Water/Wastewater Division the sum of One Thousand Four Hundred Forty -Four Dollars ($1,444.00) to insure against damage to a 2 V2" Fire Hydrant water meter which will be furnished and installed by the City at a point convenient to the site of the work. This deposit will be refunded to the CONTRACTOR upon completion of the Project if, after removal and inspection or said meter by the City, it is found to be in satisfactory condition. In event of damage to this meter while under the jurisdiction of the CONTRACTOR, all or any part of said deposit may be retained by the City. A non-refundable Activation Fee of One Hundred Ten Dollars ($110.00) will be charged upon activation of the temporary meter. 5. CALIFORNIA - OCCUPATIONAL SAFf"ITY & 1-1EAUT11 ADMINIS'"I'RA"rlO,N All work performed under this contract will be done in strict compliance with the Cal -OSHA Rules and Regulations, latest edition. 11-A-1 Agreement No. 5747 6. SOUND CONTROL The Contractor will comply with all local sound control and noise level rules, regulations and ordinances that apply to any work performed pursuant to the contract. Each internal combustion engine, used for any purpose on the Project or related to the Project, will be equipped with a muffler of a type recommended by the rnallufacturer. No internal combustion engine will be operated on the Project without said muffler. The use of loud signals will be avoided in favor of light warnings except those required by safety laws for the protection of personnel. 7. AIR POLLUTION CONTROL The Contractor is put on notice that he must abide by all existing rules and regulations of the SCAQMD (South Coast Air Quality Management District), relating to all operations or equipment which discharge visible emissions or solid or liquid particles to the atmosphere. 8. WORKER UNIFORMS All workers under the employment of the Contractor or his/her Sub -Contractor will wear an orange vest or an orange shirt while working in the public right-of-way. 11-A-2 Agreement No. 5747 CITY OF EL SEGUNDO PUBLIC WORKS DEPARTMENT GENERAL PROVISIONS 0-0 STANDARD SPECIFICATIONS 0-1 GENERAL Except as modified by these Standard Specifications, the provisions of the latest edition of the "Standard Specifications for Public Works Construction" and its supplements prepared and promulgated by the Southern California Chapters of the American Public Works Association and the Associated General Contractors of America, constitute the Standard Specifications for this project. 0-2 NUMBERING OF SECTIONS The numbering contained within the Standard Specifications of the Contract Documents is intended to correspond with Greenbook numbering. 0-3 MODIFICATIONS To the extent that the provisions of the Contract Documents conflict with the Greenbook, the Contract Documents take precedence. 1-2 DEFINITIONS The following subsection is added to Subsection 1-2 of the Greenbook. 1-2.1 ADDITIONAL, DEFINITIONS Acceptance — The date on which the City Council accepts the Work as complete. Architect, Design Engineers, Soils Engineer, Structural Engineers - Advisors employed by the City. Bidder - Any individual, firm, partnership, corporation, or combination thereof, submitting a proposal for the work contemplated, acting directly or through a duty authorized representative. City Council - The body constituting the awarding authority of the City. Compensable Delay -- a delay entitling the Contractor to an adjustment of the Contract Sum and an adjustment of the Contract Time in accordance with this Agreement. 11-B-1 Agreement No. 5747 Due Notice - A written notification, given in due time, of a proposed action where such notification is required by the contract to be given a specified interval of time (usually 48 hours or two working days) before the commencement of the contemplated action. Notification may be from Engineer to Contractor or from Contractor to Engineer. Engineer - The City Engineer, or designee, as defined in the Greenbook. Unless otherwise provided, all correspondence and decisions made relative to the contract will be by the City Engineer or his designated representative. Greenbook — The most recent edition of the Standard Specifications for Public Works Construction. PCC — California Public Contract Code. Prompt - The briefest interval of time required for a considered reply, including time required for approval of a governing body. Public Works Director — The City's Public Works Director, or designee. ❑ (Check if applicable) State Standard Specifications - State of California Standard Specifications, dated July 1992, Business and Transportation Agency, Department of Transportation Working Days - A working day is defined as any day, except Saturdays, Sundays, legal holidays and days when work is suspended by the Engineer, as provided in Subsection 6-3 and days determined to be non -working in accordance with Subsection 6-7, "Time of Completion." 1-3 ABBREVIATIONS The following Subsection is added to Subsection 1-3 of the Greenbook. 1-3.1 The following abbreviations are added to Subsection 1-3 of the Greenbook: AAN American Association of Nurserymen AGC Associated General Contractors of America AISC American Institute of Steel Construction APWA American Public Works Association ASME American Society of Mechanical Engineers IEEE Institute of Electric and Electronic Engineers NEC National Electric Code Green Book The most current edition of the Standard Specification for Public Works Construction, and subsequent supplements prepared by Southern California Chapters of AGC and APWA WATCH Work Area Traffic Control Handbook SPPWC Standard Plans for Public Works Construction by the American Public Agreement No. 5747 Works Association current edition and subsequent supplements ASA American Standard Association CITY City of El Segundo SSP State of California Standard Plans, current edition SSS State of California Standard Specifications, current edition SECTION 2 — SCOPE AND CONTROL OF WORK The following subsections 2-1.1 and 2-1.2 are added to the Greenbook. 2-1.1 ACCESS TO PROJECT SITE Not later than the date designated in the current Contract Schedule submitted by the Contractor, the City will provide access to the real property and facilities upon which the Work is to be performed, including access to real property and facilities designated in the Contract Documents for the Contractor's use. 2-1.2 OWNERSHIP AND USE OF CONTRACT DOCUMENTS. The Contract Documents and all copies furnished to or provided by the Contractor are the City's property and may not be used on other work. 2-3 SUBCONTRACTS Subsection 2-3 Subcontractors of Greenbook is deleted in its entirety and replaced with the following subsection. 2-3.1 GENERAL Except as provided in PCC §§ 4100 et. seq., each bidder will file with its bid the name and location of the place of business of each subcontractor who will perform work or labor or render service to the prime contractor in or about the construction of the work or improvement, or a subcontractor licensed by the State of California who, under subcontract to the prime contractor, specifically fabricates and installs a portion of the work or improvement according to detailed drawings contained in the plans and specifications, in an amount in excess of one-half of one percent of the prime contractor's total bid. Only one subcontractor will be listed for each portion of the work, which portion will be defined in the bid. In each instance, the nature and extent of the work to be sublet will be described. The failure ofthe Contractor to specify a subcontractor, or the listing of more than one subcontractor for the same portion of the work, constitutes an agreement by the Contractor that it is fully qualified to perform that portion itself and that it will perform that portion itself. The Contractor must have the City Council's written consent to substitute a subcontractor other than that designated in the original bid, to permit any subcontract to be assigned or transferred, or to allow a subcontract to be performed by other than the II -B-3 Agreement No. 5747 original subcontractor. Subcontracting of work fbr which no subcontractor was designated in the original bid, and which is more than one-half of one percent of the work, will be allowed only in cases of public emergency or necessity, and then only after a finding reduced to writing as a public record of the City Council setting forth the facts constituting the emergency or necessity. Violation of any of the above provisions will be considered a breach of the Contract, and the City may terminate the Contractor's control over the Work, cancel the contract, or assess the Contractor a penalty of not more than ten percent of the subcontract involved. All persons engaged in the work, including subcontractors and their employees will be considered as ernployces of the Contractor, The Contractor will be solely responsible for and have control over construction means, methods, techniques, sequences., procedures, and the coordination of all portions of the Work. The City will deal directly with, and make all payments to, the prime Contractor. When subcontracted work is not being prosecuted in a satisfactory manner, the Contractor will be notified to take corrective action. The Engineer may report the facts to the City Council. If the City Council so orders, and on receipt by the Contractor of written instructions from the Engineer, the subcontractor will be removed immediately from the Work. That subcontractor will not again be employed on the Work. If licensure or proper licensure is controverted, then proof of licensure pursuant to this section must be made by production of a verified certificate of licensure from the Contractors' State License Board which establishes that the individual or entity bringing the action was duly licensed in the proper classification of contractors at all times during the performance of any act or contract covered by the action. Nothing in this subdivision reqLiires any person or entity controverting licensure or proper licensure to produce a verified certificate. When licensure or proper licensure is controverted, the burden of proof to establish licensure or proper licensure is on the licensee. 2-3.2 ADDY'RONAL RESPONSIBILITY Add the following to Subsection 2-3.2 Additional Responsibility: The Contractor will submit experience statements for each subcontractor who will perform contract work that amounts to more than ten percent (10%) of the Work. 2-4 CONTRACT BONDS, The following paragraph is added to Subsection 2-4 of the Greenbook. The Faithful Performance Bond and the Labor and Materials Bond must be paid up and in effect for one year after the acceptance of the job by the City in accordance with the 11-B-4 Agreement No. 5747 guarantee required by Subsection 6-8.1. 2-5 PLANS AND SPEC IFICA"I"IONS Subsection 2-5.1 of the Greenbook is replaced by the following subsection. 2-5.1 GENERAL The Contractor will maintain the following at the Work site: One as -built copy of the Plans and Specifications, in good order and marked to record current changes and selections made during construction. As -built plans are to be submitted to the City representative for approval prior to acceptance of the project as complete. 2. The current accepted Contract Schedule. 3. Shop Drawings, Product Data, and Samples. 4. Approved permits from other agencies, including Cal -OSHA permits for trench shoring. 5. All other required submittals. The Plans, Specifications, and other Contract Documents will govern the Work. The Contract Documents are intended to be complementary and cooperative and to describe and provide for a complete project. Anything in the Specifications and not on the Plans, or on the Plans and not in the Specifications, will be as though shown or mentioned in both. Payment for any items on the plans for which there are no specific bid item will be included in the various items of work or in any item to which it is appurtenant. If the Contractor performs any work which it knows or should know involves an error, inconsistency, or omission without notifying and obtaining written consent from the Engineer, the Contractor will be responsible for the resulting losses, including, without limitation, the costs of correcting defective work. 2-5.2 PRECEDENCE OF CONTRACT DOCUMENTS The following paragraph is added to subsection 2-5.2 of the Greenbook: As the figured dimensions shown on the plans and in the specifications of the Contract may not in every case agree with scaled dimensions, the figured dimensions will be followed in preference to the scaled dimensions, and plans to a large scale will be followed in preference to the plans to a small scale. Should it appear that the work to be 11-B-5 Agreement No. 5747 done, or any of the matters relative thereto, are not sufficiently detailed or explained in the Contract, the Contractor will apply to the Engineer for such further explanations as may be necessary, and will conform thereto as part of the Contract so far as may be consistent with the terms thereof. Any items shown on drawings and not mentioned in the specifications will be of like effect as if shown or mentioned in both. 2-5.5 ACC(.;'RACY OF PLANS AND SPECIFICATIONS Although it is believed that much of the information pertaining to conditions and existing utilities that may affect the cost of the Work will be shown on the Plans or indicated in the Specifications, the City does not warrant the completeness or accuracy of such information. The Contractor will carefully study and compare each of the Contract Documents with the others and with information furnished by the City and will promptly report in writing to the Engineer any errors, inconsistencies, or omissions in the Contract Documents or inconsistencies with applicable law observed by the Contractor. The Contractor will take field measurements, verify field conditions, perform soil investigations, and carefully compare with the Contract Documents such field measurements, conditions, and other information known to the Contractor before commencing the Work. Errors, inconsistencies, or omissions discovered at any time will be promptly reported in writing to the Engineer. 2-8 RIGHT-OF-WAY The following subsection is added to Subsection 2-8 of the Greenbook. 2-8.1 ADDITIONAL WORK AREAS AND FACILITIES When the Contractor arranges for additional temporary work areas and facilities, the Contractor will provide the City with proof that the additional work areas or facilities have been left in a condition satisfactory to the owner(s) of said work areas or facilities before acceptance of the work. 2-9 SURVEYING Subsection 2-9.3, Survey Service, is deleted in its entirety and replaced by the following subsection: 2-9.3 St.JRVEY SERVI('.E 2-9.3.1 CONS]" RI.JCTION SURVEYING The Contractor will provide for all construction surveying required to layout, monitor and complete the work. The surveying will be performed by a Land Surveyor or Civil H= Agreement No. 5747 Engineer authorized to practice land surveying by the State of California. The Project Benchmark is shown on the plans. The Contractor will establish all necessary control lines based on the plans and record information on file with the County of Los Angeles Surveyor and the Engineer. It is the responsibility of the Contractor to protect the survey control as shown on the plans. If the survey control is destroyed or disturbed during construction, the Contractor will provide for resetting them and file appropriate documents with the County of Los Angeles at the direction of the Engineer. Computations, survey notes, and other data used to accomplish the work will be neat, legible and accurate. Copies of all computations, survey notes, and other data (electronic format may be required) will be furnished to the Engineer before beginning work that requires their use. 2-9.3.2 MEASUREMENT AND PAYMENT Construction Survey — Unless a separate bid item is provided, payment will be considered included in the other items of the bid and no additional payment will be made therefore. 3-3.2.2 BASIS FOR ESTABLISHING COSTS Subsection 3-3.2.2 (c), Tool and Equipment Rental is modified where the second and third paragraphs are replaced with "Regardless of ownership, the rates to be used in determining the equipment usage costs will not exceed those listed for the same or similar equipment in the California State Department of Transportation publication of Labor Surcharge and Equipment Rates effective for the period of usage." 3-3.2.3 MARK UP Subsection 3-3.2.3, Mark Up, is deleted in its entirety and replaced by the following subsection: (a) Work by Contractor. The following percentages will be added to the Contractor's costs and will constitute the markup for all overhead and profits. 1) Labor ............................................20 2) Materials ..................................... J5 3) Equipment Rental ......................... 15 4) Other Items and Expenditures ...... 15 To the sum of the costs and markups provided for in this subsection, I percent will be added as compensation for bonding. No other formula, e.g., the Eichleay or other method, may be used to calculate daily damages for office overhead, II -B-7 Agreement No. 5747 profit, or other purported loss. (b) Work by Subcontractors. When all or any part of the extra work is performed by a Subcontractor, the markup established in 3-3.2.3(a) will be applied to the Subcontractor's actual cost of such work. A markup of 10 percent on the first $5,000 of the subcontracted portion of the extra work and a markup of 5 percent on work added in excess of $5,000 of the subcontracted portion of the extra work may be added by the Contractor. (c) In the event that City becomes liable to Contractor for compensable delays, City agrees to pay Contractor the daily Contractor Delay Damages set forth in the Bid Form or Contractor's actual daily delay damages, whichever is less, for each day of Compensable Delay as provided for by these Contract Documents. 3-3.3 DAILY REPORTS BY CONTRACTOR Add the following paragraph to subsection 3-3.3, Daily Reports by Contractor: If disagreement continues regarding extra work, the Contractor may seek compensation in accordance with the Claims procedure. Daily Reports required by this subsection must be made part of the Claim as supporting data for the Claim. 3-4 CHANGED CONDITIONS Subsection 3-4, Changed Conditions, is deleted in its entirety and replaced with the following subsection: If the Contractor encounters concealed or unknown conditions that differ materially from those anticipated or expected ("changed conditions"), the Contractor will immediately notify the Engineer in writing of such changed conditions (upon discovery and before disturbing such changed conditions), as provided in Subsection 6-11, so that the Engineer can determine if such conditions require design details that differ from those design details shown in the Contract Documents. Notwithstanding the thirty (30) day time period set forth in Subsection 6-11.3, the Contractor will be liable to the City for any extra costs incurred as a result of the Contractor's failure to promptly give such notice. Changed conditions will include, without limitation, the following: Subsurface or latent physical conditions differing materially from those represented in the Contract Documents; 2. Unknown physical conditions of an unusual nature differing materially from those ordinarily encountered and generally recognized as inherent in work of the character being performed; and II -B-8 Agreement No. 5747 3. Material differing from what is represented in the Contract which the Contractor believes may be hazardous waste as defined in California Health & Safety Code § 25117 that is required to be removed to a Class 1, 11, or III disposal site in accordance with applicable law. The Engineer will promptly investigate conditions that appear to be changed conditions. The Engineer's decision, and any dispute regarding that decision, will be made in accordance with Section 6-11 except that the Engineer will render a decision promptly. Any information provided pursuant to INFORMATION AVAILABLE TO BIDDERS is subject to the following provisions: The information is made available for the Bidders' convenience and is not a part of the Contract. 2. The City has not determined the accuracy or completeness of such information and all such information is made available to Bidders without any representation or warranty by the City whatsoever as to its accuracy, completeness, or relevancy. 3. Bidders will independently evaluate such information for their use and will be solely responsible for use or interpretation of such information. Any such use or interpretation will not be the basis of any claim against the City. 3-5 DISPUTED WORK Subsection 3-5 is deleted in its entirety and replaced by the following subsection. If the Contractor and the City do not reach agreement on disputed work, the City may direct the Contractor to proceed with the work. Any payment for the disputed work will be determined pursuant to the claims procedures in these Standard Specifications. Although not to be construed as proceeding under extra work provisions, the Contractor will keep and furnish records of disputed work as required by the Contract Documents. 4-1.3 INSPECTION lel! MIRENIENTS Subsection 4-1.3, Inspection Requirements, is deleted in its entirety and replaced by the following subsections. 4-1.3.1 GENERAL Unless otherwise specified, inspection at the source of production for such materials and fabricated items as bituminous paving mixtures, structural concrete, fabricated metal products, cast metal products, Welding. reitilorced and unrei n forced concrete pipe, application ofprotecLive coatings,, and similar shop and plant, operations is not required. A certificate of compliance, signed by an authorized officer of the producer, certifying Agreement No. 5747 compliance with the contract documents will be submitted for all of the following materials: steel pipe, sizes less than 18 inches; vitrified clay pipe; asbestos cement pipe; cast iron pipe; reinforced concrete pipe; non -reinforced concrete pipe; and PVC sewer and water pipe; subject to sampling and testing by City. Standard items of equipment, such as electric motors, conveyors, plumbing fittings and fixtures, lumber, plywood, and so on, are subject to inspection at the job site. All other equipment items will be inspected and tested in accordance with the contract documents. The City does not provide full time inspection. The Contractor will provide 24-hour minimum notice for each inspection required by the work unless other arrangements have been agreed upon, in writing, with the City Engineer. Any inspection required outside of normal working hours and days, including holidays, will be at the Contractor's cost at rates established by the City. 4-1.3.2 INSPECTION OF MATERIALS NO]" PRODUCED LOCALLY Contractor purchased materials, fabricated items, and equipment, produced at sources located more than 50 miles outside the corporate limits of the City, and which are specified to be inspected in the Contract! Documents, will be inspected by inspectors or testing laboratories arranged for and paid for by City. Report ofsuch inspection must be submitted to the City. If any item inspected fails to meet the specified criteria, the Contractor will pay all costs for reinspection, and such costs may be deducted from payments due to the Contractor. 4-1.6 TRADE NAMES OR EQUALS Whenever any material, product, equipment, or service is specified by brand, trade, or proprietary name, the item so specified will be deemed to be followed by the words "or equal". For the City's consideration of a proposed "equal" item, the Bidder will submit, a minimum of ten (10) calendar days before the date of the bid opening, documentation of the particulars of the proposed "equal item". At a minimum, the submitted documentation will include: • Written request with explanation of why the product should be considered as an equal product. • Material specifications. • Technical specifications. • Test data. • Samples. al Comparison chart of key specifications of the "equal" item against similar specifications of the specified item. 11-B-10 Agreement No. 5747 Work locations and reference telephone numbers of at least three (3) locations where the proposed "equal" item has been recently installed under similar conditions. a Warranty data. The Bidder will be notified by the Engineer whether or not the proposed "equal" product is acceptable to the City rive (5) calendar days before the date of the bid opening. Failure to submit all required documentation and/or submittal of incomplete documents may result in the City's rejection of the proposed "equal" product without further consideration. 5-2 PROTECTION The following subsection is added to Subsection 5-2 of the Greenbook. 5-2.1 INCORRECT LOCATION OF UTILITIES If the Contractor, while performing the Work, discovers utility facilities not identified correctly or not shown in the contract plans or specifications by the City, the Contractor will immediately notify the City and utility owner in writing. 5-4 RELOCATION The following subsection is added to Subsection 5-4 of the Greenbook. 5-4.1 RESPONSIBILITY OFUTILFFY REMOVAL GIS RELOCKFION The City will be responsible to arrange for the removal, repair, or relocation of existing utilities located within the project limits if such utilities are not correctly identified in the contract plans or specifications by the City. The City will have the sole discretion to perform repairs or relocation work or permit the Contractor to do such repairs or relocation. 5-5 DELAYS The following paragraphs are added to Subsection 5-5 of the Greenbook. Actual loss, as used in this Subsection, will be understood to include no items of expense other than idle time of equipment and necessary payments for idle time of workers, cost of extra moving of equipment, and cost of longer hauls. Compensation for idle time of equiprnent and idle time of"workers will be determined by Subsection 5-5.1 and no markup will be added in either case for overhead and profit. The Cost of extra moving of equipment and the cost of longer hauls will be paid for as extra work. The following subsection is added to Subsection 5-5 of the Greenbook. 11-B- I I Agreement No. 5747 5-5.1 CALCULATING IDLE TIME Equipment idle time will calculated in accordance with Subsection 3-3.2.2(c) and based upon the actual normal working time during which the delay condition exists, but in no case will exceed 8 hours in any one day. The days for which compensation will be paid will be the calendar days, excluding Saturdays, Sundays and legal holidays, during the existence of the delay. Worker idle time will be calculated in accordance with Subsection 3-3.2.2(a), 6-1 CONSTRUCTION SCHEDULE AND COMMENCEMENT fila" WORK Section 6-1, Construction Schedule and Commencement of Work, is deleted in its entirety and replaced by the following subsections. Pre -Construction Meetina: A fte r contract award, the City w i II at -range for a pre -construction meeting to discuss the construction of the pro.ject. City will invite utility agencies and the contractor will arrange for all of its sub -contractors to attend the meeting. 6-1.1 CONTRACT SCIJEDULE After notification of award and before starting any work, the Contractor will submit a Contract Schedule to the Engineer for review, as required by these Specifications within fifteen (15) days of award. 6-1.2 CONTENTOF CONTRACTSCHEDULE The Contract Schedule, and any updated Contract Schedule, will meet the following requirements: 1. Schedules must be suitable for monitoring progress of the Work. 2. Schedules must provide necessary data about the time for the Engineer's decisions. 3. Schedules must be sufficiently detailed to demonstrate adequate planning for the Work. 4. Schedules must represent a practical plan to complete the Work within the Contract Time. 5. Schedules must show the critical path method for completing the Work. The Engineer's review of the form and general content of the Contract Schedule and any updated Contract Schedules is only for the purpose of determining if the listed requirements are satisfied, nothing more, 6-1.3 EFFECT OF CONTRACTSCHL,"DULE 11-B-12 Agreement No. 5747 The Contract Schedule, and any updated Contract Schedules, will represent a practical plan to complete the Work within the Contract Time, Extension of any schedule beyond the Contract Time will not be acceptable. Schedules showing the Work completed in less than the Contract may be acceptable if Judged by the Engineer to be practical. Acceptance of such a schedule by the Engineer will not change the Contract Time. The Contract Time, not the Contract Schedule, will control in determining liquidated damages payable by the Contractor and in determining any delay. If a schedule showing the Work completed in less than the Contract Time is accepted, the Contractor will not be entitled to extensions of the Contract Time for Excusable Delays or Compensable Delays or to adjustments of the Contract Sum for Compensable Delays until such delays extend the completion of the Work beyond the expiration of the Contract Time. The Contractor will plan, develop, supervise, control, and coordinate the performance of the Work so that its progress and the sequence and timing of Work activities conform to the current accepted Contract Schedule. The Contractor will continuously obtain from Subcontractors information and data about the planning for and progress of the Work and the delivery of equipment, will coordinate and integrate such information and data into updated Contract Schedules, and will monitor the progress ofthe Work and the delivery of equipment. The Contractor will act as the expeditor of potential and actual delays, interruptions, hindrances, or disruptions for its own lorces and those forces of' Subcontractors. The Contractor will cooperate with the Engineer in developing the Contract Schedule and updated Contract Schedules. The Engineer's review and comments about any schedule or scheduling data will not relieve the Contractor from its sole responsibility to plan for, perform, and complete the Work within the Contract Time. Review and comments about any schedule will not transfer responsibility for any schedule to the Engineer or the City nor imply their agreement with (1) any assumption upon which such schedule is based or (2) any matter underlying or contained in such schedule, The Engineer's failure to discover errors or omissions in schedules that have been reviewed, or to inform the Contractor that the Contractor, Subcontractors, or others are behind schedule, or to direct or enforce procedures for complying with the Contract Schedule will not relieve the Contractor from its sole responsibility to perform and complete the Work within the Contract Time and will not be a cause for an adjustment of the Contract Time or the Contract Sum. The Contractor will perform the Work in accordance with the currently accepted Contract Schedule. 6-1.4 COMMENCEMENT OF CONTRACT TIME The Contract Time will commence when the City issues a Notice to Proceed. The Work 11-B-13 Agreement No. 5747 will start on the date specified in the Notice to Proceed and within a maximum of fifteen (15) days after the date of the Notice to Proceed, and be diligently prosecuted to completion with the time provided in the Specifications. 6-4 DEFAULT BY CONTRACTOR The language in subsection 6-4 is deleted in its entirety and replaced with the following subsections. 6-4.1 GENERAL Should the Contractor fail to begin delivery of material and equipment, to commence the Work within the time specified, to maintain the rate of delivery of material, to execute the Work in the manner and at such locations as specified, or fail to maintain the Work schedule (as determined by the current accepted Contract Schedule) which will ensure the City's interest, or if the Contractor is not carrying out the intent of the Contract, the City may serve written notice upon the Contractor and the Surety on its Faithful Performance Bond demanding satisfactory compliance with the Contract. 6-4.2 TERINIFNATION OF CONTRACTOR'S CONTROL OVER "rHE WORK The City may terminate the Contractor's control over the Work without liability for damages when, in the City's opinion, the Contractor is not complying in good faith, has become insolvent, or has assigned or subcontracted any . part of the Work without the City's consent. Should SUchterinination occur, the Contractor will be paid the actual amount due based on Contract Unit Prices or lump sums bid and the quantity and quality of the work completed and in place at the time of termination, less damages caused to the City by the Contractor's action or inaction. In the event of such termination of control, the City may do any one, or combination of, the following: 1. Serve written notice upon the Surety on its Faithful Performance Bond demanding satisfactory compliance with the Contract. In such event the Surety will, within 5 days, assume control and perform the Work as successor to the Contractor; 2. The City may perform the Work itself and deduct the cost thereof from any payment due to the Contractor; 3. The City may replace the Contractor with a different contractor to complete the work and deduct the cost thereof from any payment due to the Contractor. Nothing herein will waive, or serve as a limitation upon, any additional remedy the City may have under these Contract Documents or applicable law. 11-B-14 Agreement No. 5747 6-4.3 SURETY'S ASSUMPTION OF CONTROL Should the Surety assume any part of the Work, it will take the Contractor's place in all respects for that part, and will be paid by the City for all work performed by it in accordance with the Contract. If the Surety assumes the entire Contract, all money due the Contractor at the time of its default will be payable to the Surety as the Work progresses, subject to the terms of the Contract. If the Surety does not assume control and perform the Work within 5 days after receiving notice of cancellation, or fails to continue to comply, the City may exclude the Surety from the premises. The City may then take possession of all material and equipment and complete the Work by City's forces, by letting the unfinished work to another contractor, or by a combination of such methods. In any event, the cost of completing the Work will be charged against the Contractor and its Surety and may be deducted from any money due or becoming due from the City. If the sums due under the Contract are insufficient for completion, the Contractor or Surety will pay to the City within 5 days of completion, all costs in excess of the sums due. The provisions of this subsection will be in addition to all other rights and remedies available to the City under applicable law. 6-6 DELAYS AND EXTENSIONS OF TIME Subsections 6-6.1 to 6-6.4 are deleted and replaced with the following subsections. 6-6.1 GENERAL If delays are caused by unforeseen events beyond the control of the Contractor, such delays will entitle the Contractor to an extension of time as provided herein, but the Contractor will not be entitled to damages or additional payment due to such delays except as otherwise provided herein. Excusable delay may include: war, earthquakes exceeding 3.5 on the Richter Scale, government regulation, labor disputes outside the contemplation of the parties, strikes outside the contemplation of the parties, fires, floods, changes to the Work as identified herein, or other specific events that may be further described in the Specifications. Delays to the project caused by labor disputes or strikes involving trades not directly related to the project, or involving trades not affecting the project as a whole will not warrant an extension of time. The City will not grant an extension of time for a delay by the Contractor's inability to obtain materials unless the Contractor furnishes to the Engineer documentary proof. The proof must be provided in a timely manner in accordance with the sequence of the C'ontractor's operations and accepted construction schedule. Should delays be caused by events other than those included herein, the Engineer may, fl -B-15 Agreement No. 5747 but is not required to, deem an extension of time to be in the City's best interests. 6-6.2 EXTENSIONS OF TIME If granted, extensions of time will be based upon the effect of delays to the critical path of the Work as determined by the current accepted Contract Schedule. Delays to minor portions of the Work that do not affect the critical path will not be eligible for extensions of time. 6-6.3 PAYMENT FOR DELAYS TO, CONTRACTOR Any payment for compensable delay will be based upon actual costs as set forth in Subsection 5-5 excluding, without limitation, what damages, if any, the Contractor may have reasonably avoided. The Contractor understands that this is the sole basis for recovering delay damages and explicitly waives any right to calculate daily damages for office overhead, profit, or other purported loss, using different formulas including, without limitation, the Eichleay Formula. 6-6.4 WRITTEN NOTICE AND REPORT If the Contractor desires payment for a delay or an extension of time, it will give the Engineer written notice of such request not later than the time limit set forth in the Proposal for submitting a claim after the event or occurrence giving rise to a delay claim. Failure to submit a written request within such amount of time will result in the Contractor waiving its delay claim. Any claim for payment or an extension of time must be in the form required by the "Claims" sections of these Specifications. In no event will the City grant the Contractor an extension of time if the delay is within the Contract Time as identified by the Contract Documents. 6-7.2 WORK DAYS AND WORKING HOURS City Hall is open from Monday thru Thursday lam -6pm. It is closed every other Friday and the following holidays: New Year's Day Martin Luther King, Jr. Day President's Day Memorial Day Independence Day Labor Day Veterans' Day Thanksgiving Christmas Eve II -B-16 Agreement No. 5747 Christmas New Year's Eve Working on Fridays when City Hall is closed is acceptable; however, if the Contractor requests an inspection a day when City Hall is closed, then the Contractor will have to reimburse the City for the costs of inspection. The Contractor must request such an inspection at least 48 hours in advance. City inspections during hours when City Hall is closed are subject to inspection overtime fees to be paid for by the Contractor. Friday work that does not require inspection can be done without an inspection fee and must be discussed with City staff prior to its occurrence. If the Contractor does construction on a Friday or a day when City Hall is closed, that day shall be counted as a project working day. On workdays, Contractor's activities will be confined to the hours between 7:00 a.m. and 4:00 p.m. Please see Section 6-7.5 below for weekend and holiday work restrictions. 6-7.4 NIGiIT' WORK The following paragraph is added to Section 6-7 of the Greenbook: The City will not permit Work between the hours of 4 p.m. and 7 a.m. of the following day unless specifically provided for in the bid documents or unless the Contractor receives prior written approval. 6-7.5 WEEKEND AND HOLIDAY WORK The Engineer may, but is not required to, allow the Contractor to work on Saturdays, Sundays and City Holidays. 6-8 COMPLETION AND ACCEPTANCE Subsection 6-8 is deleted in its entirety and replaced by the following: The Work will be inspected by the Engineer for acceptance upon the Engineer receiving the Contractor's written assertion that the Work is complete. If, in the Engineer's judgment, the Work is complete and is ready for acceptance, the Engineer will accept the Work on behalf of the City in the manner prescribed by the City. The Engineer will recommend approval of the Notice of Completion to the City Council. This will be the date when the Contractor is relieved from responsibility to protect the Work. All work will be guaranteed by the Contractor against defective workmanship and materials furnished by the Contractor for a period of I year from the date the Work was II -B-17 Agreement No. 5747 completed. The Contractor will replace or repair any such defective work in a manner satisfactory to the Engineer, after notice to do so from the Engineer, and within the time specified in the notice. If the Contractor fails to make such replacement or repairs within the time specified in the notice, the City may perform this work and the Contractor's sureties will be liable for the cost thereof. 6-8.1 GENERAL GUARANTY The Contractor will remedy any defects in the work and pay for any damage to other work resulting therefrom, which will appear within a period of one year from the date of final acceptance of the work unless a longer period is specified. The owner will give notice of observed defects with reasonable promptness. 6-9 LJOUIDATED DAMAGES Subsection 6-9, Liquidated Damages, of the Greenbook is deleted in its entirety and replaced by the following subsections. 6-9.1 FAIL[jRE TO COMPLETE WORK ON -riME If all the work called for under the contract is not completed before or upon the expiration of the Contract 'Time, the City will sustain damage. Since it is and will be impracticable to determine the actual damage which the City will sustain in the event of and by reason of such delay, it is therefore agreed that the Contractor will pay to the City the sum specified in the Proposal for each and every calendar day beyond the time prescribed to complete the work not as a penalty. but as a predetermined liquidated damage. The Contractor agrees to pay such liquidated damages as are herein provided, and in case the same are not paid, agrees that the City may deduct the amount thereof from any money due or that may become due to the Contractor under the contract. Unless otherwise specified, liquidated damages will be $250 per calendar day. 6-11 DISPUTES AND, CLAIMS: PROCEDURE 6-11.1 GENERAL Consistent with PCC § 10240.6, "Claim" means a written demand or assertion by the Contractor that seeks an adjustment or interpretation of the terms of the Contract Documents, payment of money, extension of time, or other relief with respect to the Contract Documents, including a determination of disputes or matters in question between the City and the Contractor arising out of or related to the Contract Documents or the performance of the Work, and claims alleging an unforeseen condition or an act, error, or omission by the City, the Engineer, their agents or employees. "Claim" does not mean, and the Claims procedures herein do not apply, to the following: Claims respecting penalties for forfeitures prescribed by statute or regulations, 11-B-18 Agreement No. 5747 which a government agency is specifically authorized to administer, settle, or determine. 2. Claims respecting personal injury, death, reimbursement, or other compensation arising out of or resulting from liability for personal injury or death. 3. Claims respecting a latent defect, breach of warranty, or guarantee to repair. 4. Claims respecting stop notices. If a Claim is subject to the Change Order procedures, the Claim arises upon the issuance of a written final decision denying in whole or in part the Contractor's Change Order Request. If a Claim is not subject to the Change Order Procedures, the Claim arises when the Contractor discovers, or reasonably should discover, the condition or event giving rise to the Claim. 6-11.2 FORM A Claim must include the following: A statement that it is a Claim and a request for a decision. 2. A detailed description of the act, error, omission, unforeseen condition, event or other condition giving rise to the Claim. 3. If the Claim is subject to the Change Order procedures, a statement demonstrating that a Change Order Request was timely submitted and denied. 4. A detailed justification for any remedy or relief sought by the Claim, including to the extent applicable, the following: a) If the Claim involves extra work, a detailed cost breakdown claimed. The breakdown must be provided even if the costs claimed have not been incurred when the Claim is submitted. b) To the extent costs have been incurred when the Claim is submitted, the Claim must include actual cost records (including, without limitation, payroll records, material and rental invoices) demonstrating that costs claimed have actually been incurred. C) To the extent costs have not yet been incurred at the time the Claim is submitted, actual cost records must be submitted on a current basis not less than once a week during any periods costs are incurred. A cost record will be considered current if submitted within 7 days of the date the cost reflected in the record is incurred. At the Engineer's request, claimed extra costs may be Subject to further verification procedures (such as having an inspector verify e th I performance of alleged extra work on a daily basis). II -B-19 Agreement No. 5747 If the Claim involves an error or omission in the Contract Documents: a) An affirmative representation that the error or omission was not discovered before submitting a bid for the Contract; and b) A detailed statement demonstrating that the error or omission reasonably should not have been discovered by the Contractor, its Subcontractors and suppliers, before submitting a bid for the Contract. 6. If the Claim involves an extension of the Contract Time, written documentation demonstrating the Contractor's entitlement to a time extension. 7. If the Claim involves an adjustment of the Contract Sum for delay, written documentation demonstrating the Contractor's entitlement to such an adjustment. 8. A personal certification from the Contractor that reads as follows: 441, -, BEING THE (MUST BE AN OFFICER) OF ..... . ....... — (CONTRACTOR NAME), DECLARE UNDER PENALTY OF PERJURY UNDER CALIFORNIA LAW, AND DO PERSONALLY CERTIFY AND ATTEST THAT I HAVE THOROUGHLY REVIEWED THE ATTACHED CLAIM FOR ADDITIONAL COMPENSATION OR EXTENSION OF TIME, AND KNOW ITS CONTENTS, AND SAID CLAIM IS MADE IN GOOD FAITH; THE SUPPORTING DATA IS TRUTHFUL AND ACCURATE; THAT THE AMOUNT REQUESTED ACCURATELY REFLECTS THE CONTRACT ADJUSTMENT FOR WHICH THE CONTRACTOR BELIEVES CITY IS LIABLE; AND, FURTHER, THAT I AM FAMILIAR WITH CALIFORNIA PENAL CODE § 72 AND CALIFORNIA GOVERNMENT CODE § 12650, ET SEQ., PERTAINING TO FALSE CLAIMS, AND FURTHER KNOW AND UNDERSTAND THAT SUBMITTING OR CERTIFYING A FALSE CLAIM MAY LEAD TO FINES, IMPRISONMENT, AND OTHER SEVERE LEGAL CONSEQUENCES." 6-11.3 CLAIMS SLIBMITTED TO ENGINEER Within 30 days after the circumstances giving rise to a Claim occur, the Contractor will submit its Claim to the Engineer for a decision. Regardless of any Claim submittal, or any dispute regarding a Claim, unless otherwise directed by the Engineer, the Contractor will not cause any delay, cessation, or termination of the Work, but will diligently proceed with the performing, the Work in accordance with the Contract Documents. Except as otherwise provided, the City will continue to make payments in accordance with the Contract Documents. 6-11.4 CLAIM IS PREREQL11SITE'ro OTHER REMEDY 11-B-20 Agreement No. 5747 The Contractor certifies that it is familiar with PCC § 10240.2 and understands and agrees that submitting a Claim in accordance with these Specifications is an express condition precedent to the Contractor's right to otherwise pursue a claim whether through alternative dispute resolution or by litigation. Should the Contractor fail to submita claim in accordance with these Specifications, including the tune limits set forth herein, it will waive any right to a remedy, whether in law or equity, it might otherwise have pursuant to the Contract Documents or applicable law. 6-11.5 DECISION ON CLAIMS The Engineer will promptly review Claims submitted by the Contractor in accordance with these Specifications. Should the Engineer require additional supporting evidence to evaluate the claim, the Engineer will request such additional information in writing. Any such requested data will be furnished not later than 10 days after the Contractor receives the Engineer's request. The Engineer will render a decision not later than 60 days after either receiving the Clairn or the deadline for furnishing additional supporting data, whichever is later. Ifthe Engineer fails to render a decision within the time period established herein, then the Claim will be deemed denied. The Engineer's decision will be final and binding unless appealed in accordance with these Specifications. The Engineer's decision on a Claim will include a statement substantially as follows: "This is a decision pursuant to the General Specifications of your contract. If you are dissatisfied with the decision, and have complied with the procedural requirements for asserting claims, you may have the right to alternative dispute resolution or litigation. Should you fail to take appropriate action within 30 days of the date of this decision, the decision will be come final and binding and not subject to further appeal." 6-11.6 APPEAL OFENGINEER'S, DECISION Should the Contractor dispute the Engineer's decision, then the Contractor must appeal that decision to the City's Public Works Director within 30 days of receiving the Engineer's decision. The Public Works Director will address disputes or claims within 30 calendar days after receiving such request and all necessary supporting data. The Public Works Director's decision on the dispute or claim will be the City's final decision. If the Contractor disputes the Public Works Director's decision, then the Contractor must demand alternative dispute resolution in accordance with this Section and the PCC within 30 days of the City's final decision. 6-11.7 MEDIATION 11-B-21 Agreement No. 5747 If the City and the Contractor agree, disputes between the parties may be submitted to non-binding mediation. If the parties cannot agree to an alternative form of mediation, then mediation will be administered by the American Arbitration Association ("AAA") under its Construction Industry Mediation Rules, unless the use of such rules are waived by mutual stipulation of both parties. The parties may, but are not required to be, represented by counsel in mediation. The requirement for mediation will not alter or modify the time limitations otherwise provided for claims and no conduct or settlement negotiation during mediation will be considered a waiver of the City's right to assert that claim procedures were not followed. 6-11.8 ARBITRATION If the City and Contractor do not agree to mediation, then a disputes will be submitted to neutral non-binding (except as provided herein) arbitration. Arbitration will be conducted in accordance with PCC § 10240.3. Any decision rendered by an arbitrator will be consistent with PCC § 10240.8. The exclusive venue for any arbitration will be in Los Angeles County. The expenses and fees of the arbitrators and the administrative fees, if any, will be divided among the parties equally. Each party will pay its own counsel fees, witness fees, and other expenses incurred for its own benefit. 6-11.9 WHEN ARBITRATION DECISION BECOMES BINDING The decision rendered by the arbitrator will become binding upon the parties unless appealed to the Los Angeles County Superior Court pursuant to PCC § 10240.12 within 30 days of the decision. 11'subsequent litigation re:sLi Its in all award to the party appealing the arbitration that is less than or equal to that of the arbitration decision, or if the litigation results in a decision in favor of the nonappealing party, then the party appealing the arbitration will pay the nonappealing party's attorney's fees and court costs. 6-11.10 APPEAL TO SUPERIOR COURT. WAIVER OF J(JRY TRIAI, Should a party timely object to the arbitration decision, it may file a petition with the Los Angeles County Superior Court in accordance with California Code of Civil Procedure (-CCP") §§ 1285, et seq. Notwithstanding the limitations set forth in CCP § 1286.2, the court may vacate, correct, or adjust an arbitration award, and enter judgment in accordance with CCP § 1287.4, for any legal or equitable basis including, without limitation, error of law. The court will apply the substantial evidence standard of review when considering the appeal of an objecting party. BY EXECUTING THESE CONTRACT DOCUMENTS, THE CONTRACTOR 11-B-22 Agreement No. 5747 AGREES TO HAVE DISPUTES OR CONTROVERSY CONCERNING THE CONSTRUCTION, INTERPRETATION, PERFORMANCE, OR BREACH OF THESE CONTRACT DOCUMENTS, INCLUDING CLAIMS FOR BREACH OF CONTRACT OR ISSUES OF BAD FAITH DECIDED IN ACCORDANCE WITH THIS SECTION 6-11. BOTH THE CITY AND THE CONTRACTOR WAIVE THEIR RIGHT TO A JURY TRIAL FOR THESE DISPUTES OR ISSUES. 6-11.11 AB 626 CLAIMS PROCESS Claims made by a Contractor for one or more of the following are subject to the claim resolution process set forth in Public Contract Code section 9204: (A) A time extension, including, without limitation, for relief from damages or penalties for delay assessed by the city under a contract for a public works project. (B) Payment by the city of money or damages arising froin work done by, or Oil behalf of. the contractor pLirsuant to tile contract for a public works project and payment for which is not otherwise expressly provided or to which tile claimant is not otherwise entitled. (C) Payment of an amount that is disputed by the city. 7-2 LABOR The following subsections are added to Subsection 7-2 of the Green Book. 7-2.3 PREVAILING WAGES The Contractor will post at appropriate conspicuous points at the site of the project a schedule showing determinations of tile Director of Industrial Relations of the prevailing rate of per them wages. It will be the Contractor's responsibility to obtain copies of the prevailing rate of per diene wages. One source that may be Used is the California Department of Industrial Relations website which is currently located at www.dir.ca.gov, or by calling the Prevailing Wage Unit at (415) 703-4774. Attention is directed to Labor Code §§ 1777.5, 1777.6 and 3098 concerning the employment of apprentices by the Contractor or any subcontractor. Labor Code § 1777.5 requires the Contractor or subcontractor employing tradesmen in any apprenticeship occupation to apply to the joint apprenticeship committee nearest the site of the public works project and which administers the apprenticeship program in that trade for a certificate of approval. The certificate will also fix the ratio of apprentices to journeymen that will be used in the performance of the contract. The ratio of apprentices to journeymen in such cases will not be less than one to five except: a) When employment in the area of coverage by the joint apprenticeship committee 11-B-23 Agreement No. 5747 has exceeded an average of 15 percent in the 90 days before the request for certificate, or b) When the number of apprentices in training in the area exceeds a ratio of one to five, or C) When the trade can show that it is replacing at least 1/30 of its membership through apprenticeship training on an annual basis state-wide or locally, or d) When the Contractor provides evidence that the Contractor employs registered apprentices on all of his contracts on an annual average of not less than one apprentice to eight journeymen. The Contractor is required to make contributions to funds established for the administration of apprenticeship programs if the Contractor employs registered apprentices or journeymen in any apprenticeable trade on such contracts and if other contractors on the public works site are making such contributions. The Contractor and any subcontractor will comply with Labor Code §§ 1777.5 and 1777.6 in the employment of apprentices. Information relative to apprenticeship standards, wage schedules and other requirements may be obtained from the Director of Industrial Relations, ex -officio the Administrator of Apprenticeship, San Francisco, California, or from the Division of Apprenticeship Standards and its branch offices. 7-2.4 RECORD OF' WAGES PAID: INSPECTION Every Contractor and subcontractor will keep an accurate certified payroll records showing the name, occupation, and the actual per them wages paid to each worker employed in connection with the Work. The record will be kept open at all reasonable hours to the inspection of the body awarding the contract and to the Division of Labor Law Enforcement. If requested by the City, the Contractor will provide copies of the records at its cost. 7-3 LIABILITY INSURANCE Subsection 7-3, Liability Insurance, of the Greenbook is deleted in its entirety and replaced by the following subsections. 7-3.1 GENERAL Contractor will procure and maintain for the duration of the contract the following insurance coverages and limits against claims for injuries to persons or damage to property which may arise from or in connection with the performance of the work covered by this agreement by the Contractor, its agents, representatives, employees or 11-B-24 subcontractors: COVERAGE PER OCCURRENCE Comprehensive General Liability Business Auto Workers' Compensation MTell CL 00 02 01 85 or 88 CA 00 01 01 87 Agreement No. 5747 COMBINED SINGLE LIMIT $2,000,000 $1,000,000 Statutory Contractor will provide endorsements or other proof of coverage for contractual liability. Combined single limit per occurrence will include coverage for bodily injury, personal injury, and property damage for each accident. If Commercial General Liability Insurance or other form with a general aggregate limit is used, the policy will be endorsed such that the general aggregate limit will apply separately to this contract and a copy of the endorsenient provided to the City. Liability policies will contain, or be endorsed to contain the following provisions: GENERAL LIABILITY AND AUTOMOBILE LIABILITY: The City, its officers, officials, employees, agents, and volunteers will be covered as insureds as respects: liability arising out of activities performed by or on behalf of the Contractor; products and completed operations of the Contractor; premises owned, occupied or used by the Contractor; or automobiles owned, ]eased, hired or borrowed by the Contractor. The coverage will contain tic), special limitations on the scope or protection afforded to the City, its officers, officials, employees, agents, or VOlUnteers. The Contractor's insurance coverage will be primary insurance as respects the City, its officers, officials, employees, agents, and volunteers. Any insurance or self-insurance maintained by the City, its officers, officials, employees, agents, and volunteers will be excess of the Contractor's insurance and will not contribute with it. The insurer will agree in writing to waive all rights of subrogation against the City, its officers, officials, employees and volunteers for losses arising from work performed by the Contractor for the City. Any failure to comply with reporting provisions of the policies will not affect coverage provided to the City, its officers, officials, employees, agents and volunteers. The Contractor's insurance will apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. WORKERS' COMPENSATION: 11-B-25 Agreement No. 5747 The insurer will agree to waive all rights of subrogation against the City, its officers, officials, employees and volunteers for losses arising from work performed by the Contractor for the City. ALL COVERAGES: Each insurance policy required by this subsection will be endorsed to state that coverage will not be suspended, voided, cancelled by either party, reduced in coverage or in limits except after thirty (30) days written notice by certified mail, return receipt requested, has been given to: CITY CLERK City of El Segundo 350 Main Street El Segundo, CA 90245 Notwithstanding the foregoing, the endorsement may state that insurance may be cancelled upon ten (10) day notification for non-payment of premium. The Contractor will provide the City with updated proof of insurance should the Contract Time extend beyond the policy expiration date. All liability insurance will be on an occurrence basis. Insurance on a claims made basis will be rejected. Any deductibles or self-insured retentions will be declared to and approved by City. The insurer will provide an endorsement to City eliminating such deductibles or self-insured retentions as respects the City, its officials, employees, agents, and volunteers. Except for Workers Compensation Insurance, Contractor will furnish to City certificates of insurance and endorsements on forms acceptable to the City's City Attorney, duly authenticated, giving evidence of the insurance coverages required in this contract and other evidence of coverage or copies of policies as may be reasonably required by City from time to time. Endorsements must be supplied on ISO Form No. CG 20 10 1185, or equivalent. Certificate/endorsement for Workers Compensation Insurance will be furnished on State Cornp Fund or other industry, standard form. Except for worker's compensation insurance, all insurance required herein will be placed with insurers with a Best's Rating of not less than A:VII. Worker's compensation insurance policies will meet the requirements of California law. All subcontractors employed on the work referred to in this contract will meet the insurance requirements set forth for Contractor. Contractor will furnish certificates of insurance and endorsements for each subcontractor at least five days before the subcontractor entering the job site, or Contractor will furnish City an endorsement including all subcontractors as insureds under its policies. Except as provided in Subsection 6-10, the Contractor will save, keep and hold harmless the City, its officers, officials, employees, agents and volunteers from all damages, costs 11-B-26 Agreement No. 5747 or expenses in law or equity that may at any time arise or be claimed because of daniages to property, or personal injury received by reason of or in the course of performing work, which may be Caused by any willful or negligent act or omission by the Contractor or any Ll� of the Contractor's employees, or any subcontractor. The City will not be liable for any accident, loss or damage to the work before its completion and acceptance, except as provided in Subsection 6-10. The cost of such insurance will be included in the various items of work in the Contractor's bid and no additional compensation for purchasing insurance or additional coverage needed to meet these requirements will be allowed. In the event that any required insurance is reduced in coverage, cancelled for any reason, voided or suspended, Contractor agrees that City may arrange for insurance coverage as specified, and Contractor further agrees that administrative and premium costs may be deducted from payments due to the Contractor. Contractor will not be allowed to work until alternate coverage is arranged. Coverage will not extend to any indemnity coverage for the active negligence of the additional insured if the agreement to indemnify the additional insured would be invalid under Civil Code § 2782(b). 7-3.2 INDEMNIFICATION AND DEFENSE In addition to the provisions of Subsection 7-3 of the Greenbook as between the City and Contractor, Contractor will take and assume all responsibility for the work as stated herein or shown on the plans. The Contractor will bear all losses and damages directly or indirectly resulting to it, to the City, its officers, employees, and agents, or to others on account of the performance or character of the work, unforeseen difficulties, accidents, traffic control, job site maintenance, or any other causes whatsoever. The Contractor will assume the defense of and indemnify and save harmless the City of El Segundo, its officers, employees, and agents, from and against any and all claims, losses, damage, expenses and liability of every kind, nature, and description, directly or indirectly arising from the performance of the contract or work, regardless of responsibility for negligence, and from any and all claims, losses, damage, expenses, and liability, howsoever the same may be caused, resulting directly, or indirectly from the nature of the work covered by the contract, regardless of responsibility for negligence, to the fullest extent permitted by law. In accordance with Civil Code § 2782, nothing in this Subsection 7-3.2 or in Subsection 7-3 of the Standard Specifications will require defense or indemnification for death, bodily injury, injury to property, or any other loss, damage or expense arising from the sole negligence or willful misconduct of the City, or its agents, servants or independent contractors who are directly responsible to the City, or for defects in design furnished by, such persons. Moreover, nothing in this Subsection 7-3.2 or in Subsection 7-3 will apply to impose on the Contractor, or to relieve the City 11-B-27 Agreement No. 5747 from, liability for active negligence of the City. The City does not, and will not, waive any rights against the Contractor which it may have by reason of the aforesaid hold harmless agreements because of the acceptance by the City, or deposit with City by Contractor, of any insurance policies described in Subsection 7-3 of the Special Provisions. This hold harmless agreement by the Contractor will apply to all damages and claims for damages of every kind suffered, or alleged to have been suffered by reasons of any of the aforesaid operations of Contractor, or any subcontractor, regardless of whether or not such insurance policies are determined to be applicable to any of such damages or claims for damages. No act by the City, or its representatives in processing or accepting any plans, in releasing any bond, in inspecting or accepting any work, or of any other nature, will in any respect relieve the Contractor or anyone else from any legal responsibility, obligation or liability he might otherwise have. 7-5 PERMITS The following paragraph will be added to Subsection 7-5 of Greenbook: The Contractor will apply for permits required by the City Building Safety Division. These permits will be issued on a "no -fee" basis. However, the Contractor must pay for and obtain all other permits from other governmental and utility agencies necessitated by their operations. All bonding fees, (overweight and oversized vehicle permit fees) inspection permit fees or other fees charged or required for such permits must be paid by the Contractor. These costs will be included in the bid item provided. If no bid item is included, costs will be included in the various items of work, and no additional payment will be allowed. 7-8.1 CLEANUP AND DUST CONTROL, Subsection 7-8.1, Cleanup and Dust Control, of the Greenbook is deleted in its entirety and replaced by the following subsections. 7-8.1.1 GENERAL On any construction project requiring trenching within public streets and for which total trenching is in excess of 500 feet, the Contractor will be required to sweep the worksite utilizing a pick-up type street sweeper a minimum of once daily. 7-8.1.2 WATERING Water for the laying of dust caused by Contractor's operations or the passage of traffic through the work will be applied as necessary or as directed by the Engineer. Water for the above or other purposes may be obtained from any approved source. If the 11-B-28 Agreement No. 5747 Contractor chooses to use a City fire hydrant upon placing a $300 meter deposit and the payment of a $50 service fee, the Engineer will cause a meter to be installed. All water used from the hydrant will be metered and charged to the Contractor at the prevailing rate plus the current daily meter rental rate. The Contractor Will be charged a $15 reconnect fee if the Contractor wishes to move the meter to a different hydrant. Costs of water to be used will be included in the cost of various bid items. 7-8.6 WA` E -R POL.L.UTION CONTROL, This section is supplemented by the addition of the following requirements which establish storm water and urban runoff pollution prevention controls. (a) Storm or construction generated water containing sediment such as, construction waste, soil, slurry from concrete/asphalt concrete saw cutting operations, clean up of concrete transit mixers or other pollutants from construction sites and parking areas will be retained or controlled on site and will not be permitted to enter the storm drain system. (b) Temporary sediment filtering systems such as sandbags, silt fences, or gravel berms will be utilized to trap sediment so that only filtered water enters the City's storm drain system. Proper clean up and disposal of settled sediment and the filtering system will be the responsibility of the CONTRACTOR. (c) Discharge of concrete transit mixer wash water on to approved dirt areas (sub - grade area designated for new concrete construction for example) is acceptable. Discharge on to private property, parkway areas, or the street is not permitted. (d) Plastic or other impervious covering will be installed where appropriate to prevent erosion of an otherwise unprotected area, along with any other runoff control devices deemed appropriate by the City. (e) Excavated soil stored on the site will be covered in a manner that minimizes the amount of sediments running into the storm drain system, street or adjoining properties. (f) No washing of construction or other industrial vehicles and equipment will be allowed adjacent to a construction site. During the rainy season (October 15 to April 15), Contractor will keep at the construction site sufficient materials and labor to install temporary sediment filtering systems and other water pollution prevention control measures. These control measures will be in place and maintained by the Contractor on a daily basis on days when construction is not in progress due to rain. (h) All costs associated with water pollution control will be borne by the Contractor. Any expense incurred by the City to expeditiously respond to storm drain contamination resulting from Contractor's failure to implement water pollution 11-B-29 Agreement No. 5747 control measures will be charged to the Contractor. 7-9 PROTECTION AND RESTORATION OF EXISTING IMPROVEMENTS Section 7-9 is supplemented by the following additional requirements: Where existing traffic striping, pavement markings, and curb markings are damaged or their reflectively reduced by the Contractors operations, such striping or markings will also be considered as existing improvements and the Contractor will replace such improvements. Relocations, repairs, replacements, or re -establishments will be at least equal to the existing improvements and will match such improvements in finish and dimensions unless otherwise specified. 7-10 PUBLIC CONVENIENCE AND SAFETY Section 7-10 is supplemented by the following additional requirements: Unless otherwise specified all traffic control will be performed in accordance with the Work Area Traffic Control Handbook (WATCH) Latest Edition, published by Building News, 3055 Overland Avenue, Los Angeles, CA 90034, telephone 310-474-7771. 7-10.1 TRAFFIC AND ACCESS The Contractor will notify the occupants of all affected properties at least 48 hours prior to any temporary obstruction of access. Vehicular access to property line will be maintained except as required for construction for a reasonable period of time. No overnight closure of any driveway will be allowed except as permitted by the Engineer. At least one (I) twelve (12) foot wide traffic lane will be provided for each direction of travel on all streets at all times except as permitted by the Engineer. The traffic lanes will be maintained on pavement, and will remain LinobstrUcted. All work requiring that a lane be closed or a lane moved right or left will be'noticed to the traveling public by use of City approved lighted arrow boards. Clearances from traffic lanes will be five feet to the edge of any excavation and 2 feet to the face of any curb, pole, barricade, delineator, or other vertical obstruction. One four (4) foot wide paved pedestrian walkway will be maintained in the parkway area on each side of all streets. The clearance from the pedestrian walkway to any traffic lane will be five (5) feet. Pedestrians and vehicles will be protected from all excavations, material storage, and/or obstructions by the placement of an adequate number of lighted barricades (minimum two (2)) at each location, one (1) at each end of the obstruction or excavation). which will have flashing lights during darkness. Barricades will be Type I or Type If per Section 7-3 and lights will be Type A per Section 7-6 of the "Work Area 11-B-30 Agreement No. 5747 Traffic Control Handbook" (WATCH). 7-10.2 STREET CLOSURES. DETOURS. BARRICADES Street closures will not be allowed except as specifically permitted by the Engineer. The Contractor will prepare any traffic control or detour plans that may be required as directed by the Engineer. Lane transitions will not be sharper than a taper of thirty (30) to one (1). Temporary traffic channelization will be accomplished with barricades or delineators. Temporary striping will not be allowed unless specifically permitted by the Engineer. The Contractor will prepare any plans that may be required for temporary striping to the satisfaction of the Engineer. In no event will temporary striping be allowed on finish pavement surfaces, which are to remain. Where access to driveway or street crossings need to be maintained, minimum 1 1/4 inch thick steel plating will be used to bridge the trench. All steel plating will have temporary asphalt concrete 1:12 minimum sloped ramps to assist vehicles to cross comfortably over the plates and have a non-skid surface. Plates subject to vehicle high traffic speeds and in residential areas will be secured by welding at the discretion of the Engineer. 7-10.5 PROTECTION OF THE PUBLIC It is part of the service required of the Contractor to make whatever provisions are necessary to protect the public. The Contractor will use foresight and will take such steps and precautions as his operations warrant to protect the public from danger, loss of life or loss of property, which would result from interruption or contamination of public water supply, interruption of other public service, or from the failure of partly completed work or partially removed facilities. Unusual conditions may arise on the Project which will require that immediate and unusual provisions be made to protect the public from danger or loss of life, or damage to life and property, due directly or indirectly to prosecution of work under this contract. Whenever, in the opinion of the Engineer, an emergency exists against which the Contractor has not taken sufficient precaution for the public safety, protection of utilities and protection of adjacent structures or property, which may be damaged by the Contractor's operations and when, in the opinion of the Engineer, immediate action will be considered necessary in order to protect the public or property due to the Contractor's operations under this contract, the Engineer will order the Contractor to provide a remedy for the unsafe condition. If the Contractor fails to act on the situation immediately, the Engineer may provide suitable protection to said interests by causing such work to be done and material to be furnished as, in the opinion of the Engineer, may seem reasonable and necessary. The cost and expense of said labor and material, together with the cost and expense of 11-B-31 Agreement No. 5747 such repairs as are deemed necessary, will be borne by the Contractor. All expenses incurred by the City for emergency repairs will be deducted from the progress payments and the final payment due to the Contractor. Such remedial measures by the City will not relieve the Contractor from full responsibility for public safety. 7-15 HAZARDOUS MATERIAL The following Subsection will be added to Section 7 of the Greenbook: For any excavation, which extends more than four feet below existing grade, the Contractor will promptly, and before the conditions are disturbed, notify the Engineer, in writing, of 1) any material that the Contractor believes may be hazardous waste, as defined in Health and Safety Code § 25117, which is required to be removed to a Class 1, Class 11, or Class III disposal site in accordance with provisions of existing law, 2) subsurface or latent physical conditions at the site differing from those indicated, or 3) unknown physical conditions at the site of any unusual nature, different materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract Documents. After receiving notice from the Contractor, the Engineer will promptly investigate any condition identified by the Contractor as being hazardous. The rights and obligations of the City and the Contractor with regard to such conditions (including, without limitation, the procedures for procuring change orders and filing claims) will be specified by the provisions of Subsection 3-4 (Changed Conditions) of the Greenbook. If a dispute arises between the City and the Contractor whether the conditions materially differ, involve hazardous waste, or cause a change in the Contractor's cost or time required for performance of the work, the Contractor will not be excused from any scheduled completion date provided for by the contract, but will proceed with all work to be performed under the contract. The Contractor will retain all rights provided by Subsection 3-5, Disputed Work, of the Greenbook. If the Engineer determines that material called to the Engineer's attention by the Contractor is hazardous waste, or if the Engineer otherwise discovers the existence of hazardous waste, the Contractor will be responsible for removal and disposal of the hazardous waste by qualified personnel and appropriate equipment in the manner required by law as directed by the Engineer, subject to the provisions of Section 3 (Changes in Work) of the Greenbook. 9-2 LUMP SUM WORK Subsection 9-2, Lump Sum Work, of the Greenbook is deleted in its entirety and replaced by the following: Items for which quantities are indicated as "Lump Sum," "L.S.," or "Job" will be paid for at the price indicated in the Proposal. Such payment will be full compensation for all 11-B-32 Agreement No. 5747 costs for labor, equipment, materials and plant necessary to furnish, construct and install the lump sum item of work, complete, in place, and for all necessary appurtenant work, including, but not limited to, all necessary cutting, patching, repair and modification of existing facilities, and clean up of site. Contractor will furnish three copies of a detailed schedule, which breaks down the lump sum work into its component parts and cost for each part, in a form and sufficiently detailed as to satisfy Engineer that it correctly represents a reasonable apportionment of the lump sum. This schedule is subject to approval by Engineer as to both the components into which the lump sum item is broken down, and the proportion of cost attributable to each component. This schedule will be the basis for progress payments for the lump sum work. 9-3.2 PARTIAL, AND FINAL PAYMENTS The text of Subsection 9-3.2 of the Standard Specifications is hereby deleted and replaced with the following: The closure date for the purpose of making partial progress payments will be the last working day of each month. The Contractor will prepare the partial payment invoice with measurement of the work performed through the closure date and submit it to the CITY for approval. When work is complete, the Contractor will determine the final quantities of the work performed and prepare the final progress payment, and submit it to the Engineer for approval. It will take a minimum of thirty-five (35) calendar days from the date of approving the Contractor's invoice to make the payment to the Contractor. However, payments will be withheld pending receipt Of any Outstanding reports required by the contract documents, or legal release of filed Stop Payment Notices against the Contractor. In addition, the final progress paymentwi It not be released until the Contractor returns the control set of Plans and Specifications showing the as -built conditions. The full five percent (5%) retention will be deducted from all progress payments. The Contractor will make a payment request for the retained amount, for approval by the City, upon field acceptance of the work by the City Engineer. The City Engineer upon field acceptance and receipt of the final as -built plans and any other reports or dOCUMentS required, to be provided by the Contractor will process a recommendation to the City Council for acceptance of the work. Not less than thirty-five (35) calendar days from the City Council acceptance of the work, the Contractor's final payment will be made provided Stop Payment N(,)tices or other claims have not been filed against the Contractor and/or the City by material suppliers, sub -contractors, other governmental agencies,, and private property owners. Until these Stop Payment Notices are released and claims are resolved the stop payment/claim amount will be withheld from the final 11-B-33 Agreement No. 5747 payment. The Contractor, however, may receive interest on the retention for the length of construction, or receive the retention itself as long as the retention is substituted with escrow holder surety or equal value. At the request and expense of the Contractor, surety equivalent to the retention may be deposited with the State Treasurer, or a State or Federally chartered bank, as the escrow agent, who will pay such surety to the Contractor upon satisfactory completion of the contract. Pursuant to PCC § 22300, the Conti -actor may substitute securities for retention monies field by the City or request that the City place such monies into an escrow account. The Contractor is notified, pursuant to PCC § 22300, that any such election will be at the Contractor's own expense and will include costs incurred by the City to accommodate the Contractor's request. Progress payment paid by the City as contemplated herein, will be contingent upon the Contractor submitting, in addition to any additional documents, an updated Contract Schedule in the form prescribed by these Contract Documents. Failure of the Contractor to submit an acceptable updated Contract Schedule will result in the City withholding partial payment, without liability to the City, until such an acceptable updated Contract Schedule is submitted. Nothing herein will allow the Contractor to suspend or slow progress of the Work. A City Council resolution established a Project Payment Account. encumbered money in the current budget, and assigned that money to the Project Payment Account which is the sole source of funds available for payment of the Contract, Sum. Contractor understands and agrees that Contractor will be paid only from this special fund and if for any reason this fund is not sufficient to pay Contractor, Contractor will not be entitled to payment. The availability of money in this fund, and City's ability to draw from this fund, are conditions precedent to City's obligation to make payments to Contractor. 9-3.3 DELIVERED .MATERIALS Materials and equipment delivered or stored, but not incorporated into the work, will not be approved for progress payments. 100-1 TERMINATION OF AGENCY LIABILITY Before receiving final payment, the Contractor will execute a Release on Contract" form which will operate as, and will be a release to the City, the City Council, and each member of the City Council and their agencies, from all claims and liability to the Contractor for anything done or furnished for, or relating to, the work or for any act of neglect of the City of any person relating to or affecting the work, except the claim against the City for the remainder, if any there be, of the amounts kept or retained as II -B-34 Agreement No. 5747 provided in Subsections 9-3 of the Standard Specifications and except for any unsettled claims listed on said form which have been filed in compliance with the requirements for making claims. - END OF SECTION - 11-B-35 Agreement No. 5747 SECTION III — SPECIAL PROVISIONS 1-0. GENERAL SCOPE, TIME FORCOMPLETION, AND LOCATION OF WORK I -L General Scove of Work: The work to be done consists of furnishing all labor, materials, tools, equipment and incidentals for removal of problem trees, removal of curb and replacement with curb and gutter, removal and replacement of sidewalk, driveway approaches, and asphalt pavement. The work proposes to improve the drainage on McCarthy Court. 1-2. Location of the Work: McCarthy Court between Walnut Avenue and Lomita Street. 1-3, Workina Days and'Dine for Completion 1. Contractor will commence work on date specified in the Notice to Proceed to be issued to the said Contractor by City of El Segundo Public Works Department and shall complete work within forty-five (45) working days after the date of commencement. 2. New concrete shall be installed within five (5) calendar days of excavation. 3. The last two weeks of December shall be a moratorium period, from December 23, 2019, 7:00 am to January 3, 2020, 7:00 am, during which no construction work shall take place on City streets or other public right-of-way. The contractor shall schedule their work such that no excavations are left open during those two weeks. 111-A-1 Agreement No. 5747 2-0. NOTIFICATIONS The CONTRACTOR will notify all agencies listed here in a minimum of forty-eight (48) hours before start of operation. The following list of names and telephone numbers are intended for the convenience of the CONTRACTOR and the City does not guarantee either the completeness or correctness of this list. OPERATION OFFICE TELEPHONE 1. Start of work, Floriza Rivera, Public Works Staff 310-524-2361 shutdown of work, Beto Moreno, Street Maintenance Supervisor 310-524-2899 or resumption of 310-524-2358 work after shutdown Lifan Xu, City Engineer 310-524-2356 Ken Berkman, Director of Public Works 310-524-2356 2. Closing of streets El Segundo Police Department" 310-524-2200 El Segundo Fire Department" 310-524-2236 ** The CONTRACTOR will notify the Engineering Division before notifying these offices. The following information is provided for CONTRACTOR'S use to notify agencies if their facilities are affected by CONTRACTOR'S work: 1. Underground Service Alert (all excavation in public right-of-way) 800-227-2600 2. City of El Segundo — Water Division 310-524-2742 3. City of El Segundo - Wastewater Division 4. City of El Segundo - Recreation and Parks 5. Southern California Gas Company 6. Southern California Edison Company (SCE) 7. AT&T 8. Time Warner Communication (Cable) 9. Los Angeles County Sanitation District 10. El Segundo Unified School District 111-A-2 310-524-2754 310-524-2707 310-671-9002 310-417-3366 310-515-4430 310-768-0400 Extension 414 310-699-7411 310-615-2650 Agreement No. 5747 3-0. STANDARDS Section 0-1 on page II -B-1 of these Specifications is supplemented by the following additional requirements: All work shall conform to the most recent edition of the Standard Plans for Public Works Construction (SPPWC), unless otherwise shown on the plans, or as specified herein, Submittal of a bid will be evidence that the Contractor is familiar and knowledgeable about these specifications. 2. Strict compliance with State and local safety codes will be enforced. 4-0. EXAMINATION OF JOB SITE The BIDDER shall make a detailed physical inspection of the site and submit any questions that may affect their bid price to City staff by the deadline prov ided on page I -B-3 before submitting his proposal. It is understood that the BIDDER has satisfied himself, before submitting his bid, regarding existing conditions and existing access which may affect bid prices for the proposed work. 5-0. INSPECTION Section 4-1.3 on page 11-B-9 of these Specifications is supplemented by the following additional requirements: 1. On all questions relating to quantities, the acceptability of material, or work, the execution, progress or sequence of work, and the interpretation of specifications or plans, the decision of the Engineer or City Inspector is final and binding, and shall be precedent to any payment under the, contract. 2. All work and materials are subject to inspection and approval of the Engineer or City Inspector. 3. Legible copies of material/weight certification shall be turned over to the City Inspector on a daily basis. 4. Inspection of the work shall not relieve the Contractor of the obligations to fulfill all conditions of the contract. 5. As stated in Section 11-6.7.2, working on Fridays when City Hall is closed is acceptable; however, the Contractor shall not pour concrete nor install backfill or asphalt on an off -Friday as these require inspections. Formwork inspection shall be scheduled the following Monday or available working day in those cases. 111-A-3 Agreement No. 5747 6-0. USE OF PRIVA11 PROPERTY The use of any private property by the Contractor is prohibited. The prohibited uses include, but are not limited to, the Contractor's use of water, electricity or natural gas from the private property, and storage of material or equipment and turning around/ parking of his vehicles on private property. 7-0. STORAGE Cl~ MATERIALS AND EQUIPMEXF 1. No material or equipment shall be stored in public right-of-way. 2. The contractor shall be responsible for obtaining a site for storage of material and equipment. The site shall not be within or adjoining the residential areas of the City. Site shall be subject to approval by the City. 3. The sites for stockpiling and batching materials shall be clean and free from objectionable material. 4. The City does not have nor does it guarantee any designated property within the City for storage of materials. 5. If the Contractor finds a private property for storage of his materials. the Contractor shall furnish the City a letter of approval and a letter of release (at the end of the job and cleanup of the storage site) from the property owner for this purpose. 8-0. CENTERLINE TIES AND BOUNDARY MARKERS The Contractor is to verify if there are existing centerline ties or boundary markers and submit such verification to City staff prior to dernolition/removal. If they cannot be protected in place, the Contractor's state -licensed surveyor is to re-establish them after construction at no additional cost to the City. 9-0, QUALITY ASSURANCE Contractors shall exercise due care to assure procurement, storage and placement of materials from the site or offsite sources will comply with the requirements, specifications and standards set out herein. Contractor rnay, at his discretion, have such tests and inspections as he may desire performed by qualified personnel or independent testing services, for his guidance and control of the work. If required, the contractor shall provide and pay for inspection and testing by independent testing service selected by the Contractor and approved by the Engineer. Costs for all such inspections and tests will be paid by the Contractor. The Contractor shall bear the cost of retest and re -inspection of work redone &e to non-compliance, 111-A-4 Agreement No. 5747 SECTION IV — MEASUREMENT AND PAYMENT 1 -0. GENERAL: Proposed Bid prices shall be complete for each bid item. All bid items shall cover the costs for all mobilization, construction, and demobilization activities required for each item. All unit prices for concrete adjacent to asphalt pavement shall include the cost of removal and replacement of slot paving per these specifications. Prior to bidding, the Contractor shall inspect project areas and bring any discrepancies to the City's attention. Should the contractor request and obtain permission to use admixtures for its own benefit, it shall furnish such admixtures and incorporate them in the concrete mixture at its expense, and NO additional compensation will be allowed. Should the City Engineer direct the Contractor to incorporate any admixtures in the concrete when their use is not required by these Specifications, furnishing the admixtures and adding them to the concrete will be paid for as Extra Work as provided in Subsection 3-3 of the Greenbook, as amended by these Special Provisions. 2-0 BID YFEIMS 2-1 Mobilization/Demobilization (Bid Item F) See Section V for items considered under Mobilization/Demobilization, payment for which will be made on a percentage -completed basis of the lump sum price named in the Bid Schedule. The bid price shall cover full compensation for furnishing all labor, equipment, tools, materials and incidentals needed for doing all work involved in construction phasing and traffic control including the preparation of traffic control plans, placing, removing, storing, maintaining, moving, replacing and disposing of the components of the traffic control system as specified in these specifications, per the MUTCD, per the WATCH manual, and as directed by the City Inspector and no additional compensation shall be allowed therefore. 2-2 Remove existing curb and rcolace with curb and 18" -wide QUttel' ('Bid Item 2) Measurement for payment of removal of existing curb and replacement with curb and gutter will be paid for at the contract price per linear foot of curb and gutter, for furnishing all labor, equipment, tools, materials and incidentals needed to remove existing P.C.C. curb and gutter, and asphalt slot paving immediately adjacent to it. The contract price per linear foot of curb and gutter shall also include full compensation for furnishing all labor, equipment, tools, materials and incidentals needed to install new P.C.C. curb and 18" -wide gutter. The contract unit price shall also include full compensation for compaction, formwork installation, expansion joints and details, finishing and curing, survey activities to inventory and restore centerline ties and IV -A-1 Agreement No. 5747 benchmarks, survey activities as necessary to establish proper flowlines, complete removal and immediate disposal of existing concrete and asphalt, removal of tree roots under the proposed construction area as necessary, and restoration of existing drainage pipes under the sidewalk and through the curb, to the City's satisfaction. 2-3 Remove and replace 4" -thick sidewalk (Bid Item 3). Measurement for payment of 4" thick sidewalk installation will be paid for at the contract price per square foot of concrete installed per location and shall include compensation for furnishing all labor, equipment, tools, materials and incidentals needed for removal and construction of P.C.C. sidewalk in place. The contract unit price shall include full compensation for traffic control, compaction, formwork installation, expansion joints and details, finishing and curing, and temporary access ramping. The contract unit price shall also include any 'necessary Survey activities to inventory and restore centerline ties and benchmarks; complete removal and immediate disposal of existing concrete; removal of vegetation and tree roots under the proposed sidewalk as necessary; and restoration of existing drainage pipes under the sidewalk and through the curb; to the City's satisfaction. 2-4 Remove and reolace 6" -thick driveway a i �-Proach (Bid Item -41 Measurement for payment of 6" thick driveway approach installation will be paid for at the contract price per square foot of concrete installed per location and shall include compensation for furnishing all labor, equipment, tools, materials and incidentals needed to construct P.C.C. driveway approach in place. as well as any curb, gutter and asphalt slot paving to be constructed immediately adjacent to it per these specifications, 'Fhe contract unit price shall include full compensation for traffic control, compaction, installation of forms, expansion joints and details, finishing and curing, and temporary access ramping. The contract unit price shall include complete removal and immediate disposal of existing concrete and asphalt, survey activities as necessary to establish proper drainage, as well as removal of tree roots under the proposed driveway approach as necessary to the City's satisfaction. Note that because curb length is already measured in Bid Item 2, Bid Item 4 measures the driveway approach areas from the sidewalk to the back of the curb and does not include the curb area. 2-5 Install asphalt slot oavine. 3%wide (Bid Item 51 Measurement for payment of minimum 3' -wide asphalt slot paving will be paid for at the contract price per square foot of pavement removed and replaced where applicable adjacent to new concrete and shall include compensation for furnishing all labor, equipment, tools, materials and incidentals needed to construct slot paving per these specifications. The contract unit price shall include full compensation (*or traffic control, excavation, grading, base installation, asphalt installation, compaction, tack coat application, feathering, and finishing. 'rho contract unit price shall include complete removal and immediate disposal of excavation debris, preparatory removal of vegetation and tree roots as necessary, as well as the restoration of public and private IV -A-2 Agreement No. 5747 property damaged during the construction, to the City's satisfaction. 2-6 :onivletelv remove existina tree (Bid Item 6) Measurement for payment of tree removal will be paid for at the contract unit price per location and it shall include compensation for finishing all labor, equipment, tools, materials and incidentals needed to completely remove an entire tree including leaves, branches, trunk, stump, and roots per these specifications and per Standard Plan 111-5. The contract unit price shall include full compensation for traffic control, necessary equipment and labor, tree removal and proper disposal. 3-1 Remove liardscat)e and replace with compacted soil (Bid Item 7) If approved by City staff, measurement for payment of tree removal will be paid for at the contract unit price per square foot of hardscape and it shall include compensation for finishing all labor, equipment, tools, materials and incidentals needed to completely remove non -permitted hardscape that conflicts with the construction and replacing it with properly compacted native soil or Class C topsoil. The contract unit price shall include full compensation for traffic control, necessary equipment and labor, hardscape removal and proper disposal. 3-2 Remove existing curb and replace with curb only ('Bid Item 8). If approved by City staff, measurement for payment of removal of existing curb and replacement with curb only will be paid for at the contract price per linear foot of curb only, for furnishing all labor, equipment, tools, materials and incidentals needed to remove existing P.C.C. curb, and asphalt slot paving immediately adjacent to it. The contract price per linear foot of curb shall also include full compensation for furnishing all labor, equipment, tools, materials and incidentals needed to install new P.C.C. curb. The contract unit price shall also include full compensation for traffic control, compaction, formwork installation, expansion joints and details, finishing and curing, survey activities to inventory and restore centerline ties and benchmarks, survey activities as necessary to establish proper flowlines, complete removal and immediate disposal of existing concrete and asphalt, removal of vegetation and tree roots as necessarv, restoration of landscaping, restoration of public and private property damaged during the construction, and restoration of existing drainage pipes under the sidewalk and through the curb, to the City's satisfaction. 4-0 PAYMENT OF CHANGE ORDER ITEMS Payment of any change order item shall only occur if the item is added to the project scope through both a change order agreement and, if necessary, an amendment agreement. Contractor shall check with the City Inspector prior to proceeding with any potential change order work. A writteii Request for Information shall be provided to the City regarding potential change order work. Additional project work of exactly the same type and scope mentioned under the sections listed above shall apply the bid unit IV -A-3 Agreement No. 5747 price used by the bidder. Costs for work not similar in type and scope to those listed in the sections above shall be agreed upon by the Contractor and City through a change order agreement. Per Section 11-3-4, the Contractor shall inform City inspector of any changed conditions. The City Inspector and the Contractor together shall then record the date the changed conditions were found, the nature of the changes, the measurements taken, the time period for any additional labor, and the number and labor classification of those laborers. This information may be required for determining costs. Both agreements shall be completed by the Contractor and the City and the original purchase order updated prior to payments occurring for the change order items. A change order agreement greater than 25 percent of the original bid/contract amount also requires the approval of City Council before the Purchase order can be updated and any payment processed for the change order. 5-0 PROGRESS PAYMENTS Lump sum items shall be billed on a percentage completed basis. The City reserves the right to request a schedule of values to be submitted by the contractor for any or all bid items in order to determine payment for work completed. IV -A-4 Agreement No. 5747 SECTION V — TECHNICAL SPECIFICATIONS 1-0 MOBILIZATION Mobilization shall conform to the provisions of Section 9-3.4 of the Standard Specifications. The scope of work under mobilization includes but is not limited to: 1. Obtaining all required permits 2. Moving on to the site of all Contractor's equipment required for operations 3. Providing on-site sanitary facilities 4. Arranging for and erection of Contractor's work and storage yard 5. Posting all OSHA required notices 6. Submittal of Construction Schedule, Contractor Contact List, Striping Inventory, Centerline Tie Inventory, Survey Marking Inventory, and Notices to Residents for City approval 7. Notification of property owners and residents and posting of No -Parking notices 8. Re -notification of all residents for any construction schedule changes 9. Traffic control as required per W.A.T.C.H. manual and MUTCD 10. Coordinating with Underground Service Alert (USA) or Dig Alert to mark underground utilities before any excavation. 11. Potholing as needed to avoid construction conflicts. 12. Coordination with utility agencies, street sweeper, and waste hauler to avoid conflicts during project activities 13. Clearing and grubbing, and landscape removal and replacement as necessary for construction 14. Placing temporary ramping for excavated areas 15. Restoration of private and public property damaged by construction activities to existing standard conditions upon demobilization 16. Removal of all formwork, nails, stakes, excess dried concrete, and other construction debris from the project sites. 17. Removal of all USA markings after new concrete improvements are installed. 18. Demobilization 1-1 Clearing, grubbing, and landscape removal shall take place as necessary for all construction activities to occur, including but not limited to Section 300-1 of the Standard Specifications. Where necessary, the contractor shall replace residential landscaping or sprinklers damaged by construction after construction is complete. 1-2 Underground Service Alert, 1-800-227-2600, shall be contacted and the contractor shall determine the exact location of all utilities prior to beginning excavation and construction. If conflicts are discovered, the Contractor shall notify the Engineer immediately and pothole carefully to determine a facility's location and depth. A detailed description of the depth and location of utility conflicts in relation to the proposed storm drain facilities shall be provided to City Inspector as well as the applicable utility agency. 1-3 Demobilization shall include all activities for the Contractor to remove all equipment, on-site sanitary facilities, etc. from the project areas after construction is complete. V -A-1 Agreement No. 5747 Demobilization shall also include general cleanup activities and specific punch list items and cleanup activities determined by the City Public Works Inspector, to repair or replace any private or public facilities damaged by the construction and return public right-of-way to the same or better condition as that existing prior to construction. 2-0 No,rIFICA"I"ION The Contractor shall submit all required resident and property owner notices to the City at the pre -construction meeting for approval. The contractor shall hand -deliver approved Notices to Property Owners or Notices to Residents regarding the concrete work to affected residents at least two weeks before the project begins construction at those locations. Notices shall include the project times, dates, working hours, description of project activities, and description of any steps required of owners and residents to ensure safety and successful construction. The Contractor shall place delineators and dated "TEMPORARY NO PARKING" signs at motorist eye level along the curb 72 hours in advance of the construction, to alert motorists that parking shall not occur at the location and for what length of time. See Appendix for City Standard detail for "Typical Temporary No Parking Sign". The Contractor shall inform the inspector or City staff every morning of all locations being worked on and all locations being posted for that day for TEMPORARY NO PARKING. The dates and times on the signs shall be site specific and shall cover the minimum time required for "NO PARKING" to facilitate construction. Generic long-term "NO PARKING" time designations are not acceptable. Parking shall not be restricted during any period when construction activity is not scheduled at this particular site. Postings shall adequately convey to the public the dates and time periods during the day when No Parking will be in effect at posted locations. Postings shall be removed as soon as possible if the construction schedule changes and the information on the postings is no longer valid, to allow the public to park in the area. The Contractor shall submit traffic control plans and a project schedule to City staff at the project pre -construction meeting. Any changes to the submitted plans and schedule must be submitted to staff prior to their occurrence. Traffic control shall adhere to W.A.T.C.H. manual guidelines. The contractor shall notify motorists of impending detours at least seventy-two hours prior to their occurrence, through the use of traffic control devices and postings. The Contractor shall also notify the Police Department, the Fire Department, the City street sweeper, the City waste hauler, and all utilities of the construction schedule and any changes to it. BOOM Agreement No. 5747 3-0 TRASH PICKUP, STREET SWEEPING. AND MAIL. DE1,IVERlES The Contractor shall coordinate with the City waste hauler and the City street sweeper to avoid construction conflicts on days when trash will be collected or streets will be swept on the project streets. If applicable, the contractor must coordinate with the [JS Post Office to ensure that mail will be delivered without interruption. The notification to the US Post Office shall be submitted for City approval before the notice is sent. 4-0 STORM DRAIN PROTECTION' Nearby catch basin and storm drain openings must be protected with felt, straw wattles and sand bags to ensure that there will be no spillage into the City storm drain systems. 5-0 EXCAVATION 5-1 Grading, excavation and preparation of subgrade shall be done in accordance with, and shall include, all work specified in subsection 300-2. "Unclassified Excavation," and 301-1, "Subgrade Preparation," of the SPPWC, except as modified and supplemented herein. This item shall include all labor, equipment tools, materials and set -vices required to complete all site and subgrade preparation and earthwork public right-of- way reconstruction areas, per City Standards. Prior to construction beginning, City staff will mail notices to property owners with nonstandard non -permitted hardscape in their parkways that may be affected by construction. During excavation/construction the Contractor shall remove loose nonstandard hardscape from parkway areas that conflict with the work. Contractor shall inform owners hardscape will NOT be re -installed. During street excavation, the existing pavement must be sawCUt and removed to clean straight lines, free of irregularities, to a depth sufficient to permit pavement removal without damage to pavement left in place. Sawcut boundaries shall be either parallel or perpendicular to the curl) face. If a longitudinal pavernentJoint or edge of pavement is located within three (3) feet of the limit of the excavation, the Contractor shall remove all intervening pavement and replace it after trench backfilling. Material excavated in the roadway and not needed for backfill shall be immediately removed and disposed of by the Contractor. Surplus materials shall be properly stored according to Best Management Practices and shall NOT be placed on private property. Changed conditions found during excavation shall be immediately brought to the Inspector's attention and the details of the change recorded by both the Contractor and the Inspector before formwork installation. See also Section 11-3-4 and Section IV -4-0. 5-2 Survevine See also. Section 2-9, page 11-B-6. V -A-3 Agreement No. 5747 Contractor shall have a licensed surveyor verify all existing flowline elevations prior to demolition. The surveyor shall also lay out and confirm positive drainage for areas with proposed changes in flowline elevations prior to construction. Existing flowline elevations shall be verified where driveway approaches begin and end along the curb face, at concrete join points, between driveway approaches, at grade breaks, at the entrance to catch basins, at curb drains, along crossgutter and spandrel flowlines, etc. The contractor shall submit survey results and any calculations to City staff. The contractor shall bring any drainage issues to City staffs attention before continuing construction at a location. If flowlines are not proposed to change, the existing flowline elevations and slopes shall be re-established. Drainage issues that occur after construction shall be resolved by the Contractor prior to the project being accepted, at no further expense to the City. A licensed surveyor shall verify elevations and locations of all existing survey -related items prior to construction for the purpose of re-establishing them after construction. These include but are not limited to boundary lines, boundary markers, centerline ties, benchmarks, etc. The contractor shall submit their survey results to City staff. The cost to re-establish these items shall be included in the bid unit costs of construction of the items in which the markers are located. 6-0 RI-",'MOVAL OF EXIS'l'lNG CONCRETE OR ASPHALT Concrete demolition and construction shall be per Standard Plans for Public Works Construction, current ADA standards, and City of El Segundo Standards. The Contractor shall inspect all locations called out in the project specifications to determine the extent of the removals needed. Existing Portland cement concrete or asphalt concrete that is broken into pieces to be discarded shall be removed from the project site and properly disposed of the same day. The Contractor shall take care that areas shall be sufficiently watered down during demolition as well as construction for dust control. All removed materials shall become the property of the Contractor and shall be legally disposed of by the Contractor's representatives away from the site of work. (Note: there are no authorized dump facilities within the City of El Segundo) Spillage resulting from material hauling operations along or across any public traveled way shall be removed immediately by the Contractor at no expense to the City. 7-0 REPLACEMENTOF DAMAGE TO EXISTING FACILITIES The Contractor shall take care to protect -in-place City and private property not within the scope of this project from any damage. If damaged during demolition or construction, City property and private property shall be replaced in type and kind or better. The Contractor shall guarantee to remedy any defects in the repaired areas within a period of one year from the date of final acceptance of the work unless a V -A-4 Agreement No. 5747 longer period is specified, The City staff will give notice of observed defects with reasonable promptness. This applies to drainage, landscaping and irrigation systems including, but not limited to, drainage pipes, irrigation pipes, sprinklers, appurtenances, trees, shrubs, flowerbeds, and native vegetation. City properties shall include, but are not limited to, City parks, sidewalk, parkways, and street right-of-way. The Contractor shall replace and or supply any irrigation system necessary for proper restoration of all landscaping disturbed by the Contractor during the project. The irrigation system shall become the property of the City twelve months after project completion. The contractor shall mark existing through -the -curb drainage systems prior to construction, re-establish them during construction if removed, and ensure they are in good working order after curb construction is complete. This includes coring through the curb for the pipe opening. The Contractor shall relocate if necessary and reconstruct all curb drainage outlets that fall within the scope of his work. Cost of this work shall be included in the bid. Any pavement, curb, or sidewalk removed beyond the limits established by the Engineer shall be reconstructed by the Contract6r at his own expense and no additional compensation will be allowed. 8-0 CONCRETE REI'WOVALSYR_EPLACEMENTS AND INSTALLATIONS The Concrete mix design shall be Class 520-C-2500 unless otherwise stated in these specifications or in SP'PWC plans. The mix design is subject to review and approval by the City Engineer no later than 14 days prior to first use. Any change in the mix design shall require approval by the City Engineer. Hand -mixing of concrete shall not be permitted. Additional water shall not be added to the concrete mix once it leaves the batch plant. The Surfaces of all concrete shall receive a wood float finish. The contractor shall mark existing through -the -curb drainage systems prior to construction, re-establish them during construction if removed, and ensure they are in good working order after curb construction is complete. The Contractor shall relocate or restore all curb drainage Outlets that fall within the scope of his work. The cost of this work shall be included in the bid. The Contractor shall inform the Inspector of any relocations and record those relocations and their new trajectory in as -built plans for each applicable address. All existing concrete facilities affected by tree growth and tree root uplift shall be scheduled for concrete demolition and removal before all other areas. The Contractor shall coordinate with City staff for Recreation and Parks Department to assess future tree stability prior to any construction occurring. See also Section V-13-0. All new concrete facilities shall be installed over a 2" thick ninety-five percent 95% compacted Crushed Miscellaneous Base (CMB) over ninety percent 90% compacted native subgrade. The subgrade shall have a sufficient moisture content such that moisture is not drawn out of the concrete. V -A-5 Agreement No. 5747 Contractor shall confirm acceptable storm water flow prior to project completion using a City -approved method of water -testing. Should water tests fail and ponding occur, contractor shall re -do the concrete improvement until positive drainage is achieved. Water tests, surveys, and any construction needed to ensure positive drainage shall be performed at no additional cost to the City. Should a sidewalk leading directly to a property walkway/door or a driveway approach be excavated at the end of a workday, the Contractor shall provide a temporary access ramp to residences/businesses. The temporary access ramp shall be removed by the Contractor on the following day so that construction can be completed. The cost for placement and removal of the temporary ramp as long as it is needed shall be included in the bid cost for these items. The Contractor shall make adjustments to existing meter boxes and electrical boxes to match new grade. The cost of this work shall be included in the bid costs. Slot paving per these specifications shall occur at any asphalt pavement location adjacent to new concrete. 9-0 REMOVE EXISTING CURB AND REPLACE WITH CURB AND OUTTER The Contractor shall review all curb only or curb and gutter to be removed and replaced on the project with the Inspector in the field prior to any construction. The Contractor shall furnish all labor, tools, and materials necessary to remove and replace curb only, curb and gutter, and adjacent asphalt slot paving in those locations specified. Curb and gutter shall be constructed in accordance with Section 303-5 of the Standard Specifications and shall conform to Standard Plan 120-2. Curb height varies based on existing top -of -curb elevation and adjoining flovdine grade. New gutter Width shall be 18 -inches wide at all locations unless otherwise directed in these specifications or by City staff. Contractor shall have the length of curb or curb and gutter to be replaced surveyed prior to demolition to verify the resulting flowline elevations will be feasible. Survey submittals to City staff are required. Any conflicts or items of concern shall be brought to City staffs attention prior to construction. Survey costs are to be included in the cost of these bid items. In locations where curb -only demolition reveals curb to be more than six inches deep below the street surface, the Contractor shall construct curb depth to match the standard. The additional depth below the new curb and gutter shall be filled with crushed miscellaneous base and compacted per City standards prior to the concrete pour. Curb and gutter shall be poured monolithically. MMO Agreement No. 5747 10-0 REPLACE SIDEWALK The Contractor shall review all sidewalk to be constructed on the project with the City Inspector in the field prior to any construction. The Contractor shall furnish all labor, tools, and materials necessary to construct a minimum 4 -inch thick sidewalk in those locations specified. Sidewalk shall be constructed in accordance with Section 303-5 of the Standard Specifications and shall conform to Standard Plan 134-2. New sidewalk dimensions shall match existing and shall conform to current ADA requirements. Cross slopes for new sidewalk shall be maximum 2% sloping toward the street including at join areas. In locations where sidewalk demolition has revealed the existing sidewalk to be more than four inches deep below the street surface, the Contractor shall construct new sidewalk depth to four inches. The additional depth below the sidewalk shall be filled with crushed miscellaneous base and compacted per City standards prior to the concrete pour. 11-0 REPLACE DRIVEWAY APPROACH The Contractor shall review all driveway approaches to be constructed on the project with the City Inspector in the field prior to any construction. The Contractor shall furnish all labor, tools, and materials necessary to construct a minimum 6 -inch thick driveway in those locations specified. Driveway approaches shall be constructed in accordance with Section 303-5 of the Standard Specifications and shall conform to Standard Plan 110-2. Driveway approaches shall be standard size, be constructed of concrete only, with no other hardscape materials or color additives used. In locations where driveway approach demolition has revealed the existing driveway approach to be more than six inches deep below, the street Surface, the Contractor shall construct new driveway approach depth to six inches. The additional depth below the driveway approach shall be filled with crushed miscellaneous base and compacted per City standards prior to the concrete pour. The Contractor shall note that because curb length is already measured in a separate bid item, the driveway approach bid item measures the approach areas from the sidewalk to the back of the curb and does not include the curb area. 12-0 WASI-JING OF CONCRETE 'MANSIT MIXERS Concrete transit mixers shall not be washed out on alleys, streets, or parking lots. Also refer to Section 7-8.6 of these Specifications on page 11-13-28 regarding Water Pollution Control for additional requirements. 13-0 TREES AND ROOTS The Contractor shall contact Underground Service Alert, 1-800-227-2600, to determine the exact location of all utilities prior to beginning any tree root and stump grinding and/or removal. V -A-7 Agreement No. 5747 For the purposes of this project, a tree stump is defined as the remaining vertical portion of the tree trunk after the tree branches have been felled and removed, and the majority of the tree trunk has also been cut off and removed. For the purposes of this project, a tree root is defined as the portion of a tree that grows out of a tree trunk and can continue to grow above ground and/or under the ground, generally in a horizontal direction above ground and/or down into the ground, providing the tree with nourishment and support. Tree roots can be of any length or diameter. After a tree has been cut down, tree roots continue to extend from the tree stump. 13-1 Recreation and Parks Devartment Tree Root Assessrnent Unless an existing tree has already been called out below for complete tree removal, the existing concrete facilities affected by a live tree and tree root uplift shall be scheduled for concrete demolition and removal before all other areas. The Contractor shall inform the inspector when the roots have been uncovered and allow 72 hours for a response regarding root pruning. The Recreation and Parks Department will assess to what degree the roots can be safely pruned or whether the tree should be removed. Tree root removals shall be included in the bid costs for the item to be constructed. All such removals shall take place prior to excavation for construction. 13-2 Base Bid Tree Removals The trees at the following addresses have been called out on the plans and shall be entirely removed by the Contractor, including the stump. In the event of tree removal, the Contractor shall be responsible for removing any remaining tree stump and tree roots in a project area. Tree stump or root removal necessary for the construction of concrete or asphalt improvements shall be completed before the replacement of the concrete or asphalt facility. At locations where tree roots are encountered, the Contractor shall cut out the tree roots to the full cross section of the new work a minimum of two (2) feet below finish grade. The contractor shall then fill the area with soil and compact it to match the new or existing sidewalk and top -of -curb grade. 1. 800 McCarthy Court 2. 805 McCarthy Court 3. 808 McCarthy Court 4. 812 McCarthy Court 5. 813 McCarthy Court 6. 816 McCarthy Court 7. 820 McCarthy Court 8. 845 McCarthy Court Should the Recreation and Parks Department request additional trees to be removed, the Contractor shall not begin the removals without a written change order for each tree removal in place, and without notifying the property owners in advance. The V -A-8 Agreement No. 5747 Contractor may perform construction activities on a different portion of the project in the interim. 13-3 Asphalt Pavement UDlift Due to 'Tree 1�oots Where tree roots have damaged and uplifted asphalt beyond the project boundaries per these plans and specifications, the contractor shall bring these areas to the City's attention and allow 72 hours for a response regarding tree root removal and asphalt repair. If approved, the Contractor shall sawcut beyond the damaged area by a minimum of 6 inches in all applicable directions, with sawcut boundaries either parallel or perpendicular to the curb face. Contractor shall cut all interfering tree roots down to two (2) feet below finish grade, and shall remove and repair the portions of damaged asphalt. 14-0 SLoT PAVING AND ASPHALT PAVEMENTREPAIR Asphalt slot paving, at minimum three feet in width, shall occur in the asphalt portion of the street or alley adjacent to all newly installed concrete and shall properly direct storm flow to the storm drain system. Asphalt shall be saw cut for removal, with sawcut boundaries either parallel or perpendicular to the curb face or property line. Slot paving shall consist of 6 inches of V2 -inch-maximum State mix over a 6 -inch base. New asphalt shall be feathered to meet existing asphalt, and shall also meet new concrete at a reasonable height and slope to allow proper drainage. Slot paving shall occur within three working days after the concrete forms have been removed. Asphalt shall be 6 inches thick and applied in two lifts over a minimum of 6 inches of crushed aggregate or crushed slag base. Where a series of cuts are made, regardless of the spacing between individual cuts, the series shall be treated as a continuous open trench and the pavement repair shall be continuous across all cuts. All asphalt concrete pavement shall conform to Section 203-6 of the Standard Specifications and as shown on the details in the plans. Asphalt concrete shall be V2 - inch -maximum State mix unless otherwise specified. Paving shall occur in lifts, after backfill with and compaction of appropriate materials has occurred. All backfilling and paving shall be to the City Public Works Inspector's approval, Paving rollers shall be on the job site before any paving is started. The final height of the new slot paving next to new gutter shall not be more than V2 -inch high. The Contractor shall be responsible for bringing to the City's attention any additional asphalt required for proper drainage prior to placement of new asphalt. If improper asphalt placement occurs, detrimentally affecting drainage, the contractor shall remove and replace the asphalt at no further cost to the City. Base material for the reconstruction of the pavement shall be in accordance with Subsection 200-2.2 of the Standard Specifications. A tack coat of PG 64-10 paving asphalt shall be uniformly applied to the surface to be paved. The surface shall be free of water, foreign material, and dust when the tack coat is applied, 15-0 SURFACE RESTORATfON V -A-9 Agreement No. 5747 Permanent restoration of concrete or asphalt or earthwork surface improvement shall be completed to the approval of the Engineer no later than five (5) calendar days after completion of the concrete work. Until completion, the project area shall be safely set apart and covered to current standards. Excavated areas shall be property covered and marked for safety until they are backfilled or otherwise restored. 15-1 Cor wc—t —i() 11 If compaction testing is required, any soil compaction testing and certification shall be certified by a Geotechnical Engineer and provided and paid for by the Contractor. The soil testing company shall be subject to approval by the City Engineer prior to any testing. A relative compaction of ninety percent (90%) is required under all asphalt concrete pavement, and ninety percent (90%) under all concrete curb, stamped concrete and concrete slab. 16-0 STRIPING Any striping and pavement markers removed or damaged or to be re-striped/touched- up during construction shall be replaced in kind or better. The Contractor shall take inventory of striping to be replaced before beginning construction. Striping that does not fit MUTCD standards could be aerial survey or city boundary markers, and shall be brought to the Inspector's attention prior to any removal. This striping, if it will be removed during the course of construction, should also be inventoried and replaced. If the stripes are City boundary markers, then the Contractor shall hire a licensed surveyor prior to striping removal to document their existing locations and to re-establish their original locations upon re -striping. 17-0 J, RAFFIC CONTROL Traffic control shall conform in accordance to the latest editions of the Work Area Traffic Control Handbook, the Caltrans' Manual of Traffic Control in Construction and Maintenance Zones, and the standards contained in the "Manual of Uniform Traffic Control Devises (MUTCD)" and the stipulations set forth in this article. Contractors shall maintain one lane of traffic in each direction at all times unless otherwise approved by City staff. The Contractor shall provide and maintain all signs, barricades, flashers, delineators and other necessary facilities for the protection of the motoring public within the construction area limits. The Contractor shall post signs to notify the public regarding detours and conditions of the roadway, in accordance with the provisions of the Vehicle Code and current State of California Department of Transportation "Manual of Warning Signs, Lights, and Devices for Use in Performance of Work upon Highways." Portable delineators shall be spaced as necessary for proper delineation of the travel way. If the traffic cones or portable delineators are damaged, or are not in an upright position, from any cause, said cones or portable delineators shall immediately be replaced or restored to an upright position, by the Contractor. V -A-10 Agreement No. 5747 The Contractor shall furnish such flagmen as are necessary to give adequate warning to traffic or to the public of any dangerous conditions to be encountered. Flagmen shall give warning to the public of the street is under construction and of any dangerous conditions to be encountered as a result thereof. Flagmen shall perform their duties and shall be provided with the necessary equipment in accordance with the current "Instructions to Flagmen" of the Department of Transportation. The equipment shall be furnished and kept clean and in good repair by the Contractor, at his expense. Should the Contractor appear to be neglectful or negligent in furnishing warning and protective measures as above provided, the inspector may direct attention to the existence of a hazard, and the necessary warning and protective measures shall be furnished and installed by the Contractor, at his expense. Should the inspector point out the inadequacy of warning and protective measures, such action on the part of the inspector shall not relieve the Contractor from responsibility for public safety or abrogate his obligation to furnish and pay for these devices. The Contractor shall conduct his operations so as to provide reasonable access to the adjacent properties and have no greater length or quality of work under construction than he can property prosecute with a minimum of inconvenience to the public and other contractors engaged on adjacent or related work. When entering or leaving roadways carrying public traffic, the Contractor's equipment, whether empty or loaded, shall in all cases yield to public traffic. Access to driveways shall be available throughout construction. Temporary driveway closures may be approved by the City inspector. 18-0 ALTERNATIVE ITEMS, 18-1 Remove existinLy liardscaoe from varkwav areas If approved by City staff, the Contractor shall remove existing concrete and brick from parkway areas if they conflict with construction, while protecting in place adjacent sidewalk, curb, driveway approaches, and landscaping that will remain. Contractor shall NOT re -install hardscape removals. Instead, the contractor shall replace the hardscape with native soil or Class C topsoil and compact the soil to City standards to meet the grade of the sidewalk and the top of curb. 18-2 Removal and reolacement of curb only If approved by City staff, the Contractor shall review all curb to be removed and replaced on the project with the Inspector in the field prior to any construction. The Contractor shall furnish all labor, tools, and materials necessary to remove and replace curb only. Curb shall be constructed in accordance with Section 303-5 of the Standard Specifications and shall conform to Standard Plan 120-2. Curb height will be minimum 6" -high and maintain a positive drainage slope for the flowline. The contractor shall bring any discrepancies to the City Inspector's attention prior to demolition. V -A-1 I Agreement No. 5747 Contractor shall have the length of curb to be replaced surveyed prior to demolition to verify the resulting flowline elevations will be feasible. Survey submittals to City staff are required. Any conflicts or items of concern shall be brought to City staffs attention prior to construction. Survey costs are to be included in the cost of this bid item. In locations where curb -only demolition reveals curb to be more than six inches deep below the street surface, the Contractor shall construct curb depth to match the standard. The additional depth below the new curb shall be filled with crushed miscellaneous base and compacted per City standards prior to the concrete pour. V -A-12 Agreement No. 5747 SECTION VI — APPENDICES 1. City Map 2. "l'ypical No Parking Sign — El Segundo Standard ST -18 3. Street Sweeping Schedule 4. Trash Hauling Schedule 5. Centerline Tic Information 6. Project Plans V -A-13 Agreement No. 5747 APPENDICES 1. City Map 2. Typical No Parking Sign — El Segundo Standard ST -18 3. Street Sweeping Schedule 4. Trash Hauling Schedule 5. Project Plans Agreement No. 5747 APPENDIX I Project Location Map ©N 17J ... . ..... . . ... ..... . . . .......... 111 w. ............. . .. . ........................... . .. . . ....... .. .. . . ........... .. ......... . . . .. ...... mI . . ......... . ......... F 7� 7, E: J it I . . .. . . . . . 5j 11n sIn- tH .......... . .... ---------- j . . ..... . .... 1:7f5 I- PEI P ER--irv, .............. UHIET oo .1 E . .. �' %, l I—= IF F- . .. . ............... . ... .............. . .... . 7 w�IIfl- 0'S PIEREMP] iLuu I .............. I L:Jj 1�1 =1 Agieemenl No. c5747 co Z CD o mtev tZ2 Agreement No. 5747 Typical No Parking Sign — El Segundo Standard ST -18 l7s, vivim Agreement No. 5747 i I Q: W M ' F~ - w J it _ w W N ~ I- COLOR LEGEND SIGN SHALL BE LIGHT REFLECTIVE AND BE RED MADE OF WATER RESISTANT STIFF CARDBOARD WHITE OR OTHER STIFF DURABLE MATERIAL. DESIGN BY: P.B. CITY ENGINEERING LSE DO CALIFORNIA APPROVED BY: ' I J f4- r DIVISION Cit Engineer. DATE: I I. 7.89 o s o STANDARD°R.E.' 8 at TYPICALe DRAWN BY: Y.B. DRAWING N0. DATE: 11. 13. 89 TEMPORARY NO PARKING SIGN - ST -1 �� 12 0 l7s, vivim Agreement No. 5747 i I Q: W M ' F~ - w J it _ w W N ~ I- COLOR LEGEND SIGN SHALL BE LIGHT REFLECTIVE AND BE RED MADE OF WATER RESISTANT STIFF CARDBOARD WHITE OR OTHER STIFF DURABLE MATERIAL. DESIGN BY: P.B. CITY ENGINEERING LSE DO CALIFORNIA APPROVED BY: ' I J f4- r DIVISION Cit Engineer. DATE: I I. 7.89 o s o STANDARD°R.E.' 8 at TYPICALe DRAWN BY: Y.B. DRAWING N0. DATE: 11. 13. 89 TEMPORARY NO PARKING SIGN - ST -1 Agreement No. 5747 APPENDIX 3 Street Sweeping Schedule Eucalyptus Drive and Surrounding Streets Only , g *CqrqeptoNp. 5747 m m . E o CA79 VCI2klfld]S N 0 Z. 'd 'd m m (a -9 aLS 7NOIIINIH�SVMI Lc IFIP 0 i MI is EON Ov- iT VINHOAM cn JS NMANO 0 W", ui 4y, I is opq AHYO 1. Is NNId Is Tfu Is N00IMB ngw� 'dO SPIdAWOP.3 Is auvams . .. . . . ....... 4 it NIVA iS aNONHOfb o Zzlye amu. Ult JS YINIONIA m t�, Fir, 39P W-17 Agreement No. 5747 APPENDIX 4 Trash Hauling Schedule Important, Phone Numhers, Addresses and Websites' Consolidated Disposal Service Residential Services (800) 299-4898 Construction Debris Collection (310) 527-6980 Bulky Item and White Goods Disposal Options American Waste Transfer Station 1449 W. Rosecrans Avenue Gardena, CA 90249 (310) 527-6980 City of El Segundo City Maintenance Yard for Centralized Drop Off of Recyclables and Green Waste 150 Illinois Street El Segundo, CA 90245 www.elsegundo.org (310) 524-2709 City of Los Angeles, Hyperion Hazardous Waste Drop Off /Collection Center Saturday/Sunday: 9:00 a.m. to 3:00 p.m. 7660 West Imperial Hwy, Gate B Playa del Rey, CA (800) 988-6942 Los Angeles County HHW Collection Facilities/Events (888) CLEAN -LA [888-253-2652] http://Iadpw.org/ Tree Musketeers (310) 322-0263 www.treemusketeers.org Printed on Recycled Content Paper Printed by American Printing 951-279-0601 ,l SegundifflWAUNdule Sepulveda !Blvd Pacific Coast Highway m a Qon o oc Ln LL w LU a Q Center Street tA a � CC c > a W 0 Q o I— LA W Z LU Q w j W w I � > m Main Street Main Street Ln �. > a w 0 E. Z E W 0 Dune Stceet Holiday Collection Schedule Trash and Recycling collection does not occur on N the following six holidays: New Year's Day, Memorial Day, 4th of July, Labor Day, Thanksgiving Day, and Christmas Day. When any of these days are observed on a weekday, services will be delayed one day. All other days are unaffected. Agreement No. 5747 APPENDIX 5 Project Plans M Agreement No. 5747 cjH f= w ..b_ b Qi h7d�s2 W i e = K cgs" a! V a m - I $ X02 Rv IFlI,r:"j� —R r a z Ga ;u Y6 uj a! o � ZO 1 id mm�a����am a. M Fo �,r3 b1000?M� WS3� ilia 0 5 109[ w Ewo xo°a e xa�— yy g�2o�o =Goon SggE� I I T IW WNW�ZW _ P:zzzde Yo�p Ad AB�flMw.XJMI ..._. o rz zp a a oF� i N, .. ^01 it 1—•- o �zao o�SHE r i ZF-o�'iz6 sJW _ z rF>aflel E S - ¢ z �J��W�3� o��cc 9g NF N �"F isc�¢oY zo Z w ¢O = g °x,2 is N (naHS R y R f °a d au M,-zio u -!k mor RK -00 Z Nwk.R Aw;wJ5 to t lu Own Z� M<RFM Agreement No. 5747 Eg 01 J1 p M A q; a R 9 A E tl a E)OO&flU0 8 SO (5 Oaf logo 10 oil I 1INJ,11,1��11 gadR 1Y Al Pp 1! to M,-zio u -!k mor RK -00 Z Nwk.R Aw;wJ5 to t lu Own Z� M<RFM Agreement No. 5747 Eg 01 J1 p M A q; a R 9 A E tl a E)OO&flU0 8 SO (5 Oaf logo 10 oil I 1INJ,11,1��11 gadR r 7T—PN5 v5 T —jRtl Pp 1! HIP 771 is It M,-zio u -!k mor RK -00 Z Nwk.R Aw;wJ5 to t lu Own Z� M<RFM Agreement No. 5747 Eg 01 J1 p M A q; a R 9 A E tl a E)OO&flU0 8 SO (5 Oaf logo 10 oil I 1INJ,11,1��11 gadR r 7T—PN5 v5 T —jRtl Pp 1! HIP is �X z 3 4 ;ik M,-zio u -!k mor RK -00 Z Nwk.R Aw;wJ5 to t lu Own Z� M<RFM Agreement No. 5747 Eg 01 J1 p M A q; a R 9 A E tl a E)OO&flU0 8 SO (5 Oaf logo 10 oil I r 7T—PN5 v5 T —jRtl Pp HIP is M,-zio u -!k mor RK -00 Z Nwk.R Aw;wJ5 to t lu Own Z� M<RFM Agreement No. 5747 Eg 01 J1 p M A q; a R 9 A E tl a E)OO&flU0 8 SO (5 Oaf logo 10 oil I HIP Agreement No. 5747 qa "Nam I z V 1 , I Sz, In OM Zl LLJ 4, oil V �p h, -7, A 3 id t1 YX {� a �° 4j, _ n N PIN ILI 0, Mill 1101 Zi u, -71 1,11 to IS. LAI—, 1 i 1 2 11 low 1-13 oil Moll, 11 g M - HH I will! ease see 0 so (D '3AV!inN-1VM via 4— Mm i Al IL St 7—T! itl MW z Agreement No. 5747 qa "Nam I z V 1 , I Sz, In OM Zl LLJ 4, oil V �p h, -7, A 3 id t1 YX {� a �° 4j, _ n N PIN ILI 0, Mill 1101 Zi u, -71 1,11 to IS. LAI—, 1 i 1 2 11 low 1-13 oil Moll, 11 g M - HH I will! ease see 0 so (D '3AV!inN-1VM Agreement No, 5747 Ol Y I AW LU 11 LL 01 Awl o A4 ,l444 Agreement No, 5747 Ol Agreement No. 5747